Solicitation Amendment-0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Solicitation No. W912EQ20B0003 for Below Piggott Seepage Remediation is amended as follow s:

1.The required response date/time has been determined. The scheduled response date/time is 23 July 2020 at 1:30pm.

2. Amended Specificaiions and Plans w ill be provided.

SEE SUMMARY OF CHANGES

1. CONTRACT ID CODE PAGE OF PAGES

1 10

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 24-Jun-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912EQ20B0003

X 9B. DATED (SEE ITEM 11)

24-Mar-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

24-Jun-2020

CODE

US ARMY ENGINEER DISTRICT, MEMPHIS

167 N. MAIN STREET

MEMPHIS TN 38103-1894

W912EQ 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

BELOW PIGGOTT AND BELOW HWY 90 BPH90

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time 23-Jul-2020 01:30 PM has been added.

The contractor period of performance end date has increased by 5 days from 540 days to 545 days.

The required performance has changed from The project consists of furnishing all plant, labor and materials for a channel cleanout of the St. Francis River south of Arkansas Hwy. 90 between STA 58+00 and STA 345+00 in Clay County, Arkansas, to include clearing and disposal of debris; 44,060 LF of seepage berm on the west-bank levee between Levee Mile 17 to Levee Mile 28; 36,426 LF of interior drainage; establishment of turf;

environmental protection; and any incidental related work according to the specifications and plans. The Noth American Industry Classification System code for this acquisition is 237990,with a small business standard of $36.5Million. The estimated value of the proposed work is between $10,000,000.00 and $20,000,000.00.This Project is advertised as a HUBZone Set-Aside.

to

The project consists of furnishing all plant, labor and materials for a channel cleanout of the St. Francis River south of Arkansas Hwy. 90 between STA 58+00 and STA 345+00 in Clay County, Arkansas, to include clearing and disposal of debris; 39,000 LF of seepage berm on the west-bank levee between Levee Mile 17 to Levee Mile 28;

28,806 LF of interior drainage; establishment of turf; environmental protection; and any incidental related work according to the specifications and plans. The Noth American Industry Classification System code for this acquisition is 237990,with a small business standard of $36.5Million. The estimated value of the proposed work is between $10,000,000.00 and $20,000,000.00.Two options are included with the base contract. Option 1 may be awarded in the event that lead and/or asbestos abatement is required with the structural demolition. Option 2 adds an additional 5,060 LF of seepage berm and 7,620 LF of interior drainage indicated in plan from M23 4+00 to M24 28 +50. Option 2 is located 3 miles southwest of Ar. Hwy. 90. No access or storage within the option limits is permitted unless Option 2 is awarded; however, traffic is permitted on the levee crown at all times.This Project is advertised as a HUBZone Set-Aside..

SECTION 00100 - INSTRUCTIONS TO BIDDERS

BIDDING SCHEDULE

The following have been added by full text:

DOCUMENT 00 41 00.00 11

BIDDING SCHEDULE

PART 1 BIDDING SCHEDULE

BELOW PIGGOTT SEEPAGE REMEDIATION &

BELOW AR HWY 90 CHANNEL CLEANOUT,

CLAY AND GREENE COUNTIES, AR

1.1 LINE ITEMS

This contract will be awarded as one lump sum with unit prices required for specifically selected work. A schedule of the unit price work is contained in Standard Form SF 1442, "Solicitation, Offer and Award." See Contract Clauses, "FAR 52.211-18, Variation in Estimated Quantity" and "FAR 52.236-16, Quantity Surveys Alternative I (1984)," "DFARS 52.236-7008, Contract Prices."

