Solicitation Amendment - W911N226QA001 0001 CONFOMRED.pdf
PDF 3 MB Posted
- Attached to
- Fire Extinguisher Repair & Testing Services
- Solicitation number
- W911N226QA001
About this file
This is a Solicitation Amendment and conformed purchase order for fire extinguisher maintenance, hydrostatic testing, and recharge services at Letterkenny Army Depot in Chambersburg, Pennsylvania. The solicitation (W911N226QA001) is a 100% set-aside for women-owned small businesses (WOSB), issued February 26, 2026, with a quote due date of March 19, 2026 at 3:00 PM local time. The contract is a requirements-type purchase order for commercial services with a firm fixed price structure and time-and-materials options, with a NAICS code of 811310 (automotive repair and maintenance) and a size standard of $12.5 million.
The solicitation covers four main service categories across the base year (April 8, 2026 to April 7, 2027) and two optional years: 6-year maintenance on various fire extinguisher types (10lb ABC, 20lb ABC, FE36, and Class D extinguishers), hydrostatic testing on 10 different extinguisher types, recharge services on multiple extinguisher models, and parts acquisition billed as actual costs with a $50 approval threshold for individual parts. Quantities vary by extinguisher type, ranging from 5 to 350 lots, with corresponding option year quantities also specified. The contractor must be DOT-certified as a cylinder requalification facility under 49 CFR Section 107.805, possess appropriate certifications for fire safety services, and demonstrate experience with similar scope work. The conformed amendment incorporates revised Performance Work Statement requirements and updates to applicable fire extinguisher makes and models, and all quoters must submit a signed, priced conformed solicitation with Amendment 0001 as part of their response. The contract incorporates FAR and DFARS clauses including small business subcontracting plan requirements, cybersecurity maturity model certification, and service contract labor standards.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
WOMEN-OWNED SMALL
BUSINESS (WOSB)
SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES
1. REQUISITION NUMBER PAGE 1 OF
2. CONTRACT NUMBER 3. AWARD/EFFECTIVE
DATE
4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE
DATE
7. FOR SOLICITATION
INFORMATION CALL:
a. NAME b. TELEPHONE NUMBER (No collect 8. OFFER DUE DATE/
LOCAL TIME
9. ISSUED BY
13b. RATING
14. METHOD OF SOLICITATION
CODE
15. DELIVER TO 16. ADMINISTERED BY CODE
18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/
OFFEROR
CODE
FACILITY
CODE
CODE
TELEPHONE NUMBER
17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN
OFFER
18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK
BELOW IS CHECKED
REQUEST
FOR QUOTE
(RFQ)
INVITATION
FOR BID
(IFB)
REQUEST
FOR
PROPOSAL
(RFP)
SEE ADDENDUM
19.
ITEM NUMBER
20.
SCHEDULE OF SUPPLIES/SERVICES
21.
QUANTITY
22.
UNIT
23.
UNIT PRICE
24.
AMOUNT
(Use Reverse and/or Attach Additional Sheets as Necessary)
25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)
28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN
COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH
AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND
ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS
SPECIFIED
29. AWARD OF CONTRACT: REFERENCE OFFER
DATED . . YOUR OFFER ON SOLICITATION
(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE
SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:
30a. SIGNATURE OF OFFEROR/CONTRACTOR
30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED
31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)
31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED
AUTHORIZED FOR LOCAL REPRODUCTION
PREVIOUS EDITION IS NOT USABLE
STANDARD FORM 1449 (REV. 11/2021)
Prescribed by GSA - FAR (48 CFR) 53.212
10. THIS ACQUISITION IS UNRESTRICTED OR
NORTH AMERICAN
INDUSTRY CLASSIFICATION
STANDARD (NAICS):
SIZE STANDARD:
13a. THIS CONTRACT IS A
RATED ORDER UNDER
THE DEFENSE PRIORITIES
AND ALLOCATIONS
SYSTEM - DPAS (15 CFR 700)
SET ASIDE: % FOR:
11. DELIVERY FOR FREE ON
BOARD (FOB) DESTINATION
UNLESS BLOCK IS MARKED
SEE SCHEDULE
12. DISCOUNT TERMS
ARE ARE NOT ATTACHED
ARE ARE NOT ATTACHED
27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3
AND 52.212-5 ARE ATTACHED. ADDENDA
27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA
8(A)
ECONOMICALLY
DISADVANTAGED
WOMEN-OWNED SMALL
BUSINESS (EDWOSB)
SERVICE-DISABLED
VETERAN-OWNED
SMALL BUSINESS
(SDVOSB)
HUBZONE SMALL
BUSINESS
SMALL BUSINESS
NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.
