PreProposal_Conference_Barda_School_AZ_6_June_2017_compiled.ppt

“The views, opinions and findings contained in this report are those of the authors(s) and should not be construed as an official Department of the Army position, policy or decision, unless so designated by other official documentation.”

6 June 2017

U.S. ARMY CORPS OF ENGINEERS

EUROPE DISTRICT

PRE-PROPOSAL CONFERENCE

SOLICITATION W912GB-17-R-0044

CONSTRUCT SCHOOL,

BARDA, AZERBAIJAN

File Name

Sign In Sheet for Attendance

As a courtesy to all attendees, request all cellular telephones are turned off

Ask questions and follow up with email. All questions must be submitted in writing and will be answered via an amendment that will be posted on www.fbo.gov

Slide * Before We Start…

Make sure people sign in and turn off cell phones.

Today’s Agenda Introductions

Project Brief

Solicitation Brief

Site Visit

Slide 3

Introductions

USACE TEAM

Introduction and Project Brief

Cynthia Perez, Senior Project Manager

Solicitation Brief

Robert Corkrum, Contracting Specialist

Field Office Representatives

Gwen Nelson, Project Engineer Giorgi Shikhiashvili Shalva Khvadagadze Levan Imedadze

US EMBASSY

Brandon Files

CONTRACTORS (MAIN POC)

Slide 4

Project Brief

Cynthia Perez Senior Project Manager

The project requires construction of:

BASE BID

New School Building includes all work associated with design & construction of the school building shall accommodate 220 students, 46 employees; male/female ratio 50-50 consists of 10 classrooms, a laboratory, a PC room, a library, a cafeteria/kitchenette/auditorium, a teacher’s room, a principle’s room, a janitor’s room, a storage room & separate students’ & teachers’ bathrooms ( total 677.92 m2) includes all surveys, mobilization/demobilization, earthwork & grading, installation/adaptation/relocation of utilities, storm drainage, sanitary & water systems directly related to this item

(BASE BID cont’d)

New Utility/Heating Building includes all work associated with design & construction of the utility/heating building shall consists of a heating/boiler room & an electrical room (total 25 m2) includes all surveys, mobilization/demobilization, earthwork & grading, installation/adaptation/relocation of utilities, site drainage features directly related to this item

OPTIONS

Two Additional Classrooms includes all work associated with design & construction of two additional classrooms in the school building expansion of all utilities features (utility/heating building, etc.) and systems (electrical, mechanical, etc.) necessary to support the additional classrooms includes all surveys, mobilization/demobilization, earthwork & grading, installation/adaptation/relocation of underground utilities, site drainage features directly related to this item

(OPTIONS cont’d)

Perimeter Fence and Gates includes all work associated with design & construction of a min.

1.8 m high fence around property perimeter, one vehicular gate (min. 4.5 m wide) & one pedestrian gate (min. 1 m wide) More gates may be needed for septic and water tank access to provide a safe playing area for the students.

Road and Pedestrian Path includes all work associated with design & construction of a road to connect the site entrance(s) to the new school building, water tank, & septic tank Includes a pedestrian path to connect the new school building to the heating building & Sports Court

(OPTIONS cont’d) Sports Court includes all work associated with design & construction of a sports court

Landscaping includes all work associated with the provision of green spaces by lawn seeding and with the protection/replacement of existing/damaged vegetation if any

Kitchenette includes all work associated with the provision of the built-in kitchenette

Water Storage Tank includes all work associated with the provision of a water storage tank

Any Questions on Project Brief?

Solicitation Brief

Robert Corkrum Contracting Specialist

DISCLAIMER

Information Provided During Pre-proposal Conference Any remarks or explanations provided during this Pre-proposal Conference are for general information and will not change the terms and conditions of the solicitation.

Any changes resulting from the conference or responses to questions received will be done in writing by the issuance of amendments.

