FINAL_ATMP_RFP_W900KK-17-R-0034.pdf

CODE

(Hour)

PAGE(S)

until 01:00 PM local time 22 Dec 2016

X

A

X B

X C X D

EX

X

G

F 164 - 179

180 - 195

X H 196 - 202 megan.d.weidner.civ@mail.mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

1 202

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

W900KK 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 2 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and

12211 Science Dr, Orlando, FL conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

MEGAN WEIDNER 407 208-3260

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

1 - 2

3 - 65

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

67 - 69

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

70 - 73

74 - 89 X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 90 - 98 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 99 - 119 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

120 - 160

PART II - CO NTRACT CLAUSES

ARMY CONTRACTING COMMAND - ORLANDO

ATTN: DELTA DIVISION

12211 SCIENCE DRIVE

ORLANDO FL 32826-3224

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

161 - 163

6. REQUISITION/PURCHASE NO.5. DATE ISSUED

09 Nov 2016

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

W900KK-17-R-0034

Section A - Solicitation/Contract Form

The Army Training Aids, Devices, Simulations and Simulators (TADSS) Maintenance Program (ATMP) will result in a Single Award (SA) Indefinite-Delivery/Indefinite Quantity (ID/IQ) contract with a one year ordering period and six, one year options. In addition to the basic ID/IQ contract, the Government initially intends to award 28 Task

Orders (TOs) following award of the basic Contract. Additional task orders may be contemplated during contract performance. For a list of the TOs see ATMP Master TO List identified in Section J. TO 0001 will be awarded immediately following the basic award to accomplish Phase-In tasks (approximately six months), whereas the remaining TO’s will be awarded prior to full performance.

Contract Not-To-Exceed Ceiling amount is $3,531,926,800. The minimum amount and contract value for all orders issued against this contract shall not be less than the minimum amount stated in the following table. The maximum amount and contract value for all orders issued against this contract shall not exceed the maximum amount and contract value stated in the following table. The cumulative total of all task orders awarded will not exceed

$3,531,926,800 during contract performance, base and option periods, without prior written approval from the

Procuring Contracting Officer (PCO).

MINIMUM QUANTITY MINIMUM AMOUNT MAXIMUM QUANTITY MAXIMUM AMOUNT

N/A $1,000,000 N/A $3,531,926,800

The majority of this contract will be performed as Firm Fixed Price (FFP). Additional contract types that will be utilized include: Cost (no fee) for travel, Cost Plus Fixed Fee (CPFF) and Time and Materials (T&M). Fixed Price

Incentive Firm Target (FPIF) or Cost Plus Incentive Fee (CPIF) contract types may be utilized in special circumstances (e.g. Newly Fielded TADSS).

Each future TO and/or Contract Line Item Number (CLIN) will be reviewed by the PCO to determine the applicable contract type to meet those requirements.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Months ATMP Reserved Year 1

FFP

Army TADSS Maintenance Program (ATMP) performance in accordance with the

Basic Performance Work Statement, as further specified by separate task orders issued under this contract.

FOB: Destination

NET AMT

0002 1 Lot Reserved Year 1- CMR

FFP

Contractor Manpower Reporting

0003 1 Months Reserved- Year 1 LABOR

FFP

0004 1 Months Reserved- Year 1 MATERIAL

0005 1 Months Reserved- Year 1 ODC

0006 Lot

Reserved- Year 1 LABOR

FPI

TARGET COST

TARGET PROFIT

TOTAL TARGET PRICE

CEILING PRICE

SHARE RATIO ABOVE TARGET

SHARE RATIO BELOW TARGET

0007 Lot

Reserved- Year 1 MATERIAL

TOTAL TARGET PRICE

CEILING PRICE

0008 Lot

Reserved- Year 1 ODC

TOTAL TARGET PRICE

CEILING PRICE

0009 Lot Reserved- Year 1 LABOR

CPIF

TARGET FEE

TOTAL TGT COST + FEE

MINIMUM FEE

MAXIMUM FEE

0010 Lot Reserved- Year 1 MATERIAL

0011 Lot Reserved- Year 1 ODC

0012 Lot Reserved- Year 1 LABOR

CPFF

ESTIMATED COST

FIXED FEE

TOTAL EST COST + FEE

0013 Lot Reserved- Year 1 MATERIAL

0014 Lot Reserved- Year 1 ODC

0015 Lot Reserved- Year 1 LABOR

T&M

TOT ESTIMATED PRICE

CEILING PRICE

0016 Lot Reserved- Year 1 MATERIAL

0017 Lot Reserved- Year 1 ODC

0018 Lot Reserved- Year 1 TRAVEL

COST

0019 1 Months Reserved- Year 1

0020 1 Months Reserved- Year 1

0021 1 Months Reserved- Year 1

0022 1 Months Reserved- Year 1

0023 1 Months Reserved- Year 1

0024 1 Months Reserved- Year 1

1001 1 Months OPTION ATMP Reserved Year 2

FFP

This CLIN is established for Year 2 of the Army TADSS Maintenance Program

(ATMP) in accordance with the Basic Performance Work Statement, as further specified by separate task orders issued under this contract.

