STEP 1 IFB 90 SPECIFICATIONS_20250519.pdf

SPECIFICATIONS

(For Construction Contract)

Solicitation Number W9128F25BA010

West Abutment Lignite Drain

Garrison Dam, ND

May 2025

US Army Corps of Engineers Omaha District

This page was intentionally left blank for duplex printing.

West Abutment Lignite Drain Garrison Dam, ND GR00116

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 12 00 CONSTRUCTION GENERAL

01 20 00 PRICE AND PAYMENT PROCEDURES

01 30 00.24 OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 41 26.06 24 (NORTH DAKOTA) NPDES PERMIT REQUIREMENTS FOR STORM WATER

DISCHARGES FROM CONSTRUCTION SITES

01 45 00 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 78 39.00 24 AS-BUILT DRAWINGS

DIVISION 03 - CONCRETE

03 42 13.00 10 PRECAST CONCRETE PRODUCTS FOR BELOW GRADE CONSTRUCTION

DIVISION 05 - METALS

05 50 13 MISCELLANEOUS METAL FABRICATIONS

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 92 19 SEEDING

DIVISION 33 - UTILITIES

33 46 16 DRAIN PIPING

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 73 13 EMBANKMENT FOR EARTH AND ROCKFILL DAMS

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

1.1.2 Location

1.2 EXISTING WORK

1.3 UTILITIES AND FACILITIES

1.3.1 Notification Prior to Excavation

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes installing an 812-foot long, 12-inch slotted PVC drain surrounded by a two-stage gravel and sand filter, two cleanouts, and a manhole that connects the new drain to an existing 18-inch PVC collector pipe in the 3A lignite outcrop in the west abutment at Garrison Dam, and incidental related work.

1.1.2 Location

The work is located at the west abutment of Garrison Dam, North Dakota, approximately as indicated. Garrison Dam is a high hazard potential dam located on the Missouri River in McLean and Mercer Counties, North Dakota. The town of Riverdale is east of the dam on the left abutment, Pick City is west of the dam on the right abutment, and Bismarck is approximately 70 miles to the south. The exact location will be shown by the Contracting Officer.

1.2 EXISTING WORK

Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.3 UTILITIES AND FACILITIES

Obtain digging permits prior to start of excavation. Contact local utility locating service a minimum of 48 hours prior to excavating, to mark utilities, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

Locate all utilities prior to the commencement of work. Protect from damage all concrete flumes, manholes, drains, and all dam safety instrumentation in the area of work. The location of all dam safety instrumentation will be identified and marked by the COR and the Garrison Dam Project Office prior to the commencement of work. Damage to any of these features must be repaired or replaced by the Contractor at no additional cost the Government.

1.3.1 Notification Prior to Excavation

Notify the Contracting Officer at least 5 days prior to starting

SECTION 01 11 00 Page 2 excavation work.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 3

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

1.2 CONSTRUCTION RIGHT-OF-WAY

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

1.4 CARE OF WATER

1.5 PROJECT SURVEY AND LAYOUT

1.6 DISPOSITION OF CONSTRUCTION FACILITIES

1.7 ACCESS ROADS AND HAUL ROADS

1.7.1 Access Roads

1.7.2 Haul Roads

1.7.3 Joint Use of Transportation Facilities

1.8 PUBLIC ROADS

1.8.1 State and Federal Highways

1.8.2 State and Local Public Roads

1.9 COOPERATION WITH OTHER CONTRACTORS

1.10 ORDER OF WORK

1.11 SUBMITTALS

1.12 WARRANTY OF CONSTRUCTION (MAR 1994)

1.13 TELEPHONE/INTERNET

1.14 PORTABLE TOILETS

1.15 FEDERAL HOLIDAYS AND WORKING HOURS

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 1

SECTION 01 12 00

CONSTRUCTION GENERAL

PART 1 GENERAL

1.1 SCOPE

The work covered in this section is outlined as a statement of construction requirements common to all the work. Specific requirements for materials and installations are provided under the Technical Sections herewith. No claims for extras shall be made on account of items presumed to have been omitted from this section.