Contracting Officer Authority Only a warranted Contracting Officer (either a Procuring Contracting Officer (PCO), or an Administrative Contracting Officer (ACO), acting within their delegated limits, has the authority to issue modifications or otherwise change the terms and conditions of a contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of a contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

CORs cannot change the contract in terms of time or money They can only enforce what is written in the contract

WHO DO I CONTACT IN CONTRACTING?

Robert Corkrum(Contract Specialist) Telephone: +49 611 9744 2235 Robert.e.corkrum@usace.army.mil

Jefferey Ball(Contracting Officer) Telephone: +49 611 9744 2619 Jefferey.a.ball@usace.army.mil

U.S. PROCUREMENT

LAWS AND REGULATIONS

Federal Acquisition Regulation (FAR) http://farsite.hill.af.mil/vffara.htm

Defense FAR Supplement (DFARS) http://farsite.hill.af.mil/vfdfara.htm

Army FAR Supplement (AFARS) http://farsite.hill.af.mil/vfafara.htm

USACE Acquisition Instructions http://www.usace.army.mil/BusinessWithUs/Contracting/Resources.aspx

FEDERAL BUSINESS OPPORTUNITIES

Announcement of Opportunities: The synopsis, solicitation and all subsequent amendments are posted through the Federal Business Opportunities (FedBizOpps) website below. It is the Offeror’s sole responsibility to obtain the solicitation and any subsequent amendments through this website. You must register to receive notices.

FedBizOpps Website http://www.fbo.gov

User guides are located under the “Getting Started” tab

FEDERAL BUSINESS OPPORTUNITIES

Type Solicitation or Name/ Number here and then press Search

Click here

Click on the Packages tab to access the Zip file

Opens the document in a separate browser window Allows the document to be downloaded as a zip file

SYSTEM FOR AWARD MANAGEMENT (SAM)

Mandatory Registration in SAM: The Federal Government mandates that a contractor be registered in the SAM database prior to the award of a Federal contract. Federal Acquisition Regulation (FAR) clause 52.204-7 states that in order to do business with the Government, the contractor must be registered in the SAM database. Firms interested in doing business with the Federal Government should now visit the SAM website, which consolidates Federal procurement systems such as Central Contractor Registration (CCR) and Online Representations and Certifications Application (ORCA). The Joint Venture (JV) must be registered prior to award with a unique Duns and Bradstreet Number and CAGE Code. You can not use one of the JV partner’s registration.

https://www.sam.gov/

The website contains a video overview briefing and user guides for assistance.

Note: All CCR data has been migrated into SAM. If already registered, please wait to create an account in SAM until a month prior to your registration expiration.

DATA UNIVERSAL NUMBERING SYSTEM (DUNS) NUMBER

Obtain a DUNS Number:

If you do not have a DUNS number, contact Dun and Bradstreet to obtain one.

http://www.dnb.com

CONTRACTOR AND GOVERNMENT ENTITY CODE (CAGE)

Obtain a CAGE Code:

The CAGE code is a required piece of data for registering in the System for Award Management (SAM). If you are a vendor located in the United States and do not have a CAGE code, a CAGE code will be assigned to you when you register in the SAM database for the first time.

CAGE Websites

The CAGE welcome information page is at: http://www.dlis.dla.mil/CAGE/cage_welcome.aspx

DESIGN – BUILD FIRM FIXED PRICE

Full and open competed Firm Fixed Price (FFP) stand alone contract

Magnitude of Construction: $500,000.00 - $1,000,000.00

Best Value - Tradeoff

Design-Build procurement

One offeror will be awarded the contract

BANK LETTER OF ASSURANCE (BLA)/BANK LETTER OF GUARANTEE (BLG)

Original BLA submitted with offeror’s proposal (a sample letter is provided as attachment with the solicitation)

The Government will return the original BLA received from the unsuccessful offerors

Original BLG will be submitted by the successful offeror within seven (7) calendar days of notice of award

Sample BLG is also included in the solicitation (Offeror must work with their bank to use the same language provided in the sample letter provided in the solicitation)

The BLG submitted by the successful offeror will be reviewed by the Procuring Contracting Officer and Legal Counsel. If the same language is not used in the submitted BLG from the successful offeror it may be rejected and sent back to the successful offeror for revision.

Secure your BLG language from the bank early

PLACE AND PERIOD OF PERFORMANCE

Place of Performance: Barda, Azerbijan.

Base Items Period of Performance: 365 calendar days from issuance of Notice to Proceed (NTP).

Optional Items Period of Performance: The Government reserves the right to award any options within 120 calendar days following issuance of NTP for the base work. If an option is exercised, it must be completed with the Base Period of Performance of 365 calendar days.

A Single NTP will be issued for all awarded work. All work shall be completed within 365 calendar days from the issuance date of the NTP.

WHAT DO I NEED TO SUBMIT?

Section 00 21 00 “Instructions to Bidders/Offerors” of the solicitation outline the format for your proposals Review Section 00 21 00 carefully! Failure to submit all required documentation may result in rejection of your proposal Volume I: Three Non-price Factors Factor One (1) – Experience Factor Two (2) – Past Performance Factor Three (3) – Management Approach Volume II – Price / Administrative Proposal Factor Four (4) – Price

Read pages 14 – 28 thoroughly

HOW MANY COPIES DO I NEED TO SUBMIT?

Submitted via https://safe.amrdec.army.mil/safe Volume I: Three Non-price Factors One (1) Original

Volume II – Price / Administrative Proposal One (1) Original

Slide *

Reminder that volumes must be binders – not spiral or heat bound documents.

Please keep the Bid Schedule an Excel Spreadsheet with a PDF copy – the PDF will prevail.

SUBMISSION REQUIREMENTS

VOLUME I

Three Non-Price Factors

Other Documents to be Submitted:

Letter(s) of Commitment for Key Subcontractors

Joint Venture Agreement (if applicable)

SUBMISSION REQUIREMENTS

VOLUME II

Factor Four (4) - Price

Other Documents to be Submitted with Volume II

Offer Standard Form 1442 Amendments Standard Form 30 Section 00 45 00 Representations and Certifications (System for Award Management (SAM) Pricing Schedule The name, address, telephone, e-mail addresses of the Point(s) of Contact with the authority to legally bind the Contractor.

Name, Address, DUNS, CAGE, and TAX Identification Number of the Contractor submitting the proposal.

WHEN ARE PROPOSALS DUE?

Proposals are due on or before

30 June 2017 14:00 hours Central European Summer Time (CEST)

If there is a change in the proposal due date, you will be notified by an amendment to the solicitation which you must acknowledge.

Late proposals will be handled in accordance with FAR 15.208(b)(1)

“LATE IS LATE”

WHAT IF MY PROPOSAL IS LATE?

Late proposals are handled in accordance with FAR 15.208

Any proposal, modification, or revision, that is received at the designated Government office after the exact time specified for receipt of proposals is “late” and will not be considered unless it is received before award is made, the contracting officer determines that accepting the late proposal would not unduly delay the acquisition; and—

WHERE DO I DELIVER MY PROPOSAL?

Proposals shall be submitted utilizing the U.S. Army Aviation and Missile Research Development and Engineering Center Safe Access File Exchange (AMRDEC SAFE) Application at https://safe.amrdec.army.mil/safe. The AMRDEC SAFE Application is used to send large files to individuals that would normally be too large to send via email. There are no user accounts for SAFE. Authentication is handled via email. Anyone has access to SAFE, and the application is available for use by anyone.

Proposal Must be received at this location.

PROPOSAL INFORMATION

The AMRDEC SAFE application can be accessed via https://safe.amrdec.army.mil/safe.

There are two options to proceed from the SAFE homepage:

Proceed as Guest

After selecting one of the options above, the page will be redirected to the package upload form. Fill in all the required input fields:

15.208 -- Submission, Modification, Revision, and Withdrawal of Proposals.

(a) Offerors are responsible for submitting proposals, and any revisions, and modifications, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. Offerors may use any transmission method authorized by the solicitation.

QUALITY

Offerors are advised to provide their

BEST PROPOSAL

in the first submission

WHAT IS THE BEST VALUE DETERMINATION?

