SPECIFICATIONS dated 10 June 2020.pdf

CASTAÑO & ASOCIADOS

CERTIFIED PASSIVE HOUSE DESIGNER

Sevilla Budapest Tlfno.: +34.644.595.525 Tlfno.:+36 1 700 1200 Edificio Marie Curie, Avenida Leonardo da Vinci. 18 Fogaskerekü utca 4-6/ 5 epület Planta 2. Módulo 2. 1125 Budapest, Hungary 41092 Sevilla

Juan Manuel Castaño Salvador Móvil:+34.610.777.219 jm.castano@castanoyasociados.com www.castanoyasociados.com CASTAÑO & ASOCIADOS CONSTRUCCIÓN SOSTENIBLE S.L., C.I.F.: B90197807 Inscrita en el Registro Mercantil de Sevilla Hoja SE105118 Tomo 6013 Folio 41 Inscripción 1

100% DESIGN SUBMITTAL

SPECIFICATIONS

USMC PEB (REVISION A)

A/E FIRM: CASTAÑO&ASOCIADOS

PROJECT NUMBER: QUUG 19-1011

CONTRACT NUMBER: FA557517D0001

DELIVERY ORDER: FA557519FA004

At MORON AIR BASE, SPAIN

USAFE_U.S. AIR FORCE IN EUROPE

June 2020

1/225 mailto:jm.castano@castanoyasociados.com http://www.castanoyasociados.com/

PREPARED FOR DEPARTMENT OF THE

AIR FORCE

BY

CASTAÑO & ASSOCIATES

(CASTAÑO Y ASOCIADOS CONSTRUCCIÓN SOSTENIBLE, S.L.)

TECHNICAL PROVISIONS & SPECIFICATIONS FOR:

PROJECT QUUG 19-1011

USMC PEB (REVISION A)