1.2 CONSTRUCTION RIGHT-OF-WAY

The Contractor will be assigned working areas or working right-of-way limits for this contract.

1.3 PROTECTION OF EXISTING FACILITIES AND WORKS

The Contractor shall be responsible for the protection of the work area from damage and upon completion of the work shall leave existing works in a condition equal to that which existed when the work started. All work, storage of materials, and construction plant shall be kept within the limits of the areas assigned. Prior to construction operations, the Contractor shall confer with the Contracting Officer's representative to determine the proximity of any possible under-ground obstructions, pipe or equipment which could be damaged as a result of construction operations.

Existing utility lines that are shown on the drawings or the locations are otherwise made known to the Contractor shall be protected from damage, and if damaged, shall be repaired by the Contractor at no additional expense to the Government. In the event that the Contractor damages any existing utility lines that are not shown or the locations of which have not been made known to the Contractor, the Contractor shall immediately notify the Contracting Officer. The Contracting Officer will review the information and discuss with the Contractor how to proceed. The Contractor will be responsible for the protection of structures from any structural damage during the construction operations. Roads and surfaces shall be protected from damage by the work or if damaged shall be repaired with equal materials at no additional expense to the Government. At all times the plant and work areas shall be kept in a condition conducive to safety of workmen and the public and neat in appearance. Waste or surplus materials shall not be allowed to accumulate in the construction areas.

1.4 CARE OF WATER

Full responsibility for care of water shall be borne by the Contractor until completion of work under this contract. The Contractor shall provide the materials and equipment and perform all work necessary to facilitate construction and to protect the work from damage by water. The Contractor shall make determinations of conditions, both existing and anticipated concerning care of water. Plans for care of water are subject to approval by the Contracting Officer prior to construction. Facilities shall be removed upon completion of the work.

SECTION 01 12 00 Page 2

1.5 PROJECT SURVEY AND LAYOUT

In addition to the requirements of FAR 52.236-17 Layout of Work, the Contractor shall provide a licensed land surveyor to check initial project control, and to provide and set hubs for project construction. The Contractor shall use (and reference in all as-built data) project stationing as described on the contract drawings. In addition, a licensed land surveyor shall provide final as-built survey to include major breakpoints and elevations of installed features of work. This survey shall provide and verify both horizontal and vertical project control, and also be used for the as-built condition in accordance with Section

01 78 39.00 24 AS-BUILT DRAWINGS.

The Contractor may utilize their own quality control personnel to provide interim surveys for quantity determination for payment in accordance with paragraph entitled Quantity Surveys (Apr 1984).

1.6 DISPOSITION OF CONSTRUCTION FACILITIES

All buildings and facilities constructed by the Contractor shall be maintained in a satisfactory condition with strict observance of the rules of sanitation, safety and order as may be established by the Contracting Officer. Prior to final payment under the contract, all buildings and facilities constructed by the Contractor for the Contractor's use shall be removed from the site by the Contractor.

1.7 ACCESS ROADS AND HAUL ROADS

1.7.1 Access Roads

Access roads as required for the prosecution of the work shall be maintained (including sprinkling for dust control, safety personnel, and traffic control) within the work areas assigned to the Contractor.

Consideration shall be given to the avoidance of interference with others, safety and frequency of traffic, subject to review and approval prior to construction. Access road areas shall be restored to their original or suitable condition upon completion of this contract. The Contractor shall be responsible for repair of damage to existing roads caused by the Contractor's operation.

