W911WN19B8004-0003.pdf

W81ET491059655

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

RE: Berlin Remote Control Upgrades, Berlin Lake, Mahoning County and Portage County, Ohio

The purpose of this amendment is to incorporate the current Wage Determination, General Decision Number OH20190001 dated 08/16/2019, as indicated in the Summary of Changes to this amendment. The hour and date specif ied for receipt of bids remains unchanged at 11:00 am on 22 August 2019.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 7

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 21-Aug-2019

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W911WN19B8004

X 9B. DATED (SEE ITEM 11)

16-Jul-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

21-Aug-2019

CODE

U.S. ARMY ENGINEER DISTRICT, PITTSBURGH

ATTN CELRP-RC-P

W S MOORHEAD FEDERAL BUILDING

1000 LIBERTY AVENUE ROOM 2203

PITTSBURGH PA 15222-4186

W911WN 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911WN19B8004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

SECTION 00 73 00

ADDENDUM TO SECTION 00 73 00 – SUPPLEMENTARY CONDITIONS

00 73 00 - 01 WAGE RATES

The wage rates identifed below are incorporated into this solicitation and any resultant contract. The rates apply to all performed work.

General Decision Number: OH20190001 08/16/2019

Superseded General Decision Number: OH20180002

State: Ohio

Construction Types: Heavy, Highway

Counties: Adams, Allen, Ashland, Ashtabula, Athens, Auglaize, Belmont, Brown, Butler, Carroll, Champaign, Clark, Clermont, Clinton, Columbiana, Coshocton, Crawford, Cuyahoga, Darke, Defiance, Delaware, Erie, Fairfield, Fayette, Franklin, Fulton, Gallia, Geauga, Greene, Guernsey, Hamilton, Hancock, Hardin, Harrison, Henry, Highland, Hocking, Holmes, Huron, Jackson, Jefferson, Knox, Lake, Lawrence, Licking, Logan, Lorain, Lucas, Madison, Mahoning, Marion, Medina, Meigs, Mercer, Miami, Monroe, Montgomery, Morgan, Morrow, Muskingum, Noble, Ottawa, Paulding, Perry, Pickaway, Pike, Portage, Preble, Putnam, Richland, Ross, Sandusky, Scioto, Seneca, Shelby, Stark, Summit, Trumbull, Tuscarawas, Union, Van Wert, Vinton, Warren, Washington, Wayne, Williams, Wood, Wyandot https://beta.sam.gov/wage-determination/OH20190001/10?index=wd&date_filter_index=0&date_rad_selection=date&wdType=dbra&st ate=OH&county=17094&page=1

00 73 00 - 02 PAYMENT FOR PERFORMANCE AND PAYMENT BONDS

a. In order to ensure that sufficient funds have been set-aside for payment of performance and payment bond premiums, bidders shall insert in Bid Item No. 0001 and Bid Item No. 1001, an appropriate not-to-exceed dollar amount. Failure of bidders to insert a not-to-exceed dollar amount in Bid Item No. 0001 and Bid Item No. 1001 will cause the bid to be rejected as non-responsive.

b. The Contractor shall be reimbursed the actual bond costs only, as established by evidence of full payment to the surety, up to the dollar amount set forth in Bid Item No. 0001 and Bid Item No. 1001. In no case will the Contractor be reimbursed an amount which exceeds the dollar amount set forth in Bid Item No. 0001 and Bid Item 1001.

c. The Government will reimburse only the Prime Contractor for actual paid bond premiums. The Government will not reimburse any subcontractor's paid bond premiums.

00 73 00 - 03 REQUIRED INSURANCE

a. The Contractor shall procure and maintain during the entire performance period of this contract, the following minimum insurance. (See also Section 00 70 00 CONDITIONS OF THE CONTRACT, FAR 52.228-5 Insurance – Work On A Government Installation (JAN 1997).)

Type Bodily Injury Amount Property Damage

Comprehensive General Liability $500,000 Per Occurrence $100,000

Automobile Liability $200,000 Each Person --

$500,000 Per Occurrence $ 20,000 Workmen’s Compensation and Employers Liability As required by State (OH)

b. The Contracting Officer will notify the Contractor of any noncompliance with the foregoing provisions. The Contractor shall, after receipt of such notice, immediately comply. Such notice, when delivered to the Contractor or his representative at the site or mailed to the Contractor's address, will be deemed sufficient for the purpose. If the Contractor fails or refuses to comply promptly, the Contracting Officer may issue an order stopping all or part of the work until the Contractor complies. No part of the time lost due to any such stop orders shall be made the subject of a claim for extension of time or for excess costs or damages by the Contractor. Compliance with the provisions of this article by subcontractors will be the responsibility of the Contractor.

c. Longshoreman and Harbor Worker's Insurance MAY be required for this work. Please consult with your insurance carrier and applicable statutes (33 USC 901, et. seq.).

00 73 00 - 04 SAFETY AND HEALTH REQUIREMENTS MANUAL

A copy of the current US Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1 and its changes are available at http://www.usace.army.mil/SafetyandOccupationalHealth/SafetyandHealthRequirementsManual.aspx .

The Contractor shall be responsible for complying with the current edition and all changes posted on the web as of the effective date of this solicitation.

00 73 00 - 05 WORK UNDER OTHER CONTRACTS

Attention is directed to the fact that other Contractors may be employed by the Government or by local interests at or in the vicinity of the work covered by these specifications. All Contractors shall have equal rights to the use of all roads and grounds so far as practicable and this Contractor shall cooperate with other Contractors so that the work may be performed with the maximum efficiency. Should a disagreement occur between Contractors as to the use of facilities or in other matters, the decision of the Contracting Officer shall govern. (See also the Section 00 70 00 CONDITIONS OF THE CONTRACT, FAR 52.236-8 Other Contracts (APR 1984).)

00 73 00 - 06 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with FAR clause 52.249-10 entitled "Default (Fixed-Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied.

(1) The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. This delay must be beyond the control and without the fault or negligence of the Contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all-weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

11 9 7 6 5 5 5 5 4 3 5 10

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more on the Contractor's scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b. above, the Contracting Officer will convert any qualifying delays to work days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with FAR clause 52.249-10 entitled, "Default (Fixed-Price Construction)".

d. The anticipated adverse weather work days listed above are based on days with precipitation greater than 0.1 inch and/or maximum temperature below 32 degrees F. The numbers shown represent the number of work days (not calendar days) normally expected to have these particular weather conditions based on historical data obtained from the "Climatography of the United States No. 20". The actual number of days will vary. This information is furnished for computation of possible time extensions due to weather delays and is not intended to imply that no work can be done on these days. The Contractor shall make his own determination of the effect of these conditions on his operations under this contract, and schedule his work accordingly.