calls)
Continuation of Supplies or Services and Prices/Costs
Additional Information/Notes
Item Supplies/Service Quantity Unit Unit Price
Amount
0001 MAINTENANCE THE CONTRACTOR
SHALL PROVIDE ALL LABOR,
MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE ON ALL FIRE
EXTINGUSIHERS IN ACCORDANCE
WITH PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
0001AA 10lb ABC 6 YEAR MAINTENANCE
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM SIX (6)
YEAR MAINTENANCE IN
ACCORDANCE WITH PARAGRAPH
5.6 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
350 Lot
0001AB 20lb ABC 6 YEAR MAINTENANCE
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM SIX (6)
YEAR MAINTENANCE IN
ACCORDANCE WITH PARAGRAPH
5.9 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0001AC FE36 6 YEAR MAINTENANCE THE
CONTRACTOR SHALL PROVIDE ALL
5 Lot
W911N226QA0010001
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPH 5.23 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
0001AD Class D 6 Year Maintenance THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPH 5.25 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
10 Lot
0002 HYDROSTATIC TESTING THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM HYDROSTATIC TESTING
ON ALL FIRE EXTINGUSIHERS IN
ACCORDANCE WITH
PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
0002AA 10lb ABC HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.5 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1
110 Lot
Pricing Arrangement: Firm Fixed Price
0002AB 20lb ABC HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.8 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0002AC 15lb Co2 HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.11 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0002AD 5lb Co2 HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.13 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0002AE Pressurized Water HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
5 Lot
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.15 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
0002AF WET CHEMICAL HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.16 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0002AG WATER MIST HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.18 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0002AH CLASS D HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.20 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1
10 Lot
0002AJ FE36 HYDROSTATIC TESTING THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM HYDROSTATIC TESTING
IN ACCORDANCE WITH
PARAGRAPH 5.22 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0003 RECHARGE THE CONTRACTOR
SHALL PROVIDE ALL LABOR,
MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM THE RECHARGE YEAR
MAINTENANCE ON ALL FIRE
EXTINGUSIHERS IN ACCORDANCE
WITH PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
0003AA 10lb ABC RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.7 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
25 Lot
0003AB 20lb ABC RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
5 Lot
ACCORDANCE WITH PARAGRAPH
5.10 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
0003AC 15lb CO2 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.12 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0003AD 5lb CO2 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.14 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0003AE CLASS D RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.21 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
10 Lot
0003AF FE36 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
20 Lot
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.24 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
0003AG WATER MIST RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.19 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0003AH WET CHEMICAL RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.17 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
0004 PARTS PROVIDE ALL MATERIAL
AND PARTS TO PERFORM
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPHS 5.3 OF THE
PERFORMANCE WORK
STATEMENT. **ALL PARTS WILL BE
BILLED AS ACTUALS. CLIN PRICE
SET BY THE GOVERNMENT**
CONTRACTOR ACQUIRED:
ORIGINAL PAID INVOICES MUST BE
FURNISHED TO BILL UNDER THIS
CLIN AT COST. THE COR SHALL
1 Lot
APPROVE ALL PARTS COSTING
MORE THAN FIFTY DOLLARS ($50)
EACH THAT ARE PARTS REQUIRED
BY SERVICES PERFORMED UNDER
PARAGRAPH 5.5 THROUGH 5.25.