1.7.2 Haul Roads

Construct haul roads as may be necessary for the conduct of the work without additional cost to the Government. Arrange the hauling operations so as to cause a minimum interference with traffic, develop Temporary Traffic Control (TTC) plan(s), and furnish all necessary traffic control devices and personnel as required to avoid additional hazards to the public. Perform routine day and night inspections of TTC elements as required by MUTCD and maintain all furnished traffic control devices at their expense and without additional cost to the Government. Lines, grades and widths for haul roads, must be selected to fulfill the requirements for safe and efficient hauling operations and be approved by the Contracting Officer prior to construction. Haul roads shall have ample width to provide safety. Preference shall be given to one-way haul roads when these are feasible. All roads shall be maintained in original as-built condition during all periods of their use. Roads shall be sprinkled whenever, in the opinion of the Contracting Officer, control of dust is necessary to insure safe movements of construction traffic. Upon completion of work under this contract, roads shall be disposed of as

SECTION 01 12 00 Page 3 directed by the Contracting Officer. All traffic control devices, culverts, guards, fences and other improvements on roads constructed for the Contractor's convenience and operations shall be removed from the project site and shall remain property of the Contractor. Use and repair of existing roads and bridges shall be subject to the requirements of local authorities. Prior to start of hauling operations on public roads, f urnish written evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

1.7.3 Joint Use of Transportation Facilities

The Contractor may use jointly with Contractors and others, existing access and haul roads constructed by the Government or by others. Unless otherwise specifically authorized in writing, the Contractor will not be granted exclusive use of any access or haul road whether it be an existing road or one constructed by the Contractor. However, the use by others of roads constructed by or assigned to the Contractor primarily for the Contractor's use will be limited by the Contracting Officer to the minimum considered consistent with efficient prosecution of the work under this and other contracts in force. Maintenance of jointly used facilities shall be shared in proportion to use. In the event of a disagreement between this Contractor and others as to the use of any road, the decision of the Contracting Officer shall be final. The Contractor shall not obstruct any existing road on the land controlled by the Government.

1.8 PUBLIC ROADS

1.8.1 State and Federal Highways

Where the Contractor hauls across or on State or Federal highways, the Contractor shall enter into all agreements with the State Highway Commission and shall comply with any restrictions they may impose relative to load limits, care of traffic and cleanup. Such agreements shall clearly relieve the Government of any responsibility for damages resulting from hauling across or on State highways. Copies of such agreements shall be furnished to the Contracting Officer before the Contractor begins hauling on these highways.

1.8.2 State and Local Public Roads

(a) Load Limits:

The North Dakota Department of Transportation and local County Road Commissions restrict the load weights of haul vehicles using highways and county roads during the spring thaw period. The load restrictions are usually imposed from 1 April through June depending on actual weather conditions.

(b) Hauling Regulations:

Prior to start of hauling operations on public roads, the Contractor shall furnish evidence to the Contracting Officer that an agreement has been consummated with State and County officials on the use of public roads and bridges. Such agreements shall clearly relieve the Government of any responsibility for damage resulting from hauling across or on these roads.

SECTION 01 12 00 Page 4

1.9 COOPERATION WITH OTHER CONTRACTORS

The Contractor shall cooperate and coordinate work with that of others working in the area during the life of this contract. The Contractor shall coordinate work with others to avoid undue interference and shall conduct operations, other than approved required access, within the limits of the assigned construction area or construction right-of-way limits.

The Contractor shall cooperate with others as necessary in the interest of timely completion of all work and in the event of disagreement the decision of the Contracting Officer shall be final.

1.10 ORDER OF WORK

The sequence of operations shall be maintained so that the maximum amount of work may be done under favorable working conditions in accordance with the completion time set forth. The Contractor shall submit for approval, within 15 days after receipt of notice to proceed a narrative description of the proposed methods of operation.

1.11 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Proposed Methods of Operation; G-AO

Construction Right-of-Way

(Right-of-Way Agreements)

State and Federal Highways

(Agreements for hauling on highways)

State and Local Public Roads

(Agreements for hauling on roads)

SD-02 Shop Drawings

Care of Water; G-AO

SD-07 Certificates

Licensed Land Surveyor

SD-11 Closeout Submittals

Warranty of Construction

(List of warranties with copy of each)

SECTION 01 12 00 Page 5

1.12 WARRANTY OF CONSTRUCTION (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government-owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall--

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect

SECTION 01 12 00 Page 6 in Government-furnished material or design.