00 73 00 - 07 COPYING, DISSEMINATION OR DISTRIBUTION OF INFORMATION.

Those who disseminate information contained on this CD-ROM or in the solicitations and/or drawings must ensure that the recipients have a legitimate need for the information and maintain a record of each recipient. Legitimate need means recognized business entities seeking to do business, or having business, with the Government as prime contractors, subcontractors or suppliers. You shall maintain a record of the following information on each recipient:

Business name and address, the Unique Entity Identifier (formerly DUNS) Number, and name and telephone number of person receiving the information

00 73 00 - 08 SUBMISSION OF CONTRACT DOCUMENTATION

Provide contract documentation in an electronic format to the greatest extent practicable. Contract documentation to be submitted electronically includes, but is not limited to, the following:

Submittals, including ENG 4025 transmittal form

Meeting Minutes Construction Photographs Correspondence Requests for Information Payroll Documents Statement and Acknowledgement Forms (SF 1413) Request for Additional Classification (SF 1444) Progress Payment Requests and Supporting Documentation Contract Modification Documentation, including SF 30, Contractor’s Offer, Cost/Pricing Audit Report, and

Certificate of Current Cost or Pricing Data Contractor Quality Control Reports (with attachments) Accident Reports Schedules and Schedule Updates Closeout Documentation, including Release of Claims

Electronic files must be of sufficient quality that all information is legible. Electronic format shall be in Adobe.PDF format, unless otherwise specified or directed by the Contracting Officer. Whenever possible, PDF files shall be generated from original documents so that the text included in the PDF file is both searchable and can be copied. If documents are scanned, Optical Character Resolution (OCR) routines are required. Files exceeding 30 pages shall be indexed and bookmarked to allow efficient navigation of the file. When required, the electronic file must include a valid electronic signature, or scan of a signature.

Email electronic documents fewer than 10MB to an email address as directed by the Contracting Officer. Provide electronic documents over 10MB on an optical disc or through an electronic file sharing system such as AMRDEC SAFE Web Application located at the following website:

https://safe.amrdec.army.mil/safe/

The Contractor shall be prepared to provide up to five (5) additional paper hard copies of any contract document at the discretion of the Contracting Officer, at no additional cost to the Government. In addition to the electronic file format described above, the following list of documents shall be provided in their original format because law or other regulations require signed originals be kept in accordance with FAR 4.805 -- Storage, Handling, and Disposal of Contract Files:

Advance Payment Bond Bid Bond including Annual Bid Bond Performance Bond including Annual Performance Bond Payment Bond Patent Infringement Bond Any performance security instruments Certificate of Insurance Novation/Change of Name Agreement Assignment of Claims Any document containing a raised seal. Examples include o Notarized documents o Architecture Drawings

Paper Payroll Documents Physical signatures on contracts and modifications o SF 1442 o SF 30

00 73 00 - 09 OHIO SALES TAX PROVISIONS

Contractors are exempt from the payment of the Ohio Sales Tax on building and construction materials sold to them for incorporation into a structure or improvement to real property under a construction contract with the United States, provided an exemption certificate is signed both by the Contractor and the United States. (Ohio Revised Code, Sec 5739.02). The certificate will be in such form as prescribed by the Ohio Tax Commissioner, and must be executed within the period for filing the return for the period in which the sale is consummated. (Ohio Revised Code, Sec 5739.03). The Contractor shall be responsible for obtaining the required exemption certificate and submitting it to the Contracting Officer for execution.

00 73 00 - 10 WORK PERFORMED BY CONTRACTOR

Within ten (10) calendar days after award of the contract, the successful bidder will be required to furnish a description of the work which he intends to perform with his own organization, the percentage of the total work this represents, and the estimated cost thereof.

00 73 00 - 11 AWARDABLE OPTIONS

The basic contract items, Items Nos. 0001 thru 0003, will be awarded at the same time as the awardable option items (1001 thru 1002) based on Contractor’s bid and based upon availability and receipt of funds. Awardable Option Items within each of these groupings will be awarded as a group. The determination to award these awardable option items will be made no later than the following dates:

Awardable Option, Items 1001 thru 1002 - 31 January 2020

The contract completion time will not be extended for of award of any of these optional items, and the optional item work shall be performed concurrently with the base contract work. The completion time for the base contract items will remain unchanged.

00 73 00 - 12 CONTRACTOR QUALITY CONTROL

Section 01 45 00.00 08, QUALITY CONTROL, of this specification requires that the Contractor's Quality Control System Manager or person responsible for Contractor Quality Control complete the Corps of Engineers' "Construction Quality Management for Contractors" course not later than 90 calendar days after receipt of the Notice to Proceed. The course consists of approximately 12 hours of classroom instruction and is offered periodically by the Pittsburgh District. For additional information on scheduling and location of the training, contact U.S. Army Engineer District, Pittsburgh, Theresa Bonanno, U.S. Army Engineer District, Pittsburgh, Upper Ohio Area Office, 3510 Grand Avenue, Pittsburgh, Pennsylvania 15225, telephone (412) 395-7677. Certification of course completion is valid for 5 years. Completion of training offered by other Corps of Engineers Districts will be acceptable provided a valid certification is presented.

00 73 00 - 13 ELECTRONIC EMAIL (E-MAIL) ADDRESS

Establish and maintain electronic mail (e-mail) capability along with the capability to open various electronic attachments as text files, pdf files, and other similar formats. Within 10 calendar days after contract award, provide the Contracting Officer a single (only one) e-mail address for electronic communications from the Contracting Officer related to this contract including, but not limited to contract documents, invoice information, request for proposals, and other correspondence. The Contracting Officer may also use e-mail to notify the Contractor of base access conditions when emergency conditions warrant, such as hurricanes or terrorist threats. Multiple e-mail addresses are not allowed.

It is the Contractor's responsibility to make timely distribution of all Contracting Officer initiated e-mail with its own organization including field office(s). Promptly notify the Contracting Officer, in writing, of any changes to this e-mail address.

(End of Summary of Changes)

"General Decision Number: OH20190001 08/16/2019

Superseded General Decision Number: OH20180002

State: Ohio

Construction Types: Heavy and Highway

Counties: Ohio Statewide.