Bid Items with Unit Prices Form ITEM DESCRIPTION Estimated Unit

Quantity Unit Price Amount

0001 Mobilization and Demobilization 1 JA XXX.XX $____.__

0002 Environmental Protection 1 JA XXX.XX $____.__

0003 Storm Water Pollution Prevention

0003A Write and Amend Storm Water 1 JA XXX.XX $____.__ Pollution Prevention Plan

0003B Temporary Environmental Seeding 1 JA XXX.XX $____.__

0003C Erosion Control Berm 100,600 LF _______ $____.__

0003D Silt Fence 11,270 LF _______ $____.__

0003E Construction Entrance/Exit 2 EA _______ $____.__

0003F Check Dam 28 EA _______ $____.__

0004 Demolition

0004A Structural Demolition 1 JA XXX.XX $____.__

0004B Pipe and Well Abandonment 1 JA XXX.XX $____.__

0004C Canopy Removal 1 JA XXX.XX $____.__

0004D Demolition, All Other Items 1 JA XXX.XX $____.__

0004E Hazardous Substance Testing 1 JA XXX.XX $____.__

DOCUMENT 00 41 00.00 11 Page 2

ITEM DESCRIPTION Estimated Unit

Quantity Unit Price Amount

0005 Traffic Control and Signage 1 JA XXX.XX $____.__

0006 Haul Roads and Low Water Crossing

0006A Haul Road #1 1 EA XXX.XX $____.__

0006B Haul Road #2 1 EA XXX.XX $____.__

0006C Haul Road #3 1 EA XXX.XX $____.__

0006D Haul Road #4 1 EA XXX.XX $____.__

0007 Geotextile, Non-Woven 75,300 SY _______ $____.__

0008 Clearing - Channel Bank 285 HL _______ $____.__

0009 Clearing and Grubbing - Berm 240 AC _______ $____.__

0010 Channel Cleanout Excavation 362,041 CY _______ $____.__

0011 Excavation 77,100 CY _______ $____.__

0012 Semi-Compacted Fill 764,500 CY _______ $____.__

0013 Corrugated Metal Pipe (CMP) Culvert

0013A 24" CMP Culvert 92 LF _______ $____.__

0013B 30" CMP Culvert 59 LF _______ $____.__

0014 24" Steel Pipe Culvert 528 LF _______ $____.__

0015 Seeding - Channel Bank 129 AC _______ $____.__

0016 Establishment of Turf - Berm 240 AC _______ $____.__

0017 Stone Products

0017A Aggregate Surface Course 19,200 TN _______ $____.__

0017B Coarse Aggregate, Size #1 21,670 TN _______ $____.__

0017C Coarse Aggregate, Size #57 13,240 TN _______ $____.__

Sub-Total Items 0001 thru 0017 $_______.__

Option 1 Bid Items Bid Items with Unit Prices Form

DOCUMENT 00 41 00.00 11 Page 3

ITEM DESCRIPTION Estimated Unit

Quantity Unit Price Amount

0018 Asbestos Abatement 1 JA XXX.XX $____.__

0019 Lead Abatement 1 JA XXX.XX $____.__

Sub-Total Option 1 $_______.__

Option 2 Bid Items Bid Items with Unit Prices Form

ITEM DESCRIPTION Estimated Unit

Quantity Unit Price Amount

0020 Mobilization and Demobilization 1 JA XXX.XX $____.__

0021 Environmental Protection 1 JA XXX.XX $____.__

0022 Storm Water Pollution Prevention

0022A Write and Amend Storm Water 1 JA XXX.XX $____.__ Pollution Prevention Plan

0022B Temporary Environmental Seeding 1 JA XXX.XX $____.__

0022C Erosion Control Berm 7,600 LF _______ $____.__

0022D Silt Fence 100 LF _______ $____.__

0022E Check Dam 7 EA _______ $____.__

0023 Demolition, All Other Items 1 JA XXX.XX $____.__

0024 Geotextile, Non-Woven 5,000 SY _______ $____.__

0025 Clearing and Grubbing - Berm 50 AC _______ $____.__

0026 Excavation 17,900 CY _______ $____.__

0027 Semi-Compacted Fill 119,500 CY _______ $____.__

0028 Steel Pipe Culvert

0028A 24" Steel Pipe Culvert 132 LF _______ $____.__

0028B 30" Steel Pipe Culvert 36 LF _______ $____.__

0029 Establishment of Turf - Berm 50 AC _______ $____.__

0030 Stone Products

0030A Coarse Aggregate, Size #1 1,430 TN _______ $____.__

DOCUMENT 00 41 00.00 11 Page 4

0030B Coarse Aggregate, Size #57 860 TN _______ $____.__

Sub-Total Option 2 $_______.__

Grand Total $_______.__

1.2 NOTES

NOTE 1: Offerors shall furnish unit prices for all items listed on the schedule of bid items, which require unit prices. If the offeror fails to insert a unit price in the appropriate blank for required items, but does furnish an extended total or an estimated amount for such items, the Government will deem his unit price to be the quotient obtained by dividing the extended estimated amount for that line item by the quantity. IF THE

