Atch_2__Supplemental_Contract_Requirements.pdf

W91238-18-x-00xx 1 of 1 Attachment 2 April 18, 2018

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to contract section 00700, FAR 52.211-10. The performance period for the work shall be 730 calendar days after notice to proceed.

2. Liquidated Damages. Refer to contract section 00700, FAR 52.211-12, Liquidated Damages-Construction. Liquidated damages for this work is $ 5,778.00 for each day of delay.

3. Authorities. No person other than the Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision No. CA180029 in its most current modification at the time of award is hereby applicable to work performed under this task order. The most current decision or its modification can be found at http://www.wdol.gov/wdol/scafiles/davisbacon/CA29.dvb

5. Time Extensions For Unusually Severe Weather. All weather delay will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK – Ft. Hunter Liggett, CA

FORT HUNTER-LIGGETT MIL RES/KING CITY

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(10) (07) (05) (03) (01) (00) (00) (00) (00) (02) (06) (11)

DRAFT

http://www.wdol.gov/wdol/scafiles/davisbacon/CA29.dvb

SUPPLEMENTAL CONTRACT REQUIREMENTS