Heavy and Highway Construction Projects

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR

Page 1 of 69beta.SAM.gov

8/19/2019https://beta.sam.gov/wage-determination/OH20190001/10/document

5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/04/2019 1 01/25/2019 2 02/15/2019 3 03/01/2019 4 04/05/2019 5 05/03/2019 6 06/07/2019 7 06/21/2019 8 06/28/2019 9 08/09/2019 10 08/16/2019

BROH0001-001 06/01/2017

DEFIANCE, FULTON (Excluding Fulton, Amboy & Swan Creek Townships), HENRY (Excluding Monroe, Bartlow, Liberty, Washington, Richfield, Marion, Damascus & Townships & that part of Harrison Township outside corporate limits of city of Napoleon), PAULDING, PUTNAM and WILLIAMS COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0001-004 06/01/2017

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 28.65 14.55

Page 2 of 69beta.SAM.gov

BROH0003-002 06/01/2017

FULTON (Townships of Amboy, Swan Creek & Fulton), HENRY (Townships of Washington, Damascus, Richfield, Bartlow, Liberty, Harrison, Monroe, & Marion), LUCAS and WOOD (Townships of Perrysburg, Ross, Lake, Troy, Freedom, Montgomery, Webster, Center, Portage, Middleton, Plain, Liberty, Henry, Washington, Weston, Milton, Jackson & Grand Rapids) COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0005-003 05/01/2019

CUYAHOGA, LORAIN & MEDINA (Hinckley, Granger, Brunswick, Liverpool, Montville, York, Homer, Harrisville, Chatham, Litchfield & Spencer Townships and the city of Medina)

Rates Fringes

BRICKLAYER

BRICKLAYERS; CAULKERS;

CLEANERS; POINTERS; &

STONEMASONS.................$ 34.85 16.94

SANDBLASTERS................$ 35.10 16.94

SEWER BRICKLAYERS & STACK

BUILDERS....................$ 35.35 16.94

SWING SCAFFOLDS.............$ 35.35 16.94

BROH0006-005 06/01/2017

CARROLL, COLUMBIANA (Knox, Butler, West & Hanover Townships), STARK & TUSCARAWAS

Page 3 of 69beta.SAM.gov

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0007-002 06/01/2017

LAWRENCE

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0007-005 06/01/2017

PORTAGE & SUMMIT

Rates Fringes

BRICKLAYER.......................$ 28.65 14.55

BROH0007-010 06/01/2017

PORTAGE & SUMMIT

Rates Fringes

MASON - STONE....................$ 28.65 14.55

BROH0008-001 06/01/2017

COLUMBIANA (Salem, Perry, Fairfield, Center, Elk Run, Middleton, & Unity Townships and the city of New Waterford), MAHONING & TRUMBULL

Rates Fringes

Page 4 of 69beta.SAM.gov

BRICKLAYER.......................$ 28.65 14.55

BROH0009-002 06/01/2017

BELMONT & MONROE COUNTIES and the Townships of Warren & Mt.

Pleasant and the Village of Dillonvale in JEFFERSON COUNTY

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55 Refractory.......................$ 31.45 19.01

BROH0010-002 06/01/2017

COLUMBIANA (St. Clair, Madison, Wayne, Franklin, Washington, Yellow Creek & Liverpool Townships) & JEFFERSON (Brush Creek & Saline Townships)

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0014-002 06/01/2017

HARRISON & JEFFERSON (Except Mt. Pleasant, Warren, Brush Creek, Saline & Salineville Townships & the Village of Dillonvale)

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0016-002 06/01/2017

Page 5 of 69beta.SAM.gov

ASHTABULA, GEAUGA, and LAKE COUNTIES

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0018-002 06/01/2017

BROWN, BUTLER, CLERMONT, HAMILTON, PREBLE (Gasper, Dixon, Israel, Lanier, Somers & Gratis Townships) & WARREN COUNTIES:

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0022-004 06/01/2017

CHAMPAIGN, CLARK, CLINTON, DARKE, GREENE, HIGHLAND, LOGAN,

MIAMI, MONTGOMERY, PREBLE (Jackson, Monroe, Harrison, Twin, Jefferson & Washington Townships) and SHELBY COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0032-001 06/01/2017

GALLIA & MEIGS

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0035-002 06/01/2017

Page 6 of 69beta.SAM.gov

ALLEN, AUGLAIZE, MERCER and VAN WERT COUNTIES

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0039-002 06/01/2017

ADAMS & SCIOTO

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0040-003 06/01/2017

ASHLAND, CRAWFORD, HARDIN, HOLMES, MARION, MORROW, RICHLAND,

WAYNE and WYANDOT (Except Crawford, Ridge, Richland & Tymochtee Townships) COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

FOOTNOTE: Layout Man and Sawman rate: $1.00 per hour above journeyman rate.

Free standing stack work ground level to top of stack;

Sandblasting and laying of carbon masonry material in swing stage and/or scaffold; Ramming and spading of plastics and gunniting: $1.50 per hour above journeyman rate.

""Hot"" work: $2.50 above journeyman rate.

BROH0044-002 06/01/2017

Rates Fringes

Page 7 of 69beta.SAM.gov

Bricklayer, Stonemason

COSHOCTON, FAIRFIELD,

GUERNSEY, HOCKING, KNOX,

KICKING, MORGAN,

MUSKINGUM, NOBLE (Beaver, Buffalo, Seneca & Wayne Townships) & PERRY

COUNTIES:...................$ 28.65 14.55

BROH0045-002 06/01/2017

FAYETTE, JACKSON, PIKE, ROSS and VINTON COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0046-002 06/01/2017

ERIE, HANCOCK, HURON, OTTAWA, SANDUSKY, SENECA, WOOD (Perry & Bloom Townships) and WYANDOT (Tymochtee, Crawford, Ridge & Richland Townships) COUNTIES & the Islands of Lake Erie north of Sandusky

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

FOOTNOTE: Layout Man and Sawman rate: $1.00 per hour above journeyman rate.

Free standing stack work ground level to top of stack;

Sandblasting and laying of carbon masonry material in swing stage and/or scaffold; Ramming and spading of plastics and gunniting: $1.50 per hour above journeyman rate.

""Hot"" work: $2.50 above journeyman rate.