Prepared by: __________________________________________________________________

Name: Juan Manuel Castaño Salvador, Architect (DOR) Date: 10 June 20

Name: Juan Manuel Castaño Reyes, Technical Architect Date: 10 June 20

Name: Juan de Dios Montero Naranjo, Building Engineer Date: 10 June 20

Name: María Vico García, Architect Date: 10 June 20

Name: Martín Benjumea Delgado, Architect Date: 10 June 20

Name: Rubén de la Rosa Morales, Technical Architect Date: 10 June 20

Name: Helena Cumbreras Torrente, Architect Date: 10 June 20

Name: Irene García Sáez, Architect Date: 10 June 20

2/225

LIST OF SPECIFICATIONS

DIVISION 01 - GENERAL REQUIREMENTS # of pages

01 11 00 Scope of Work, Drawings and Special Conditions 5

01 11 01 General Conditions 33

01 11 02 Special Conditions 3

DIVISION 02 - EXISTING CONDITIONS

02 41 00 Demolition and deconstruction 8

DIVISION 03 - CONCRETE

03 30 00 Cast-In-Place Concrete 8

DIVISION 05 – METALS

05 05 23.16 Structural Welding 4

DIVISION 22 - PLUMBING

22 00 00 Plumbing 13

DIVISION 26 – ELECTRICAL

26 00 00.00 20 Basic Electrical Materials and Methods 8

26 20 00 Interior Distribution System 13

26 56 00 Exterior Lighting 7

DIVISION 31 – EARTHWORK

31 00 00 Earthwork 10

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 03 30 Enbankment 8

32 04 22 Geotextile as separation and filter element 3

32 05 10 Aggregates 6

32 05 12 Soils stabilized in-situ 9

32 05 30 Prime Coat 3

32 05 31 Tack Coat 2

3/225

32 05 32 Curing Coat 3

32 05 42 Hot Mix Bituminous Pavement 11

32 07 01 Retroreflective Traffic Signs 2

32 16 19 Concrete curbs, gutters and sidewalks 8

32 17 23 Pavements markings 2

32 31 13 Chain Link Fence and Gates 7

32 92 19 Seeding 9

DIVISION 33 - UTILITIES

33 30 00 Sanitary Sewer 10

33 40 00 Storm Drainage Utilities 4

33 71 02 Underground electrical distribution 17

33 82 00 Telecommunications Outside Plant 5

4/225

01 11 00 - 1

SECTION 01 11 00

SCOPE OF WORK AND DRAWINGS

1. SCOPE OF WORK: The scope of work consists of the furnishing of all the labor, materials, plants, transportations, equipment and services to accomplish all the work, in strict accordance with the drawings and specifications, complete and ready for use under a firm fixed price construction contract. The work includes, but is not limited to the following activities, which include the tests to be performed by an independent laboratory for the quality control:

BASE BID: CONCRETE PAD FOR SECURITY CONTAINERS, PERIMETER FENCE

AND ELECTRICAL WORKS

Perform all below detailed works in the area indicated in drawings, for the full earthworks and construction of a concrete pad where two security containers are expected to be installed, including electrical installation and a perimeter fence with three barbed wire.

Works to be performed are the following:

Civil Works

a. Clean and grubbing the area affected by the works.

b. Excavation, cut and fill works for concrete slab.

c. Grading and leveling works for the subgrade of the slab.

d. Compaction of the subgrade

e. Placing and compaction of the subbase and base courses.

f. Install information signs as required.

g. Install perimeter chain link fence with 3 strand barbed wire, single extension arm, main double swinging door gates as indicated in project drawings.

h. Transport security containers from the Base storage to new concrete pad and install in the assigned place.

Concrete Works

a. Pour lean concrete and screed the bedding layers for slab.

b. Install form work as indicated.

c. Install steel rebars and wire mesh for concrete slab as required.

d. Construct connection manholes for electric power and communications.

e. Install required elements for building connection in accordance with project drawings.

f. Pour concrete and screed to complete the foundation elements IAW the approved design.

5/225

01 11 00 - 2

Electrical Works

a. Provide electrical service lines to security container from existing panel boards

b. Provide grounding system for mobile containers and new fence

c. Modify route of existing High Voltage underground line, surrounding new concrete slab.

Mechanical Works

a. Provide a new Double Check Valve Assembly in the Fire Protection line of the Building.

b. Provide new Reduced Pressure Principle Device in the sanitary water line.

c. Provide new water meter in the sanitary water line, to be installed above surface, in the same pipe section than the new Reduced Pressure Principle Device.

Miscellaneous

a. Testing and Commissioning.

b. Final cleaning.

c. Delivery of As-built drawings.

d. Delivery of Spatial Data.

ADDITIONAL OPTION 1: CONCRETE SLAB FOR PEB ADDITION

Civil Works

a. Clean and grubbing the area affected by the works.

b. Excavation, cut and fill works for concrete slab.

c. Grading and leveling works for the subgrade of the slab.

d. Compaction of the subgrade

e. Placing and compaction of the subbase and base courses.

f. Construct sidewalks as indicated in project drawings.

g. Landscaping of the ground area as indicated.

Concrete Works

a. Pour lean concrete and screed the bedding layers for slab.

b. Install form work as indicated.

c. Install steel rebars and wire mesh for concrete slab as required.

d. Construct connection manholes for electric power and communications.

e. Install required elements for building connection.

f. Pour concrete and screed to complete the foundation elements IAW the approved design.

Telecommunication works

6/225

01 11 00 - 3

a. Demolish the existing line section crossing the area affected by the new PEB concrete slab

b. Provide new communication ductbank from the existing handhole located at the west side of the building, surrounding it, and connecting to the existing handhole of the main façade. Coordinate these works with MAB communications department.

ADDITIONAL OPTION 2: NEW ASPHALT PARKING LOT

a. Clean and grubbing the area affected by the works.

b. Excavation, cut and fill works for asphalt pavement.

* Special caution shall be taken to existing Electrical HV posts close to the excavation areas, avoiding damages on existing lines, and taken the required measures for pilling and bracing.

c. Grading and leveling works for the subgrade of asphalt pavements.

d. Compaction of the subgrade for asphalt pavements. Placing and compaction of the subbase and base courses of pavements.

e. Apply prime coat for asphalt pavement.

f. Apply asphalt intermediate layer for asphalt pavement.

g. Apply tack coat for asphalt pavement.

h. Apply wearing layer for asphalt pavement.

i. Construct drain swales, ditches, channels, trench channels, grates, catch basin, manholes, collectors and hydrocarbons separator for parking lot and storage area IAW the SWPPP as required.

j. Install prefabricated concrete drain channel curb along the access road sides and around the parking lot.

k. Construct complete culvert pipe, headwall and wingwalls for access road.

l. Install curbs for parking area.

m. Paint markings.

n. Install traffic and information signs as required.

o. Install Rubber Wheel Stops

Mechanical Works

a. Replace hydrants w/ American standards including a hose connection adapter, and hydrant painting in accordance with code standard.

b. Demolish existing sewer line running below the new asphalt area

c. Provide new sewer line adjacent to the parking area

d. Demolish existing water lines running below new asphalt area.

e. Provide new water lines, adjacent to parking area, for building sanitary water and for Fire hydrants and building Fire Department hose connections, including indicated valves.

Fire Protection

a. “Fire Lane” text painting in existing concrete storage area

ADDITIONAL OPTION 3: EXTERIOR LIGHTING

7/225

01 11 00 - 4

Electrical Works

a. Provide lighting system with LED projectors to provide at least, minimum illuminance values required for parking areas

b. Construct electrical ductbank to new lighting items.

ADDITIONAL OPTION 4: NEW TELECOMMUNICATION LINE

Telecommunication works

a. Provide a new communication ductbank to the Security Containers directly from the existing communication connection point, as defined in project drawings. Coordinate these works with

MAB communications department.

ADDITIONAL OPTION 5: SECURITY CONTAINERS ELECTRICAL RETROFITTING

Electrical Works*

a. Replace existing HVAC units in security containers, providing new units, in same quantity and features, that are compliant with American Electrical Standards (NFPA 70, Unified Facilities

Criteria and applicable local codes).

b. Replace existing dehumidifiers units, providing new ones, in same quantity and features, that are compliant with American Electrical Standards (NFPA 70, Unified Facilities Criteria and applicable local codes).

c. Replace existing Electrical Shunt Trip Disconnect Panel, Electrical Panelboard, Circuit Breakers, conduits and receptacles, providing new materials of the same characteristics in compliance with

American Electrical Standards (NFPA 70, Unified Facilities Criteria and applicable local codes).

d. Replace existing Luminaires, providing new ones in accordance with American Electrical

Standards, ensuring adequate illuminance levels in accordance with applicable code (NFPA 70, Unified Facilities Criteria and applicable local codes).

Contractor is responsible for inspecting the existing conditions of the security containers, and replace all electrical components to ensure full compliance with U.S.A. applicable standards. Some electrical items may not have been shown on project documents. Is part of the Contractor investigation to identify all items to be replaced as part of the contract, whether they are included in project documents or not.

8/225

01 11 00 - 5

2. DRAWINGS:

No. of

Drawing

Sheet Date Title

R-770-01 01 of 37 G001 June 2020 Cover sheet, drawing index

R-770-02 02 of 37 G101 June 2020 Scope of work

R-770-03 03 of 37 GC101 June 2020 Contractor Haul Routes

R-770-04 04 of 37 GR101 June 2020 Security Containers: Existing Conditions

R-770-05 05 of 37 CD101 June 2020 Existing utilities and Civil Demolitions

R-770-06 06 of 37 CD102 June 2020 Existing topography. General Plan

R-770-07 07 of 37 CD103 June 2020 Existing topography. Sections I

R-770-08 08 of 37 CD104 June 2020 Existing topography. Sections II

R-770-09 09 of 37 CD105 June 2020 Existing topography. Sections III

R-770-10 10 of 37 C101 June 2020 New Site Plan

R-770-11 11 of 37 C102 June 2020 New Topography. General Plan

R-770-12 12 of 37 C103 June 2020 New topography. Sections I

R-770-13 13 of 37 C104 June 2020 New topography. Sections II

R-770-14 14 of 37 C105 June 2020 New topography. Sections III

R-770-15 15 of 37 C106 June 2020 New topography. Sections IV

R-770-16 16 of 37 C107 June 2020 New topography. Sections V

R-770-17 17 of 37 C108 June 2020 New topography. Sections VI

R-770-18 18 of 37 C109 June 2020 Concrete Pavement Joint Plan

R-770-19 19 of 37 C110 June 2020 New drainage system

R-770-20 20 of 37 C501 June 2020 Civil Details I

R-770-21 21 of 37 C502 June 2020 Civil Details II

R-770-22 22 of 37 C503 June 2020 Civil Details III

R-770-23 23 of 37 C504 June 2020 Civil Details IV

R-770-24 24 of 37 S101 June 2020 Structural. PEB Addition Concrete Pad

R-770-25 25 of 37 S102 June 2020 Structural. Security Containers Concrete Pad

R-770-26 26 of 37 PP101 June 2020 Plumbing

R-770-27 27 of 37 PS101 June 2020 Sewer

R-770-28 28 of 37 P501 June 2020 Plumbing Details

R-770-29 29 of 37 P502 June 2020 Sewer Details

R-770-30 30 of 37 EP101 June 2020 Electrical Exterior Power

R-770-31 31 of 37 EL101 June 2020 Electrical Exterior Lighting

R-770-32 32 of 37 EG101 June 2020 Grounding System

R-770-33 33 of 37 E501 June 2020 Electrical Details I

R-770-34 34 of 37 E501 June 2020 Electrical Details II

R-770-35 35 of 37 E601 June 2020 Electrical Diagrams

R-770-36 36 of 37 T101 June 2020 Telecommunications

R-770-35 37 of 37 T501 June 2020 Telecommunications Details

*** END OF SECTION ***

9/225

01 11 01 - 1

SECTION 01 11 01

GENERAL CONDITIONS

1. GENERAL: The work consists of furnishing all labor, materials, utilities, transportation, equipment, and services to execute the project. In accordance with the drawings and specifications, complete and ready for use. Measurements shown on the drawings and specifications are given for reference use only. It is the Contractor’s responsibility to verify any and all of measurements.

2. GENERAL DESCRIPTION: The work consists in, but is not limited to, executing the line items indicated in the scope of work. All line items indicated in the scope of work do not limit nor reduce the Contractor’s responsibility to perform all work as required by the project in order to provide a complete and usable facility.

3. LOCATION: The work is located at the USMC PEB area between A & B Avenues with access from 7th Street, adjacent to fenced area of BLDGs #939 and #923. In Morón Air Base, Spain, as shown on the contract drawings.

4. DRAWINGS ACCOMPANYING SPECIFICATIONS: Drawings are the property of the

Government and shall not be used for any purpose other than that contemplated by the specifications. The drawings indicated in the specifications are in A1 size.

5. WARRANTY: For this contract the Contractor shall provide a two year standard commercial warranty for with all line items of the scope of work, including materials and workmanship. The warranty shall cover all defects noticed and reported to the Contractor within two years after acceptance of the work. The Contractor shall repair or replace defective materials at their expense within a reasonable time and as approved by the Contracting Officer. The Contractor must comply with any additional warranty periods established by Spanish codes and regulations. The

Contractor shall submit the warranty letter within 15 calendar days after to the acceptance of the work by the Contracting Officer.