(j) This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

1.13 TELEPHONE/INTERNET

The Contractor is responsible for arranging telephone/Internet service for the Contractor's trailer through the local telephone company.

1.14 PORTABLE TOILETS

Toilet facilities will not be available for Contractor's use. The Contractor shall provide and maintain portable toilets for use by the Contractor's staff. Toilet(s) shall be placed at the location directed by the Contracting Officer. To prevent overturning by high winds, all portable toilets shall be anchored down.

1.15 FEDERAL HOLIDAYS AND WORKING HOURS

The Contractor will have access to the facility for work during normal plant business hours from 0700 to 1700 hrs Monday through Friday, excluding any federally recognized holidays or observance days. Dam operations support are available from 0630 to 1630 hrs Monday through Thursday. Plant personnel regarding lockout tagout are only available from 0730 to 1600 hrs Monday through Thursday. The Contractor shall plan all work accordingly. These hours will be strictly adhered to unless the Government determines work outside this time is beneficial to the Government or a bilateral modification for extended working hours is executed.

The following Federal legal holidays are observed by this installation:

New Year's Day 1 January Martin Luther King's Birthday Third Monday in January President's Day Third Monday in February Memorial Day Last Monday in May Juneteenth 19 June Independence Day 4 July Labor Day First Monday in September Columbus Day Second Monday in October Veterans Day 11 November Thanksgiving Day Fourth Thursday in November Christmas Day 25 December

If the wage determination has a discrepancy with the above list of observed Federal holidays, then the wage determination takes precedence.

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 12 00 Page 7

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 SUBMITTALS

1.2 CONTRACT COST BREAKDOWN

1.3 CONTRACTOR'S INVOICE AND CONTRACT PERFORMANCE STATEMENT

1.3.1 Submission of Invoices

1.3.2 Final Invoice

1.4 SINGLE JOB PAYMENT ITEMS

1.4.1 Mobilization and Demobilization - CLIN 0001

1.4.1.1 Payment

1.4.1.2 Unit of Measure

1.4.2 All Remaining Work - CLIN 0002

1.4.2.1 Payment

1.4.2.2 Unit of Measure

1.4.3 Cleanouts - CLIN 0003

1.4.3.1 Payment

1.4.3.2 Unit of Measure

1.4.4 Manhole - CLIN 0004

1.4.4.1 Payment

1.4.4.2 Unit of Measure

1.5 UNIT PRICE PAYMENT ITEMS

1.5.1 12-Inch Slotted C900 PVC Pipe - CLIN 0005

1.5.1.1 Payment

1.5.1.2 Measurement

1.5.1.3 Unit of Measure

1.5.2 Fine Filter Aggregate - CLIN 0006

1.5.2.1 Payment

1.5.2.2 Measurement

1.5.2.3 Unit of Measure

1.5.3 Coarse Filter Aggregate - CLIN 0007

1.5.3.1 Payment

1.5.3.2 Measurement

1.5.3.3 Unit of Measure

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 20 00 Page 1

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for information only. When used, a code following the "G" classification identifies the office that will review the submittal for the Government.

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-07 Certificates

Record of Accepted Work; G-AO

1.2 CONTRACT COST BREAKDOWN

The Contractor must furnish within 30 days after the date of Notice to Proceed, and prior to the submission of its first partial payment estimate, a breakdown of its single job pay item or items which will be reviewed by the Contracting Officer as to propriety of distribution of the total cost to the various accounts. Any unbalanced items as between early and late payment items or other discrepancies will be revised by the Contracting Officer to agree with a reasonable cost of the work included in the various items. This Contract cost breakdown will then be utilized as the basis for progress payments to the Contractor.

1.3 CONTRACTOR'S INVOICE AND CONTRACT PERFORMANCE STATEMENT

1.3.1 Submission of Invoices

If DFARS Clause 252.232-7006 Wide Area WorkFlow Payment Instructions is included in the Contract, provide the documents listed in above paragraph CONTENT OF INVOICE in their entirety as attachments in Wide Area Work Flow (WAWF) for each invoice submitted. The maximum size of each WAWF attachment is two megabytes, but there are no limits on the number of attachments. If a document cannot be attached in WAWF due to system or size restriction, provide it as instructed by the Contracting Officer.