Page 8 of 69beta.SAM.gov

BROH0052-001 06/01/2017

ATHENS COUNTY

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0052-003 06/01/2017

NOBLE (Brookfield, Noble, Center, Sharon, Olive, Enoch, Stock, Jackson, Jefferson & Elk Townships) and WASHINGTON COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

BROH0055-003 06/01/2017

DELAWARE, FRANKLIN, MADISON, PICKAWAY and UNION COUNTIES

Rates Fringes

Bricklayer, Stonemason...........$ 28.65 14.55

CARP0003-004 05/01/2017

MAHONING & TRUMBULL

Rates Fringes

CARPENTER........................$ 26.20 17.42

CARP0069-003 05/01/2017

Page 9 of 69beta.SAM.gov

CARROLL, STARK, TUSCARAWAS & WAYNE

CARPENTER........................$ 25.98 15.98

CARP0069-006 05/01/2017

COSHOCTON, HOLMES, KNOX & MORROW

Rates Fringes

CARPENTER........................$ 24.04 15.29

CARP0171-002 05/01/2019

BELMONT, COLUMBIANA, HARRISON, JEFFERSON & MONROE

Rates Fringes

CARPENTER........................$ 27.37 20.02

CARP0200-002 05/01/2017

ADAMS, ATHENS, DELAWARE, FAIRFIELD, FAYETTE, FRANKLIN, GALLIA,

GUERNSEY, HIGHLAND, HOCKING, JACKSON, LAWRENCE, LICKING,

MADISON, MARION, MEIGS, MORGAN, MUSKINGUM, NOBLE, PERRY,

PICKAWAY, PIKE, ROSS, SCIOTO, UNION, VINTON and WASHINGTON

COUNTIES

Rates Fringes

CARPENTER........................$ 29.07 16.22

Diver............................$ 39.41 10.40

PILEDRIVERMAN....................$ 29.07 16.22

Page 10 of 69beta.SAM.gov

CARP0248-005 07/01/2008

LUCAS & WOOD

Rates Fringes

CARPENTER........................$ 27.27 14.58

CARP0248-008 07/01/2008

Rates Fringes

CARPENTER

DEFIANCE, FULTON, HANCOCK,

HENRY, PAULDING & WILLIAMS

COUNTIES....................$ 23.71 13.28

CARP0254-002 05/01/2017

ASHTABULA, CUYAHOGA, GEAUGA & LAKE

Rates Fringes

CARPENTER........................$ 32.40 16.97

CARP0372-002 05/01/2016

ALLEN, AUGLAIZE, HARDIN, MERCER, PUTNAM & VAN WERT

Rates Fringes

CARPENTER........................$ 24.54 18.21

CARP0639-003 05/01/2017

MEDINA, PORTAGE & SUMMIT

Page 11 of 69beta.SAM.gov

CARPENTER........................$ 30.42 16.99

CARP0735-002 05/01/2019

ASHLAND, ERIE, HURON, LORAIN & RICHLAND

Rates Fringes

CARPENTER........................$ 26.30 17.91

CARP1311-001 05/01/2017

BROWN, BUTLER, CHAMPAIGN, CLARK, CLERMONT, CLINTON, DARKE,

GREENE, HAMILTON, LOGAN, MIAMI, MONTGOMERY, PREBLE, SHELBY &

WARREN

Rates Fringes

Carpenter & Piledrivermen........$ 29.34 15.95 Diver............................$ 40.58 9.69

CARP1393-002 07/01/2008

CRAWFORD, DEFIANCE, FULTON, HANCOCK, HENRY, LUCAS, OTTAWA,

PAULDING, SANDUSKY, SENECA, WILLIAMS & WOOD

Rates Fringes

Piledrivermen & Diver's Tender...$ 27.30 16.05

DIVERS - $250.00 per day

Page 12 of 69beta.SAM.gov

CARP1393-003 07/01/2008

ALLEN, AUGLAIZE, HARDIN, MERCER, PUTNAM, VAN WERT & WYANDOT

Rates Fringes

Piledrivermen & Diver's Tender...$ 25.15 15.92

DIVERS - $250.00 per day

CARP1871-006 05/01/2017

BELMONT, HARRISON, & MONROE

Rates Fringes

Diver, Wet.......................$ 48.11 17.33 Piledrivermen; Diver, Dry........$ 32.07 17.33

CARP1871-008 05/01/2017

ASHLAND, ASHTABULA, CUYAHOGA, ERIE, GEAUGA, HURON, LAKE,

LORAIN, MEDINA, PORTAGE, RICHLAND & SUMMIT

Rates Fringes

Diver, Wet.......................$ 45.80 18.84 Piledrivermen; Diver, Dry........$ 30.53 18.84

CARP1871-014 05/01/2017

CARROLL, STARK, TUSCARAWAS & WAYNE

Rates Fringes

Diver, Wet.......................$ 38.34 16.95

Page 13 of 69beta.SAM.gov

Piledrivermen; Diver, Dry........$ 25.56 16.95

CARP1871-015 05/01/2017

COSHOCTON, HOLMES, KNOX & MORROW

Rates Fringes

Diver, Wet.......................$ 37.34 16.07 Piledrivermen; Diver, Dry........$ 24.89 16.07

CARP1871-017 05/01/2017

MAHONING & TRUMBULL

Rates Fringes

Diver, Wet.......................$ 40.65 17.62 Piledrivermen; Diver, Dry........$ 27.10 17.62

CARP2235-012 01/01/2014

COLUMBIANA & JEFFERSON

Rates Fringes

PILEDRIVERMAN....................$ 31.74 16.41

CARP2239-001 07/01/2008

CRAWFORD, OTTAWA, SANDUSKY, SENECA & WYANDOT

Rates Fringes

CARPENTER........................$ 23.71 13.28

ELEC0008-002 05/27/2019

Page 14 of 69beta.SAM.gov

DEFIANCE, FULTON, HANCOCK, HENRY, LUCAS, OTTAWA, PAULDING,

PUTNAM, SANDUSKY, SENECA, WILLIAMS & WOOD

Rates Fringes

CABLE SPLICER....................$ 38.98 18.96

ELECTRICIAN......................$ 40.45 1.5%+20.23

ELEC0032-003 06/01/2019

ALLEN, AUGLAIZE, HARDIN, LOGAN, MERCER, SHELBY, VAN WERT &

WYANDOT (Crawford, Jackson, Marseilles, Mifflin, Ridgeland, Ridge & Salem Townships)

Rates Fringes

ELECTRICIAN......................$ 30.37 18.42

ELEC0038-002 04/29/2019

CUYAHOGA, GEAUGA (Bainbridge, Chester & Russell Townships) & LORAIN (Columbia Township)

