Att_0012_-_Additional_Solicitation_and_Contract_Requirements.docx
DOCX document 26 KB Posted
- Solicitation number
- W15QKN-18-R-0016
About this file
This solicitation notice seeks proposals for the manufacture and delivery of the FMU-153A/B Point Detonating/Delay Fuze. A single 5-year Indefinite Delivery/Indefinite Quantity contract with Firm-Fixed Price orders will be awarded by the Army Contracting Command-New Jersey on behalf of the Office of the Project Manager for Combat Ammunition Systems. The FMU-153A/B Fuze is used in conjunction with 105mm projectiles fired from AC-130 Gunships, and can be set for either point detonating or delay modes. Interested offerors must be located in the United States or Canada, and must submit completed non-disclosure and technical data agreements to receive the restricted Government Technical Data Package. Inquiries should be directed to the points of contact via email only.
Additional Solicitation and Contract Requirements.
View the file
Other files
Show all 20
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
ATTACHMENT 0012 - ADDITIONAL SOLICITATION AND CONTRACT REQUIREMENTS
This Attachment is to document Additional Solicitation and Contract Requirements for the FMU 153 A/B Point Detonating/Delay (PD/DLY) Fuze.
1.) EXPLOSIVE MATERIAL HANDLING
The Contractor shall comply with the requirements of the Department of the Army Pamphlet 385-64, Safety, Ammunition and Explosives Safety Program, in effect on the date of the solicitation for this contract.
2.) SAFETY REQUIREMENTS FOR HAZARDOUS ITEMS
a. The contractor shall use the safety data provided in the Hazardous Component Safety Data Sheets (HCSDS) to insure the safe handling of the energetic material. The HCSDS are in Section J of the contract.
b. The contractor shall comply with Paragraph F, Chapter 1 of DOD 4146.26M, DOD Contractor's Safety Manual for Ammunition and Explosives. This requires the contractor to submit all site and construction plans through the local Defense Contract Management District Safety Office to the Contracting Officer for approval. The contractor must also submit changes for approval. Contractors will assure that their subcontractors follow the same procedures.
c. Whenever the contractor uses a government facility, he shall comply with the local safety requirements of that facility.
d. The contractor must obtain written approval from the Contracting Officer before the award of a subcontract involving explosives, propellants or pyrotechnic materials. When the contractor requests the Contracting Officer's approval, the Contracting Officer will arrange a Defense Logistics Agency pre-award safety survey for each subcontractor.
e. The contractor is responsible for decontaminating all facilities/equipment at the end of the contract unless the contractor intends to continue using the facilities/equipment for similar purposes. Any associated costs must be included as part of the contractor’s proposal. The contractor must provide the Contracting Officer with a certification that all contaminated facilities/equipment have been decontaminated.
f. The contractor is responsible for properly disposing of hazardous materials during this contract. If disposal is done on the subcontractor's site, the contractor must note this in his site plan per paragraph b, above. The Contracting Officer must approve a subcontractor prior to him performing disposal per paragraph d, above.
g. The contractor will provide reports of accidents/incidents as required by Data Item DI-SAFT-81563. The government reserves the right to investigate any accident/incident under Chapter 2, Paragraphs F and G of DOD 4145.26M, DOD Contractor's Safety Manual for Ammunition and Explosives.
File details come from the government source that posted it. Updated .