6. NOTICE TO PROCEED:

6.1. Design-Build Contracts: This document is applicable to both Construction and Design

Build Contracts. In the below sections, Design Notice to Proceed (DNTP) and Construction Notice to Proceed (CNTP) appear. These are specified for the purposed of Design Build contracts.

Contractors should request a CNTP from the Contracting Officer when preparing to mobilize for construction, the CNTP can be requested before design has been finalized.

6.2. Construction Contracts: The contractor will be provided one Notice to Proceed (NTP), in the subsequent sections both DNTP and CNTP are applicable for the NTP date.

10/225

01 11 01 - 2

7. BASE ACCESS:

7.1. Permits or Authorizations: The Contractor shall obtain all permits or authorizations required to access Morón Air Base. Once the works have finalized, the Contractor will return the permits or authorizations. Contractor is responsible to provide the required escorts as required to execute the works.

7.2. Delays and Interruptions: The Contractor is advised that delays are liable to occur, due to security reasons, during the access/egress process of personnel and materials from Morón Air

Base. Additionally, the Contractor shall immediately interrupt the work when it is required if security warning/risk situations occur. The contractor shall submit in writing, excess delays (90 minutes or more) experienced due to base access.

8. WORK CLEARANCE REQUEST:

8.1. Within 5 calendar days after the notice to proceed (CNTP) date, the Contractor shall request

AF Form 103 “BCE Work Clearance Request” to Construction Management in order to obtain all the information pertaining to the current status of Base utilities. Additional requests shall be submitted to Construction Management 15 calendar days in advance, at minimum. The Contractor shall not perform any work under any circumstances without having the approved Work Clearance at the construction site (hard copy) and not before having marked at the site with stakes and/or pins the location of the utilities. Work Clearance Request shall only be processed once all materials and documentation necessary to commence work have been submitted and approved. The

Contractor shall be responsible for any damage caused to Base utilities shown on the AF Form 103 and project drawings and shall be responsible for the repairs without additional cost to the

Government.

8.2. Return entire permit to Geobase Office after completion of digging excavating activities.

If additional utilities are located or encounters (or marked utilities are not found in their expected locations) then the requester shall provide an as-built sketch to Geobase office precisely detailing the location(s) of all utilities that were found to not be in the location expected.

9. BASE UTILITIES:

9.1. The Contractor, at its expense and in coordination with the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, and associated accessories.

11/225

01 11 01 - 3

9.2. Use of Base Utilities: Water, sewage and electrical utilities may be available to the

Contactor, when feasible and their consumptions are reasonable, for supply to the following buildings: Offices, latrines, break rooms and laboratories. If not available and the contractor requires it, the contractor is shall provide at no additional cost to the government.

Other utilities, apart from the listed below, shall be supplied by the Contractor at no cost to the

Government.

The following utilities are available from the existing Base utilities:

1. Electricity: 120/208 volts, 60 Hz.

2. Non-potable water.

9.3. Base utility connection and/or disconnection: 15 calendar days before the connection/disconnection date, the Contractor shall request the connection and/or disconnection and shall indicate:

1. Type of utility required

2. Type of connection and/or disconnection to be performed

3. Utility use

4. Required consumption

5. Maximum duration

All connection and/or disconnection works of Base utilities shall be programmed between 08:30 and 16:00 hours (between 08:30 to 15:00 during the period from 15 June to 15 September) from

Monday to Friday, except holidays. The utility connections and/or disconnections can be considered critical by the Government, in which case they shall be performed on the date and time most convenient to the Government, i.e. weekends and/or during nighttime hours, without additional cost to the Government. The Contractor shall be responsible for making connections and/or disconnections, conversion, transportation of Base utility to the work site, including the furnishing and installation of the mechanisms that prevent the backflow of water to the Base service (backflow preventers) and the furnishing and installation of the transformers, if required.