1002 1 Lot OPTION Reserved Year 2- CMR

FFP

1003 1 Months OPTION Reserved- Year 2 LABOR

1004 1 Months OPTION Reserved- Year 2 MATERIAL

1005 1 Months OPTION Reserved- Year 2 ODC

1006 Lot

OPTION Reserved- Year 2 LABOR

TOTAL TARGET PRICE

CEILING PRICE

1007 Lot

OPTION Reserved- Year 2 MATERIAL

TOTAL TARGET PRICE

CEILING PRICE

1008 Lot

OPTION Reserved- Year 2 ODC

TOTAL TARGET PRICE

CEILING PRICE

1009 Lot OPTION Reserved- Year 2 LABOR

1010 Lot OPTION Reserved- Year 2 MATERIAL

1011 Lot OPTION Reserved- Year 2 ODC

1012 Lot OPTION Reserved- Year 2 LABOR

1013 Lot OPTION Reserved- Year 2 MATERIAL

1014 Lot OPTION Reserved- Year 2 ODC

1015 Lot OPTION Reserved- Year 2 LABOR

1016 Lot OPTION Reserved- Year 2 MATERIAL

1017 Lot OPTION Reserved- Year 2 ODC

1018 Lot OPTION Reserved- Year 2 TRAVEL

1019 1 Months OPTION Reserved- Year 2

1020 1 Months OPTION Reserved- Year 2

1021 1 Months OPTION Reserved- Year 2

1022 1 Months OPTION Reserved- Year 2

1023 1 Months OPTION Reserved- Year 2

1024 1 Months OPTION Reserved- Year 2

2001 1 Months OPTION ATMP Reserved Year 3

FFP

This CLIN is established for Year 3 of the Army TADSS Maintenance Program

(ATMP) in accordance with the Basic Performance Work Statement, as further

2002 1 Lot OPTION Reserved Year 3- CMR

FFP

2003 1 Months OPTION Reserved- Year 3 LABOR

2004 1 Months OPTION Reserved- Year 3 MATERIAL

2005 1 Months OPTION Reserved- Year 3 ODC

2006 Lot

OPTION Reserved- Year 3 LABOR

TOTAL TARGET PRICE

CEILING PRICE

2007 Lot

OPTION Reserved- Year 3 MATERIAL

TOTAL TARGET PRICE

CEILING PRICE

2008 Lot

OPTION Reserved- Year 3 ODC

TOTAL TARGET PRICE

CEILING PRICE

2009 Lot OPTION Reserved- Year 3 LABOR

2010 Lot OPTION Reserved- Year 3 MATERIAL

2011 Lot OPTION Reserved- Year 3 ODC

2012 Lot OPTION Reserved- Year 3 LABOR

2013 Lot OPTION Reserved- Year 3 MATERIAL

2014 Lot OPTION Reserved- Year 3 ODC

2015 Lot OPTION Reserved- Year 3 LABOR

2016 Lot OPTION Reserved- Year 3 MATERIAL

2017 Lot OPTION Reserved- Year 3 ODC

2018 Lot OPTION Reserved- Year 3 TRAVEL

2019 1 Months OPTION Reserved- Year 3

2020 1 Months OPTION Reserved- Year 3

2021 1 Months OPTION Reserved- Year 3

2022 1 Months OPTION Reserved- Year 3

2023 1 Months OPTION Reserved- Year 3

2024 1 Months OPTION Reserved- Year 3

3001 1 Months OPTION ATMP Reserved Year 4

FFP

This CLIN is established for Year 4 of the Army TADSS Maintenance Program

(ATMP) in accordance with the Basic Performance Work Statement, as further

3002 1 Lot OPTION Reserved Year 4- CMR

FFP

3003 1 Months OPTION Reserved- Year 4 LABOR

3004 1 Months OPTION Reserved- Year 4 MATERIAL

3005 1 Months OPTION Reserved- Year 4 ODC

3006 Lot

OPTION Reserved- Year 4 LABOR

TOTAL TARGET PRICE

CEILING PRICE

3007 Lot

OPTION Reserved- Year 4 MATERIAL

TOTAL TARGET PRICE

CEILING PRICE

3008 Lot

OPTION Reserved- Year 4 ODC

TOTAL TARGET PRICE

CEILING PRICE

3009 Lot OPTION Reserved- Year 4 LABOR

3010 Lot OPTION Reserved- Year 4 MATERIAL

3011 Lot OPTION Reserved- Year 4 ODC

3012 Lot OPTION Reserved- Year 4 LABOR

3013 Lot OPTION Reserved- Year 4 MATERIAL

3014 Lot OPTION Reserved- Year 4 ODC

3015 Lot OPTION Reserved- Year 4 LABOR

3016 Lot OPTION Reserved- Year 4 MATERIAL

3017 Lot OPTION Reserved- Year 4 ODC

3018 Lot OPTION Reserved- Year 4 TRAVEL

3019 1 Months OPTION Reserved- Year 4

3020 1 Months OPTION Reserved- Year 4

3021 1 Months OPTION Reserved- Year 4

3022 1 Months OPTION Reserved- Year 4

3023 1 Months OPTION Reserved- Year 4

3024 1 Months OPTION Reserved- Year 4

4001 1 Months OPTION ATMP Reserved Year 5

FFP

This CLIN is established for Year 5 of the Army TADSS Maintenance Program

(ATMP) in accordance with the Basic Performance Work Statement, as further

4002 1 Lot OPTION Reserved Year 5- CMR

FFP

4003 1 Months OPTION Reserved- Year 5 LABOR

4004 1 Months OPTION Reserved- Year 5 MATERIAL

4005 1 Months OPTION Reserved- Year 5 ODC

4006 Lot

OPTION Reserved- Year 5 LABOR

TOTAL TARGET PRICE

CEILING PRICE

4007 Lot

OPTION Reserved- Year 5 MATERIAL

TOTAL TARGET PRICE

CEILING PRICE

4008 Lot

OPTION Reserved- Year 5 ODC

TOTAL TARGET PRICE

CEILING PRICE

4009 Lot OPTION Reserved- Year 5 LABOR

4010 Lot OPTION Reserved- Year 5 MATERIAL

4011 Lot OPTION Reserved- Year 5 ODC

4012 Lot OPTION Reserved- Year 5 LABOR

4013 Lot OPTION Reserved- Year 5 MATERIAL

4014 Lot OPTION Reserved- Year 5 ODC

4015 Lot OPTION Reserved- Year 5 LABOR

4016 Lot OPTION Reserved- Year 5 MATERIAL

4017 Lot OPTION Reserved- Year 5 ODC

4018 Lot OPTION Reserved- Year 5 TRAVEL

4019 1 Months OPTION Reserved- Year 5

4020 1 Months OPTION Reserved- Year 5

4021 1 Months OPTION Reserved- Year 5

4022 1 Months OPTION Reserved- Year 5

4023 1 Months OPTION Reserved- Year 5

4024 1 Months OPTION Reserved- Year 5

5001 1 Months OPTION ATMP Reserved Year 6

FFP

This CLIN is established for Year 6 of the Army TADSS Maintenance Program

(ATMP) in accordance with the Basic Performance Work Statement, as further

5002 1 Lot OPTION Reserved Year 6- CMR

FFP

5003 1 Months OPTION Reserved- Year 6 LABOR

5004 1 Months OPTION Reserved- Year 6 MATERIAL