Monthly invoices and supporting forms for work performed through the anniversary award date of the Contract must be submitted to the Contracting Officer within 5 calendar days of the date of invoice. For example, if Contract award date is the 7th of the month, the date of each monthly invoice must be the 7th and the invoice must be submitted by the 12th of the month.

1.3.2 Final Invoice

A final invoice must be accompanied by the Contractor's Final Release. If the Contractor is incorporated, the Final Release must contain the corporate seal. An officer of the corporation must sign and the corporate secretary must certify the Final Release.

SECTION 01 20 00 Page 2

1.4 SINGLE JOB PAYMENT ITEMS

Payment items for the work of this Contract for which Contract job payments will be made are listed in the BIDDING PROPOSAL SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The job price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.4.1 Mobilization and Demobilization - CLIN 0001

1.4.1.1 Payment

Payment will be made for costs associated with mobilization and demobilization, as defined:

(a) The Government will pay all costs for the mobilization and demobilization of all of the Contractor's plant and equipment at the contract lump sum price for this item.

(1) 50 percent of the lump sum price upon completion of the contractor's mobilization at the work site.

(2) The remaining 50 percent upon completion of demobilization.

(b) The Contracting Officer may require the Contractor to furnish cost data to justify this portion of the bid if the Contracting Officer believes that the percentages in paragraphs (a)(1) and (2) of this clause do not bear a reasonable relation to the cost of the work in this contract.

(1) Failure to justify such price to the satisfaction of the Contracting Officer will result in payment, as determined by the Contracting Officer, of—

(i) Actual mobilization costs at completion of mobilization;

(ii) Actual demobilization costs at completion of demobilization; and

(iii) The remainder of this item in the final payment under this contract.

(2) The Contracting Officer's determination of the actual costs in paragraph (b)(1) of this clause is not subject to appeal.

1.4.1.2 Unit of Measure

Unit of measure: job.

SECTION 01 20 00 Page 3

1.4.2 All Remaining Work - CLIN 0002

1.4.2.1 Payment

Payment will be made for costs associated with operations necessary for all remaining work including clearing, grubbing, topsoil stripping, excavation, shoring, dewatering, placement of embankment fill, moisture conditioning, compaction, disposition of excess excavated material, topsoil placement, seeding, erosion control blanket, surveying, as-built drawings, and other miscellaneous items.

1.4.2.2 Unit of Measure

Unit of measure: job.

1.4.3 Cleanouts - CLIN 0003

1.4.3.1 Payment

Payment will be made for costs associated with operations necessary for construction of the cleanouts as shown on the drawings.

1.4.3.2 Unit of Measure

Unit of measure: job.

1.4.4 Manhole - CLIN 0004

1.4.4.1 Payment

Payment will be made for costs associated with operations necessary for construction of the manhole and connection to the existing collector pipe as shown on the drawings.

1.4.4.2 Unit of Measure

Unit of measure: job.

1.5 UNIT PRICE PAYMENT ITEMS

Payment items for the work of this Contract on which the Contract unit price payments will be made are listed in the BIDDING PROPOSAL SCHEDULE and described below. The unit price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for each of the unit price items.

The Record of Accepted Work must be used to document the quantity of materials installed in the accepted work.

1.5.1 12-Inch Slotted C900 PVC Pipe - CLIN 0005

1.5.1.1 Payment

Payment will be made for costs associated with furnishing, transporting, stockpiling, installing, and testing the pipe materials including pipe connections to manholes, fittings, and pipe specialties.

SECTION 01 20 00 Page 4

1.5.1.2 Measurement

The total quantity of pipe for which payment will be made will be the quantity installed in the accepted work.

1.5.1.3 Unit of Measure

Unit of measure: linear feet.

1.5.2 Fine Filter Aggregate - CLIN 0006

1.5.2.1 Payment

Payment will be made for costs associated with furnishing, transporting, stockpiling, placing, moisture conditioning, and compacting the material as specified.