Award will be made to the offeror whose total evaluated price and technical proposal provides the best value to the Government.

The Government reserves the right to accept other than the lowest price offer and to reject any or all offers.

WHAT ABOUT DISCUSSIONS?

The Government reserves the right to conduct discussions, if in the best interest of the Government.

The primary purpose of these exchanges is to maximize the Government's ability to get the best value, based on the requirements and evaluation factors stated in the solicitation.

Slide *

If discussions are held, all exchanges will be conducted in accordance with the regulations, policies and procedures established by FAR 15.306 and the U.S. Army Source Selection Guide.

The contracting officer establishes a competitive range before conducting discussions.

The competitive range consists of all of the most highly rated proposals.

Proposals are determined within the competitive range based on the evaluated price and other evaluation factors included in the RFP.

The number of proposals in the competitive range may be limited to the greatest number that will permit an efficient competition among the most highly rated proposals Establishing the competitive range:

Results in greater efficiency by limiting the number of offerors with whom discussions are held, Precludes offerors who have relatively weaker proposals from having to spend additional resources just to make their proposals competitive with the rest of the field.

After discussions, only Contractors still considered to be in the competitive range will be asked to submit a final revised proposal.

BASIS FOR AWARD

Subject to the provisions contained herein, award will be made to one Offeror who is deemed responsible in accordance with the Federal Acquisition Regulation (FAR), conforms to the solicitation requirements, and whose proposal, judged by an overall assessment of the evaluation criteria and other considerations specified in this solicitation, represents the Best Value to the Government. This source selection approach, called Best-Value Tradeoff, includes an evaluation of all factors: experience, past performance, management approach, and price.

All non-cost factors are of equal importance and when combined are significantly more important than price.

The Government reserves the right to award to other than the lowest proposed price. The greater the equality of technical proposals, the more important price shall become in selecting the Best Value to the Government. Unreasonably high or low proposed prices may be grounds for eliminating a proposal from the competition based upon an assessment that the Offeror does not understand the requirement or the Offeror has made an unreasonable proposal. The awarded contract will incorporate the successful Offeror's proposal to the extent it offers betterments and does not conflict with the Request for Proposal.

Slide *

The sub-factors stated in management approach of management plan and execution plan are listed in descending order of importance.

CONTRACT AWARD

One contract awarded after evaluation.

Responsible in Accordance with FAR 9.104. Contractor Qualification: contractor determined to be responsible Conforms to Solicitation Requirements Proposal Represents Best Value to Government. We can award to other to the lowest overall evaluated price.

Slide *

WHAT IS A DEBRIEFING?

Post-Award – FAR 15.506

PRE: (1) The agency’s evaluation of significant elements in the offeror’s proposal;

(2) A summary of the rationale for eliminating the offeror from the competition; and

(3) Reasonable responses to relevant questions about whether source selection procedures contained in the solicitation, applicable regulations, and other applicable authorities were followed in the process of eliminating the offeror from the competition.

(1) The offeror may request a preaward debriefing by submitting a written request for debriefing to the contracting officer within 3 days after receipt of the notice of exclusion from the competition.

(2) At the offeror’s request, this debriefing may be delayed until after award. If the debriefing is delayed until after award, it shall include all information normally provided in a postaward debriefing (see 15.506(d)). Debriefings delayed pursuant to this paragraph could affect the timeliness of any protest filed subsequent to the debriefing.

(3) If the offeror does not submit a timely request, the offeror need not be given either a preaward or a postaward debriefing. Offerors are entitled to no more than one debriefing for each proposal.

SOLICITATION INSTRUCTIONS

AND

HOW TO COMPLETE PROPOSAL

PROPOSAL FORMAT

Basic Proposal Submission Requirements:

Typed In English Organized Tabs for Factors Phase I: Three Non-priced Factors Factor One (1) – Experience Factor Two (2) – Past Performance Factor Three (3) – Management Approach Volume II – Price / Administrative Proposal

Factor Four (4) – Price Failing to submit attachments or failing to complete properly, may result in rejection of the offer without further evaluation. Therefore, Offerors are urged to follow instructions and speak with the Contracting Officer if the instructions are not understood.

