Amd 01 for W9128F26QA043 - GDSM Subdrain Camera Inspections.pdf

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Solicitation/Contract Form Continuation

The following changes have been made:

Miscellaneous text in this section has been modified to:

52.211-18 Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than above or below the estimated quantity, an 15 percent equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation of the estimated quantity. If the quantity variation above 115 percent or below 85 percent is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

(End of clause)

Addendum to FAR 52.237-1 Site Visit

Offerors or quoters are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

(b) An organized site visit has been scheduled for--

28 April 2026 at 9:00am (Central Time)

An additional site visit has been scheduled for --

1 May 2026 at 10:00am (Central Time)

(c) Participants will meet at--

W9128F26QA0430001

Garrison Project Administration Building at 201 1st Street in Riverdale, ND 58565

**Contractors shall submit the name, email address and company represented for each attendee to Nadine Catania and Karen Caskey via email at Nadine.L.Catania@usace.army.mil and Karen.L.Caskey@usace.army.mil, respectively. Contractors shall submit this information by 3:00pm (Central Time) on 30 April 2026.

(End of Provision)

Addendum to Contract Clauses

Additional Information/Notes

The following clauses were added:

FAR Clauses Incorporated by Reference Number Title Effective Date Alternate/

Deviation Variation Effective Date

52.222-90 Addressing DEI Discrimination by Federal Contractors. (Deviation 2026-O0038)

Apr 2026

The following clauses were modified:

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. Sep 2000 hereby reads as follows:

hereby reads as follows:

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

If the Contractor fails to deliver the supplies or perform the services within the time specified in (a) this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $483.00 per calendar day of delay.

If the Government terminates this contract in whole or in part under the Default-Fixed-Price (b) Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

The Contractor will not be charged with liquidated damages when the delay in delivery or (c) performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

KO CONTRACTING OFFICE, 1616 CAPITOL AVENUE

OMAHA, NE 68102-4901

UNITED STATES

KAREN CASKEY, EMAIL: KAREN.L.CASKEY@USACE.ARMY.MIL TELEPHONE: 402-995-2047

AdminBy:

SCD: PAS: