AM_04.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Amendment #03 provides the follow ing changes to the RFP:

a. Proposal due date is extended to 29 March 2018 at 2:00 PM

b. SCR-GE020 is deleted

c. Wage Rate Determination is updated

d. Bidder Inquiry Report is added.

e. Revised drawings C-102 and C-701 provided.

1. CONTRACT ID CODE PAGE OF PAGES

1 29

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 26-Mar-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W911KB18R0011

X 9B. DATED (SEE ITEM 11)

22-Feb-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

26-Mar-2018

CODE

U.S. ARMY ENGINEER DISTRICT, AK

CEPOA-CT (W911KB)

PO BOX 6898

JBER AK 99506-0898

W911KB 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911KB18R0011

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 11 00 - STANDARD FORM (SF) 1442

The required response date/time has changed from 22-Mar-2018 02:00 PM to 29-Mar-2018 02:00 PM.

SECTION 00 73 00 - SPECIAL CONTRACT REQUIREMENTS

The following have been modified:

SCRS

SECTION 00 73 00.00 29

SPECIAL CONTRACT REQUIREMENTS

4/12/2013

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

1.2 GENERAL SCR'S

1.2.1 SCR-GE010 Insurance - Work On A Government Installation:

In accordance with SECTION 00 72 00, 52.228-5, the Contractor shall, at its own expense, provide and maintain during the entire performance of this contract, at least the following kinds and minimum amounts of insurance:

1. Workman's Compensation and Employers' Liability Insurance:

$100,000.00.

2. General Liability Insurance: A Bodily Injury, Comprehensive policy which provides $500,000.00 per occurrence.

3. Automobile Liability Insurance: A comprehensive policy which provides $200,000.00 per person and $500,000.00 per occurrence for bodily injury and $20,000.00 per occurrence for property damage, covering the operation of its automobiles used in connection with the performance of the contract.

4. Aircraft Public and Passenger Liability Insurance: Where aircraft are used in connection with the performance of the contract; $200,000.00 per person, $500,000.00 per occurrence for bodily injury, other than passenger liability, and $200,000.00 per occurrence for property damage; $200,000.00 per person for passenger liability bodily injury aggregate equal to the total number of seats or number of passengers, whichever is greater.

5. Vessel Collision Liability and Protection and Indemnity Liability Insurance: Where vessels are used in connection with the performance of the contract.

AM#04…

1.2.2 SCR-GE020 Supplemental Price Breakdown Information:

After contract award, the Government will require the Contractor to provide a cost breakdown of each facility by square foot (square meter), including major building systems to the five-foot (1.5 meter) line, for programming validation purposes. There will be no separate payment for this information and the Contractor shall include it in the contract price. The Government will provide a format with the directive....AM#04

1.2.3 SCR-GE030 Certificates Of Compliance And Lab Test Report:

SEE SECTION 01 33 00: SUBMITTAL PROCEDURES. Any certificates required for demonstrating proof of compliance of materials with specification requirements shall be executed in 3 copies. Each certificate shall be signed by an official authorized to certify in behalf of the manufacturing company and shall contain the name and address of the Contractor, the project name and location, and the quantity and date or dates of shipment or delivery to which the certificates apply. Copies of laboratory test reports submitted with certificates shall contain the name and address of the testing laboratory and the date or dates of the tests to which the report applies. Certification shall not be construed as relieving the Contractor from furnishing satisfactory material, if, after tests are performed on selected samples, the material is found not to meet the specific requirements.

1.2.4 SCR-GE040 Self Performance Of Work By The Contractor:

A. The following describes the applicable clause or requirement for self-performance of work by the Contractor, depending upon the type of solicitation (e.g., unrestricted or full or partial set-aside) and/or whether or not a price evaluation preference was provided for in the source selection evaluation.

B. Contract clause 52.236-1, PERFORMANCE OF WORK BY THE CONTRACTOR, is applicable to unrestricted procurement contract awards to any business except as explained in paragraphs C. and E., below.

C. In lieu of the above clause, contract clause 52.219-4, NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS CONCERNS is applicable for award to a HUBZone small business concern on an unrestricted solicitation when the awardee is a HUBZone small business concern or joint venture and claimed a price evaluation preference in accordance with the clause. For purposes of this clause, "cost of the contract" includes all direct and indirect costs, excluding profit or fees. "Cost of contract performance incurred for personnel" means direct labor costs and any overhead which has only direct labor as its base, plus the concern's general and administrative overhead rate multiplied by the labor cost.

D. Contract clause 52.219-3 NOTICE OF TOTAL HUBZONE SET-ASIDE is applicable to awards made under a partial or total HubZone set-aside. For purposes of this clause, "cost of the contract" includes all direct and indirect costs, excluding profit or fees. "Cost of contract performance incurred for personnel" means direct labor costs and any overhead which has only direct labor as its base, plus the concern's general and administrative overhead rate multiplied by the labor cost.

