Specs - Seed Project Attachment - Construction Specifications 849-MM24-01.pdf

NCA MASTER SPECIFICATIONS

100% DESIGN SUBMISSION

HAMPTON NATIONAL CEMETERY

HAMPTON, VIRGINIA

PROJECT NO. 849-MM22-06

DESIGN THE CONDUIT INSTALLATION

FOR NEW COMMUNICATION FEED

Prepared for:

United States Department of Veterans Affairs

APRIL 7, 2023

HAMPTON NATIONAL CEMETERY PROJECT NO. 849-MM22-06

DESIGN THE CONDUIT INSTALLATION FOR NEW COMMUNICATION FEED APRIL 7, 2023

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

NCA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 05-10

DIVISION 01 - GENERAL REQUIREMENTS

01 00 02 General Requirements (Minor NCA Projects) 06-14

01 32 17 Network Analysis Schedules (Microsoft Project Gantt Chart) 10-10

01 33 23 Shop Drawings, Product Data, and Samples 06-14

01 42 19 Reference Standards 06-14

01 45 29 Testing Laboratory Services 06-14

01 57 19 Temporary Environmental Controls 06-14

01 74 19 Construction Waste Management 06-14

01 81 13 Sustainable Construction Requirements 08-16

DIVISION 03 – CONCRETE

03 30 53 (Short-Form) Cast-in-Place Concrete 06-14

DIVISION 26 – ELECTRICAL

26 05 41 Underground Electrical Construction 07-17

DIVISION 27 – COMMUNICATIONS

27 05 33 Conduits and Backboxes for Communications Systems 11-16

DIVISION 31 – EARTHWORK

31 20 11 Earth Moving (Short Form) 11-16

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 05 23 Cement and Concrete for Exterior Improvements 11-16

32 12 16 Asphalt Paving 11-16

32 90 00 Planting 11-16

LIST OF DRAWING SHEETS

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

NO. DRAWING DRAWING TITLE

1. GI001 COVER SHEET

2. GI002 GENERAL NOTES, SYMBOLS AND ABBREVIATIONS

3. VL101 EXISTING CONDITIONS & DEMOLITION PLAN

4. VL102 EXISTING CONDITIONS & DEMOLITION PLAN

5. VL103 EXISTING CONDITIONS & DEMOLITION PLAN

6. CS100 SITE PLAN

7. CS101 SITE PLAN

8. CS102 SITE PLAN

9. E-001 ELECTRICAL LEGEND & SYMBOLS

10. E-100 SITE PLAN - CONDUIT ROUTING

11. E-101 ELECTRICAL PHOTOS

- - - END - - -

i

SECTION 01 00 02

GENERAL REQUIREMENTS (MINOR NCA PROJECTS)

TABLE OF CONTENTS

1.1 GENERAL INTENTION

1.2 STATEMENT OF BID ITEM(S)

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.4 CONSTRUCTION SECURITY REQUIREMENTS

1.5 FIRE SAFETY

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 ENVIRONMENTAL CONTROLS

1.9 DISPOSAL AND RETENTION

1.10 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS

1.11 RESTORATION

1.12 PHYSICAL DATA

1.13 PROFESSIONAL SURVEYING SERVICES

1.14 AS-BUILT DRAWINGS

1.15 USE OF ROADWAYS

1.16 TEMPORARY TOILETS

1.17 AVAILABILITY AND USE OF UTILITY SERVICES

1.18 TESTS

1.19 INSTRUCTIONS

1.20 GOVERNMENT-FURNISHED PROPERTY

1.21 RELOCATED EQUIPMENT AND ITEMS

1.22 CONSTRUCTION DIGITAL IMAGES

1.23 HISTORIC PRESERVATION

1.24 PROJECT HEALTH AND SAFETY PLAN

ii

This page intentionally blank

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 1

SECTION 01 00 02

GENERAL REQUIREMENTS (MINOR NCA PROJECTS)

1.1 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor, materials, equipment and services and perform and complete all work for Hampton National Cemetery Design to Install a New Conduit in Support of

Upgrading Telecommunications as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the Cemetery Director.

C. Offices of INTEGRITY FEDERAL SERVICES, as Architect-Engineers (A/E), may render certain technical services during construction. Such services shall be considered as advisory to the

Government and shall not be construed as expressing or implying a contractual act of the

Government without affirmations by Resident Engineer/Contracting Officers Representative

(RE/COR) or his duly authorized representative.

D. All employees of general contractor and subcontractors shall comply with security requirements as established by the RE/COR, be identified by name and employer. They shall be restricted from unauthorized access.

F. Prior to commencing work, general contractor shall provide proof that a OSHA certified

“competent person” (CP) (29 CFR 1926.20(b)(2) will maintain a presence at the work site whenever the general or subcontractors are present.

G. Training:

1. All employees of general contractor or subcontractors shall, at the minimum, have successfully completed the 30-hour OSHA certified Construction Safety course and/or other relevant competency training, as determined by VA CP.

2. Submit OSHA training records of all employees for approval before the start of work.

1.2 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Installation of all work shown on the plans and described in the specifications including but not limited to: Install a new conduit in support of upgrading telecommunications at the Hampton National Cemetery. Conduit shall originate at a telecommunication manhole located on adjacent Hampton VAMC campus and terminate at the

Cemetery Offices located in the Lodge.

1.3 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. AFTER AWARD OF CONTRACT, 2 bond paper set(s) of specifications and drawings will be furnished.

B. Additional sets of drawings may be made by the Contractor, at Contractor's expense, from digital files furnished by the Issuing Office.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 2

1.4 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the site without following the procedures approved by the RE/COR. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. For working outside the “regular hours” as defined in the contract, The General Contractor shall give 3 days’ notice to the RE/COR so that appropriate arrangements can be provided for the Cemetery employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the RE/COR.

4. VA reserves the right to close down or shut down the project site and order General

Contractor’s employees off the premises in the event of a national emergency. The General

Contractor may return to the site only with the written approval of the RE/COR.

C. Guards:

1. The General Contractor shall provide unarmed guards at the project site when theft or vandalism warrants.

D. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the RE/COR for the purpose of security inspections of every area of project including tool boxes and parked machines, and to take any necessary emergency action.

1.5 FIRE SAFETY

A. Applicable Publications: Publications listed below form part of this Article to the extent referenced.

Publications are referenced in text by basic designations only.

1. American Society for Testing and Materials (ASTM):

E84-2009a Surface Burning Characteristics of Building Materials

2. National Fire Protection Association (NFPA):

10-2010 Standard for Portable Fire Extinguishers

30-2008 Flammable and Combustible Liquids Code

51B-2009 Standard for Fire Prevention During Welding, Cutting and Other

Hot Work

70-2008 National Electrical Code

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 3

241-2009 Standard for Safeguarding Construction, Alteration, and

Demolition Operations

3. Occupational Safety and Health Administration (OSHA):

29 CFR 1926 Safety and Health Regulations for Construction

B. Fire Safety Plan: Establish and maintain a fire protection program in accordance with 29 CFR

1926. Prior to start of work, prepare a plan detailing project-specific fire safety measures, including periodic status reports, and submit to RE/COR/Cemetery Director for review for compliance with contract requirements in accordance with Section 01 33 23, SHOP DRAWINGS, PRODUCT DATA AND SAMPLES. Prior to any worker for the contractor or subcontractor’s beginning work, they shall undergo a safety briefing provided by the General Contractor’s competent person per OSHA requirements. This briefing shall include information on the construction limits, safety guidelines, means of egress, break areas, work hours, locations of restrooms, use of NCA equipment, etc. Documentation shall be provided to the RE/COR that individuals have undergone the Contractor’s safety briefing.

C. Site and Building Access: Maintain free and unobstructed access to emergency services and for fire, police and other emergency response forces in accordance with NFPA 241.

D. Separate temporary facilities, such as trailers, storage sheds, and dumpsters, from existing buildings and new construction by distances in accordance with NFPA 241. For small facilities with less than 6 m (20 feet) exposing overall length, separate by 3m (10 feet).

E. Means of Egress: Do not block exiting for occupied buildings, including paths from exits to roads.

Minimize disruptions and coordinate with RE/COR/Cemetery Director.

F. Egress Routes for Construction Workers: Maintain free and unobstructed egress. Inspect daily.

Report findings and corrective actions weekly to RE/COR.

G. Fire Extinguishers: Provide and maintain extinguishers in construction areas and temporary storage areas in accordance with 29 CFR 1926, NFPA 241 and NFPA 10.

H. Flammable and Combustible Liquids: Store, dispense and use liquids in accordance with 29 CFR

1926, NFPA 241 and NFPA 30.

I. Existing Fire Protection: Do not impair automatic sprinklers, smoke and heat detection, and fire alarm systems, except for portions immediately under construction, and temporarily for connections. Request interruptions in accordance with Article, OPERATIONS AND STORAGE

AREAS, and coordinate with RE/COR. All existing or temporary fire protection systems (fire alarms) located in construction areas shall be tested as coordinated with the Cemetery.

Parameters for the testing and results of any tests performed shall be recorded by the Cemetery and copies provided to the RE/COR.

J. Smoke Detectors: Prevent accidental operation. Remove temporary covers at end of work operations each day. Coordinate with RE/COR.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 4

K. Hot Work: Perform and safeguard hot work operations in accordance with NFPA 241 and NFPA

51B. Coordinate with RE/COR.

L. Fire Hazard Prevention and Safety Inspections: Inspect entire construction areas weekly.

Coordinate with, and report findings and corrective actions weekly to RE/COR.

M. Smoking: Smoking is prohibited in and adjacent to construction areas inside existing buildings and additions under construction. In separate and detached buildings under construction, smoking is prohibited except in designated smoking rest areas.

N. Dispose of waste and debris in accordance with NFPA 241. Remove from buildings daily and site weekly.

O. Perform other construction, alteration and demolition operations in accordance with 29 CFR

1926.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the RE/COR. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage trailers, office trailers) and utilities may be erected by the

Contractor only with the approval of the RE/COR and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the Contractor at its expense upon completion of the work.

C. The Contractor shall, under regulations prescribed by the RE/COR, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the RE/COR. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as determined by the RE/COR with agreement of the Cemetery. Contractor parking will be only in areas and on roadways designated and agreed to by the RE/COR in agreement of the Cemetery.

E. Workmen are subject to rules of the Cemetery applicable to their conduct.

F. Execute work so as to interfere as little as possible with normal functioning of Cemetery as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others.

1. Do not store materials and equipment in other than assigned areas.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 5

2. Provide unobstructed access to the Cemetery areas required to remain in operation.

G. Phasing: To ensure such executions, the Contractor shall furnish the RE/COR with a schedule of approximate dates on which the Contractor intends to accomplish work in each specific area of site. In addition, the Contractor shall notify the RE/COR two weeks in advance of the proposed date of starting work in each specific area of site. Arrange such dates to insure accomplishment of this work in successive phases mutually agreeable to the Cemetery Director, RE/COR and

Contractor.

H. Construction Fence: Before construction operations begin, the Contractor shall provide a chain link construction fence, 2.1m (seven feet) minimum height, around the construction. Provide gates as required for access with necessary hardware, including hasps and padlocks. Fasten fence fabric to terminal posts with tension bands and to line posts and top and bottom rails with tie wires spaced at maximum 375mm (15 inches). Bottom of fences shall extend to 25mm (one inch) above grade. The temporary fencing shall encompass the construction work area(s) to serve as a pedestrian barrier to alert cemetery patrons of the construction site. Remove the fence when directed by RE/COR.

I. Utilities Services: Maintain existing utility services for the Cemetery at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by RE/COR. All such actions shall be coordinated with the Utility

Company involved.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of RE/COR.

Electrical work shall be accomplished with all affected circuits or equipment de-energized.

When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without the RE/COR, and Cemetery Director’s prior knowledge and written approval.

2. The Contractor shall submit a request to interrupt any such services to both RE/COR and the

Cemetery Director in writing, 48 hours in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. The Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of the Cemetery.

Interruption time approved by the Cemetery and RE/COR may occur at other than

Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the RE/COR.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 6

5. In case of a contract construction emergency, service will be interrupted on approval of

RE/COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the

Contractor.

J. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

K. To minimize interference of construction activities with flow of Cemetery traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

Wherever excavation for new utility lines cross existing roads, at least one lane must be open to traffic at all times.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the RE/COR.

L. Coordinate the work for this contract with other construction operations as directed by RE/COR.

This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF

ROADWAYS.

M. Coordination of Construction with Cemetery Director: The burial activities at a National Cemetery shall take precedence over construction activities. The Contractor must cooperate and coordinate with the Cemetery Director, through the RE/COR, in arranging construction schedule to cause the least possible interference with Cemetery activities in actual burial areas. Construction noise during the committal services shall not disturb the service. Trucks and workmen shall not pass through the service area during this period.

1. The Contractor is required to discontinue his work sufficiently in advance of Easter Sunday, Mother's Day, Father's Day, Memorial Day, Veteran's Day and/or Federal holidays, to permit him to clean up all areas of operation adjacent to existing burial plots before these dates.

2. Cleaning up shall include the removal of all equipment, tools, materials and debris and leaving the areas in a clean, neat condition.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 7

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the

RE/COR of areas of buildings andareas in which alterations occur and furnish a signed report, to the Contracting Officer. This report shall list:

1. Existing condition and types of resilient flooring, doors, windows, walls, and other surfaces not required to be altered throughout affected areas.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and

RE/COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of RE/COR, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by the Contractor with new items in accordance with specifications which will be furnished by the Government. Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and

RE/COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report.

1. Re-survey report shall also list any damage caused by the Contractor to such flooring and other surfaces, despite protection measures; and, will form the basis for determining extent of repair work required of the Contractor to restore damage caused by the Contractor's workmen in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protect the interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 8

1.8 ENVIRONMENTAL CONTROLS

A. In general, following preventive measures shall be adopted during construction to keep down dust and prevent mold.

1. Dampen debris to keep down dust and provide temporary construction partitions in existing structures where directed by RE/COR. Block off ducts and diffusers to prevent circulation of dust into occupied areas during construction.B. Vacuum and wet mop all transition areas from construction to the occupied Cemetery buildings at the end of each workday.

C. Final Cleanup:

1. Upon completion of the project, or as work progresses, remove all construction debris from above ceiling, vertical shafts and utility chases that have been part of the construction.

1.9 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by

RE/COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from the Cemetery.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

1.10 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workmen, the Contractor shall trim

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 9 those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the RE/COR.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the

Contractor fails or refuses to repair the damage promptly, the RE/COR may have the necessary work performed and charge the cost to the Contractor.

(FAR 52.236-9)

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils and the environment. Refer to Articles, "Alterations", "Restoration", and "Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

1.11 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work.

Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, water/irrigation, or electric work without approval of the RE/COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the RE/COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged. Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, landscape stone, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At the Contractor's own expense, the Contractor shall immediately restore to service and repair any damage caused by the Contractor's workmen to existing piping and conduits, wires, cables, etc., of utility services, fire protection systems, communications systems (including telephone), ,irrigation system control, and power which are indicated on drawings and which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES" (FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING SITE

CONDITIONS" (FAR 52.236-2).