Claimant Program Code: S1 Pricing Arrangement: Time and Materials
Option Line Item
MAINTENANCE THE CONTRACTOR
SHALL PROVIDE ALL LABOR,
MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE ON ALL FIRE
EXTINGUSIHERS IN ACCORDANCE
WITH PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
Option Line Item
1001AA
10lb ABC 6 YEAR MAINTENANCE
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM SIX (6)
YEAR MAINTENANCE IN
ACCORDANCE WITH PARAGRAPH
5.6 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
175 Lot
Option Line Item
1001AB
20lb ABC 6 YEAR MAINTENANCE
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM SIX (6)
YEAR MAINTENANCE IN
ACCORDANCE WITH PARAGRAPH
5.9 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1001AC
FE36 6 YEAR MAINTENANCE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPH 5.23 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1001AD
Class D 6 Year Maintenance THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPH 5.25 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
HYDROSTATIC TESTING THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM HYDROSTATIC TESTING
ON ALL FIRE EXTINGUSIHERS IN
ACCORDANCE WITH
PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
Option Line Item
1002AA
10lb ABC HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
200 Lot
5.5 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
1002AB
20lb ABC HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.8 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1002AC
15lb Co2 HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.11 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1002AD
5lb Co2 HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.13 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Item
1002AE
Pressurized Water HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.15 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1002AF
WET CHEMICAL HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.16 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1002AG
WATER MIST HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.18 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1002AH
CLASS D HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
5 Lot
5.20 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
1002AJ
FE36 HYDROSTATIC TESTING THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM HYDROSTATIC TESTING
IN ACCORDANCE WITH
PARAGRAPH 5.22 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
RECHARGE THE CONTRACTOR
SHALL PROVIDE ALL LABOR,
MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM THE RECHARGE YEAR
MAINTENANCE ON ALL FIRE
EXTINGUSIHERS IN ACCORDANCE
WITH PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
Option Line Item
1003AA
10lb ABC RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.7 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
20 Lot
Option Line Item
20lb ABC RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
5 Lot
1003AB SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.10 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
1003AC
15lb CO2 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.12 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1003AD
5lb CO2 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.14 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1003AE
CLASS D RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.21 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option 20 Lot
Item
1003AF
FE36 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.24 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
1003AG
WATER MIST RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.19 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
1003AH
WET CHEMICAL RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.17 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
PARTS PROVIDE ALL MATERIAL
AND PARTS TO PERFORM
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPHS 5.3 OF THE
PERFORMANCE WORK
STATEMENT. **ALL PARTS WILL BE
BILLED AS ACTUALS. CLIN PRICE
SET BY THE GOVERNMENT**
CONTRACTOR ACQUIRED:
1 Lot
ORIGINAL PAID INVOICES MUST BE
FURNISHED TO BILL UNDER THIS
CLIN AT COST. THE COR SHALL
APPROVE ALL PARTS COSTING
MORE THAN FIFTY DOLLARS ($50)
EACH THAT ARE PARTS REQUIRED
BY SERVICES PERFORMED UNDER
PARAGRAPH 5.5 THROUGH 5.25.
Claimant Program Code: S1 Pricing Arrangement: Time and Materials
Option Line Item
MAINTENANCE THE CONTRACTOR
SHALL PROVIDE ALL LABOR,
MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE ON ALL FIRE
EXTINGUSIHERS IN ACCORDANCE
WITH PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
Option Line Item
2001AA
10lb ABC 6 YEAR MAINTENANCE
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM SIX (6)
YEAR MAINTENANCE IN
ACCORDANCE WITH PARAGRAPH
5.6 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
120 Lot
Option Line Item
2001AB
20lb ABC 6 YEAR MAINTENANCE
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM SIX (6)
YEAR MAINTENANCE IN
5 Lot
5.9 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
2001AC
FE36 6 YEAR MAINTENANCE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPH 5.23 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2001AD
Class D 6 Year Maintenance THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM SIX (6) YEAR
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPH 5.25 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
HYDROSTATIC TESTING THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM HYDROSTATIC TESTING
ON ALL FIRE EXTINGUSIHERS IN
ACCORDANCE WITH
PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
Option Line
10lb ABC HYDROSTATIC TESTING
THE CONTRACTOR SHALL
100 Lot
2002AA
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.5 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
2002AB
20lb ABC HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.8 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2002AC
15lb Co2 HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.11 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2002AD
5lb Co2 HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
5 Lot
5.13 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
2002AE
Pressurized Water HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.15 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2002AF
WET CHEMICAL HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.16 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2002AG
WATER MIST HYDROSTATIC
TESTING THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.18 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Item
2002AH
CLASS D HYDROSTATIC TESTING
THE CONTRACTOR SHALL
PROVIDE ALL LABOR, MATERIAL,
PARTS, TOOLS, SERVICES AND
EQUIPMENT TO PERFORM
HYDROSTATIC TESTING IN
ACCORDANCE WITH PARAGRAPH
5.20 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2002AJ
FE36 HYDROSTATIC TESTING THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM HYDROSTATIC TESTING
IN ACCORDANCE WITH
PARAGRAPH 5.22 OF THE
PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
RECHARGE THE CONTRACTOR
SHALL PROVIDE ALL LABOR,
MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM THE RECHARGE YEAR
MAINTENANCE ON ALL FIRE
EXTINGUSIHERS IN ACCORDANCE
WITH PERFORMANCE WORK
STATEMENT AND PER NFPA 10.
Option Line Item
2003AA
10lb ABC RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.7 OF THE PERFORMANCE WORK
STATEMENT.
20 Lot
Claimant Program Code: S1
Option Line Item
2003AB
20lb ABC RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.10 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2003AC
15lb CO2 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.12 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2003AD
5lb CO2 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.14 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2003AE
CLASS D RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5 Lot
5.21 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
2003AF
FE36 RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.24 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
20 Lot
Option Line Item
2003AG
WATER MIST RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.19 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
2003AH
WET CHEMICAL RECHARGE THE
CONTRACTOR SHALL PROVIDE ALL
LABOR, MATERIAL, PARTS, TOOLS,
SERVICES AND EQUIPMENT TO
PERFORM RECHARGE IN
ACCORDANCE WITH PARAGRAPH
5.17 OF THE PERFORMANCE WORK
STATEMENT.