JOINT VENTURES/SUBCONTRACTORS

Ensure that any Joint Ventures (JV) comply with the requirements and submit a JV agreement addressing all requirements stated in section 00 21 00. "***The authorized member noted in the Joint Venture Agreement shall sign the SF 1442 and the Bank Letter of Assurance or Bid Bond***".

If an Offeror wishes to be credited with the experience of a Key Subcontractor or supplier (i.e., a firm that is not the prime contractor or part of the JV) a letter of commitment signed by the Key Subcontractor and the prime contractor shall be submitted. The commitment letter shall be submitted even if the firm is in some way related to a JV Partner (for example, the Key Subcontractor is a subsidiary of a JV Partner, or a subsidiary of a firm to which the JV partner is also a subsidiary). If a letter of commitment is not submitted, the experience will not be considered.

SECTION 00 21 00 PROPOSAL FORMAT

Phase I, Factor 1 – Experience Submissions Requirements:

For Factor 1 – Experience, Offerors shall submit two attachments, Attachment 1 and Attachment 2, detailing previous work experience projects meeting the requirements of this solicitation.

1.Information for completing Attachment 1 and Attachment 2:

a. Offerors shall complete an Experience Overview Sheet, Attachment 1, with a total listing not-to-exceed four (4) projects, performed within the last six years or currently being performed and at least 50% complete, that best represent the Offeror’s work experience required on this solicitation. If more than four projects are submitted, only the first four projects will be evaluated.

b. Offerors shall provide an Experience Information Sheet, Attachment 2, for each project listed on Attachment 1 Experience Overview Sheet.

SECTION 00 21 00 PROPOSAL FORMAT

Phase I, Factor 1 – Experience Submissions Requirements (continued):

Offerors shall submit Experience Information Sheets, Attachment Two (2), for each project listed on the Experience Overview Sheet, Attachment One (1). Projects provided should demonstrate the experience in managing multiple projects. Projects also should demonstrate experience in performance in Azerbijan and/or Europe; be between $200,000 and $1,250,000; and include work performing the following:

Projects similar in magnitude ($200,000 to $1,250,000), projects outside the range will be less relevant.

Project which demonstrate design-build experience.

Projects that demonstrate experience working in any European countries with projects performed in Azerbaijan being considered most relevant.

d. Projects that are completed or more than 50% complete by the time this solicitation is issued.

e. Projects performed within the last six (6) years. Projects older than six (6) years will be evaluated but will be considered less relevant.

f. Projects which demonstrate experience in building schools.

g. Projects which demonstrate experience in electrical and controls work to include transformer installation, buried electrical and control cables, control panels, disconnect switches, grounding protection, etc.

h. Projects which demonstrate experience in minor earthwork, grading, and roadway surface repair

ATTACHMENT 1

ATTACHMENT 2

EXPERIENCE INFORMATION SHEET

PROJECT NO. _____, Page 1 Must have a total of 5 projects, more than 5 will not be evaluated; less than 5 may result in a lower rating Project Name and Location:

Experience:

1. The location work was performed, work in Poland will be considered more relevant: ___________________________________

1. The location work was performed, work performed in Azerbaijan will be considered more relevant: ___________________________________

2. The day, month, and year work was completed; work must be completed within the last seven (7) years. For work still ongoing, the work must be at least 50% complete:__________________________

3. The final cost of this project, must be between $200,000 and $1,250,000: $____________________

4. Is this project more than 50% complete? ____ Yes ____ No If “No” explain percentage of completion, if not 50% complete for any reason, rating may be lower

5. Indicate whether the work was performed as the prime contractor, a subcontractor, or as a partner of a Joint Venture (JV). If work was performed as a subcontractor or JV partner, clearly describe what part of the work the firm for which the experience information is submitted performed (both in magnitude and description of the work performed).