E. Contract Clause 52.219-14, LIMITATIONS ON SUBCONTRACTING, is the applicable requirement for awards to small business concerns for solicitations that were fully or partially set-aside for Small Business, 8(a), or award to a small disadvantaged business (SDB) concern on an unrestricted procurement where an SDB concern has claimed a price evaluation preference (but see next paragraph for suspension of the SDB price preference).

1.2.5 SCR-GE050 Coordination With Other Contractors:

Contracts may be executed on sites with multiple contractors. Minimize interference and inconvenience through cooperation with other authorized contractors. See Contract Clause 52.236-8, OTHER CONTRACTS.

1.2.6 SCR-GE060 Qualifications Of The Contractor Quality Control Systems Manager (CQCSM):

(a) The CQC System Manager (CQCSM) described in SECTION 01 45 04.00 29 CONTRACTOR QUALITY CONTROL shall be assigned no other duties.

(b) In lieu of the education and experience requirements for the CQC System Manager listed in the CQC SECTION 01 45 04.00 29 CONTRACTOR QUALITY CONTROL, a candidate may qualify provided they have a minimum of 7 years experience in construction quality control and are International Code Council (ICC) certified as a Commercial Building Inspector. For Military Family Housing projects, ICC Residential Building Inspector certification is required in lieu of the Commercial Building Inspector certification.

1.2.7 SCR-GE070 Requirements For Contractors Performance Evaluation:

The Government will evaluate the contractor's performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), a web-based system (https://www.cpars.gov/). After an evaluation (interim or final) is generated by the Government, the contractor will have the ability to access, review and comment on the evaluation for a period of 30 days. If the Contractor fails to review, and or comment on the evaluation within the 30-day period, the Contracting Officer will take the appropriate steps to finalize the evaluation without the contractor's comments. It is the sole responsibility of the Contractor to purchase any necessary software to access the electronic system, including a Public Key Infrastructure (PKI) certificate. Contractors are encouraged to obtain and use the Public Key Infrastructure (PKI) certificate. Details and information to access the system are listed below. The contractor shall provide the Contacting Officer the primary contact name and email address in order to receive the initial email and to access the system. Additional information and training material is available at https://www.cpars.gov/.

This web site will give the contractor an understanding of the system and levels of access, the policies and regulations governing CPARS and the electronic workflow with particular attention to the Contractor comment function. Contractor users are required to obtain a PKI certificate in order to log into CPARS. PKI certificates can be purchased from DoD's industries partners under External Certificate Authorities (ECAs). A list of ECAs vendors is available at http https://www.cpars.gov/main/pki_info.htm.

1.2.8 SCR-GE080 Additional Requirements For Railroad Protection:

Work under this contract involves construction operations on or adjacent to the right-of-way of an operating railroad. The Contractor shall comply with the following requirements in performing work under this contract and, unless specifically provided for elsewhere in this contract, no separate payment or extension of time will be made for meeting these requirements and all costs in connection therewith and payment therefore shall be considered incidental to and included in the contract price or prices:

1. The Contractor shall execute an agreement on the form hereinafter set forth (Exhibit "A") with the Railroad Company named therein for the protection of the property and facilities of the Railroad Company and for indemnification for any loss, damage, and injuries that may occur during performance of the contract work. At least 4 days before commencing any work adjacent to or on the railroad right-of-way, the Contractor shall submit to the Contracting Officer for approval a signed copy of this agreement together with a copy of the insurance policy or policies required therein, with evidence of a commitment by the insurers to notify the Railroad Company and the Contracting Officer in writing of any change, expiration or cancellation of the insurance not less than 30 days before such change, expiration or cancellation is effective.

2. The safe and uninterrupted operation of the Railroad shall take precedence over all contract work, and nothing shall be done or suffered to be done by the Contractor, its agents or employees, which will endanger or delay such operation. The Contractor shall comply with the rules and regulations of the Railroad Company in relation to the protection of persons and property and shall consult with the Chief Engineer of the Railroad Company, or his authorized representative, in regard thereto. Such services and material of whatever kind and nature required by the Contractor's operations to provide the necessary protective measures, referred to above, will be furnished at the Contractor's expense by the Railroad Company at prevailing rates and charges.

3. The Contractor shall coordinate his/her work with the Alaska Rail Road, provide approved warning devices, and obtain permits as necessary. Flagmen and proper safety devices are required while working on an active Railroad Line. See attachments for additional permit and standards required by Alaska railroad (Attachments: Alaska Rail Road Work Permit Application and Alaska Rail Road Standard Specifications).

4. Should ARRC bill the Government directly for any work accomplished under this contract, the Government will forward the invoice to the contractor for payment. Should the contractor fail to pay the invoice, the Government will deduct the amount of the outstanding invoice from the Contract amount.

1.2.9 SCR-GE102 Contractor Supply and Use of Electronic Software for Processing DAVIS-BACON ACT Certified Labor Payrolls (April 2011):

The contractor is encouraged to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Davis-Bacon Act as stated in FAR 52.222-8, PAYROLLS AND BASIC RECORDS and FAR 52.222-13, COMPLIANCE WITH

DAVIS-BACON AND RELATED ACT REGULATIONS.

If the contractor elects to use an electronic Davis-Bacon payroll processing system, then the contractor shall be responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the contractor to comply with Davis-Bacon and related Act regulations. When the contractor uses an electronic Davis-Bacon payroll system, the electronic payroll service shall be used by the contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract and the electronic payroll service shall be capable of preserving these payrolls and related basic records for the required 3 years after contract completion. If the contractor chooses to use an electronic Davis-Bacon payroll system, then the contractor shall obtain and provide electronic system access to the Government, as required to comply with the Davis-Bacon and related Act regulations over the duration of this construction contract. The access shall include electronic review access by the Government contract administration office to the electronic payroll processing system used by the contractor.

The contractor's provision and use of an electronic payroll processing system shall meet the following basic functional criteria: commercially available; compliant with appropriate Davis Bacon Act payroll provisions in the FAR; able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract; capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records (format at http://www.rmssupport.com/guides.aspx) for export in an Excel spreadsheet to be imported into the contractor's Quality Control System (QCS) version of Resident Management System (RMS), that in turn shall export payroll data to the Government's Resident Management System (RMS);

demonstrated security of data and data entry rights; ability to produce contractor-certified electronic versions of weekly payroll data; ability to identify erroneous entries and track the data/time of all versions of the certified Davis Bacon payrolls submitted to the government over the life of the contract; capable of generating a durable record copy, that is, a CD or DVD and PDF file record of data from the system database at end of the contract closeout. This durable record copy of data from the electronic Davis-Bacon payroll processing system shall be provided to the Government during contract closeout.

All contractor-incurred costs related to the contractor's provision and use of an electronic payroll processing service shall be included in the contractor's price for the overall work under the contract. The costs for

Davis-Bacon Act compliance using electronic payroll processing services shall not be a separately bid/proposed or reimbursed item under this contract.

1.2.10 SCR-GE103 Contractor Manpower Reporting

The contractor shall report ALL contractor labor hours (including subcontractor labor hours) required for performance of services provided under this contract for the Department of the Army via a secure data collection site. The contractor is required to completely fill in all required data fields using the following web address: http://www.ecmra.mil/.

Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year of contract/task order performance. Contractors may direct questions to the help desk at help desk at: http://www.ecmra.mil/ to review user manuals and gain an understanding about the data fields that will be included in the reporting structure that is hosted at http://www.ecmra.mil/.

1.2.11 SCR-GE104 Veterans Employment Emphasis for USACE Contracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veterans Affairs-VOW to Hire Heros Act http://benefits.va.gov/vow/ Army Wounded Warrior Program -http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation-Hiring Our Heros http://www.hiringourheroes.org/ Guide to Hiring Veterans - Reference Material http://www.whitehouse.gov/sites/default/files/docs/white_house_business_coun cil_-_guide_to_hiring_veterans_0.pdf

1.2.12 SCR-GE110 Simplified Scheduling Requirements - Small Projects

Schedule Preparation

The contractor shall develop a construction schedule in accordance with FAR 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS. The construction schedule shall be submitted, reviewed and approved by the Contracting Officer or designated representative prior to the start of any construction activities.

The schedule shall be in bar chart format and include activities that correspond with the pay activities listed in the QCS data base. Non pay activities sufficient to clearly describe the efforts needed to execute the work will also be included in the schedule. A narrative describing the work items shall be submitted with the schedule. As a minimum, the schedule shall include following items:

a. Notice to Proceed (NTP) date

b. Mobilization

c. Plan submittals/approvals

d. Work Activities

e. Pre-Final/Final Inspection

f. Demobilization

g. Construction Completion Date (CCD)

Schedule Updates

An updated schedule and narrative shall be provided as part of each pay request package. The bar chart shall be updated to graphically reflect the current progress of each item. The narrative shall be updated with the current status of the work; any changes, impacts or delays to the work; and other information as requested by the Contracting Officer. The schedule will also be discussed during weekly update meetings.

1.2.13 SCR-GE112 Equipment Ownership and Operating Expense Schedule (MAR 1995)

(a) This clause does not apply to terminations. See 52.249-9000, Basis for Settlement of Proposals, and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule, Region XI.

Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36, Rental Costs. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the SAT, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

1.2.14 SCR-GE113 Payment for Materials Delivered Off-Site

(a) Pursuant to FAR 52.232-5, Payments Under Fixed Price Construction Contracts, materials delivered to the contractor at locations other than the site of the work may be taken into consideration in making payments if included in payment estimates and if all the conditions of the General Provisions are fulfilled. Payment for items delivered to locations other than the work site shall be limited to:

(1) Materials required by the technical provisions; or

(2) Materials that have been fabricated to the point where they are identifiable to an item of work required under this contract; or

(3) Items specifically listed below.

Payment for materials delivered off-site shall be made only after receipt of paid invoices listing the value of material and labor incorporated in the items along with a canceled check showing the prime contractor's title to the items delivered off site. Payment for materials delivered off-site shall be limited to the following items: Items approved for payment by the Contracting Officer, or their representative.

1.2.15 SCR-GE114 Plant And Material Removal After Contract Termination

Should this contract be terminated as provided in clause 52.232-5001 because of the failure of Congress to provide additional funds for its completion, the contractor may be permitted to remove plant and material on which payments for preparatory work have been made, subject to an equitable deduction from the amounts due the contractor to reimburse the United States for the unabsorbed value of such plant and material.

1.2.16 SCR-GE115 Basis For Settlement Of Proposals

Actual costs will be used to determine equipment costs for a settlement proposal submitted on the total cost basis under FAR 49.206-2(b). In evaluating a terminations settlement proposal using the total cost basis, the following principles will be applied to determine allowable equipment costs:

(1) Actual costs for each piece of equipment, or groups of similar serial or series equipment, need not be available in the contractor's accounting records to determine total actual equipment costs.

(2) If equipment costs have been allocated to a contract using predetermined rates, those charges will be adjusted to actual costs.

(3) Recorded job costs adjusted for unallowable expenses will be used to determine equipment operating expenses.

(4) Ownership costs (depreciation) will be determined using the contractor's depreciation schedule (subject to the provisions of FAR 31.205-11).

(5) License, taxes, storage and insurance costs are normally recovered as an indirect expense and unless the contractor charges these costs directly to contracts, they will be recovered through the indirect expense rate.

1.2.17 SCR-GE117 Variations In Estimated Quantities, Subdivided Items

This variation in estimated quantities clause is applicable only to Items N0. 0002.

(a) Variation from the estimated quantity in the actual work performed under any second or subsequent sub-item or elimination of all work under such a second or subsequent sub-item will not be the basis for an adjustment in contract unit price.

(b) Where the actual quantity of work performed for Items No. 0002 is less than 85% of the quantity of the first sub-item listed under such item, the contractor will be paid at the contract unit price for that sub-item for the actual quantity of work performed and, in addition, an equitable adjustment shall be made in accordance with the clause FAR 52.211-18, Variation in Estimated Quantities.

(c) If the actual quantity of work performed under Items No. 0002 exceeds

115% or is less than 85% of the total estimated quantity of the sub-item under that item and/or if the quantity of the work performed under the second sub-item or any subsequent sub-item under Items No. 0002 exceeds 115% or is less than 85% of the estimated quantity of any such sub-item, and if such variation causes an increase or a decrease in the time required for performance of this contract the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, Variation in Estimated Quantities.

1.3 SAFETY/SITE/SECURITY SCR'S

1.3.1 SCR-SS010 Safety And Health Requirements Manual:

EM 385-1-1 and its changes are available at http://www.usace.army.mil/CESO/Pages/Home.aspx. At the HQ homepage, select Safety and Occupational Health.

The Contractor shall be responsible for complying with the current edition and all changes posted on the web (see web address above) as of the effective date of this solicitation and shall comply with the version in effect on the contract award date. This EM 385-1-1 shall remain in effect throughout the life of the contract.

1.3.2 SCR-SS030 Communication Security:

All communications with DOD organizations are subject to COMSEC review.

Contractor personnel shall be aware that telecommunications networks are continually subject to intercept by unfriendly intelligence organizations.

The DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls originating from or terminating at DOD organizations. Therefore, civilian Contractor personnel are advised that any time they place a call to or receive a call from Alaska District offices or Resident Engineer offices located on military installations, they are subject to COMSEC procedures. The Contractor will assume the responsibility for ensuring wide and frequent dissemination of the above information to all employees dealing with official DOD information.

1.3.3 SCR-SS040 Haul Roads:

Whenever practical, one-way haul roads shall be used on this contract. Haul roads built and maintained for this work shall comply with the following:

1. One-way haul roads for off-the-road equipment; e.g., belly dumps, scrapers, and off-the-road trucks shall have a minimum usable width of 25 feet. One-way haul roads for over-the-road haulage equipment only (e.g., dump trucks, etc.) may be reduced to a usable width of 15 feet.

When the Contracting Officer determines that it is impractical to obtain the required width for one-way haul roads (e.g., a road on top of a levee), a usable width of not less than 10 feet may be approved by the Contracting Officer, provided a positive means of traffic control is implemented. Such positive means shall be signs, signals, and/or signalman and effective means of speed control.

2. Two-way haul roads for off-the-road haulage equipment shall have a usable width of 60 feet. Two-way haul-roads for over-the-road haulage equipment only may be reduced to a usable width of 30 feet.

3. Haul roads shall be graded and otherwise maintained to keep the surface free from potholes, ruts, and similar conditions that could result in unsafe operation.

4. Grades and curves shall allow a minimum sight distance of 200 feet for one-way roads and 300 feet for two-way roads. Sight distance is defined as the centerline distance an equipment operator (4.5 feet above the road surface) can see an object 4.5 feet above the road surface. When conditions make it impractical to obtain the required sight distance (e.g., ramp over levees), a positive means of traffic control shall be implemented.

5. Dust abatement shall permit observation of objects on the roadway at a minimum distance of 300 feet.

6. Haul roads shall have the edges of the usable portion marked with posts at intervals of 50 feet on curves and 200 feet maximum elsewhere. Such markers shall extend 6 feet above the road surface and, for nighttime haulage, be provided with reflectors in both directions.

1.3.4 SCR-SS050 Salvage Materials And Equipment (JAN 1965):

The Contractor shall maintain adequate property control records for all materials or equipment specified to be salvaged. These records may be in accordance with the Contractor's system of property control, if approved by the property administrator. The Contractor shall be responsible for the adequate storage and protection of all salvaged materials and equipment and shall replace, at no cost to the Government, all salvage materials and equipment which are broken or damaged during salvage operations as the result of its negligence, or while in its care.

1.3.5 SCR-SS060 Preservation Of Historical, Archaeological & Cultural Resources:

A. Known historical, archeological and cultural resources within the Contractor's work area are designated on the contract drawings. The Contractor shall install protection for these resources as shown on the drawings and shall be responsible for their preservation during the contract.

B. If, during construction activities, the Contractor observes items that might have historical or archeological value, such observations shall be reported immediately to the Contracting Officer so that the appropriate authorities may be notified and a determination can be made as to their significance and what, if any, special disposition of the finds should be made. The Contractor shall cease all activities that may result in the destruction of these resources and shall prevent its employees from trespassing on, removing, or otherwise damaging such resources.

1.3.6 SCR-SS070 Time Extensions For Unusually Severe Weather (ER 415-1-15, 31 OCT 89):

A. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Contract Clause entitled "DEFAULT (FIXED PRICE CONSTRUCTION)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

1. The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location during any given month.

2. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

B. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather Delay Work Days Based on a 5-Day Work Week

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

22 20 21 2 0 4 5 0 0 10 21

C. Upon acknowledgement of the Notice to Proceed and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and the resultant impact to normally scheduled work. Actual adverse weather delays days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday.

The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather days exceeds the number of days anticipated in Paragraph B, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather workdays, and issue a modification in accordance with the Contract Clause entitled "DEFAULT

(FIXED-PRICE CONSTRUCTION)".

1.3.7 SCR-SS080 Electrical Conformance Inspection

Provisions shall be made by the contractor for Government inspection of those parts to be energized of all service equipment, transformers, switchboards, panel boards, non-power limited industrial control panels, and motor control centers. Inspections shall be performed after electrical construction is complete, before equipment is energized, and prior to final inspection. However, if special circumstances require parts to be inspected while energized, the contractor shall provide exposure of, and safe and controlled access to, the live parts.

The Government shall be notified not less than 24 hours in advance of the scheduled inspection date. The Government inspector will be an electrician or electrical engineer qualified (as defined in NFPA 70E) to perform this type of work. Deficiencies found during the inspection shall be documented and corrected, and, at the Government's discretion, re-inspected under the provisions of this paragraph.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Document --

SECTION 00 73 46 - WAGE DETERMINATIONS SCHEDULES

The following have been modified:

WAGE DETERMINATION

General Decision Number: AK180001 02/09/2018 AK1

Superseded General Decision Number: AK20170001

State: Alaska

Construction Types: Building and Heavy

Counties: Alaska Statewide.

BUILDING AND HEAVY CONSTRUCTION PROJECTS (does not include residential construction consisting of single family homes and apartments up to and including 4 stories)

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.35 for calendar year 2018 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.35 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2018. The EO minimum wage rate will be adjusted annually.

Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/05/2018 1 01/12/2018 2 02/09/2018

ASBE0097-001 01/01/2017

Rates Fringes

Asbestos Workers/Insulator (includes application of all insulating materials protective coverings, coatings and finishings to all types of mechanical systems).........................$ 38.68 20.07

HAZARDOUS MATERIAL HANDLER

(includes preparation, wetting, stripping, removal scrapping, vacuming, bagging, and disposing of all insulation materials, whether they contain asbestos or not, from mechanical systems).........$ 37.38 19.55

BOIL0502-002 08/01/2016

Rates Fringes

BOILERMAKER......................$ 44.26 28.41

BRAK0001-002 07/01/2017

Rates Fringes

Bricklayer, Blocklayer, Stonemason, Marble Mason, Tile Setter, Terrazzo Worker.....$ 40.81 19.19 Tile & Terrazzo Finisher.........$ 34.79 19.19

CARP1501-001 09/01/2016

Rates Fringes

MILLWRIGHT.......................$ 36.74 22.99

CARP2520-003 09/01/2016

Rates Fringes

Diver Stand-by....................$ 42.65 25.04 Tender......................$ 41.65 25.04 Working.....................$ 82.45 25.04 Piledriver Carpenter...................$ 38.34 25.04 Piledriver; Skiff Operator and Rigger..................$ 38.34 25.04 Sheet Stabber...............$ 38.34 25.04 Welder......................$ 43.90 25.04

DEPTH PAY PREMIUM FOR DIVERS BELOW WATER SURFACE:

50-100 feet $1.00 per foot 101 feet and deeper $2.00 per foot

ENCLOSURE PAY PREMIUM WITH NO VERTICAL ASCENT:

5-50 FEET $1.00 PER FOOT/DAY

51-100 FEET $2.00 PER FOOT/DAY

101 FEET AND ABOVE $3.00 PER FOOT/DAY

SATURATION DIVING:

The standby rate applies until saturation starts. The saturation diving rate applies when divers are under pressure continuously until work task and decompression are complete. the diver rate shall be paid for all saturation hours.

WORK IN COMBINATION OF CLASSIFICATIONS:

Employees working in any combination of classifications within the diving crew (except dive supervisor) in a shift are paid in the classification with the highest rate for that shift.

CARP4059-001 09/01/2016

Rates Fringes

CARPENTER

Carpenter...................$ 38.34 25.04 Lather/Drywall Applicator...$ 36.59 22.59

ELEC1547-004 04/01/2017

Rates Fringes

CABLE SPLICER....................$ 39.82 3%+25.44

ELECTRICIAN......................$ 39.49 3%+25.69

ELEC1547-005 04/01/2017

Line Construction

Rates Fringes

CABLE SPLICER....................$ 52.57 3%+30.81

Linemen (Including Equipment Operators, Technician)...........$ 50.52 3%+30.81 Powderman........................$ 48.52 3%+30.81

TREE TRIMMER.....................$ 35.84 3%+23.56

ELEV0019-002 01/01/2018

Rates Fringes

ELEVATOR MECHANIC................$ 55.45 32.645+a+b

FOOTNOTE: a. Employer contributes 8% of the basic hourly rate for over 5 year's service and 6% of the basic hourly rate for 6 months to 5 years' of service as vacation paid credit. b. Eight paid holidays:

New Year's Day; Memorial Day; Independence Day;

Labor Day; Veteran's Day; Thanksgiving Day; Friday after Thanksgiving, and Christmas Day

ENGI0302-002 01/01/2017

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 40.28 22.65

GROUP 1A....................$ 42.04 22.65

GROUP 2.....................$ 39.51 22.65

GROUP 3.....................$ 38.79 22.65

GROUP 4.....................$ 32.58 22.65

TUNNEL WORK

GROUP 1....................$ 44.31 22.65

GROUP 1A...................$ 46.24 22.65

GROUP 2....................$ 43.46 22.65

GROUP 3....................$ 42.67 22.65

GROUP 4....................$ 35.84 22.65

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Asphalt Roller: Breakdown, Intermediate, and Finish; Back Filler; Barrier Machine (Zipper); Beltcrete with power pack and similar conveyors; Bending Machine;

Boat Coxwains; Bulldozers; Cableways, Highlines and Cablecars; Cleaning Machine; Coating Machine; Concrete Hydro Blaster; Cranes-45 tons and under or 150 foot boom and under (including jib and attachments): (a) Hydralifts or Transporters, all track or truck type,(b) Derricks;

Crushers; Deck Winches-Double Drum; Ditching or Trenching Machine (16 inch or over); Drilling Machines, core, cable, rotary and exploration; Finishing Machine Operator, Concrete Paving, Laser Screed, Sidewalk, Curb and Gutter Machine; Helicopters; Hover Craft, Flex Craft, Loadmaster, Air Cushion, All Terrain Vehicle, Rollagon, Bargecable, Nodwell, and Snow Cat; Hydro Ax: Feller Buncher and similar; Loaders (2 1/2 yards through 5 yards, including all attachments): Forklifts with telescopic boom and swing attachment, Overhead and front end, 2 1/2 yards through 5 yards, Loaders with forks or pipe clamps; Loaders, elevating belt type, Euclid and similar types; Mechanics, Bodyman; Micro Tunneling Machine; Mixers: Mobile type w/hoist combination; Motor Patrol Grader; Mucking Machines:

Mole, Tunnel Drill, Horizontal/Directional Drill Operator, and/or Shield; Operator on Dredges; Piledriver Engineers, L. B. Foster, Puller or similar Paving Breaker; Power Plant, Turbine Operator, 200 k.w. and over (power plants or combination of power units over 300 k.w.); Scrapers-through 40 yards; Service Oiler/Service Engineer; Sidebooms-under 45 tons; Shot Blast Machine; Shovels, Backhoes, Excavators with all attachments, and Gradealls (3 yards and under), Spreaders, Blaw Knox, Cedarapids, Barber Greene, Slurry Machine; Sub-grader (Gurries, Reclaimer, and similar types); Tack tractor; Truck mounted Concrete Pumps, Conveyor, Creter; Water Kote Machine; Unlicensed off road hauler

GROUP 1A: Camera/Tool/Video Operator (Slipline), Cranes-over 45 tons or 150 foot (including jib and attachments): (a) Clamshells and Draglines (over 3 yards),

(b) Tower cranes; Licensed Water/Waste Water Treatment Operator; Loaders over 5 yds.; Certified Welder, Electrical Mechanic, Camp Maintenance Engineer, Mechanic (over 10,000 hours); Motor Patrol Grader, Dozer, Grade Tractor, Roto-mill/Profiler (finish: when finishing to final grade and/or to hubs, or for asphalt); Power Plants: 1000 k.w.

and over; Quad; Screed; Shovels, Backhoes, Excavators with all attachments (over 3 yards), Sidebooms over 45 tons;

Slip Form Paver, C.M.I. and similar types; Scrapers over 40 yards;

GROUP 2: Boiler-fireman; Cement Hog and Concrete Pump Operator; Conveyors (except as listed in group 1); Hoist on steel erection; Towermobiles and Air Tuggers;

Horizontal/Directional Drill Locator;Licensed Grade Technician; Loaders, (i.e., Elevating Grader and Material Transfer Vehicle); Locomotives: rod and geared engines;

Mixers; Screening, Washing Plant; Sideboom (cradling rock drill regardless of size); Skidder; Trencing Machine under 16 inches; Waste/ Waste Water Treatment Operator.

GROUP 3: "A" Frame Trucks, Deck Winches: single power drum;

Bombardier (tack or tow rig); Boring Machine; Brooms-power;

Bump Cutter; Compressor; Farm tractor; Forklift, industrial type; Gin Truck or Winch Truck with poles when used for hoisting; Grade Checker and Stake Hopper; Hoist, Air Tuggers, Elevators; Loaders: (a) Elevating-Athey, Barber Green and similar types (b) Forklifts or Lumber Carrier (on construction job site) (c) Forklifts with Tower (d) Overhead and Front-end, under 2 1/2 yds. Locomotives:Dinkey (air, steam, gas and electric) Speeders; Mechanics (light duty); Oil, Blower Distribution; Post Hole Diggers, mechanical; Pot Fireman (power agitated); Power Plant, Turbine Operator, under 200 k.w.; Pumps-water; Roller-other than Plantmix; Saws, concrete; Skid Steer with all attachments; Straightening Machine; Tow Tractor

GROUP 4: Rig Oiler/Crane Assistant Engineer;Parts and Equipment Coordinator; Swamper (on trenching machines or shovel type equipment); Spotter; Steam Cleaner; Drill Helper.

FOOTNOTE: Groups 1-4 receive 10% premium while performing tunnel or underground work. Rig Oiler/Crane Assistant Engineer shall be required on cranes over 85 tons or over 100 feet of boom.