OFFEROR OMITS BOTH THE UNIT PRICE AND THE EXTENDED ESTIMATED AMOUNT FOR ANY

ITEM, THE BID WILL BE DECLARED NONRESPONSIVE.

In the event there is a difference between a unit price and the extended total, the unit price will be held to be the intended bid. If the offeror shows only the total price but fails to enter a unit price, the total divided by the estimated quantity will be held to be the intended unit price.

Any offer price for items indicated above which are unbalanced as to price may be rejected as non-responsive. An unbalanced offer is one which is based on price significantly less than cost for some work and price which is significantly overstated for other work.

Award will be made as a whole to one offeror.

AC = Acre CF = Cubic Feet CY = Cubic Yard DH = Miles EA = Each FC = 1000 Cubic Feet FT = Foot HF = 100 Feet HH = 100 Cubic Feet HL = 100 Linear Feet HR = Hours HS = 100 Square Feet HY = 100 Yards LB = Pound LF = Linear Foot LH = Labor Hour JA = Job (lump sum) LY = Linear Yard MO = Months SB = Square Mile SF = Square Foot SQ = Square SY = Square Yard TL = 1000 Linear Feet TN = Net Ton UN = Unit YD = Yard YL = 100 Linear Yards YM = Cubic Yards Per Mile

All quantities are estimated except where unit is given as "JA" or "EA".

NOTE 2: If an offer or modification to an offer based on unit prices is submitted and provides for a lump sum adjustment to the total estimated cost, the application of the lump sum adjustment to each unit price, including lump sum units, in bid schedule must be stated, or, if it is not stated, the offeror agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the bid schedule.

NOTE 3: Offerors are cautioned to read Contract Clause entitled "DFAR 252.204-7004, Alternate A, System for Award Management (FEB 2014) located in Section 00 70 00.00 11 CONTRACT CLAUSES.

-- End of Document --

DOCUMENT 00 41 00.00 11 Page 5

-- End of Document --

SECTION 00700 - CONTRACT CLAUSES

The following have been added by full text:

52.217-9 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 30 days of contract expiration; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 60 days before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed thirty-six (36) months.

(End of clause)

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 545 calendar days for the base bid, 60 additional calendar days for option 1, and 130 additional calendar days for option 2 after the date of receipt by him of notice to proceed. The time stated for completion shall include final cleanup of the premises. If either option is exercised at the same time as the base award, the Contractor shall complete the options concurrently within the base contract time.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,615.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) Physical Condition. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by aerial photographs and topographic surveys.

(b) Weather Conditions. Information with respect to temperatures and precipitation may be obtained from the National Weather Service. Also see the Special Contract Requirements Paragraph entitled TIME EXTENSIONS

FOR UNUSUALLY SEVERE WEATHER.

(c) Transportation Facilities. Access will be provided from the St. Francis Right Bank Levee, as indicated on the contract drawings. Access can also be made to the northern access point by use of an abandoned gas station along the southern right-of-way of Arkansas Highway 90.

(d) Additional Data. Additional data consisting of records of borings, and boring samples may be available for inspection at the U.S. Army Corps of Engineers District office in Memphis, Tennessee. (FAR 52.236 4)

(End of clause)

SECTION SF30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0002