6. Projects considered relevant shall be completed or at least 50% complete; performed in country of work; performed within the last six (6) years; between $200,000 and $1,250,000 and in the following:

Design-build experience.

Demonstrate experience working in any European countries with projects performed in Azerbaijan being considered most relevant Demonstrate experience in water distribution systems.

Demonstrate experience in drilling of new water wells and/or renovations of existing water well systems.

Demonstrate experience in electrical and controls work to include transformer installation, buried electrical and control cables, control panels, disconnect switches, grounding protection, etc.

Demonstrate experience with pipe trenching, small structure and shelter construction to include poured concrete form work and CMU work.

Demonstrate experience in minor earthwork, grading, and roadway surface repair

FACTOR 1: EXPERIENCE

Evaluation Criteria:

The Offeror will be evaluated on the depth and the relevancy of the experience as submitted in the proposal in accordance with the following criteria:

disconnect switches, grounding protection, etc.

Projects which demonstrate experience in minor earthwork, grading, and roadway surface repair

Section 00 22 00 Evaluation Criteria

FACTOR 1 – EXPERIENCE EVALUATION CRITERIA (CONTINUED):

- Projects demonstrating experience in multiple trades listed above will be considered more relevant than those projects demonstrating one trade.

If more than the maximum of four (4) projects are submitted, only the first four (4) will be evaluated.

EXPERIENCE

Questions on Experience?

return envelope, official, or company stamp.

FACTOR 2: PAST PERFORMANCE

Submission Requirements:

The Past Performance Questionnaire (PPQ), Attachment 3, included in the solicitation is provided for the Offeror or its team members to submit to the client for each project the Offeror includes in its proposal for Factor 1, Experience. Ensure correct phone numbers and email addresses are provided for the client point of contact. Completed PPQs should be submitted with your proposal. If the Offeror is unable to obtain a completed PPQ from a client for a project(s) before the proposal closing date, the Offeror should complete and submit with the proposal the first page of the PPQ (Attachment 3), which will provide contract and client information for the respective project(s). Offerors should follow-up with clients/references to ensure timely submittal of questionnaires. If the client requests, questionnaires may be submitted directly to the Government’s point of contact, Robert Corkrum via email at robert.e.corkrum@usace.army.mil prior to proposal closing date. Offerors shall not incorporate by reference into their proposal PPQs previously submitted for other RFPs. However, this does not preclude the Government from utilizing previously submitted PPQ information in the past performance evaluation.

Factor 2 – Past Performance Submission Requirements (continued):

Offerors may provide projects completed within the last six years or current projects at least 50 percent complete. PPQ’s shall be provided for each project submitted under Factor 1-Experience. Offerors may also include performance recognition documents received within the last six years, such as awards, award fee determinations, customer letters of commendation, and any other forms of performance recognition.

In addition to the above, the Government may review any other sources of information for evaluating past performance. Other sources may include, but are not limited to, past performance information retrieved through the Past Performance Information Retrieval System (PPIRS), including Contractor Performance Assessment Reporting System (CPARS), using all CAGE/DUNS numbers of team members (partnership, JV, teaming arrangement, or parent company/subsidiary/affiliate) identified in the offeror's proposal, inquiries of owner representative(s), Federal Awardee Performance and Integrity Information System (FAPIIS), Electronic Subcontract Reporting System (eSRS), and any other known sources not provided by the offeror.

ATTACHMENT 3

Firm Name:

Address:

Phone Number:

Email Address:

Point of Contact: Contact Phone Number: CAGE Code:

DUNS Number:

2. Work Performed as: ❑ Prime Contractor Percent of project work performed:

Contract Number:

Contract Title:

Contract Location:

Award Date (mm/dd/yy):

Contract Completion Date (mm/dd/yy):

Actual Completion Date (mm/dd/yy):

Explain Differences:

Original Contract Price (Award Amount):

Final Contract Price (to include all modifications, if applicable):

Explain Differences:

conditions, etc.)