5005 1 Months OPTION Reserved- Year 6 ODC

5006 Lot

OPTION Reserved- Year 6 LABOR

TOTAL TARGET PRICE

CEILING PRICE

5007 Lot

OPTION Reserved- Year 6 MATERIAL

TOTAL TARGET PRICE

CEILING PRICE

5008 Lot

OPTION Reserved- Year 6 ODC

TOTAL TARGET PRICE

CEILING PRICE

5009 Lot OPTION Reserved- Year 6 LABOR

5010 Lot OPTION Reserved- Year 6 MATERIAL

5011 Lot OPTION Reserved- Year 6 ODC

5012 Lot OPTION Reserved- Year 6 LABOR

5013 Lot OPTION Reserved- Year 6 MATERIAL

5014 Lot OPTION Reserved- Year 6 ODC

5015 Lot OPTION Reserved- Year 6 LABOR

5016 Lot OPTION Reserved- Year 6 MATERIAL

5017 Lot OPTION Reserved- Year 6 ODC

5018 Lot OPTION Reserved- Year 6 TRAVEL

5019 1 Months OPTION Reserved- Year 6

5020 1 Months OPTION Reserved- Year 6

5021 1 Months OPTION Reserved- Year 6

5022 1 Months Reserved- Year 6

5023 1 Months OPTION Reserved- Year 6

5024 1 Months OPTION Reserved- Year 6

6001 1 Months OPTION ATMP Reserved Year 7

FFP

This CLIN is established for Year 7 of the Army TADSS Maintenance Program

(ATMP) in accordance with the Basic Performance Work Statement, as further

6002 1 Lot OPTION Reserved Year 7- CMR

FFP

6003 1 Months OPTION Reserved- Year 7 LABOR

6004 1 Months OPTION Reserved- Year 7 MATERIAL

6005 1 Months OPTION Reserved- Year 7 ODC

6006 Lot

OPTION Reserved- Year 7 LABOR

TOTAL TARGET PRICE

CEILING PRICE

6007 Lot

OPTION Reserved- Year 7 MATERIAL

TOTAL TARGET PRICE

CEILING PRICE

6008 Lot

OPTION Reserved- Year 7 ODC

TOTAL TARGET PRICE

CEILING PRICE

6009 Lot OPTION Reserved- Year 7 LABOR

6010 Lot OPTION Reserved- Year 7 MATERIAL

6011 Lot OPTION Reserved- Year 7 ODC

6012 Lot OPTION Reserved- Year 7 LABOR

6013 Lot OPTION Reserved- Year 7 MATERIAL

6014 Lot OPTION Reserved- Year 7 ODC

6015 Lot OPTION Reserved- Year 7 LABOR

6016 Lot OPTION Reserved- Year 7 MATERIAL

6017 Lot OPTION Reserved- Year 7 ODC

6018 Lot OPTION Reserved- Year 7 TRAVEL

6019 1 Months OPTION Reserved- Year 7

6020 1 Months OPTION Reserved- Year 7

6021 1 Months OPTION Reserved- Year 7

6022 1 Months OPTION Reserved- Year 7

6023 1 Months OPTION Reserved- Year 7

6024 1 Months OPTION Reserved- Year 7

B.1 The CLINs established in this section are provided for the sole purpose of facilitating administration of the

Contract in the Governments’ Standard Procurement System (SPS). The Section B CLINs are not to be priced.

B.2 The Government has provided a CLIN Pricing Workbook in Section J of this solicitation for Offerors to price the CLINs within each Task Order, for each year. The awardees’ proposed CLIN Pricing Workbook is binding and will be incorporated into Section J of the resultant contract. See H.5 Awarding Task Orders for additional information on Task Order awards.

Section C - Descriptions and Specifications

The Contractor shall furnish the necessary supplies/services, facilities and materials required to perform the work described in this solicitation, the Base and Task Order Performance Work Statements (PWSs) and all associated attachments/exhibits referenced in Section J of this solicitation.

Section D - Packaging and Marking

CLAUSES INCORPORATED BY FULL TEXT

5152.247-5001 MARKING OF WARRANTED ITEMS (ACC-ORL) (JUN 2015)

(a) Each item covered by a warranty shall be stamped or marked in accordance with MIL-STD-129 (and changes thereto), Marking for Shipment and Storage, and MIL-STD-130, Identification Marking of U.S. Military Property, current at the date of award. Where this is impracticable, written notice shall be attached to or furnished with the warranted item.

(b) Each item covered by a warranty shall have a written notice attached to or furnished with the warranted item, and marked with the following:

(1) National stock number or manufacturer’s part number.

(2) Serial number or other item identifier (if the warranty applies to uniquely identified items).

(3) Contract number.

(4) Indication that a warranty applies.

(5) Manufacturer or entity (if other than the contractor) providing the warranty.

(6) Date or time when the warranty expires.

(7) Indication of whether or not attempted on-site repair by Government personnel will void the warranty.

(End of Clause)

5152.247-5004 PACKAGING AND MARKING OF REPORTS (ACC-ORL) (JUN 2015)

(a) All unclassified data shall be prepared for shipment in accordance with best commercial practice. Classified reports, data and documentation, if any, shall be prepared for shipment in accordance with the National Industry

Security Program Operating Manual, DoD 5220.22-M.

(b) The contractor shall prominently display on the cover of each report the following information:

(1) Name and business address of contractor.

(2) Contract Number/Delivery/Task order number.

(3) Contract/Delivery/Task order dollar amount.

(4) Whether the contract was competitively or non-competitively awarded.

(5) Name of sponsoring individual.

(6) Name and address of requiring activity.

5152.247-5006 PRESERVATION, PACKAGING, PACKING AND MARKING (ACC-ORL) (JUN 2015)

(a) Preservation, packaging and packing shall conform to prevailing industry standards for the type of commodity purchased under this contract.