1.5.2.2 Measurement

The total quantity of material for which payment will be made will be the quantity installed in the accepted work.

1.5.2.3 Unit of Measure

Unit of measure: cubic yard.

1.5.3 Coarse Filter Aggregate - CLIN 0007

1.5.3.1 Payment

Payment will be made for costs associated with furnishing, transporting, stockpiling, placing, moisture conditioning, and compacting the material as specified.

1.5.3.2 Measurement

The total quantity of material for which payment will be made will be the quantity installed in the accepted work.

1.5.3.3 Unit of Measure

Unit of measure: cubic yard.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 20 00 Page 5

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR

PAYROLLS

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS

CONTRACTS

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1.6 EXCEPTION TO COMPLETION TIME AND LIQUIDATED DAMAGES

1.7 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

1.8 CONTRACT DRAWINGS AND SPECIFICATIONS

1.8.1 SETS FURNISHED

1.8.2 DISTRIBUTION

1.8.3 NOTIFICATION OF DISCREPANCIES

1.8.4 OMISSIONS

1.9 SUBMITTALS

1.10 PAYMENT

1.10.1 PROMPT PAYMENT ACT

1.10.2 PAYMENT FOR MATERIALS STORED OFFSITE

1.11 AVAILABILITY AND USE OF UTILITY SERVICES

1.12 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.13 INSURANCE REQUIRED

1.14 CONTRACTOR QUALITY CONTROL (CQC)

1.15 NONDOMESTIC CONSTRUCTION MATERIALS

1.16 DAILY WORK SCHEDULES AND WEEKLY COORDINATION MEETINGS

1.17 AS-BUILT DRAWINGS

1.18 PARTNERING

1.18.1 Team-Led (Informal) Partnering

1.19 PROFIT

1.20 LABOR CONDITIONS APPLICABLE TO TEMPORARY FACILITIES

1.21 DRAWING SCALES

1.22 CYBERSECURITY DURING CONSTRUCTION

1.22.1 Contractor Computer Equipment

1.22.1.1 Operating System

1.22.1.2 Anti-Malware Software

1.22.1.3 Passwords and Passphrases

1.22.1.4 Contractor Computer Cybersecurity Compliance Statements

PART 2 NOT USED

PART 3 NOT USED

SECTION 01 30 00.24 Page 1

SECTION 01 30 00.24 Page 2

SECTION 01 30 00.24

OTHER ADMINISTRATIVE AND SPECIAL REQUIREMENTS

PART 1 GENERAL

1.1 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

In accordance with FAR 31.105(d)(2)(i)(b), for the predetermined schedule of construction equipment use rates, use Engineer Pamphlet (EP) 1110-1-8, Construction Equipment Ownership and Operating Expense Schedule. Copies of each regional schedule may be obtained through the following internet site:

https://www.usace.army.mil/Cost-Engineering/EP1110-1-8/ .

1.2 CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING

CONSTRUCTION WAGE RATE REQUIREMENTS STATUTE CERTIFIED LABOR PAYROLLS

a.Use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Wage Rate Requirements statute.

b. Obtain and provide for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the Contractor to comply with the Wage Rate Requirements statute. Use the electronic payroll service to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract. Use an electronic payroll service capable of preserving these payrolls and related basic records for the required three years after contract completion. Obtain and provide electronic system access to the Government, as required to comply with the Wage Rate Requirements over the duration of the construction contract.

