Atch_4_Supplemental_Contract_Requirements.pdf

PDF 16 KB Posted

Attached to
F-35A Munitions and Maintenance Complex
Solicitation number
W91238-17-R-0078
Issued by

About this file

From the source

Supplemental

View the file

Other files

File Type Posted
Amendment_0002_Drawings_&_Specifications.pdf PDF
Atch_2_Draft_Drawings_(F35A_MMC).pdf PDF
Atch_3_Draft_Specifications_(F35A_MMC).pdf PDF
Amendment_0001_F-35A_MMC.pdf PDF
SF1442_Sol_W91238-17-R-0078_F-35A_MMC_2-9-2018.pdf PDF
Atch_2_Draft_Drawings_F-35A_MMC.PDF PDF
Atch_1_SOW_(F-35A_MMC)_v8Nov17.pdf PDF
SF1442_W91238-17-R-0078_F-35A_MMC_2-9-2018.pdf PDF
Atch_6_Acknowledgement_Statement_(F35A_MMC)_v21Sep17.pdf PDF

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

Attachment 4 – Supplemental Contract Requirements F35 Munition Maintenance Facility Hill AFB, UT May 8, 2017

SUPPLEMENTAL CONTRACT REQUIREMENTS

1. Performance Period. Refer to FAR 52.211-10, Commencement, Prosecution, And Completion of Work. The time duration of performance period is 580 calendar days after Notice to Proceed date.

2. Liquidated Damages. Refer to FAR 52.211-12, Liquidated Damages-Construction.

Liquidated damages for this work is $1,642.00 for each day of delay.

3. Authorities. Only a warranted Contracting Officer (either PCO or ACO) acting within their delegated limits has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

The Government Contracting Officer/Administrative Contracting Officer has the authority to make any changes to this contract action that impact cost or schedule. Authority from the Contracting Officer/Administrative Contracting Officer to the contractor to make changes that impact cost or schedule will be in the form of an official, signed modification.

4. Wage Determination. General Decision Number UT170104, 1/27/2017 (Building), Davis County, Utah, or its most current modification at the time of award is hereby applicable to work performed under this contract. The most current decisions or their modifications can be found by clicking on hyperlink http://www.wdol.gov/wdol/scafiles/davisbacon/UT104.dvb?v=4 for such information.

5. Time Extensions For Unusually Severe Weather. Refer to FAR 52.249-10, Default (Fixed- Priced Construction). All weather delays will need to be submitted and approved by the Contracting Officer Representative.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

(22) (17) (13) (08) (05) (03) (01) (02) (03) (05) (12) (22) http://www.wdol.gov/wdol/scafiles/davisbacon/UT104.dvb?v=4

SUPPLEMENTAL CONTRACT REQUIREMENTS

File details come from the government source that posted it.