(b) All packages will be clearly marked with applicable contract number/delivery order number, and will contain appropriate packing slip. All deliveries will be marked for and/or consigned as follows:

[TBD at the individual task order level]

(c) In the event of any discrepancy in material shipped (overage, technical rejection, damage), the contractor shall, immediately upon request of the Contracting Officer, furnish disposition instructions. Normally, such disposition instruction shall be a properly completed Commercial Bill of Lading, which includes, but is not limited to, the mode of shipment, routing, special handling, and so forth.

(d) If the contractor is required to install equipment upon delivery, then the contractor shall inform the

Government of the date of shipment from the contractor’s facilities and the anticipated date of arrival at the site.

This report shall be made no later than the actual date that the shipment is made from the contractor’s facilities. The report may be made by facsimile or e-mail, to the point of contact listed in Section G. All transportation, rigging, drayage, packing, unpacking, and handling necessary to accomplish the installation shall be the responsibility of the contractor.

5152.247-5007 PRESERVATION, PACKAGING, PACKING AND MARKING FOR FOREIGN MILITARY

SALES (FMS) REQUIREMENTS (ACC-ORL) (JUN 2015)

(a) Unless specified elsewhere in the contract, packing and packaging shall comply with MIL-STD-129 (and changes thereto) and other applicable DoD regulations. Packing and packaging materials shall provide protection from abuse during handling and from environmental, magnetic, and electrical damage during handling and subsequent future storage, possibly under less than desirable conditions.

(b) Marking: All unit and exterior containers/packs shall as a minimum be marked as follows:

(1) FMS Case Number.

(2) Part Number (with CAGE Code).

(3) For - the organization/address the material is shipped to.

(4) The applicable MILSTRIP number (identified separately for each line item of the contract/delivery order)

(5) Project Code number.

(6) Project Directive Line Item (PDLI) Number.

(7) Requisition Serial Number (RSN).

(8) Quantity.

(9) From - the contractor’s address shipped from.

(10) Ship to - the shipping address provided in the contract.

(11) Transportation Priority

(12) Required Delivery Date

(c) The contractor shall affix labels to the outside of each external pack warning all handlers that fragile, delicate, etc., equipment is contained within and to warn against particular improper handling and storage procedures/conditions as may be applicable to the item(s) ordered.

5152.247-5012 PACKAGING REQUIREMENTS FOR SHIPMENTS CONTAINING NON-MANUFACTURED

WOOD PACKING MATERIALS (ACC-ORL) (JUN 2015)

All non-manufactured, wooden pallets, reels, or containers shipped or used for shipment under this contract shall be heat treated and marked in accordance with the American Lumber Standards Committee, Incorporated Non-

Manufactured Wood Packing Policy and Non-Manufactured Wood Packing Enforcement Regulations, both dated 30

May 2001.

5152.247-5013 PRESERVATION, PACKAGING, AND PACKING (ACC-ORL) (JUN 2015)

(a) The contractor shall preserve, pack and package items procured for system stock, overseas destinations or ships at sea, in accordance with the MIL-STD-2073-1 Level A requirements delineated in the schedule or elsewhere in the contract or order. If specific requirements are not included in the contract or order, the contractor shall preserve and package in accordance with previously approved level A requirements, within the technical parameters contained in MIL-STD-2073-1. Preservation and packing materials shall be fire retardant/non-combustible as prescribed in the specific packaging requirements in the contract or order, and to the maximum extent practicable.

(b) If the packaging materials specified in the contract or order are not fire retardant, and fire retardant varieties are included in commodity specifications for these materials, the contractor shall use fire retardant varieties. Fire retardant packaging materials are not required for items not used aboard ship. The use of plastic packaging materials is prohibited unless prescribed in specific packaging requirements in the contract or order, or unless required to adequately protect the item from damage

(c) For items procured for installation/immediate use, the contractor shall preserve and package in accordance with the Level C requirements of MIL-STD-2073-1. Packing for shipment (i.e., shipping container) shall be in accordance with MIL-STD-2073-1, Level A, for overseas surface shipments that are not containerized and all deliveries to ships at sea; Level B for all remaining overseas shipments; Level C or domestic shipments of items consumed at first destination. Fire retardant materials are not required in packing (i.e., shipping container) operations. All units, intermediate and shipping containers, shall be marked in accordance with MIL-STD-129. The use of shredded paper, excelsior, polystyrene and other loose-fill materials as a cushion is prohibited in all packaging and packing operation

(d) In accordance with 29 CFR, the contractor shall ensure that the following caution label is placed on all unit, intermediate and shipping containers for all items containing asbestos in a form that can be inhaled:

CAUTION

CONTAINS ASBESTOS FIBERS

AVOID CREATING DUST

BREATHING ASBESTOS DUST MAY CAUSE SERIOUS BODILY HARM

(e) All items containing asbestos in a form that can be inhaled shall be packaged in sealed, impermeable bags or other impermeable containers, as required by 29 CFR.

NOTE TO SUPPLIERS: If the supplies to be furnished on this document require the asbestos caution label described above, the contractor shall notify the contract administrator indicated in the schedule prior to shipment.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