Rates Fringes

ELECTRICIAN

Excluding Sound & Communications Work.........$ 39.13 20.69

FOOTNOTES;

a. 6 Paid Holidays: New Year's Day; Memorial Day; July 4th;

Labor Day; Thanksgiving Day; & Christmas Day

b. 1 week's paid vacation for 1 year's service; 2 weeks' paid

Page 15 of 69beta.SAM.gov vacation for 2 or more years' service

ELEC0038-008 04/29/2019

CUYAHOGA, GEAUGA (Bainbridge, Chester & Russell Townships) & LORAIN (Columbia Township)

Rates Fringes

Sound & Communication Technician Communications Technician...$ 27.55 11.98 Installer Technician........$ 26.30 11.94

FOOTNOTES;

a. 6 Paid Holidays: New Year's Day; Memorial Day; July 4th;

Labor Day; Thanksgiving Day; & Christmas Day

b. 1 week's paid vacation for 1 year's service; 2 weeks' paid vacation for 2 or more years' service

ELEC0064-003 11/26/2018

COLUMBIANA (Butler, Fairfield, Perry, Salem & Unity Townships) MAHONING (Austintown, Beaver, Berlin, Boardman, Canfield, Ellsworth, Coitsville, Goshen, Green, Jackson, Poland, Springfield & Youngstown Townships), & TRUMBULL (Hubbard & Liberty Townships)

Rates Fringes

ELECTRICIAN......................$ 33.67 15.28

ELEC0071-001 01/01/2019

Page 16 of 69beta.SAM.gov

ASHLAND, CHAMPAIGN, CLARK, COSHOCTON, CRAWFORD, DELAWARE,

FAIRFIELD, FAYETTE, FRANKLIN, GUERNSEY, HIGHLAND, HOCKING,

JACKSON (Coal, Jackson, Liberty, Milton, Washington & Wellston Townships), KNOX, LICKING, MADISON, MARION, MONROE, MORGAN, MORROW, MUSKINGUM, NOBLE, PERRY, PICKAWAY, PIKE (Beaver, Benton, Jackson, Mifflin, Pebble, Peepee, Perry & Seal Townships), RICHLAND, ROSS, TUSCARAWAS (Auburn, Bucks, Clay, Jefferson, Oxford, Perry, Salem, Rush, Washington & York Townships), UNION, VINTON (Clinton, Eagle, Elk, Harrison, Jackson, Richland & Swan Townships), and WASHINGTON COUNTIES

Rates Fringes

Line Construction Equipment Operators.........$ 33.62 13.40 Groundmen...................$ 24.17 11.32 Linemen & Cable Splicers....$ 38.27 14.42

ELEC0071-004 01/01/2019

AUGLAIZE, CLINTON, DARKE, GREENE, LOGAN, MERCER, MIAMI,

MONTGOMERY, PREBLE, and SHELBY COUNTIES

Rates Fringes

Line Construction Equipment Operator..........$ 33.62 13.40 Groundman...................$ 24.17 11.32 Lineman & Cable Splicers....$ 38.27 14.42

ELEC0071-005 12/31/2018

ASHTABULA, CUYAHOGA, GEAUGA, LAKE & LORAIN

Page 17 of 69beta.SAM.gov

LINE CONSTRUCTION: Equipment Operator DOT/Traffic Signal & Highway Lighting Projects...$ 32.44 14.10 Municipal Power/Transit Projects....................$ 40.10 16.42 LINE CONSTRUCTION: Groundman DOT/Traffic Signal & Highway Lighting Projects...$ 25.06 12.26 Municipal Power/Transit Projects....................$ 31.19 14.11

LINE CONSTRUCTION:

Linemen/Cable Splicer DOT/Traffic Signal & Highway Lighting Projects...$ 36.13 15.03 Municipal Power/Transit Projects....................$ 44.56 17.58

ELEC0071-008 01/01/2019

COLUMBIANA, MAHONING, and TRUMBULL COUNTIES

Rates Fringes

Line Construction Equipment Operator..........$ 33.62 13.40 Groundman...................$ 24.17 11.32 Lineman & Cable Splicers....$ 38.27 14.42

ELEC0071-010 01/01/2019

BELMONT, CARROLL, HARRISON, HOLMES, JEFFERSON, MEDINA, PORTAGE,

STARK, SUMMIT, and WAYNE COUNTIES

Page 18 of 69beta.SAM.gov

Line Construction Equipment Operator..........$ 33.62 13.40 Groundman...................$ 24.17 11.32 Lineman & Cable Splicers....$ 38.27 14.42

ELEC0071-013 01/01/2019

BROWN, BUTLER, CLERMONT, HAMILTON, and WARREN COUNTIES

Rates Fringes

Line Construction Equipment Operator..........$ 33.62 13.40 Groundman...................$ 24.17 11.32 Lineman & Cable Splicers....$ 38.27 14.42

ELEC0071-014 01/01/2019

ADAMS, ATHENS, GALLIA, JACKSON (Bloomfield, Franklin, Hamilton, Lick, Jefferson, Scioto & Madison Townships), LAWRENCE, MEIGS, PIKE (Camp Creek, Marion, Newton, Scioto, Sunfish & Union Townships), SCIOTO & VINTON (Brown, Knox, Madison, Vinton & Wilkesville Townships)

Rates Fringes

Line Construction Equipment Operator..........$ 33.62 13.40 Groundman...................$ 24.17 11.32 Lineman & Cable Splicers....$ 38.27 14.42

ELEC0082-002 12/03/2018

CLINTON, DARKE, GREENE, MIAMI, MONTGOMERY, PREBLE & WARREN

Page 19 of 69beta.SAM.gov

(Wayne, Clear Creek & Franklin Townships)

ELECTRICIAN......................$ 30.15 19.26

ELEC0082-006 11/26/2018

CLINTON, DARKE, GREENE, MIAMI, MONTGOMERY, PREBLE & WARREN

(Wayne, Clear Creek & Franklin Townships)

Rates Fringes

Sound & Communication Technician Cable Puller................$ 12.18 3.85 Installer/Technician........$ 24.35 11.29

ELEC0129-003 02/26/2018

LORAIN (Except Columbia Township) & MEDINA (Litchfield & Liverpool Townships)

Rates Fringes

ELECTRICIAN......................$ 33.35 17.27

ELEC0129-004 02/26/2018

ERIE & HURON (Lyme, Ridgefield, Norwalk, Townsend, Wakeman, Sherman, Peru, Bronson, Hartland, Clarksfield, Norwich, Greenfield, Fairfield, Fitchville & New London Townships)

Page 20 of 69beta.SAM.gov

ELECTRICIAN......................$ 33.35 17.27

ELEC0141-003 09/01/2018

BELMONT COUNTY

Rates Fringes

CABLE SPLICER....................$ 33.60 25.61

ELECTRICIAN......................$ 30.01 25.61

ELEC0212-003 11/26/2018

BROWN, CLERMONT & HAMILTON

Rates Fringes

Sound & Communication Technician.......................$ 24.35 10.99

ELEC0212-005 06/03/2019

BROWN, CLERMONT, and HAMILTON COUNTIES

Rates Fringes

ELECTRICIAN......................$ 30.18 18.89

ELEC0245-001 08/27/2018

ALLEN, HARDIN, VAN WERT & WYANDOT (Crawford, Jackson, Marseilles, Mifflin, Richland, Ridge & Salem Townships)

Rates Fringes

Page 21 of 69beta.SAM.gov

Line Construction Equipment Operator..........$ 31.59 25.2%+5.75 Groundman Truck Driver......$ 17.28 25.2%+5.75 Lineman.....................$ 39.49 25.2%+5.75

FOOTNOTE: a. Half day's Paid Holiday: The last 4 hours of the workday prior to Christmas or New Year's Day

ELEC0245-003 01/01/2019

DEFIANCE, FULTON, HANCOCK, HENRY, HURON, LUCAS, OTTAWA,

PAULDING, PUTNAM, SANDUSKY, SENECA, WILLIAMS, and WOOD COUNTIES

Rates Fringes

Line Construction Cable Splicer...............$ 45.17 25.2%+6.00 Groundman/Truck Driver......$ 17.19 25.2%+6.00 Heli-arc Welding............$ 39.58 25.2%+6.00 Lineman.....................$ 39.28 25.2%+6.00 Operator - Class 1..........$ 31.42 25.2%+6.00 Operator - Class 2..........$ 27.50 25.2%+6.00 Traffic Signal & Lighting Technician..................$ 35.35 25.2%+6.00

FOOTNOTE: a. 6 Observed Holidays: New Year's Day; Memorial Day; Independence Day; Labor Day; Thanksgiving Day; & Christmas Day. Employees who work on a holiday shall be paid at a rate of double their applicable classified straight-time rates for the work performed on such holiday.

ELEC0245-004 01/01/2019

Page 22 of 69beta.SAM.gov

ERIE COUNTY

Line Construction Cable Splicer...............$ 45.17 25.2%+6.00 Groundman/Truck Driver......$ 17.19 25.2%+6.00 Lineman.....................$ 39.28 25.2%+6.00 Operator - Class 1..........$ 31.42 25.2%+6.00 Operator - Class 2..........$ 27.50 25.2%+6.00

FOOTNOTE: a. 6 Observed Holidays: New Year's Day; Memorial Day; Independence Day; Labor Day; Thanksgiving Day; & Christmas Day. Employees who work on a holiday shall be paid at a rate of double their applicable classified straight-time rates for the work performed on such holiday.

ELEC0246-001 10/29/2018

Rates Fringes

ELECTRICIAN......................$ 38.00 84%+a

FOOTNOTE: a. 1 1/2 Paid Holidays: The last scheduled workday prior to Christmas & 4 hours on Good Friday.

ELEC0306-005 05/28/2018

MEDINA (Brunswick, Chatham, Granger, Guilford, Harrisville, Hinckley, Homer, Lafayette, Medina, Montville, Sharon, Spencer, Wadsworth, Westfield & York Townships), PORTAGE (Atwater, Aurora, Brimfield, Deerfield, Franklin, Mantua, Randolph, Ravenna, Rootstown, Shalersville, Streetsboro & Suffield Townships), SUMMIT & WAYNE (Baughman, Canaan, Chester, Chippewa, Congress, Green, Milton, & Wayne Townships)

Page 23 of 69beta.SAM.gov

CABLE SPLICER....................$ 36.87 16.56

ELECTRICIAN......................$ 34.54 5%+18.06

ELEC0317-002 06/01/2018

GALLIA & LAWRENCE

Rates Fringes

CABLE SPLICER....................$ 32.68 18.13

ELECTRICIAN......................$ 33.75 25.03

ELEC0540-005 01/01/2019

CARROLL (Northern half, including Fox, Harrison, Rose & Washington Townhships), COLUMBIANA (Knox Township), HOLMES, MAHONING (Smith Township), STARK, TUSCARAWAS (North of Auburn, Clay, Rush & York Townships), and WAYNE (South of Baughman, Chester, Green & Wayne Townships) COUNTIES

Rates Fringes

ELECTRICIAN......................$ 32.55 23.58

ELEC0573-003 11/26/2018

ASHTABULA (Colebrook, Wayne, Williamsfield, Orwell & Windsor Townships), GEAUGA (Auburn, Middlefield, Parkman & Troy Townships), MAHONING (Milton Township), PORTAGE (Charlestown, Edinburg, Freedom, Hiram, Nelson, Palmyra, Paris & Windham Townships), and TRUMBULL (Except Liberty & Hubbard Townships)

Page 24 of 69beta.SAM.gov

ELECTRICIAN......................$ 33.35 18.73

ELEC0575-001 12/31/2018

ADAMS, FAYETTE, HIGHLAND, HOCKING, JACKSON (Bloomfield, Franklin, Hamilton, Jefferson, Lick, Madison, Scioto, Coal, Jackson, Liberty, Milton & Washington Townships), PICKAWAY (Deer Creek, Perry, Pickaway, Salt Creek & Wayne Townships), PIKE (Beaver, Benton, Jackson, Mifflin, Pebble, PeePee, Perry, Seal, Camp Creek, Newton, Scioto, Sunfish, Union & Marion Townships), ROSS, SCIOTO & VINTON (Clinton, Eagle, Elk, Harrison, Jackson, Richland & Swan Townships)

Rates Fringes

ELECTRICIAN......................$ 32.75 16.81

ELEC0648-001 09/03/2018

BUTLER and WARREN COUNTIES (Deerfield, Hamilton, Harlan, Massie, Salem, Turtle Creek, Union & Washington Townships)

Rates Fringes

CABLE SPLICER....................$ 30.50 18.23

ELECTRICIAN......................$ 30.00 18.70

ELEC0673-004 01/01/2019

ASHTABULA (Excluding Orwell, Colebrook, Williamsfield, Wayne & Windsor Townships), GEAUGA (Burton, Chardon, Claridon, Hambden, Huntsburg, Montville, Munson, Newbury & Thompson Townships) and

