amd1.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See section 00 00 00 Procurement and Contracting Requirements for all applicable changes w ithin Amendment 0001.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 19

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 24-Jun-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HN-16-B-0004

X 9B. DATED (SEE ITEM 11)

14-Jun-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

24-Jun-2016

CODE

US ARMY CORPS OF ENGINEERS

100 WEST OGLETHORPE AVE.

SAVANNAH GA 31401-3640

W912HN 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HN-16-B-0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SECTION 00 00 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SUMMARY OF CHANGES

SECTION 00 00 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

The following have been added by full text:

Amendment 0001 Changes

A. CONTRACT CHANGES:

1) Section 00 73 00 – Supplementary Conditions – Wage Determinations for dredging has been added.

2) Section 00 73 00 – Supplementary Conditions – Delivery Information - Period of

Performance is hereby adjusted from 365 calendar days to 450 calendar days.

3) Section 00 73 00 – Supplementary Conditions – Clause 52.211-10 is hereby updated to include the adjusted Period of Performance from 365 calendar days to 450 calendar days.

4) Section 00 73 00 – Supplementary Conditions – Clause 52.223-9 is hereby updated to reflect the proper location for estimate submittals.

5) Section 00 73 00 – Supplementary Conditions – Additional Contract Requirements –

Designated Billing Office is hereby updated.

6) The site visit sign-in roster will be posted as a separate attachment.

B. TECHNICAL SPECIFICATION CHANGES: The revised Sections listed below (revised by Amendment No. 0001) are hereby added to and made a part of the solicitation. Revised or added information is underlined and deleted information is struck out. Revisions can be located in the appropriate volume of specifications by searching for an asterisk and amendment number (i.e., *1).

Revised Sections 01 11 00.10 37 01 57 19

In Attachment 1 to Section 007300, the Endangered Species Watch Plan Format has been replaced in its entirety.

C. CONTRACT DRAWINGS:

Sheet G-001 with Revision 1 dated 24 June 2016 is hereby added to and made a part of the Contract Drawings. Sheet RE100 is hereby deleted from the Contract Drawings.

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

FOB: Destination

K6H0AA0

To:

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0002 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0003 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0004 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0005 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0006 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0007 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0008AA has been changed from:

365 dys. ADC 28,730 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 28,730 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0008AB has been changed from:

365 dys. ADC 5,070 CIVIL WORKS PROGRAM SECTION

SAVANNAH GA 31402

450 dys. ADC 5,070 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0009AA has been changed from:

365 dys. ADC 28,730 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 28,730 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0009AB has been changed from:

365 dys. ADC 5,070 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 5,070 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0010AA has been changed from:

365 dys. ADC 8,120 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 8,120 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0010AB has been changed from:

365 dys. ADC 2,030 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 2,030 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0011AA has been changed from:

365 dys. ADC 8,120 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 8,120 CIVIL WORKS PROGRAM SECTION

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0011AB has been changed from:

365 dys. ADC 2,030 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 2,030 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0012AA has been changed from:

365 dys. ADC 25,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 25,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0012AB has been changed from:

365 dys. ADC 4,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 4,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0013AA has been changed from:

365 dys. ADC 25,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 25,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0013AB has been changed from:

365 dys. ADC 4,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 4,500 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0014AA has been changed from:

365 dys. ADC 7,560 CIVIL WORKS PROGRAM SECTION

SAVANNAH GA 31402

450 dys. ADC 7,560 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0014AB has been changed from:

365 dys. ADC 1,890 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1,890 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0015AA has been changed from:

365 dys. ADC 7,560 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 7,560 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0015AB has been changed from:

365 dys. ADC 1,890 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1,890 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0016AA has been changed from:

365 dys. ADC 20,400 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 20,400 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0016AB has been changed from:

365 dys. ADC 5,100 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 5,100 CIVIL WORKS PROGRAM SECTION

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0017AA has been changed from:

365 dys. ADC 20,400 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 20,400 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for SUBCLIN 0017AB has been changed from:

365 dys. ADC 5,100 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 5,100 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0018 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following Delivery Schedule item for CLIN 0019 has been changed from:

365 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

450 dys. ADC 1 CIVIL WORKS PROGRAM SECTION

100 W. OGLETHORPE AVE PO BOX 889

SAVANNAH GA 31402

The following have been modified:

Wage Determination The contractor must adhere to all applicable Wage Determinations. The following wage determinations are applicable. A full text of the wage determinations may be found at www.wdol.gov.