The Contractor's provision and use of an electronic payroll processing system must meet the following basic functional criteria:

(1) commercially available;

(2) compliant with appropriate Wage Rate Requirements statute payroll provisions in the FAR;

(3) able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract;

(4) capable of producing an Excel spreadsheet-compatible electronic output of weekly payroll records for export into an Excel spreadsheet to be imported into the contractor's mode of Resident Management System 3.0;

(5) demonstrated security of data and data entry rights;

(6) ability to produce Contractor-certified electronic versions of weekly payroll data;

SECTION 01 30 00.24 Page 3

(7) ability to identify erroneous entries and track the data/time of all versions of the certified Wage Rate Requirements statute payrolls submitted to the government over the life of the contract;

(8) capable of generating a durable record copy in a Compact Disc (CD) or Digital Versatile Disc (DVD) and Portable Document Format (PDF) file record of data from the system database at the end of the contract closeout. Provide this durable record copy of data from the electronic payroll processing system to the Government during contract closeout.

d. Include all Contractor-incurred costs related to the Contractor's provision and use of an electronic payroll processing service in the Contractor's price for the overall work under the contract. Do not include the costs for compliance with the Wage Rate Requirements statute by using electronic payroll processing services as a separately bid or reimbursed item under this contract.

1.3 VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army Corps of Engineers (USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service

(VETS):

https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program:

https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

1.4 CONTRACTOR PERFORMANCE EVALUATIONS

See Federal Acquisition Regulation (FAR) Subpart 42.1502(e) for the requirements on past performance evaluations for construction contracts.For construction contracts valued at or above $750,000.00, including all modifications, the USACE will evaluate Contractor's performance using the web-based Contractors Performance Assessment Reporting System (CPARS). After the USACE drafts an evaluation (interim or final), the Contractor will have the opportunity to access, review, comment and either concur or non-concur with the evaluation in the CPARS system for a period of 60 days. Access to the CPARS system requires either specific software called PKI certification (recommended method) or a username and password. The PKI certification is a Department of Defense recommendation and to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and may be purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and contacting vendors can be found on the web site:

SECTION 01 30 00.24 Page 4 https://www.cpars.gov .

1.5 ANTITERRORISM (AT)/OPERATIONS SECURITY (OPSEC) PROVISIONS

1. General security requirements and guidance:

The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts.

The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations.

Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures.

The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures-this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

2. Antiterrorism (AT) Level I training:

All contract personnel requiring routine access to Army installations, facilities, and controlled access areas, or requiring network access shall complete initial and annual refresher AT Level I awareness training.

Online AT Level I awareness training is available at https://jko.jten.mil/ (website subject to change).

3. Physical security and access control requirements:

All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as "NCIC-III") and Terrorist Screening Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity

SECTION 01 30 00.24 Page 5 verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

4. Not Used

5. Not Used

6. Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something):

All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

This training shall be completed within 10 days prior to mobilization and within 30 calendar days of new employees commencing performance with the results reported to the COR. (submittal: iWATCH and/or CorpsWatch Training Sign In Sheets).

7. Not Used

8. Not Used

9. Not Used

10. Not Used

11. Not Used

12. Not Used

13. Escorting in classified and/or sensitive areas: In accordance with applicable regulations, all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or restricted areas. There is no classified information or operations associated with this contract.

14. Pre-screen candidates using E-Verify Program: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

15. Not Used

SECTION 01 30 00.24 Page 6

16. Not Used

1.6 EXCEPTION TO COMPLETION TIME AND LIQUIDATED DAMAGES

In case the Contracting Officer determines that seeding, sodding, and/or planting and/or the specified maintenance thereof is not feasible during the construction period, such work will be exempt from the completion time and liquidated damages. Accomplish this work during the first seeding, sodding, and/or planting period and the specified maintenance period following the completion date.

1.7 COMPUTING COMPLETION DATES FOR NON-WORK PERIOD

No work will be required at the construction site during the period 1 November through 31 March inclusive. The days in this period have been included in computing the calendar days for completion of the work. The Contractor may perform work at the site during all or any part of this period upon giving prior written notice to the Contracting Officer.

Working during this non-work period requires approval by the Contracting Officer. No time extensions will be granted for delays during this period.

1.8 CONTRACT DRAWINGS AND SPECIFICATIONS

1.8.1 SETS FURNISHED

Utilize the bid drawings and specifications as amended in the performance of the work until the electronic Adobe Acrobat.pdf conformed specifications and contract drawings (i.e., bid drawings that have been posted with all amendment changes) are sent electronically to the Contractor. The work must conform to the contract drawings, set out in the drawing index, all of which form a part of these specifications. The work must also conform to any of the standard details bound or referenced herein. The Contractor shall be responsible for making copies of all plans and specifications as needed for the duration of the contract.