The Contractor shall not activate or alter any control device of the Base utilities including water, sewage and electricity. The Government shall operate said control devices. The Contractor shall submit additional requests to Construction Management with a minimum of 15 calendar days in advance of the estimated date for the required connection, disconnection or control maneuver of the corresponding utility. The temporary overhead connections to utility are prohibited. All utilities

12/225

01 11 01 - 4 shall be restored to their original condition prior to satisfying final contractual payments.

9.4. Base Utility Outages: When a utility outage is necessary, the Contractor shall request the utility outage, at least 15 calendar days in advance of the work, and shall indicate:

1. Type of affected utility

2. Type of cut to be performed

3. Maximum duration

All utility outages shall be scheduled from 08:30 and 16:00 hours (from 08:30 to 15:00 during the period from 15 June to 15 September) from Monday to Friday, except holidays. The utility outages can be considered critical by the Government, in which case they shall be performed on the date and time most convenient to the Government, i.e. weekends and/or during nighttime hours, without

Government cost. The Contractor shall be responsible for making the outage, including the provision and installation of devices and materials. The Contractor shall not activate or alter any control device of the Base utilities, including water, sewage and electricity. The Government shall operate said control devices. Temporary overhead connections to utility are prohibited. All systems shall be restored to their original condition prior to satisfying final contractual payments.

10. HOT WORK: The Contractor shall submit for approval a written request to Construction

Management 15 calendar days prior to any welding, as oxyacetylene or plasma cutting work. Said request shall indicate welding procedures and fire prevention measures. All welding work performed during the project execution shall be carried out by qualified welders only. The copies of the welder certificates, issued by an approved agency, shall be kept in the construction inspector’s files.

11. VEHICULAR, MACHINERY AND EQUIPMENT TRAFFIC:

11.1. Transit Control Plan: All works requiring vehicular or pedestrian traffic disruptions on the

Base shall require an approved transit control plan. Said plan shall be approved at least 15 calendar days prior to carrying out said disruption. Said plan shall include:

1. Start date of the traffic disruption

2. Duration of the traffic disruption

3. Proposed alternative routes

4. Signs, barriers, cones, flags and/or flagmen to be implemented

The Contractor shall establish alternate procedures if unforeseen circumstances take place. The responsibility of the provision, erecting, keeping and removing all signs, barriers, cones and flags

13/225

01 11 01 - 5 shall be solely the Contractor. Once the work is completed, the Contractor shall remove the signaling elements such as signs, barriers, cones and/or flags.

11.2. Access Route Plan: 10 calendar days after the notice to proceed (NTP) date, the Contractor shall submit an access route plan to Construction Management for its approval by Contracting

Officer or authorized representative.

11.3. Trucks: Trucks loaded with loose material (volatile dust, construction debris or other objects that could fall from them) shall be duly covered. Said covers (tarpaulins, etc.) shall be securely secured and placed on the load before accessing the Base roads.

12. STOCKPILING:

12.1. Stockpiling area of demolished/removed material: The Contractor shall transport the demolished or excavated materials to an authorized dump. Should any of the Morón Air Base shops need all or part of any of the materials from the demolition operations (concrete, aggregate and natural ground), the Contracting Office representative shall coordinate with the base Construction

Management office on the exact location to stockpile said material.

12.2. Stockpiling area for Contractor material and Contractor offices: The C.O. representative shall coordinate with the base Construction Management office the exact location for Contractor offices and stockpiling.

13. CONSTRUCTION SCHEDULE:

13.1. It shall be the sole responsibility of the Contractor to ensure all required submittals are submitted for approval in a timely manner, which shall not incur any delay in completion of the project. For materials or equipment requiring a long term of procurement and delivery, said term shall be included in the period of performance. Delay in delivery/procurement will not justify an extension of the period of performance.

13.2. The Contractor shall submit an updated Construction Schedule within 7 calendar days after the Notice to Proceed (CNTP) date and when requested by the Contracting Officer or his authorized representative. In no case is the Contractor required to submit an updated more frequently than 20 working days.