General Decision Number: GA160089 05/13/2016 GA89

Superseded General Decision Number: GA20150089

State: Georgia

Construction Type: Heavy

Heavy Construction, Includes Water and Sewer Lines, and Heavy Construction on Treatment Plant Sites and Industrial Sites (Refineries, Power Plants, Chemical and Manufacturing Plants, Paper Mills, Etc.)

Counties: Bryan, Chatham and Effingham Counties in Georgia.

General Decision Number: SC160001 01/08/2016 SC1 http://www.wdol.gov/

Superseded General Decision Number: SC20150001

State: South Carolina

Construction Types: Heavy (Heavy and Sewer and Water Line)

Counties: Abbeville, Allendale, Bamberg, Barnwell, Beaufort, Cherokee, Chester, Chesterfield, Clarendon, Colleton, Dillon, Georgetown, Greenwood, Hampton, Jasper, Lancaster, Lee, Marion, Marlboro, McCormick, Newberry, Oconee, Orangeburg, Union and Williamsburg Counties in South Carolina.

General Decision Number: GA160016 01/08/2016 GA16

Superseded General Decision Number: GA20150016

State: Georgia

Construction Type: Heavy Dredging

DREDGING

Counties: Georgia Statewide.

STATEWIDE

DREDGING CONSTRUCTION PROJECTS GEORGIA (East of the Aucilla and Ocmulgee Rivers within the Jacksonville & Savannah Districts of the Corps of Engineers).

General Decision Number: SC160011 01/08/2016 SC11

Superseded General Decision Number: SC20150011

State: South Carolina

Construction Type: Heavy Dredging

DREDGING

Counties: South Carolina Statewide.

STATEWIDE

DREDGING

Additional Contract Requirements

1. U.S. ARMY CORPS OF ENGINEERS SAFETY AND HEALTH REQUIREMENTS MANUAL, EM

385-1-1

This paragraph applies to contracts and purchase orders that require the contractor to comply with EM 385-1-1 (e.g., contracts that include the Accident Prevention clause at FAR 52.236-13 and/or other safety provisions). EM 385-1- 1 and its changes are available at http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf.

The Contractor shall be responsible for complying with the current edition and all changes posted on the web through the date that is 10 calendar days prior to the date offers are due. If the solicitation is amended to extend the http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM_385-1-1.pdf time set for receipt of offers, the 10 calendar days rule stated above shall be applied against the amended date. (For example, if offers are due on 10 April, all changes posted on or before 31 March shall apply to the contract. If the time for receipt of offers is extended from 10 April to 20 April, all changes posted on or before 10 April shall apply to the contract.)

2. REQUIRED INSURANCE

(a) The Contractor shall procure and maintain during the entire period of his performance under this contract the following minimum insurance:

(1) Comprehensive and Employer's Liability Insurance: Coverage in an amount not less $100,000 or in the amount required by the State law in which the work is to be performed under this contract, whichever is greater.

(2) Comprehensive General Liability Insurance: Coverage in an amount not less than $500,000 per occurrence.

(3) Automobile Liability Insurance: $200,000 per person and $500,000 per occurrence for bodily injury liability and $20,000 property damage liability.

(4) Vessel liability: When contract performance involves use of vessels, the contracting officer shall require vessel collision liability and protection and indemnity liability insurance.

(b) Prior to the commencement of work hereunder, the Contractor shall furnish to the Contracting Officer a certificate or written statement of the above-required insurance. The policies evidencing required insurance shall contain an endorsement to the effect that cancellation, or any material change in the policies adversely affecting the interests of the Government in such insurance, shall not be effective for such period as may be prescribed by the laws of the State in which this contract is to be performed and in no event less than 30 days after written notice thereof to the Contracting Officer.

(c) The Contractor agrees to insert the substance of this clause, including this subparagraph (c), in all subcontracts hereunder.

3. DESIGNATED BILLING OFFICE

Invoices will be mailed to:

Savannah District Construction Division

Attn: CD-STH 222 Blanton Rd Hunter Army Airfield, GA 31409

4. DESIGNATED PAYMENT OFFICE

Payment will be made by:

U.S. Army Corps of Engineers Finance Center

ATTN: CEFC-AO-P

5720 Integrity Drive Millington, TN 38054-5005

5. CONTRACTOR-PREPARED NETWORK ANALYSIS SYSTEM

The progress chart to be prepared by the contractor pursuant to FAR 52.236-15, Schedules for Construction Contracts, shall utilize the Critical Path Method (CPM) of network calculation.

6. EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

(a) This clause does not apply to terminations. See 52.249-5000, Basis for Settlement of Proposals and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region III. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36.

Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the small purchase threshold, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

7. BASIS FOR SETTLEMENT OF PROPOSALS

Actual costs will be used to determine equipment costs for a settlement proposal submitted on the total cost basis under FAR 49.206-2(b). In evaluating a terminations settlement proposal using the total cost basis, the following principles will be applied to determine allowable equipment costs:

(1) Actual costs for each piece of equipment, or groups of similar serial or series equipment, need not be available in the contractor's accounting records to determine total actual equipment costs.

(2) If equipment costs have been allocated to a contract using predetermined rates, those charges will be adjusted to actual costs.

(3) Recorded job costs adjusted for unallowable expenses will be used to determine equipment operating expenses.

(4) Ownership costs (depreciation) will be determined using the contractor's depreciation schedule (subject to the provisions of FAR 31.205-11).

(5) License, taxes, storage and insurance costs are normally recovered as an indirect expense and unless the contractor charges these costs directly to contracts, they will be recovered through the indirect expense rate.

8. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

(a) This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the contract clause entitled DEFAULT (FIXED PRICE CONSTRUCTION). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORKDAYS BASED ON 5-DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

6 6 5 4 5 7 7 8 5 2 3 6

(c) Upon acknowledgment of the Notice to Proceed and continuing through-out the contract, the Contractor will record on the daily Contractor Quality Control report the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather workdays, and issue a modification in accordance with the contract clause entitled

DEFAULT (FIXED PRICE CONSTRUCTION).

9. UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL

The Contractor shall not accept any instructions issued by any person, employed by the Government or otherwise, other than the Contracting Officer or the Contracting Officer’s Representative (COR) acting within the limits of the COR’s Authority. See the Contracting Officer’s Representative clause of this contract.

10. VARIATIONS IN ESTIMATED QUANTITIES — SUBDIVIDED ITEMS (MAR 1995)

This variation in estimated quantities clause is applicable only to Items Nos. 0008, 0009, 0010, 0011, 0012, 0013, 0014, 0015, 0016, and 0017.

(a) Variation from the estimated quantity in the actual work performed under any second or subsequent sub-item or elimination of all work under such a second or subsequent sub-item will not be the basis for an adjustment in contract unit price.

(b) Where the actual quantity of work performed for items Nos. 0008, 0009, 0010, 0011, 0012, 0013, 0014, 0015, 0016, and 0017 is less than 85% of the quantity of the first sub-item listed under such item, the contractor will be paid at the contract unit price for that sub-item for the actual quantity of work performed and, in addition, an equitable adjustment shall be made in accordance with the clause FAR 52.212-18, Variation in Estimated Quantities.

(c) If the actual quantity of work performed under Items Nos0008, 0009, 0010, 0011, 0012, 0013, 0014, 0015, 0016, and 0017 exceeds 115% or is less than 85% of the total estimated quantity of the sub-item under that item and/or if the quantity of the work performed under the second sub-item or any subsequent sub-item under Items Nos. 0008, 0009, 0010, 0011, 0012, 0013, 0014, 0015, 0016, and 0017 exceeds 115% or is less than 85% of the estimated quantity of any such sub-item, and if such variation causes an increase or a decrease in the time required for performance of this contract the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, Variation in Estimated Quantities.

11. ANTITERRORISM / OPERATIONS SECURITY

(a) Access and General Protection /Security Policy and Procedures: All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

(b) Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05 / AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative, as NCIC and TSDB are available), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

(c) Suspicious Activity Reporting Training: The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

(d) Pre-screen candidates using E-Verify Program: The Contractor must pre-screen Candidates using the E-verify Program (http://www.dhs.gov/E-Verify) website to meet the established employment eligibility requirements.

The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

12. Veterans Employment Emphasis for U.S. Army Corps of Engineers Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS 222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veterans Affairs–VOW to Hire Heros Act http://benefits.va.gov/vow/ Army Wounded Warrior Program – http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation–Hiring Our Heros http://www.hiringourheroes.org/ Guide to Hiring Veterans – Reference Material http://www.whitehouse.gov/sites/default/files/docs/white_house_business_council_- _guide_to_hiring_veterans_0.pdf http://www.dhs.gov/E-Verify

(End of special contract requirement)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 450 calendar days after the issuance of the notice to proceed. * The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to:

Savannah District Construction Division Attn: CD-STH 222 Blanton Rd Hunter Army Airfield, GA 31409

(End of clause)

(End of Summary of Changes)