0007 Destination Government Destination Government

0008 Destination Government Destination Government

0009 Destination Government Destination Government

0010 Destination Government Destination Government

0011 Destination Government Destination Government

0012 Destination Government Destination Government

0013 Destination Government Destination Government

0014 Destination Government Destination Government

0015 Destination Government Destination Government

0016 Destination Government Destination Government

0017 Destination Government Destination Government

0018 Destination Government Destination Government

0019 Destination Government Destination Government

0020 Destination Government Destination Government

0021 Destination Government Destination Government

0022 Destination Government Destination Government

0023 Destination Government Destination Government

0024 Destination Government Destination Government

1001 Destination Government Destination Government

1002 Destination Government Destination Government

1003 Destination Government Destination Government

1004 Destination Government Destination Government

1005 Destination Government Destination Government

1006 Destination Government Destination Government

1007 Destination Government Destination Government

1008 Destination Government Destination Government

1009 Destination Government Destination Government

1010 Destination Government Destination Government

1011 Destination Government Destination Government

1012 Destination Government Destination Government

1013 Destination Government Destination Government

1014 Destination Government Destination Government

1015 Destination Government Destination Government

1016 Destination Government Destination Government

1017 Destination Government Destination Government

1018 Destination Government Destination Government

1019 Destination Government Destination Government

1020 Destination Government Destination Government

1021 Destination Government Destination Government

1022 Destination Government Destination Government

1023 Destination Government Destination Government

1024 Destination Government Destination Government

2001 Destination Government Destination Government

2002 Destination Government Destination Government

2003 Destination Government Destination Government

2004 Destination Government Destination Government

2005 Destination Government Destination Government

2006 Destination Government Destination Government

2007 Destination Government Destination Government

2008 Destination Government Destination Government

2009 Destination Government Destination Government

2010 Destination Government Destination Government

2011 Destination Government Destination Government

2012 Destination Government Destination Government

2013 Destination Government Destination Government

2014 Destination Government Destination Government

2015 Destination Government Destination Government

2016 Destination Government Destination Government

2017 Destination Government Destination Government

2018 Destination Government Destination Government

2019 Destination Government Destination Government

2020 Destination Government Destination Government

2021 Destination Government Destination Government

2022 Destination Government Destination Government

2023 Destination Government Destination Government

2024 Destination Government Destination Government

3001 Destination Government Destination Government

3002 Destination Government Destination Government

3003 Destination Government Destination Government

3004 Destination Government Destination Government

3005 Destination Government Destination Government

3006 Destination Government Destination Government

3007 Destination Government Destination Government

3008 Destination Government Destination Government

3009 Destination Government Destination Government

3010 Destination Government Destination Government

3011 Destination Government Destination Government

3012 Destination Government Destination Government

3013 Destination Government Destination Government

3014 Destination Government Destination Government

3015 Destination Government Destination Government

3016 Destination Government Destination Government

3017 Destination Government Destination Government

3018 Destination Government Destination Government

3019 Destination Government Destination Government

3020 Destination Government Destination Government

3021 Destination Government Destination Government

3022 Destination Government Destination Government

3023 Destination Government Destination Government

3024 Destination Government Destination Government

4001 Destination Government Destination Government

4002 Destination Government Destination Government

4003 Destination Government Destination Government

4004 Destination Government Destination Government

4005 Destination Government Destination Government

4006 Destination Government Destination Government

4007 Destination Government Destination Government

4008 Destination Government Destination Government

4009 Destination Government Destination Government

4010 Destination Government Destination Government

4011 Destination Government Destination Government

4012 Destination Government Destination Government

4013 Destination Government Destination Government

4014 Destination Government Destination Government

4015 Destination Government Destination Government

4016 Destination Government Destination Government

4017 Destination Government Destination Government

4018 Destination Government Destination Government

4019 Destination Government Destination Government

4020 Destination Government Destination Government

4021 Destination Government Destination Government

4022 Destination Government Destination Government

4023 Destination Government Destination Government

4024 Destination Government Destination Government

5001 Destination Government Destination Government

5002 Destination Government Destination Government

5003 Destination Government Destination Government

5004 Destination Government Destination Government

5005 Destination Government Destination Government

5006 Destination Government Destination Government

5007 Destination Government Destination Government

5008 Destination Government Destination Government

5009 Destination Government Destination Government

5010 Destination Government Destination Government

5011 Destination Government Destination Government

5012 Destination Government Destination Government

5013 Destination Government Destination Government

5014 Destination Government Destination Government

5015 Destination Government Destination Government

5016 Destination Government Destination Government

5017 Destination Government Destination Government

5018 Destination Government Destination Government

5019 Destination Government Destination Government

5020 Destination Government Destination Government

5021 Destination Government Destination Government

5022 Destination Government Destination Government

5023 Destination Government Destination Government

5024 Destination Government Destination Government

6001 Destination Government Destination Government

6002 Destination Government Destination Government

6003 Destination Government Destination Government

6004 Destination Government Destination Government

6005 Destination Government Destination Government

6006 Destination Government Destination Government

6007 Destination Government Destination Government

6008 Destination Government Destination Government

6009 Destination Government Destination Government

6010 Destination Government Destination Government

6011 Destination Government Destination Government

6012 Destination Government Destination Government

6013 Destination Government Destination Government

6014 Destination Government Destination Government

6015 Destination Government Destination Government

6016 Destination Government Destination Government

6017 Destination Government Destination Government

6018 Destination Government Destination Government

6019 Destination Government Destination Government

6020 Destination Government Destination Government

6021 Destination Government Destination Government

6022 Destination Government Destination Government

6023 Destination Government Destination Government

6024 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996

52.246-3 Inspection Of Supplies Cost-Reimbursement MAY 2001

52.246-4 Inspection Of Services--Fixed Price AUG 1996

52.246-6 Inspection--Time-And-Material And Labor-Hour MAY 2001

52.246-16 Responsibility For Supplies APR 1984

252.211-7003 Item Unique Identification and Valuation MAR 2016

252.246-7000 Material Inspection And Receiving Report MAR 2008

5152.246-5012 INSPECTION AND ACCEPTANCE (ACC-ORL) (JUN 2015)

(a) Inspection and acceptance of the supplies or services to be furnished hereunder shall be performed by the

Procuring Contracting Officer (PCO) or his duly authorized representative, TBD at the individual Task Order.

(b) Acceptance of all Contract Line Item Numbers/Sub Line Item Numbers (CLIN/SLIN) shall be made by the accepting authority through Wide Area Work Flow (WAWF) Acceptance will only occur when the accepting authority is sure that inspections performed demonstrate compliance with contract requirements.

Section F - Deliveries or Performance

(a) The contract shall commence on TBD and shall continue TBD. However, the period of performance may be extended in accordance with the option provisions contained herein.

(b) DFARS Clause 252.216-7006, “Ordering” has been incorporated into this contract, therefore, the period in which the Government can issue orders under the contract will be extended at the exercise of an option, and extended to the end of that option period.