100% DESIGN SUBMISSION

01 00 02 - 10

1.12 PHYSICAL DATA

A. Data and information furnished or referred to below is for the Contractor's information. The

Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

1. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by the A/E.

(FAR 52.236-4)

D. The Government does not guarantee that other materials will not be encountered nor that proportions, conditions or character of several materials will not vary from those indicated.

Bidders are expected to examine the site of work and, after investigation, decide for themselves the character of materials and make their bids accordingly. Upon proper application to the

Department of Veterans Affairs, including approved scheduling bidders will be permitted to make subsurface explorations of their own at site.

1.13 PROFESSIONAL SURVEYING SERVICES

A registered professional land surveyor or registered civil engineer whose services are retained and paid for by the Contractor shall perform services specified herein and in other specification sections. The Contractor shall certify that the land surveyor or civil engineer is not one who is a regular employee of the Contractor, and that the land surveyor or civil engineer has no financial interest in this contract.

1.14 AS-BUILT DRAWINGS

A. The Contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, which will include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To insure compliance, as-built drawings shall be made available for the RE/COR's review, as often as requested.

C. Contractor shall hire an independent design firm to revise the construction documents (electronic

AutoCAD files) as necessary to review and submit final as-builts of installed work in both electronic (AutoCAD and PDF) format and physical drawings (1 full size set including specifications).

D. The Contractor shall deliver the approved completed set of as-built drawings to the RE/COR within 15 calendar days after acceptance of the project by the RE/COR.

E. Paragraphs A, B, D shall also apply to all shop drawings.

100% DESIGN SUBMISSION

01 00 02 - 11

1.15 USE OF ROADWAYS

A. For hauling, use only established public roads and permanent roads on Cemetery property. When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.16 TEMPORARY TOILETS

A. Provide where directed, (for use of all Contractor's workers) ample temporary sanitary toilet accommodations with suitable sewer and water connections, or when approved by RE/COR provide suitable dry closets where directed. Keep such places clean and free from flies, and all connections and appliances connected therewith are to be removed prior to completion of contract, and premises left perfectly clean.

1.17 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the

Contractor from existing outlets and supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the

Government. The Contractor shall carefully conserve any utilities furnished without charge.

B. The Contractor, at Contractor's expense and in a workmanlike manner satisfactory to the

RE/COR, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of electricity used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia.

C. The Contractor shall install meters at the Contractor's expense and furnish the Cemetery a monthly record of the Contractor's usage of electricity as hereinafter specified.

D. Heat: Furnish temporary heat necessary to prevent injury to work and materials through dampness and cold. Use of open salamanders or any temporary heating devices which may be fire hazards or may smoke and damage finished work, will not be permitted. Maintain minimum temperatures as specified for various materials:

E. Electricity (for Construction and Testing): Furnish all temporary electric services.

1. Obtain electricity by connecting to the Cemetery electrical distribution system. The Contractor shall meter and pay for electricity required for electric cranes and hoisting devices, electrical welding devices and any electrical heating devices providing temporary heat. Where not available or not convenient to connect to the Cemetery distribution system, the contractor shall supply power via portable generators at own expense. Generators shall be acoustically screened so as not to disturb committal services and/or visitation to the adjacent columbarium.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 12

F. Water (for Construction and Testing): Furnish temporary water service.

1. Obtain water by connecting to the Cemetery irrigation distribution system. Backflow preventer may not be required at connections to the irrigation system. Water is available at no cost to the Contractor.

2. If potable water is required and convenient connection is available the contractor may connect to the Cemetery potable water distribution system. The contractor shall install reduced pressure backflow preventer at each connection at own expense.

3. Maintain connections, pipe, fittings and fixtures and conserve water-use so none is wasted.

Failure to stop leakage or other wastes will be cause for revocation (at RE/COR's discretion) of use of water from the Cemetery's system.

4. Where not available or not convenient to connect to the Cemetery distribution system, the

Contractor shall supply water via portable/temporary means at his own expense.