Name:

Title:

Phone Number:

Email Address:

Factor 2 – Past Performance (Evaluation Criteria)

The Government will evaluate the Offeror’s past performance to determine how relevant project work is, as described in Factor 1 Experience, for recent projects. The Government will evaluate the Offeror’s performance to determine a confidence assessment of the Offeror’s performance. With respect to relevancy, more relevant past performance will typically be a stronger predictor of future performance and have more influence on the past performance confidence assessment than past performance of lesser relevance.

Past Performance will be evaluated for projects completed in the last six years or currently ongoing (at least 50% complete).

Section 00 22 00 Proposal Evaluation

Factor 2 – Past Performance (Evaluation Criteria continued) The Offeror's past performance will be evaluated based on performance on projects submitted under Factor 1 Experience, to include the past performance of any Subcontractors or Joint Venture partners whose projects the Offeror may have submitted. Proposals will be evaluated based on the information provided and any other Past Performance information obtained by the Government. Past performance will be evaluated in accordance with the following criteria:

Quality Schedule/Timeliness of Performance Customer Satisfaction Management Personnel/Labor Cost/Financial Management Cost/Financial Management Safety/Security.

Section 00 22 00 Proposal Evaluation

Factor 2 – Past Performance Evaluation Criteria (continued):

1. The Government reserves the right to verify statements the Offeror makes regarding its past performance to determine whether they are substantiated.

2. The Government will consider past performance information in evaluating overall risk associated with a particular Offeror. When evaluating these criteria, the following will be taken into consideration for evaluation purposes:

3. Unavailability of Past Performance Information: IAW FAR 15.305(a)(2)(iv), in the case of an Offeror without a record of relevant past performance or for whom information on past performance is not available; the Offeror may not be evaluated favorably or unfavorably on past performance.

PAST PERFORMANCE

Questions on Past Performance?

Factor 3 – Management Approach

Describe interactions within the team and with the Corps of Engineers during the design.

Describe how the project will be executed and managed during design and construction. Provide roles and responsibilities of each professional involved and their qualifications.

The PM should be responsible for the design and construction of the project indicated in the solicitation and must have at least one (1) year construction and construction management experience. The Designer of Record must have at least one (1) year of design experience. The QM and QCM shall have a minimum of five (5) years of experience.

The Designer(s) of Record must be able to certify designs based on local construction laws, or describe how designs will be certified under local construction laws.

Whether the proposal clearly delineates lines of authority, and communication with the Government on the organizational chart (graph) organized in a precise and logical manner, including all offices involved with the management of the contract, including Key Subcontractors and/or JV partners (if applicable). The offeror shall submit a maximum of twenty (20) pages presenting the Organizational Chart and subsequent explanation of organizational structure. Any descriptions beyond twenty (20) pages will not be considered.

The Government will evaluate whether the proposal contains comprehensive descriptions of duties, roles, major responsibilities, and authorities for the a) Program Manager, b) Project Manager, c) Site Superintendent, d) Quality Control Manager, e) Design Quality Control Manager, f) Designer(s) of Record and g) Safety Manager. Include the roles and major responsibilities and authorities for Key Subcontractors and JVs (if applicable) presented in a logical manner.

The Government will evaluate the integration of the design and construction firms and the staff during design and construction. The constructor must be actively involved in the design process.

Evaluation Criteria (continued):

The extent to which the proposal describes a reasonable and logical plan for the performance of a design-build contract that illustrates a thorough understanding of the design-build process, submittals, reviews, mobilization, permitting, site access, quality control, safety, and any other component necessary to successfully execute the project. The proposal shall also propose personnel that meet the specification requirements and provide subcontractor and personnel letters of commitment or JV agreements, when applicable.

The Government will evaluate the required information to determine how well the offeror identifies and demonstrates that its key personnel meet or exceed minimum qualifications necessary, which includes previous satisfactory experience in similar type work, to manage, control and perform the design, and to perform construction. The minimum experience requirements for the Project Manager are at least one (1) year construction and construction management experience. The minimum experience requirements for the Designer of Record are at least one (1) year of design experience. The minimum requirements for the QM and QCM are at least one (1) year of experience in their respective positions.