The contract provides a one year ordering period and six, one year options for a total ordering period, inclusive of exercised options, of seven years from the date of the contract award. The ordering period will be specified in the

Ordering Clause DFARS 252.216.7006 at time of contract award.

Period Year CLINs Period of Performance

Basic

Period 1 Year 1 CLINs 0001-0024 Date/Month/Year through Date/Month/Year

Option

Period 2 Year 2 CLINs 1001-1024 Date/Month/Year through Date/Month/Year

Option

Period 3

Year 3

CLINs 2001-2024 Date/Month/Year through Date/Month/Year

Option

Period 4

Year 4

CLINs 3001-3024 Date/Month/Year through Date/Month/Year

Option

Period 5

Year 5

CLINs 4001-4024 Date/Month/Year through Date/Month/Year

Option

Period 6

Year 6

CLINs 5001-5024 Date/Month/Year through Date/Month/Year

Option

Period 7

Year 7

CLINs 6001-6024 Date/Month/Year through Date/Month/Year

(c) The delivery period will be specified in each Task Order and will not exceed 12 months.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

0004 N/A N/A N/A N/A

0005 N/A N/A N/A N/A

0006 N/A N/A N/A N/A

0007 N/A N/A N/A N/A

0008 N/A N/A N/A N/A

0009 N/A N/A N/A N/A

0010 N/A N/A N/A N/A

0011 N/A N/A N/A N/A

0012 N/A N/A N/A N/A

0013 N/A N/A N/A N/A

0014 N/A N/A N/A N/A

0015 N/A N/A N/A N/A

0016 N/A N/A N/A N/A

0017 N/A N/A N/A N/A

0018 N/A N/A N/A N/A

0019 N/A N/A N/A N/A

0020 N/A N/A N/A N/A

0021 N/A N/A N/A N/A

0022 N/A N/A N/A N/A

0023 N/A N/A N/A N/A

0024 N/A N/A N/A N/A

1001 N/A N/A N/A N/A

1002 N/A N/A N/A N/A

1003 N/A N/A N/A N/A

1004 N/A N/A N/A N/A

1005 N/A N/A N/A N/A

1006 N/A N/A N/A N/A

1007 N/A N/A N/A N/A

1008 N/A N/A N/A N/A

1009 N/A N/A N/A N/A

1010 N/A N/A N/A N/A

1011 N/A N/A N/A N/A

1012 N/A N/A N/A N/A

1013 N/A N/A N/A N/A

1014 N/A N/A N/A N/A

1015 N/A N/A N/A N/A

1016 N/A N/A N/A N/A

1017 N/A N/A N/A N/A

1018 N/A N/A N/A N/A

1019 N/A N/A N/A N/A

1020 N/A N/A N/A N/A

1021 N/A N/A N/A N/A

1022 N/A N/A N/A N/A

1023 N/A N/A N/A N/A

1024 N/A N/A N/A N/A

2001 N/A N/A N/A N/A

2002 N/A N/A N/A N/A

2003 N/A N/A N/A N/A

2004 N/A N/A N/A N/A

2005 N/A N/A N/A N/A

2006 N/A N/A N/A N/A

2007 N/A N/A N/A N/A

2008 N/A N/A N/A N/A

2009 N/A N/A N/A N/A

2010 N/A N/A N/A N/A

2011 N/A N/A N/A N/A

2012 N/A N/A N/A N/A

2013 N/A N/A N/A N/A

2014 N/A N/A N/A N/A

2015 N/A N/A N/A N/A

2016 N/A N/A N/A N/A

2017 N/A N/A N/A N/A

2018 N/A N/A N/A N/A

2019 N/A N/A N/A N/A

2020 N/A N/A N/A N/A

2021 N/A N/A N/A N/A

2022 N/A N/A N/A N/A

2023 N/A N/A N/A N/A

2024 N/A N/A N/A N/A

3001 N/A N/A N/A N/A

3002 N/A N/A N/A N/A

3003 N/A N/A N/A N/A

3004 N/A N/A N/A N/A

3005 N/A N/A N/A N/A

3006 N/A N/A N/A N/A

3007 N/A N/A N/A N/A

3008 N/A N/A N/A N/A

3009 N/A N/A N/A N/A

3010 N/A N/A N/A N/A

3011 N/A N/A N/A N/A

3012 N/A N/A N/A N/A

3013 N/A N/A N/A N/A

3014 N/A N/A N/A N/A

3015 N/A N/A N/A N/A

3016 N/A N/A N/A N/A

3017 N/A N/A N/A N/A

3018 N/A N/A N/A N/A

3019 N/A N/A N/A N/A

3020 N/A N/A N/A N/A

3021 N/A N/A N/A N/A

3022 N/A N/A N/A N/A

3023 N/A N/A N/A N/A

3024 N/A N/A N/A N/A

4001 N/A N/A N/A N/A

4002 N/A N/A N/A N/A

4003 N/A N/A N/A N/A

4004 N/A N/A N/A N/A

4005 N/A N/A N/A N/A

4006 N/A N/A N/A N/A

4007 N/A N/A N/A N/A

4008 N/A N/A N/A N/A

4009 N/A N/A N/A N/A

4010 N/A N/A N/A N/A

4011 N/A N/A N/A N/A

4012 N/A N/A N/A N/A

4013 N/A N/A N/A N/A

4014 N/A N/A N/A N/A

4015 N/A N/A N/A N/A

4016 N/A N/A N/A N/A

4017 N/A N/A N/A N/A

4018 N/A N/A N/A N/A

4019 N/A N/A N/A N/A

4020 N/A N/A N/A N/A

4021 N/A N/A N/A N/A

4022 N/A N/A N/A N/A

4023 N/A N/A N/A N/A

4024 N/A N/A N/A N/A

5001 N/A N/A N/A N/A

5002 N/A N/A N/A N/A

5003 N/A N/A N/A N/A

5004 N/A N/A N/A N/A

5005 N/A N/A N/A N/A

5006 N/A N/A N/A N/A

5007 N/A N/A N/A N/A

5008 N/A N/A N/A N/A

5009 N/A N/A N/A N/A

5010 N/A N/A N/A N/A

5011 N/A N/A N/A N/A

5012 N/A N/A N/A N/A

5013 N/A N/A N/A N/A

5014 N/A N/A N/A N/A

5015 N/A N/A N/A N/A

5016 N/A N/A N/A N/A

5017 N/A N/A N/A N/A

5018 N/A N/A N/A N/A

5019 N/A N/A N/A N/A

5020 N/A N/A N/A N/A

5021 N/A N/A N/A N/A

5022 N/A N/A N/A N/A

5023 N/A N/A N/A N/A

5024 N/A N/A N/A N/A

6001 N/A N/A N/A N/A

6002 N/A N/A N/A N/A

6003 N/A N/A N/A N/A

6004 N/A N/A N/A N/A

6005 N/A N/A N/A N/A

6006 N/A N/A N/A N/A

6007 N/A N/A N/A N/A

6008 N/A N/A N/A N/A

6009 N/A N/A N/A N/A

6010 N/A N/A N/A N/A

6011 N/A N/A N/A N/A

6012 N/A N/A N/A N/A

6013 N/A N/A N/A N/A

6014 N/A N/A N/A N/A

6015 N/A N/A N/A N/A

6016 N/A N/A N/A N/A

6017 N/A N/A N/A N/A

6018 N/A N/A N/A N/A

6019 N/A N/A N/A N/A

6020 N/A N/A N/A N/A

6021 N/A N/A N/A N/A

6022 N/A N/A N/A N/A

6023 N/A N/A N/A N/A

6024 N/A N/A N/A N/A

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Stop-Work Order AUG 1989

52.242-17 Government Delay Of Work APR 1984

52.247-29 F.O.B. Origin FEB 2006

52.247-34 F.O.B. Destination NOV 1991

252.211-7003 Item Unique Identification and Valuation MAR 2016

252.225-7041 Correspondence in English JUN 1997

252.225-7042 Authorization to Perform APR 2003