1.18 TESTS

A. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such systems before requesting final tests. Final test will not be conducted unless pre-tested.

B. Conduct final tests required in various sections of specifications in presence of an authorized representative of the RE/COR. Contractor shall furnish all labor, materials, equipment, instruments, and forms, to conduct and record such tests.

C. Mechanical and electrical systems shall be balanced, controlled and coordinated. A system is defined as the entire complex which must be coordinated to work together during normal operation to produce results for which the system is designed. For example, air conditioning supply; air is only one part of entire system which provides comfort conditions for a building.

Other related components are return air, exhaust air, hot water, controls and electricity, etc.

Another example of a complex which involves several components of different disciplines is a burner installation. Efficient and acceptable burner operation depends upon the coordination and proper operation of fuel, combustion air, controls, and other related components.

D. All related components as defined above shall be functioning when any system component is tested. Tests shall be completed within a reasonably short period of time during which operating and environmental conditions remain reasonably constant.

E. Individual test result of any component, where required, will only be accepted when submitted with the test results of related components and of the entire system.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 13

1.19 INSTRUCTIONS

A. The Contractor shall furnish Maintenance and Operating manuals and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

B. Manuals: Maintenance and operating manuals (four copies each) for each separate piece of equipment shall be delivered to the RE/COR coincidental with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include

"exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: the Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed instructions to assigned Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment. All such training will be at the job site. These requirements are more specifically detailed in the various technical sections.

Instructions for different items of equipment that are component parts of a complete system; shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed. This is to assure proper instruction in the operation of inter-related systems. All instruction periods shall be at such times as scheduled by the RE/COR and shall be considered concluded only when the RE/COR is satisfied in regard to complete and thorough coverage. The Department of Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in the opinion of the RE/COR, does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.20 GOVERNMENT-FURNISHED PROPERTY

A. The Government shall deliver to the Contractor, the Government-furnished property shown on drawings.

B. Materials furnished by the Government to be installed by the Contractor will be furnished to the

Contractor at the Cemetery.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 14

C. Storage space for materials will be provided by the Contractor and the Contractor shall be prepared to unload and store such equipment therein upon its receipt at the Cemetery.

D. Notify RE/COR in writing, 60 days in advance, of date on which Contractor will be prepared to receive materials furnished by Government. Arrangements will then be made by the Government for delivery of materials.

1. Immediately upon delivery of materials, the Contractor shall arrange for a joint inspection thereof with a representative of the Government. At such time the Contractor shall acknowledge receipt of materials described, make notations, and immediately furnish the

Government representative with a written statement as to its condition or shortages.

2. The Contractor thereafter is responsible for such material until such time as acceptance of contract work is made by the Government.

E. Equipment furnished by the Government will be delivered in a partially assembled (knock down) condition in accordance with existing standard commercial practices, complete with all fittings, fastenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the like) necessary to make the connection between the Government furnished equipment item and the utility stub-up shall be furnished and installed by the contractor at no additional cost to the Government.

F. Completely assemble and install the Government furnished equipment in place ready for proper operation in accordance with specifications and drawings.

G. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

1.21 RELOCATED EQUIPMENT AND ITEMS

A. Contractor shall disconnect, dismantle as necessary, remove and reinstall in new location, all existing equipment and items indicated by symbol "R" or otherwise shown to be relocated by the

Contractor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the RE/COR.

C. Suitably cap existing service lines, such as water, drain, gas, air, and/or electrical, whenever such lines are disconnected from equipment to be relocated. Remove abandoned lines in finished areas and cap as specified herein before under paragraph "Abandoned Lines".

D. Provide all mechanical and electrical service connections, fittings, fastenings and any other materials necessary for assembly and installation of relocated equipment; and leave such equipment in proper operating condition.

