B.08.03 W912DR22B0006 Mid Chesapeake Bay Amendment 0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to provide an update to FAR clause 52.211-12, Liquidated Damages- Construction and to include price schedule revision 8.24.2022. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 25-Aug-2022

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912DR22B0006

X 9B. DATED (SEE ITEM 11)

08-Aug-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

25-Aug-2022

CODE

USACE, BALTIMORE

2 HOPKINS PLAZA

BALTIMORE MD 21201

W912DR 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912DR22B0006

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The following have been added by full text:

REVISED PRICE SCHEDULE

UNIT PRICE SCHEDULE

Revised 8.24.2022

Item Estimated Unit

No. Description Quantity Unit Price Amount

BASE BID ITEMS

0001 Reimbursement of Performance and Payment Bonds

JOB

0002 All costs in connection with mobilization and demobilization for

Phase 1 of the Barren Island

Restoration project.

0003 Pre-Placement Survey and Sections, complete as shown on the drawings and specified.

0004 Stone Sills

0004a All costs in connection with the

4300-lb armor stone, quarried, shipped, and placed.

101,295

Ton

0004b All costs in connection with the

2600-lb armor stone, quarried, 12,708

0004c All costs in connection with the quarry run, quarried, shipped, and placed.

53,853

0004d All costs in connection with the

#10 stone, quarried, shipped, and

15,703

C.Y. $______ $_________

0004e All costs in connection with the geotextile, complete as shown on drawings and specified.

76,969

S.Y.

TOTAL ESTIMATED BASE BID AMOUNT $

OPTIONAL BID ITEMS

0005 Stone Breakwater

0005a All costs in connection with the

5400-lb armor stone, quarried, 80,125

0005b All costs in connection with the quarry run, quarried, shipped, and

24,311

0005c All costs in connection with the core stone, quarried, shipped, and

22,881

0005d All costs in connection with the

#10 stone, quarried, shipped, and

11,519

C.Y

0005e All costs in connection with the geotextile, complete as shown on drawings and specified.

46,968

S.Y.

TOTAL ESTIMATED BASE AND OPTIONS BID AMOUNT $

NOTES TO BIDDERS

Offerors must quote on all items. Failure to quote on all items may be cause for rejection of the proposal.

Optional Items may be exercised at any time within 60 calendar days after the date of receipt of Notice To Proceed. If option(s) are exercised, an additional 180 calendar days will be added to the Period of Performance (PoP).

VARIATION IN ESTIMATED QUANTITIES: If the quantity of a unit-price item in this contract is an estimated quantity and the actual quantity of the unit-price item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the

Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon receipt of a written request for an extension, the Contracting officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

The following have been deleted:

REVISED BID SCHEDULE

SECTION 00 72 00 - GENERAL CONDITIONS

The following have been modified:

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $5,870.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

(End of Summary of Changes)