252.225-7043 Antiterrorism/Force Protection Policy for Defense

Contractors Outside the United States

JUN 2015

252.225-7994 ADDITIONAL ACCESS TO CONTRACTOR AND SUBCONTRACTOR RECORDS IN THE

UNITED STATES CENTRAL COMMAND THEATER OF OPERATIONS (DEVIATION 2015-O0013) (MAR

2015)

(a) In addition to any other existing examination-of-records authority, the Department of Defense is authorized to examine any records of the Contractor to the extent necessary to ensure that funds available under this contract are not—

(1) Subject to extortion or corruption; or

(2) Provided, directly or indirectly, to persons or entities that are actively supporting an insurgency or otherwise actively opposing United States or coalition forces in a contingency operation.

(b) The substance of this clause, including this paragraph (b), is required to be included in subcontracts under this contract that have an estimated value over $100,000.

(End of clause)

252.225-7995 CONTRACTOR PERSONNEL PERFORMING IN THE UNITED STATES CENTRAL COMMAND

AREA OF RESPONSIBILITY (DEVIATION 2015-O0009)(JAN 2015)

(a) Definitions. As used in this clause—

“Combatant Commander” means the Commander of the United States Central Command Area of Responsibility.

“Contractors authorized to accompany the Force,” or “CAAF,” means contractor personnel, including all tiers of subcontractor personnel, who are authorized to accompany U.S. Armed Forces in applicable operations and have been afforded CAAF status through a letter of authorization. CAAF generally include all U.S. citizen and third-country national employees not normally residing within the operational area whose area of performance is in the direct vicinity of U.S.

Armed Forces and who routinely are collocated with the U.S. Armed Forces (especially in non-permissive environments).

Personnel collocated with U.S. Armed Forces shall be afforded CAAF status through a letter of authorization. In some cases, Combatant Commander subordinate commanders may designate mission-essential host nation or local national contractor employees (e.g., interpreters) as CAAF. CAAF includes contractors previously identified as contractors deploying with the U.S. Armed Forces. CAAF status does not apply to contractor personnel in support of applicable operations within the boundaries and territories of the United States.

“Designated reception site” means the designated place for the reception, staging, integration, and onward movement of contractors deploying during a contingency. The designated reception site includes assigned joint reception centers and other Service or private reception sites.

“Law of war” means that part of international law that regulates the conduct of armed hostilities. The law of war encompasses all international law for the conduct of hostilities binding on the United States or its individual citizens, including treaties and international agreements to which the United States is a party, and applicable customary international law.

“Non-CAAF” means personnel who are not designated as CAAF, such as local national (LN) employees and non-

LN employees who are permanent residents in the operational area or third-country nationals not routinely residing with U.S. Armed Forces (and third-country national expatriates who are permanent residents in the operational area) who perform support functions away from the close proximity of, and do not reside with, U.S. Armed Forces.

Government-furnished support to non-CAAF is typically limited to force protection, emergency medical care, and basic human needs (e.g., bottled water, latrine facilities, security, and food when necessary) when performing their jobs in the direct vicinity of U.S. Armed Forces. Non-CAAF status does not apply to contractor personnel in support of applicable operations within the boundaries and territories of the United States.

“Subordinate joint force commander” means a sub-unified commander or joint task force commander.

(b) General.

(1) This clause applies to both CAAF and non-CAAF when performing in the United States Central Command

(USCENTCOM) Area of Responsibility (AOR)

(2) Contract performance in USCENTCOM AOR may require work in dangerous or austere conditions. Except as otherwise provided in the contract, the Contractor accepts the risks associated with required contract performance in such operations.

(3) When authorized in accordance with paragraph (j) of this clause to carry arms for personal protection, contractor personnel are only authorized to use force for individual self-defense.

(4) Unless immune from host nation jurisdiction by virtue of an international agreement or international law, inappropriate use of force by contractor personnel authorized to accompany the U.S. Armed Forces can subject such personnel to United

States or host nation prosecution and civil liability (see paragraphs (d) and (j)(3) of this clause).

(5) Service performed by contractor personnel subject to this clause is not active duty or service under 38 U.S.C. 106 note.

