am_3.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

This amendment separates the proposal submission forms into separate documents. See continuation sheet.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 12

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 27-Mar-2009

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W9126G-08-R-0246

X 9B. DATED (SEE ITEM 11)

24-Mar-2009

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

27-Mar-2009

CODE

US ARMY ENGINEER DISTRICT, FORT WORTH

ATTN: CESWF-CT

819 TAYLOR ST, ROOM 2A19

P.O. BOX 17300

FORT WORTH TX 76102-0300

W9126G 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W9126G-08-R-0246

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SECTION SF30 - CONTINUATION PAGE

SUMMARY OF CHANGES

This amendment separates the proposal submission forms into separate documents.

SECTION 00 22 11 - PROPOSAL SUBMISSION REQUIREMENTS, EVALUATION CRITERIA, AND BASIS

OF AWARD ONE STEP - BEST VALUE, DESIGN-BUILD (SINGLE AWARD)

PROPOSAL SUBMISSION RQMTS

PROPOSAL DATA SHEET

Provide the following information regarding this current solicitation:

1. Name of Firm:

2. Address:

3. Phone:

4. Fax:

5. E-mail:

6. Duns # (used for accessing

CCASS)

7. If a joint venture or contractor-subcontractor association of firms, list the individual firms and briefly describe the nature of the association.

Firm 1:

Firm 2:

Firm 3:

Nature of Association:

8. AUTHORIZED NEGOTIATORS. FAR 52.215-11

The Offeror represents that the following persons are authorized to negotiate on its behalf with the Government in connection with this Request for Proposals (RFP).

9. Name of Person Authorized to Negotiate:

10. Negotiator's Address:

11. Negotiator's Telephone:

12. Negotiator’s E-mail:

FACTOR 1: PAST PERFORMANCE INFORMATION

Provide the following information in accordance with Evaluation Factor 1 requirements.

1. Project Title:

2. Location:

3. Contract number:

4. Procuring activity:

5. Procurement Point of Contact and Telephone Number:

6. Address and telephone number of owner/customer:

7. Type of Project (private sector, Government, planned unit development, etc.):

8. General Nature of the Contract:

9. Award Date:

10. Original Contract Amount:

11. Final Contract Amount:

12. Original Completion Date:

13. Final Completion Date:

14. Explanation for any differences between original and final contract costs and completion dates:

15. Total number of Manhours including all subcontractors:

FACTOR 2: CORPORATE RELEVANT EXPERIENCE

Provide the following information in accordance with Evaluation Factor 2 requirements.

1. Project Title:

2. Location:

3. Contract number:

4. Nature of involvement in this project, i.e. General Contractor, subcontractor, designer:

5. Procuring activity:

6. Procurement point of contact and telephone number:

7. List dates of construction start and completion or percent complete if construction is in progress:

8. Address of building(s):

9. Name, address and telephone number of owner:

10. Indicate type of project (private sector, Government, planned unit development, etc.):

11. Total cost:

SAMPLE TRANSMITTAL LETTER

AND

PAST PERFORMANCE EVALUATION QUESTIONNAIRE

Date: _________________

To: ______________________________________

We have listed your firm as a reference for work we have performed for you as listed below. Our firm has submitted a proposal under a project advertised by the U.S. Army Corps of Engineers, Fort Worth District. In accordance with Federal Acquisition Regulations (FAR), an evaluation of our firm's past performance will be completed by the Corps of Engineers. Your candid response to the attached questionnaire will assist the evaluation team in this process.

We understand that you have a busy schedule and your participation in this evaluation is greatly appreciated. Please complete the enclosed questionnaire as thoroughly as possible. Space is provided for comments.

Understand that while the responses to this questionnaire may be released to the offeror, FAR 15.306 (e)(4) prohibits the release of the names of the persons providing the responses. Complete confidentiality will be maintained.

Furthermore, a questionnaire has also been sent to ____________________ of your organization. Only one response from each office is required. If at all possible, we request that you individually answer this questionnaire and then coordinate your responses with that of ________________________, to develop a consensus on one overall response from your organization.