The Government will evaluate the School Construction Plan for completeness, logic, reasonableness, and risk associated with the proposed plan as compared to the solicitation requirements.

Section 00 22 00 Evaluation Criteria

FACTOR 3 – MANAGEMENT APPROACH

EVALUATION CRITERIA (CONTINUED):

The Government will evaluate the clarity and strength of the overall organization, the structure and staffing to execute the entire scope of work. The Offeror is required to select and commit to design firms and/or designer(s) of record. Joint venture participants’ contribution to the project should be commensurate with their skills and background. The Government will evaluate the integration of the design and construction firms and the staff during design and construction. The constructor must be actively involved in the design process.

The Government will evaluate the Offeror’s understanding of the design process and the roles of the designers of record and the Government reviewers. The Government will evaluate the role of the designer in maintaining design integrity throughout the process, including its key roles during construction. Additional consideration will be given to a team that includes use of local subcontractors (e.g., the key subs for electrical and mechanical, the fire protection subcontractor, fabricators, etc.).

Evaluate how the designs will be certified according to local construction laws.

MANAGEMENT APPROACH

Questions on Management Approach?

SUBMISSION REQUIREMENTS VOLUME II

FACTOR 4 – PRICE

Submission Requirements:

Offerors shall submit the following:

SECTION 00 21 00 SUBMISSION REQUIREMENTS

Factor 4 – Price Submission Requirements:

Failure to submit Section 00 10 00 and/or failure to complete all Line Items on Section 00 10 00, may result in the Offeror’s proposal package being rejected by the Government after initial evaluation without further consideration.

Solicitation Submittal Requirements:

Firms will submit a Bank Letter of Assurance demonstrating that their bank will provide a Bank Letter of Guarantee (BLG) for 30% of the project value, or, letter from a Surety demonstrating that the firm has bonding capacity of 30% of the price proposal, or a Bid Bond that satisfies the solicitation requirements.

Firms are requested to notify their surety that representatives from USACE-NAU will be contacting them for reference information.

Additionally, the Government may use other sources of information to determine a firm’s responsibility including but not limited to Duns & Bradstreet reports and State databases.

FACTOR 4: PRICE

The Government will evaluate CLIN prices and total award price in accordance with FAR 15.404-1. Evaluation of any options shall not obligate the Government to exercise the options. In order to be considered acceptable, offerors must submit prices for all contract line item numbers and a total award price identified in the price schedule. Failure to submit a price and failure to complete all CLINs will result in the Offeror’s proposal package being rejected by the Government after initial evaluation without further consideration.

The evaluation will not be assigned an adjectival rating, yet it will be evaluated for completeness and reasonableness as follows:

Completeness – To be complete the Offeror must provide all data that is requested and necessary to evaluate the prices including all CLINS on the Price Schedule. The Government will assess the extent to which the proposed prices comply with the content and format requirements set forth in this solicitation.

FACTOR 4 PRICE CONTINUED

2. Reasonableness - The Offeror's proposal is evaluated through price analysis techniques as described in FAR 15.404-1. Price analysis techniques and procedures to ensure a fair and reasonable price may include, but is not limited to, the following:

Comparison of proposed prices received in response to the solicitation.

Comparison of proposed prices to historical prices paid, whether by the Government or other than the Government, for the same or similar items.

Use of parametric estimating methods/application of rough yardsticks to highlight significant inconsistencies that warrant additional pricing inquiry.

Comparison with competitive published price lists, published market prices of commodities, similar indexes, and discount or rebate arrangements.

Comparison of proposed prices with independent Government cost estimates.

Comparison of proposed prices with prices obtained through market research for the same or similar items.

Analysis of data other than certified cost or pricing data provided by the offeror.

Slide 69

Any Questions?

Site Visit WHEN: Wed, 7 Jun 2017 @ 1000

WHERE: Meet @ Barda Hotel near Unibank, Heyder Aliyev Prospekti 72 AZ0900 (4-story bldg.)

Slide 71

Thank you for your interest & attendance!