Page 25 of 69beta.SAM.gov

LAKE COUNTIES

CABLE SPLICER....................$ 33.31 20.96

ELECTRICIAN......................$ 33.03 20.95

ELEC0683-002 05/27/2019

CHAMPAIGN, CLARK, DELAWARE, FAIRFIELD, FRANKLIN, MADISON,

PICKAWAY (Circleville, Darby, Harrison, Jackson, Madison, Monroe, Muhlenberg, Scioto, Walnut & Washington Townships), and

UNION COUNTIES

Rates Fringes

CABLE SPLICER....................$ 34.50 21.20

ELECTRICIAN......................$ 33.50 20.18

ELEC0688-003 05/28/2018

ASHLAND, CRAWFORD, HURON (Richmond, New Haven, Ripley & Greenwich Townships), KNOX (Liberty, Clinton, Union, Howard, Monroe, Middleberry, Morris, Wayne, Berlin, Pike, Brown & Jefferson Townships), MARION, MORROW, RICHLAND and WYANDOT (Sycamore, Crane, Eden, Pitt, Antrim & Tymochtee Townships)

COUNTIES

Rates Fringes

ELECTRICIAN......................$ 29.35 17.99

ELEC0972-002 06/01/2019

Page 26 of 69beta.SAM.gov

ATHENS, MEIGS, MONROE, MORGAN, NOBLE, VINTON (Brown, Knox, Madison, Vinton & Wilkesville Townships), and WASHINGTON

COUNITES

Rates Fringes

CABLE SPLICER....................$ 33.80 26.65

ELECTRICIAN......................$ 33.55 26.65

ELEC1105-001 05/28/2018

COSHOCTON, GUERNSEY, KNOX (Jackson, Clay, Morgan, Miller, Milford, Hilliar, Butler, Harrison, Pleasant & College Townships), LICKING, MUSKINGUM, PERRY, and TUSCARAWAS (Auburn, York, Clay, Jefferson, Rush, Oxford, Washington, Salem, Perry & Bucks Townships) COUNTIES

Rates Fringes

ELECTRICIAN......................$ 30.95 17.96

* ENGI0018-003 05/01/2019

ASHTABULA, CUYAHOGA, ERIE, GEAUGA, LAKE, LORAIN, MEDINA,

PORTAGE, and SUMMIT COUNTIES

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 38.63 15.20

GROUP 2.....................$ 38.53 15.20

GROUP 3.....................$ 37.49 15.20

GROUP 4.....................$ 36.27 15.20

GROUP 5.....................$ 30.98 15.20

Page 27 of 69beta.SAM.gov

GROUP 6.....................$ 38.88 15.20

GROUP 7.....................$ 39.13 15.20

OPERATING ENGINEER CLASSIFICATIONS

GROUP 1 - Air Compressor on Steel Erection; Barrier Moving Machine; Boiler Operator on Compressor or Generator when mounted on a Rig; Cableway; Combination Concrete Mixer & Tower; Concrete Plant (over 4 yd. Capacity); Concrete Pump;

Crane (All Types, Including Boom Truck, Cherry Picker);

Crane-Compact, Track or Rubber over 4,000 lbs. capacity;

Cranes-Self Erecting, Stationary, Track or Truck (All Configurations); Derrick; Dragline; Dredge (Dipper, Clam or Suction); Elevating Grader or Euclid Loader; Floating Equipment (All Types); Gradall; Helicopter Crew (Operator-Hoist or Winch); Hoe (all types); Hoisting Engine on Shaft or Tunnel Work; Hydraulic Gantry (Lifting System);

Industrial-Type Tractor; Jet Engine Dryer (D8 or D9) Diesel Tractor; Locomotive (Standard Gauge); Maintenance Operator Class A; Mixer, Paving (Single or Double Drum); Mucking Machine; Multiple Scraper; Piledriving Machine (All Types);

Power Shovel; Prentice Loader; Quad 9 (Double Pusher); Rail Tamper (with auto lifting & aligning device); Refrigerating Machine (Freezer Operation); Rotary Drill, on Caisson work;

Rough Terrain Fork Lift with Winch/Hoist; Side-Boom;

Slip-Form Paver; Tower Derrick; Tree Shredder; Trench Machine (Over 24"" wide); Truck Mounted Concrete Pump; Tug Boat; Tunnel Machine and/or Mining Machine; Wheel Excavator; and Asphalt Plant Engineer (Cleveland District Only).

GROUP 2 - Asphalt Paver; Automatic Subgrader Machine, Self-Propelled (CMI Type); Bobcat Type and/or Skid Steer Loader with Hoe Attachment Greater than 7,000 lbs.; Boring Machine More than 48""; Bulldozer; Endloader; Horizontal Directional Drill (Over 50,000 ft lbs thrust); Hydro Milling Machine; Kolman-type Loader (production type-Dirt);

Page 28 of 69beta.SAM.gov

Lead Greaseman; Lighting & Traffic Signal Installation Equipment (includes all groups or classifications);

Material Transfer Equipment (Shuttle Buggy) Asphalt;

Pettibone-Rail Equipment; Power Grader; Power Scraper; Push Cat; Rotomill (all), Grinders & Planers of All types;

Trench Machine (24"" wide & under); Vermeer type Concrete Saw; and Maintenance Operators (Portage and Summit Counties Only).

GROUP 3 - A-Frame; Air Compressor on Tunnel Work (low pressure); Asphalt Plant Engineer (Portage and Summit Counties Only); Bobcat-type and/or Skid Steer Loader with or without Attachments; Highway Drills (all types);

Locomotive (narrow gauge); Material Hoist/Elevator; Mixer, Concrete (more than one bag capacity); Mixer, one bag capacity (Side Loader); Power Boiler (Over 15 lbs.

Pressure) Pump Operator installing & operating Well Points;

Pump (4"" & over discharge); Roller, Asphalt; Rotovator (lime soil stabilizer); Switch & Tie Tampers (without lifting & aligning device); Utility Operator (Small equipment); Welding Machines; and Railroad Tie Inserter/Remover; Articulating/straight bed end dumps if assigned (minus $4.00 per hour.