1.8.2 DISTRIBUTION

The Government will provide the Contractor with a CD-ROM or DVD-ROM or sent electronically containing Adobe Acrobat.pdf contract drawings and conformed specification sets and editable CAD file drawings (format defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS). Prepare final record or as-built drawings as defined in Section 01 78 39.00 24 AS-BUILT DRAWINGS.

1.8.3 NOTIFICATION OF DISCREPANCIES

Check all drawing files furnished by the Government immediately upon their receipt and promptly notify the Contracting Officer of any discrepancies.

Follow dimensions marked on drawings in lieu of scale measurements.

Enlarged plans and details govern where the same work is shown at smaller scales. All scales shown are based on a standard drawing size of 22" x 34".

If any other size drawings are furnished or plotted adjust the scales accordingly. Advise sub-contractors of the above. Compare all drawings and verify the figures before laying out the work and take responsibility for any errors which might have been avoided thereby.

1.8.4 OMISSIONS

Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of

SECTION 01 30 00.24 Page 7 the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing such omitted or misdescribed details of the work. Perform as if fully and correctly set forth and described in the drawings and specifications.

1.9 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit items below in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

AT Level I Training Sign In Sheets;

Sign In Sheets for all employee training required for AT Level I Training, see OPSEC paragraphs, subparagraph 2 iWATCH and/or CorpsWatch Training Sign In Sheets ;

Sign In Sheets for all employee training required for iWATCH and/or CorpsWatch Training, see OPSEC paragraphs, subparagraph 6

E-Verify ;

Provide E-Verify completion sheets required for OPSEC, see OPSEC paragraphs, subparagraph 14

Contractor Computer Cybersecurity Compliance Statements; G, RO

1.10 PAYMENT

1.10.1 PROMPT PAYMENT ACT

Pay requests authorized in GENERAL CONDITIONS (CONTRACT CLAUSES) clause:

"Payments Under Fixed-Price Construction Contracts", will be paid pursuant to the clause, "Prompt Payment for Construction Contracts". Submit pay requests on ENG Form 93 and 93a, "Payment Estimate-Contract Performance" and "Continuation". All information and substantiation required by the identified contract clauses must be submitted with the ENG Form 93, and the required certification included on the last page of the ENG Form 93a, signed by an authorized contractor official and dated when signed. The designated billing office is the Office of the Area Engineer.

1.10.2 PAYMENT FOR MATERIALS STORED OFFSITE

a. As allowed under (FAR) 52.232-5 "Payments Under Fixed Price Construction Contracts", the Administrative Contracting Officer, at their discretion, may authorize progress payments for any material stored off-site provided:

(1) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract,

(2) Material is stored in such a manner to protect it from damage, fire, theft, etc .

SECTION 01 30 00.24 Page 8

(3) The Contractor provides evidence of insurance for material, and,

(4) Material is clearly identified and delineated by contract number for use on the applicable project.

b. The Administrative Contracting Officer reserves the right to inspect any off-site material prior to authorizing progress payments. Provide paid invoices listing the value of material and labor incorporated in the items.

1.11 AVAILABILITY AND USE OF UTILITY SERVICES

Use of public and private utilities will be as found available. Make arrangements for use of public and private utilities.

1.12 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with FAR 52.249-10 "Default: (Fixed-Price Construction)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan 23 Feb 17 Mar 13 Apr 4 May 3 Jun 6 Jul 3 Aug 4 Sep 4 Oct 3 Nov 12 Dec 20

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the RMS daily CQC report, any occurrence of adverse weather and resultant impact to normally

SECTION 01 30 00.24 Page 9 scheduled work, within 24 hours of the event. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. Describe in the RMS daily CQC reports the critical path item that is being affected and provide the critical path activity number(s) from the current schedule.