W912J6-11-R-0001-0002_SQD_OPS.pdf

KNMD069209/109500

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

1. The draw ings and Specs changes as show n on “index of draw ings and Tables of Contents; f ile Name: Hick INFRA ADD1”. Posted 02/01/2011, are attached hereto by reference and make a part hereof.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 03-Feb-2011

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912J6-11-R-0001

X 9B. DATED (SEE ITEM 11)

13-Jan-2011

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

01-Feb-2011

CODE

USPFO FOR HAWAII

ATTN: CPT MANUEL LLANES

91-1179 ENTERPRISE AVE

KAPOLEI HI 96707-2150

W912J6 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912J6-11-R-0001

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Deleted

SECTION 00110 SUBMISSION REQUIREMENTS AND INSTRUCTIONS

1.1.1.1. Provide a Construction Schedule Critical Path Method (CPM) using a critical path scheduling approach considering a Notice to Proceed date of 15 April 2011 for the 720 schedule.

1.1.1.1.1. The Construction Schedule is an integrated and networked multi-layered schedule of program/project tasks. It identifies project events, accomplishment, and criteria and the expected dates of each. These dates are based on the calendar dates provided as the starting point and the logical flow of dates provided by calculating the addition of duration of all tasks using typical schedule networking tools. Each major task will be directly traceable to the requirements of the project. For the purpose of evaluation only, the offeror should use a 15 March 2011 date for Notice to Proceed.

Included in VOL 2

(End of Summary of Changes)

W912J6-11-R-0001

EXHIBIT C1

SAMPLE TRANSMITTAL LETTERAND PAST PERFORMANCE EVALUATION QUESTIONNAIRE

Your Company Letterhead

Date: _________________ To: ______________________________________

We have listed your firm as a reference for the work we have performed for you as listed below. Our firm has submitted a proposal under a project advertised by the United States Property and Fiscal Officer for Hawaii. In accordance with Federal Acquisition Regulations (FAR), they will evaluate our firm's past performance. Your candid response to the attached questionnaire will assist the evaluation team in this process. We understand that you have a busy schedule and your participation in this evaluation is greatly appreciated. Please complete the enclosed questionnaire as thoroughly as possible. Space is provided for comments. Understand that while the responses to this questionnaire may be released to the offeror, FAR 15.306 (e)(4) prohibits the release of the names of the persons providing the responses. Complete confidentiality will be maintained. Only one response from each office is required.

Please send your completed questionnaire to the following address to arrive NOT LATER THAN February 15, 2011.

2:00PM (Hawaii Stabdard Time)

Do not return them to our company.

USPFO FOR HAWAII

ATTN: CPT MANUEL LLANES

91-1179 ENTERPRISE AVE

KAPOLEI HI 96707-2150

FAX: (808)844-6340

If you have questions regarding the attached questionnaire, or require assistance, please contact CPT Manuel Llanes at 808 844-6335 or email to:manuel.llanes@us.army.mil.. Thank you for your assistance. E-Mail is preferred.

Signature and Title

(End of Summary of Changes)