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 15

E. All service lines such as noted above for relocated equipment shall be in place at point of relocation ready for use before any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

1.22 CONSTRUCTION DIGITAL IMAGES

A. During construction period through completion, furnish Department of Veterans Affairs weekly color digital photographs of construction progress (50 to 100 images per week.) Photographs of the reinforcing steel shall be taken after all reinforcing steel, sleeves, inserts, etc. are in place but prior to setting of runways. Photographs must show distinctly, at as large a scale as possible, all parts of work embraced in picture.

B. Photographs are to be taken with a high-resolution digital camera, minimum 6 megapixels, with good wide-angle capability. The images shall be recorded in JPEG format with a minimum of 24-bit color and no reduction in actual picture size.

1. Compressed size of the file shall be no less than 80% or the original with no loss of information.

2. File names shall contain the Project number, the date the image was taken, and a unique sequential identifier, for example: 101CM3202_10-01-2013_0001. Use underscore, not spaces in digital file names.

C. The digital photo files shall become property of Government and will be both e-mailed and submitted on CD-ROM.

1. The images shall be forwarded electronically to the COR/Project Manager via email to

NAME@va.gov within 2 days of when the photo was taken. Identify the content of each picture by a caption incorporated in the photo.

2. The digital photo files shall also be submitted on CD-ROM to the COR/Project Manager at the conclusion of the project. The CD-ROM shall also contain an index of all the images contained therein in either a TXT or Microsoft Word format.

1.23 HISTORIC PRESERVATION

A. Where the Contractor or any of the Contractor's employees, prior to, or during the construction work, are advised of or discover any possible archeological, historical and/or cultural resources, the Contractor shall immediately notify the RE/COR verbally, and then with a written follow up.

1.24 PROJECT HEALTH AND SAFETY PLAN

A. Prior to commencing any construction, the Contractor shall submit a site specific Project Health and Safety Plan (PHSP). At a minimum, the PHSP shall cover the following topics:

1. Organizational structure (including Responsible Persons)

100% DESIGN SUBMISSION

GENERAL REQUIREMENTS

01 00 02 - 16

2. Site Characterization and Job Hazard Identification

3. Site Control and Security

4. Training

5. PPE

6. Heat Stress

7. Spill Containment

8. Decontamination

9. Emergency Response

10. Trench Safety

- - - E N D - - -

NETWORK ANALYSIS SCHEDULE

01 32 17-1

SECTION 01 32 17

NETWORK ANALYSIS SCHEDULES

(MICROSOFT PROJECT GANTT CHART)

PART 1 - GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Microsoft Project 2003 (or later) Gantt Chart (bar chart) schedule demonstrating fulfillment of the contract requirements. The Contractor shall keep the network up-to-date in accordance with the requirements of this section. The Contractor shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). The Gantt Chart will be utilized to satisfy time applications.

1.2 CONTRACTOR’S REPRESENTATIVE:

A. The Contractor shall designate an in-house representative who will be responsible to prepare the schedule, review the schedule and report progress of the project to the Contracting Officer's

Representative.

B. The Contractor's in-house representative shall be given authority to act on behalf of the

Contractor in fulfilling the requirements of this specification section. Such authority shall not be interrupted throughout the duration of the project.

1.3 COMPUTER PRODUCED SCHEDULES:

A. The contractor shall provide to VA monthly computer processing of all computer produced schedules generated from monthly project updates. The Contractor shall provide to VA two (2) copies of the updated Microsoft Project Gantt Chart and an electronic copy of this data. This must be submitted with and substantively support the contractor’s monthly payment request.

B. The Contractor is responsible for the correctness and timeliness of the computer-produced reports. The Contractor is also responsible for the accurate and timely submittal of the updated project schedule.

C. VA shall report errors in computer-produced reports to the Contractor’s representative within ten

(10) calendar days from receipt of reports. The Contractor shall reprocess the Gantt Chart and associated CDs, when requested by the Contracting Officers Representative, to correct errors that affect the schedule for the project.