Please send your completed questionnaire to the following address:

U.S. Army Engineer District, Fort Worth ATTN: CESWF-CT-S (Alice Hancock) 819 Taylor Street Fort Worth, TX 76102

The questionnaires can also be faxed to Alice Hancock, Fort Worth District, Contracting Officer at FAX 817-886- 6407 or emailed to alice.m.hancock@usace.army.mil. If you have questions regarding the attached questionnaire, or require assistance, please contact Alice Hancock at 817-886-1061. Thank you for your assistance.

PAST PERFORMANCE EVALUATION QUESTIONNAIRE

Upon completion of this form, please send directly to the U.S. Army Corps of Engineers in the enclosed addressed envelope or fax [or e-mail] to (817) 886-6407 ATTN: Alice Hancock (alice.m.hancock@usace.army.mil.)

Do not return this form to our office. Thank you.

1. Contractor/Name & Address (City and State):

2. Type of Contract: Fixed Price ________ Cost Reimbursement ________

Other (Specify) ________________________________

3. Title of Project/Contract Number:

4. Description of Work: (Attach additional pages as necessary)

5. Complexity of Work: High ________ Mid _________ Routine __________

6. Location of Work:______________________________________________

7. Date of Award: ________________________

8. Status: Active _________ (provide percent complete)

Complete __________ (provide completion date)

9. Name, address and telephone number of Contracting Officer’s Technical Representative:

10. QUALITY OF CONSTRUCTION:

Evaluate the contractor's performance in complying with contract requirements, quality achieved and overall technical expertise demonstrated.

Excellent Quality

Good Quality

Acceptable Quality

Marginal Quality

Unsatisfactory or Experienced Significant Quality Problems

Remarks: __________________________________________________________________

11. TIMELINESS OF PERFORMANCE:

To what extent did the contractor meet the contract and/or individual task order schedules if the contract was an indefinite delivery type contract?

Completed Substantially Ahead of Schedule (Excellent)

Completed Ahead of Schedule (Good)

Completed on Schedule with Minor Delays Under Extenuating Circumstances (Acceptable)

Completed Behind Schedule (Marginal)

Experienced Significant Delays without Justification (Unsatisfactory)

12. CUSTOMER SATISFACTION:

To what extent were the end users satisfied with:

Quality

Cost

Schedule

Exceptionally Satisfied (Excellent)

Highly Satisfied (Good)

Satisfied (Acceptable)

Somewhat Dissatisfied (Marginal)

Highly Dissatisfied (Unsatisfactory)

13. SUBCONTRACTOR MANAGEMENT

How well did the contractor manage and coordinate subcontractors, suppliers, and the labor force?

Excellent management and coordination of subcontractors

Good management and coordination of subcontractors

Acceptable management and coordination of subcontractors

Marginal management and coordination of subcontractors

Unsatisfactory management and coordination of subcontractors

14. SAFETY

How well did the Contractor implement and maintain its Accident Prevention Program? Did it have an effective safety incentive program? Were there excessive lost time accidents?

Excellent Documentation

Good Documentation

Acceptable Documentation

Marginal Documentation

Unsatisfactory Documentation

Remarks: _________________________________________________________________

15. DOCUMENTATION

To what extent were the contractor’s reports and documentation accurate, complete and were they submitted in a timely manner?

Excellent Documentation

Good Documentation

Acceptable Documentation

Marginal Documentation

Unsatisfactory Documentation

Remarks: _________________________________________________________________

16. IF GIVEN THE OPPORTUNITY, WOULD YOU WORK WITH THIS CONTRACTOR AGAIN?

Yes ___________ No ____________ Not Sure ____________

17. OTHER REMARKS:

Use the space below to provide other information related to the contractor's performance. This may include the contractor's selection and management of subcontractors, flexibility in dealing with contract challenges, their overall concern for the Government's interest (if applicable), project awards received, etc.

(End of Summary of Changes)