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
5 Lot
Option Line Item
PARTS PROVIDE ALL MATERIAL
AND PARTS TO PERFORM
MAINTENANCE IN ACCORDANCE
WITH PARAGRAPHS 5.3 OF THE
1 Lot
PERFORMANCE WORK
STATEMENT. **ALL PARTS WILL BE
BILLED AS ACTUALS. CLIN PRICE
SET BY THE GOVERNMENT**
CONTRACTOR ACQUIRED:
ORIGINAL PAID INVOICES MUST BE
FURNISHED TO BILL UNDER THIS
CLIN AT COST. THE COR SHALL
APPROVE ALL PARTS COSTING
MORE THAN FIFTY DOLLARS ($50)
EACH THAT ARE PARTS REQUIRED
BY SERVICES PERFORMED UNDER
PARAGRAPH 5.5 THROUGH 5.25.
Claimant Program Code: S1 Pricing Arrangement: Time and Materials
Continuation of Description
Requirements Non-personnel, equipment, tools, materials, supervision, quality control, facilities, and non-personal services necessary to perform hydrostatic testing, maintenance, and recharge of fire extinguishers for Letterkenny Army Depot.
0001AA
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0001AB
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0001AC
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0001AD
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AA
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AB
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AC
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AD
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AE
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AF
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AG
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AH
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0002AJ
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0003AA
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0003AB
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0003AC
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0003AD
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0003AE
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0003AF
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
0003AG
North American Industry Classification System (NAICS) : 811310
0003AH
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1001AA Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1001AB Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1001AC Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1001AD Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AA Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AB Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AC Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AD Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AE
North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AF Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AG Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AH Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1002AJ Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1003AA Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1003AB Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1003AC Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1003AD Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1003AE Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1003AF
Option Line Item 1003AG Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1003AH Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 1004 Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2001AA Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2001AB Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2001AC Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2001AD Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AA Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AB Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AC Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AD
North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AE Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AF Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AG Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AH Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2002AJ Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2003AA Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2003AB Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2003AC Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2003AD Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2003AE
Option Line Item 2003AF Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2003AG Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2003AH Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Option Line Item 2004 Product Service Code : J012 North American Industry Classification System (NAICS) : 811310
Continuation of Inspection and Acceptance
Overall Contract Inspection/Acceptance Locations
0001AA Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF CountryCode: USA
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0001AB Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0001AC Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0001AD Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AA Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AB Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AC Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AD Inspection and Acceptance Location
Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AE Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AF Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AG Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AH Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0002AJ Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AA Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AB Inspection and Acceptance Location
Both Destination
Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AC Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AD Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AE Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AF Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AG Inspection and Acceptance Location
Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0003AH Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
0004 Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance in accordance with the Performance Work Statement.
DoDAAC: W800AF
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1001AA
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1001AB
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Telephone: 717-267-4024
Option Line Item
1001AC
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1001AD
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
Inspection and Acceptance Location
Both Destination
1002AA Instructions: Inspection and Acceptance is in accordance with Performance Work
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1002AB
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1002AC
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1002AD
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1002AE
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Inspection and Acceptance Location
1002AF
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1002AG
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1002AH
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1002AJ
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1003AA
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Telephone: 717-267-4024
Option Line Item
1003AB
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1003AC
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
Inspection and Acceptance Location
Both Destination
1003AD Instructions: Inspection and Acceptance is in accordance with Performance Work
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1003AE
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1003AF
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1003AG
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
1003AH
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance in accordance with the Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2001AA
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2001AB
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2001AC
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2001AD
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Telephone: 717-267-4024
Option Line Item
2002AA
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2002AB
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
Inspection and Acceptance Location
Both Destination
2002AC Instructions: Inspection and Acceptance is in accordance with Performance Work
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2002AD
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2002AE
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
Email: samuel.r.myers3.civ@army.mil Telephone: 717-267-4024
Option Line Item
2002AF
Inspection and Acceptance Location
Both Destination Instructions: Inspection and Acceptance is in accordance with Performance Work Statement.
DoDAAC: W800AF
W0L6 USA DEP LETTERKENY
LETTERKENNY ARMY DEPOT, 1 OVERCASH AVENUE BLDG 9950
CHAMBERSBURG, PA 17201-4150
UNITED STATES
Samuel Myers Email: samuel.r.myers3.civ@army.mil Telephone:…
This is the start of the file's text. The full file is on GovTribe.
File details come from the government source that posted it. Updated .