1.4 THE COMPLETE PROJECT GANTT CHART SUBMITTAL:

A. The Complete Project Microsoft Project Gantt Chart will contain sufficient work activities/events as necessary to fully detail the project schedule.

B. Within ten (10) calendar days after receipt of the Notice to Proceed, the Contractor shall submit for the Contracting Officer's review, a Microsoft Project Gantt Chart and a CD. Each activity/event on the Gantt Chart schedule shall contain as a minimum, but not limited to, activity/event description, duration, start dates and finish dates. Activity constraints, not required

01 32 17-2 by the contract, will not be accepted. Logic events (non-work) will be permitted where necessary to reflect proper sequence among work events, but must have zero duration.

C. The complete working Gantt Chart shall reflect the Contractor's approach to scheduling the complete project. The final Gantt Chart in its original form shall contain no contract changes or delays that may have been incurred during the final Gantt Chart development period. It shall reflect the Contractors “AS BID” or “DAY 1” schedule. Changes and /or delays shall be entered at the first monthly update after the final Gantt Chart has been approved. The Contractor should provide their requests for time and supporting time extension analysis for contract time as a result of contract changes/delays, after this update, and in accordance with Article, ADJUSTMENT OF

CONTRACT COMPLETION.

D. Within ten (10) calendar days after receipt of the complete project Gantt Chart, the Contracting

Officer or his representative, will do one or both of the following:

1. Notify the Contractor concerning his actions, opinions, and objections.

2. Schedule a meeting with the Contractor at, or near the job site, for joint review, correction or adjustment of the proposed plan. Within ten (10) calendar days after the joint review, the

Contractor shall revise and shall submit two (2) copies of the revised Gantt Chart and a revised CD as specified to the Contracting Officer. The revised submission will be reviewed by the Contracting Officer and, if found to be as previously agreed upon, will be approved.

1.5 WORK ACTIVITY/EVENT AND COST DATA INFORMATION:

A. The Contractor shall not be required to “cost load” the computerized Microsoft Project Gantt

Chart. As part of this submission, the Contractor shall provide a separate Schedule of Costs on

AIA document G703. This Schedule of Costs shall reflect and contain all the same activities/events identified on the Gantt Chart.

B. The Contractor and the Contracting Officer shall use this Schedule of Costs for monthly payment purposes as referenced in the General Conditions of this agreement.

C. The Contractor and Contracting Officer shall agree on percentages for monthly work accomplished. The cumulative total amount of all cost loaded activities/events (including alternates) shall equal the total contract price.

D. Prorate overhead, profit and general conditions on all work activities/events for the entire project.

Negative work activity/event cost data will not be acceptable, except on VA issued contract changes.

1.6 GANTT CHART REQUIREMENTS:

A. Show on the Gantt Chart the sequence and interdependence of work activities/events required for complete performance of all items of work. In preparing the Gantt Chart, the Contractor shall:

1. Show the following on each work activity/event:

a. Concise description of the work represented by the activity/event.

b. Duration (in work days.)

01 32 17-3

2. Show activities/events as:

a. Contractor's time required for submittal of shop drawings, templates, fabrication, delivery and similar pre-construction work.

b. Contracting Officer Representative's and Architect-Engineer's review and approval of shop drawings, equipment schedules, samples, template, or similar items.

c. Interruption of VA Cemetery utilities, delivery of Government furnished equipment, project phasing and any other specification requirements.

d. Test, balance and adjust various systems and pieces of equipment.

SPEC WRITER NOTE: Use the following on multiple phased projects only.

e. VA inspection and acceptance activity/event with a minimum duration of five (5) work days at the end of each phase and immediately preceding any VA move activity/event required by the contract phasing for that phase.

3. Break up the work into activities/events of durations no longer than thirty (30) work days each, except as to non-construction activities/events (i.e., procurement of materials, delivery of equipment, concrete and asphalt curing) and any other activities/events for which the

Contracting Officer may approve the showing of a longer duration.