IRON0751-003 07/01/2017

Rates Fringes

Ironworkers:

BRIDGE, STRUCTURAL,

ORNAMENTAL, REINFORCING

MACHINERY MOVER, RIGGER,

SHEETER, STAGE RIGGER,

BENDER OPERATOR.............$ 37.25 30.43

FENCE, BARRIER INSTALLER....$ 33.75 30.08

GUARDRAIL INSTALLERS........$ 34.75 30.08

GUARDRAIL LAYOUT MAN........$ 34.49 30.08

HELICOPTER, TOWER...........$ 38.25 30.43

LABO0341-005 04/01/2017

Rates Fringes

Laborers: South of the 63rd Parallel & West of Longitude 138 Degrees

GROUP 1.....................$ 30.55 26.72

GROUP 2.....................$ 31.55 26.72

GROUP 3.....................$ 32.45 26.72

GROUP 3A....................$ 35.73 26.72

GROUP 3B....................$ 39.27 24.01

GROUP 4.....................$ 20.12 26.72

TUNNELS, SHAFTS, AND RAISES

GROUP 1....................$ 33.61 26.72

GROUP 2....................$ 34.71 26.72

GROUP 3....................$ 35.70 26.72

GROUP 3A...................$ 39.30 26.72

GROUP 3B...................$ 43.20 24.01

LABORERS CLASSIFICATIONS

GROUP 1: Asphalt Workers (shovelman, plant crew); Brush Cutters; Camp Maintenance Laborer; Carpenter Tenders; Choke Setters, Hook Tender, Rigger, Signalman; Concrete Laborer(curb and gutter, chute handler, grouting, curing, screeding); Crusher Plant Laborer; Demolition Laborer;

Ditch Diggers; Dump Man; Environmental Laborer (asbestos (limited to nonmechanical systems), hazardous and toxic waste, oil spill); Fence Installer; Fire Watch Laborer;

Flagman; Form Strippers; General Laborer; Guardrail Laborer, Bridge Rail Installers; Hydro-Seeder Nozzleman;

Laborers (building); Landscape or Planter; Laying of Decorative Block (retaining walls, flowered decorative block 4 feet and below); Material Handlers; Pneumatic or Power Tools; Portable or Chemical Toilet Serviceman; Pump Man or Mixer Man; Railroad Track Laborer; Sandblast, Pot Tender; Saw Tenders; Scaffold Building and Erecting; Slurry Work; Stake Hopper; Steam Point or Water Jet Operator;

Steam Cleaner Operator; Tank Cleaning; Utiliwalk, Utilidor Laborer and Conduit Installer; Watchman (construction projects); Window Cleaner

GROUP 2: Burning and Cutting Torch; Cement or Lime Dumper or Handler (sack or bulk); Choker Splicer; Chucktender (wagon, airtrack and hydraulic drills); Concrete Laborers (power buggy, concrete saws, pumpcrete nozzleman, vibratorman);

Culvert Pipe Laborer; Cured in place Pipelayer;

Environmental Laborer (marine work, oil spill skimmer operator, small boat operator); Foam Gun or Foam Machine Operator; Green Cutter (dam work); Gunnite Operator; Hod Carriers; Jackhammer or Pavement Breakers (more than 45 pounds);Laying of Decorative Block (retaining walls, flowered decorative block above 4 feet); Mason Tender and Mud Mixer (sewer work); Pilot Car; Plasterer, Bricklayer and Cement Finisher Tenders; Power Saw Operator; Railroad

Switch Layout Laborer; Sandblaster; Sewer Caulkers; Sewer Plant Maintenance Man; Thermal Plastic Applicator; Timber Faller, chain saw operator, filer; Timberman

GROUP 3: Alarm Installer; Bit Grinder; Guardrail Machine Operator; High Rigger and tree topper; High Scaler;

Multiplate; Slurry Seal Squeegee Man

GROUP 3A: Asphalt Raker, Asphalt Belly dump lay down; Drill Doctor (in the field); Drillers (including, but not limited to, wagon drills, air track drills; hydraulic drills);

Powderman; Pioneer Drilling and Drilling Off Tugger (all type drills); Pipelayers

GROUP 3B: Grade checker (setting or transfering of grade marks, line and grade)

GROUP 4: Final Building Cleanup

TUNNELS, SHAFTS, AND RAISES CLASSIFICATIONS

GROUP 1: Brakeman; Muckers; Nippers; Topman and Bull Gang;

Tunnel Track Laborer

GROUP 2: Burning and Cutting Torch; Concrete Laborers;

Jackhammers; Nozzleman, Pumpcrete or Shotcrete.

GROUP 3: Miner; Retimberman

GROUP 3A: Asphalt Raker, Asphalt Belly dump lay down; Drill Doctor (in the field); Drillers (including, but not limited to, wagon drills, air track drills; hydraulic drills);

Powderman; Pioneer Drilling and Drilling Off Tugger (all type drills); Pipelayers.

GROUP 3B: Grade checker (setting or transfering of grade marks, line and grade)

Tunnel shaft and raise rates only apply to workers regularly employed inside a tunnel portal or shaft collar.

* LABO0942-001 04/01/2017

Rates Fringes

Laborers: North of…