GROUP 4 - Backfiller; Ballast Re-locator; Bars, Joint & Mesh Installing Machine; Batch Plant; Boring Machine Operator (48"" or less); Bull Floats; Burlap & Curing Machine;

Concrete Plant (capacity 4 yd. & under); Concrete Saw (Multiple); Conveyor (Highway); Crusher; Deckhand;

Farm-type Tractor with attachments (highway); Finishing Machine; Fireperson, Floating Equipment (all types);

Forklift; Form Trencher; Hydro Hammer expect masonary;

Hydro Seeder; Pavement Breaker; Plant Mixer; Post Driver;

Post Hole Digger (Power Auger); Power Brush Burner; Power Form Handling Equipment; Road Widening Trencher; Roller (Brick, Grade & Macadam); Self-Propelled Power Spreader;

Self-Propelled Power Subgrader; Steam Fireperson; Tractor

Page 29 of 69beta.SAM.gov

(Pulling Sheepfoot, Roller or Grader); and Vibratory Compactor with Integral Power.

GROUP 5 - Compressor (Portable, Sewer, Heavy & Highway); Drum Fireperson (Asphalt Plant); Generator; Masonry Fork Lift;

Inboard-Outboard Motor Boat Launch; Oil Heater (asphalt plant); Oiler/Helper; Power Driven Heater; Power Sweeper & Scrubber; Pump (under 4"" discharge); Signalperson; Tire Repairperson; VAC/ALLS; Cranes - Compact, track or rubber under 4,000 pound capacity; fueling and greasing; and Chainmen.

GROUP 6 - Master Mechanic & Boom from 150 to 180.

GROUP 7 - Boom from 180 and over.

* ENGI0018-004 05/01/2019

ADAMS, ALLEN, ASHLAND, ATHENS, AUGLAIZE, BELMONT, BROWN,

BUTLER, CARROLL, CHAMPAIGN, CLARK, CLERMONT, CLINTON,

COSHOCTON, CRAWFORD, DARKE, DEFIANCE, DELAWARE, FAIRFIELD,

FAYETTE, FRANKLIN, FULTON, GALLIA, GREENE, GUERNSEY, HAMILTON,

HANCOCK, HARDIN, HARRISON, HENRY, HIGHLAND, HOCKING, HOLMES,

HURON, JACKSON, JEFFERSON, KNOX, LAWRENCE, LICKING, LOGAN,

LUCAS, MADISON, MARION, MEIGS, MERCER, MIAMI, MONROE,

MONTGOMERY, MORGAN, MORROW, MUSKINGUM, NOBLE, OTTAWA, PAULDING,

PERRY, PICKAWAY, PIKE, PREBLE, PUTNAM, RICHLAND, ROSS,

SANDUSKY, SCIOTO, SENECA, SHELBY, STARK, TUSCARAWAS, UNION, VAN

WERT, VINTON, WARREN, WASHINGTON, WAYNE, WILLIAMS, WOOD, and

YANDOT COUNTIES

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 37.14 15.20

Page 30 of 69beta.SAM.gov

GROUP 2.....................$ 37.02 15.20

GROUP 3.....................$ 35.98 15.20

GROUP 4.....................$ 34.80 15.20

GROUP 5.....................$ 29.34 15.20

GROUP 6.....................$ 37.39 15.20

GROUP 7.....................$ 37.64 15.20

OPERATING ENGINEER CLASSIFICATIONS

GROUP 1 - Air Compressor on Steel Erection; Barrier Moving Machine; Boiler Operator on Compressor or Generator when mounted on a Rig; Cableway; Combination Concrete Mixer & Tower; Concrete Plant (over 4 yd. Capacity); Concrete Pump;

Crane (All Types, Including Boom Truck, Cherry Picker);

Crane-Compact, Track or Rubber over 4,000 lbs. capacity;

Cranes-Self Erecting, Stationary, Track or Truck (All Configurations); Derrick; Dragline; Dredge (Dipper, Clam or Suction); Elevating Grader or Euclid Loader; Floating Equipment (All Types); Gradall; Helicopter Crew (Operator-Hoist or Winch); Hoe (all types); Hoisting Engine on Shaft or Tunnel Work; Hydraulic Gantry (Lifting System); Industrial-Type Tractor; Jet Engine Dryer (D8 or D9) Diesel Tractor; Locomotive (Standard Gauge);

Maintenance Operator Class A; Mixer, Paving (Single or Double Drum); Mucking Machine; Multiple Scraper;

Piledriving Machine (All Types); Power Shovel; Prentice Loader; Quad 9 (Double Pusher); Rail Tamper (with auto lifting & aligning device); Refrigerating Machine (Freezer Operation); Rotary Drill, on Caisson work; Rough Terrain Fork Lift with Winch/Hoist; Side-Boom; Slip-Form Paver;

Tower Derrick; Tree Shredder; Trench Machine (Over 24"" wide); Truck Mounted Concrete Pump; Tug Boat; Tunnel Machine and/or Mining Machine; and Wheel Excavator.

GROUP 2 - Asphalt Paver; Automatic Subgrader Machine, Self-Propelled (CMI Type); Bobcat Type and/or Skid Steer Loader with Hoe Attachment Greater than 7,000 lbs.; Boring

Page 31 of 69beta.SAM.gov

Machine More than 48""; Bulldozer; Endloader; Hydro Milling Machine; Horizontal Directional Drill (over 50,000 ft. lbs.

thrust);Kolman-type Loader (production type-Dirt); Lead Greaseman; Lighting & Traffic Signal Installation Equipment (includes all groups or classifications); Material Transfer Equipment (Shuttle Buggy) Asphalt; Pettibone-Rail Equipment; Power Grader; Power Scraper; Push Cat; Rotomill (all), Grinders & Planers of All types; Trench Machine (24"" wide & under); and Vermeer type Concrete Saw.

GROUP 3 - A-Frame; Air Compressor on Tunnel Work (low pressure); Asphalt Plant Engineer; Bobcat-type and/or Skid Steer Loader with or without Attachments; Highway Drills (all types); Locomotive (narrow gauge); Material Hoist/Elevator; Mixer, Concrete (more than one bag capacity); Mixer, one bag capacity (Side Loader); Power Boiler (Over 15 lbs. Pressure) Pump Operator installing & operating Well Points; Pump (4"" & over discharge); Railroad Tie Inserter/Remover; Roller, Asphalt; Rotovator (lime soil stabilizer); Switch & Tie Tampers (without lifting & aligning device); Utility Operator (Small equipment); and Welding Machines; Artiaculating/straight bed end dumps if assigned (minus $4.00 per hour.

GROUP 4 - Backfiller;…