(c) Support.

(1)(i) The Combatant Commander will develop a security plan for protection of contractor personnel in locations where there is not sufficient or legitimate civil authority, when the Combatant Commander decides it is in the interests of the

Government to provide security because—

(A) The Contractor cannot obtain effective security services;

(B) Effective security services are unavailable at a reasonable cost; or

(C) Threat conditions necessitate security through military means.

(ii) In appropriate cases, the Combatant Commander may provide security through military means, commensurate with the level of security provided DoD civilians.

(2)(i) Generally, CAAF will be afforded emergency medical and dental care if injured while supporting applicable operations. Additionally, non-CAAF employees who are injured while in the vicinity of U. S. Armed Forces will normally receive emergency medical and dental care. Emergency medical and dental care includes medical care situations in which life, limb, or eyesight is jeopardized. Examples of emergency medical and dental care include examination and initial treatment of victims of sexual assault; refills of prescriptions for life-dependent drugs; repair of broken bones, lacerations, infections; and traumatic injuries to the dentition. Hospitalization will be limited to stabilization and short-term medical treatment with an emphasis on return to duty or placement in the patient movement system.

(ii) When the Government provides medical treatment or transportation of Contractor personnel to a selected civilian facility, the Contractor shall ensure that the Government is reimbursed for any costs associated with such treatment or transportation.

(iii) Medical or dental care beyond this standard is not authorized.

(3) Contractor personnel must have a Synchronized Predeployment and Operational Tracker (SPOT)-generated letter of authorization signed by the Contracting Officer in order to process through a deployment center or to travel to, from, or within the USCENTCOM AOR. The letter of authorization also will identify any additional authorizations, privileges, or

Government support that Contractor personnel are entitled to under this contract. Contractor personnel who are issued a letter of authorization shall carry it with them at all times while deployed.

(4) Unless specified elsewhere in this contract, the Contractor is responsible for all other support required for its personnel engaged in the USCENTCOM AOR under this contract.

(d) Compliance with laws and regulations.

(1) The Contractor shall comply with, and shall ensure that its personnel performing in the USCENTCOM AOR are familiar with and comply with, all applicable—

(i) United States, host country, and third country national laws;

(ii) Provisions of the law of war, as well as any other applicable treaties and international agreements;

(iii) United States regulations, directives, instructions, policies, and procedures; and

(iv) Orders, directives, and instructions issued by the Combatant Commander, including those relating to force protection, security, health, safety, or relations and interaction with local nationals.

(2) The Contractor shall institute and implement an effective program to prevent violations of the law of war by its employees and subcontractors, including law of war training in accordance with paragraph (e)(1)(vii) of this clause.

(3) The Contractor shall ensure that CAAF and non-CAAF are aware—

(i) Of the DoD definition of “sexual assault” in DoDD 6495.01, Sexual Assault Prevention and Response Program;

(ii) That the offenses addressed by the definition are covered under the Uniform Code of Military Justice (see paragraph

(e)(2)(iv) of this clause). Other sexual misconduct may constitute offenses under the Uniform Code of Military Justice, Federal law, such as the Military Extraterritorial Jurisdiction Act, or host nation laws; and

(iii) That the offenses not covered by the Uniform Code of Military Justice may nevertheless have consequences to the contractor employees (see paragraph (h)(1) of this clause).

(4) The Contractor shall report to the appropriate investigative authorities, identified in paragraph (d)(6) of this clause, any alleged offenses under—

(i) The Uniform Code of Military Justice (chapter 47 of title 10, United States Code) (applicable to contractors serving with or accompanying an armed force in the field during a declared war or contingency operations); or

(ii) The Military Extraterritorial Jurisdiction Act (chapter 212 of title 18, United States Code).

(5) The Contractor shall provide to all contractor personnel who will perform work on a contract in the deployed area, before beginning such work, information on the following:

(i) How and where to report an alleged crime described in paragraph (d)(4) of this clause.

(ii) Where to seek victim and witness protection and assistance available to contractor personnel in connection with an alleged offense described in paragraph (d)(4) of this clause.

(iii) This section does not create any rights or privileges that are not authorized by law or DoD policy.

(6) The appropriate investigative authorities to which suspected crimes shall be reported include the following—

(i) US Army Criminal Investigation Command at http://www.cid.army.mil/reportacrime.html;

(ii) Air Force Office of Special Investigations at http://www.osi.andrews.af.mil/library/factsheets/factsheet.asp?id=14522;

http://www.cid.army.mil/reportacrime.html http://www.osi.andrews.af.mil/library/factsheets/factsheet.asp?id=14522

(iii) Navy Criminal Investigative Service at http://www.ncis.navy.mil/Pages/publicdefault.aspx;

(iv) Defense Criminal Investigative Service at http://www.dodig.mil/HOTLINE/index.html;

(v) To any command of any supported military element or the command of any base.

(7) Personnel seeking whistleblower protection from reprisals for reporting criminal acts shall seek guidance through the

DoD Inspector General hotline at 800-424-9098 or www.dodig.mil/HOTLINE/index.html. Personnel seeking other forms of victim or witness protections should contact the nearest military law enforcement office.

(8) The Contractor shall ensure that Contractor employees supporting the U.S. Armed Forces deployed outside the United

States are aware of their rights to—

(A) Hold their own identity or immigration documents, such as passport or driver’s license;

(B) Receive agreed upon wages on time;

(C) Take lunch and work-breaks;

(D) Elect to terminate employment at any time;

(E) Identify grievances without fear of reprisal;

(F) Have a copy of their employment contract in a language they understand;

(G) Receive wages that are not below the legal in-country minimum wage;

(H) Be notified of their rights, wages, and prohibited activities prior to signing their employment contract; and

(I) If housing is provided, live in housing that meets host-country housing and safety standards.

(e) Preliminary personnel requirements.

(1) The Contractor shall ensure that the following requirements are met prior to deploying CAAF (specific requirements for each category will be specified in the statement of work or elsewhere in the contract):

(i) All required security and background checks are complete and acceptable.

(ii) All CAAF deploying in support of an…