13.3. The Construction Schedule shall include a Gantt chart showing each task, including task description, identification number, duration in calendar days, earliest start and finish dates, predecessor and successor task identification numbers, critical path and float that a task in the project network can be delayed without causing a delay to the subsequent task/s (free float) and to the project completion date (total float). The critical path shall be shown by means of a red color line and the float by means of black line after the predecessor task bar.

14/225

01 11 01 - 6

13.4. The Construction Schedule shall show the whole week, from Monday through Sunday. The labor days shall be from Monday through Friday. Saturday and Sunday shall be non-labor days. The holidays shall not be considered on the Construction Schedule and, therefore, they shall be considered labor days for Construction Schedule development purpose only.

13.5. The Construction Schedule shall be developed assuming 8-working hours for each labor days.

13.6. The Construction Schedule must include the following tasks if required:

13.6.1. Preconstruction tasks:

1. Preparation and transmittal of the bond and insurance submittals.

2. Preparation, transmittal, and approval of the submittals shown on document

Schedule of Material Submittals (progress schedule, mobility plan, project sign, quality control plan, key staff, health and safety plan, environmental protection plan, AF Form 103 BCE Work Clearance Request, utility connection request, utility outage requests, welding work request, transit control plan, access routes, materials and equipment).

3. Procurement, fabrication and delivery on construction site of long lead time materials, equipment and fabricated assemblies.

4. The installation of the portable/modular buildings (rest room, dressing room, dining room, first aid, office, if required).

5. The installation of temporary connections from the portable/modular buildings to the utilities of the base.

6. The installation of the temporary fence and fabric plastic mesh along the perimeter of the area assigned for the Contractor (equipment and material storage, personnel vehicle parking area, portable/modular buildings, off-construction site disposal and waste area, if required).

7. The installation of the project sign.

8. The installation of the temporary plastic Jersey barriers filled with water, fence, fabric plastic mesh, cones and lights along the perimeter of the construction site.

9. The installation of the temporary signs, barriers, cones and flags along the transit routes.

15/225

01 11 01 - 7

10. The installation of the temporary occupational safety and health signs

(prohibition, mandatory, warning, help, fire prevention, danger, directional board) at the area assigned for the Contractor.

11. The installation of the temporary occupational safety and health signs at the construction site.

13.6.2. Construction tasks:

1. The construction tasks shown on the AF Form 3052, Construction Cost

Estimate Breakdown, including testing, curing time and the submission of the delivery tickets of the waste and construction debris and the approval of the field test result data.

13.6.3. Finish tasks:

1. Required testing.

2. Commissioning.

3. Pre-final inspection, including the request.

4. Correction of deficiencies.

5. Final inspection, including the request.

6. The removal of the temporary occupational safety and health signs at the construction site.

7. The removal of the temporary plastic Jersey barriers filled with water, fence, fabric plastic mesh, cones and lights along the perimeter of the construction site.

8. Final cleaning.

9. The removal of the temporary signs, barriers, cones and flags along the transit routes.

10. The removal of the project sign.

11. The removal of the temporary occupational safety and health signs at the area assigned for the Contractor.

16/225

01 11 01 - 8

12. The removal of temporary connections to the utilities of the base, including the preparation and transmittal of the utility disconnection request, the utility outage request and the approval of the Government.

13. The removal of the portable/modular buildings.

14. The removal of the temporary fence and fabric plastic mesh along the perimeter of the area assigned for the Contractor.

15. Restoration of the area assigned for the Contractor.

16. Preparation and transmittal of the letter submittal about the inventory of all excess supplies, materials and equipment imported duty free for use under this contract.

17. Preparation and transmittal of the As-Built drawing submittal.

18. Preparation and transmittal of the spatial data submittal.

19. Preparation and transmittal of the warranty letter submittal.

20. Preparation and transmittal of the submittal of a certificate from the authorized dump about the estimated amounts or waste and construction debris managed during the execution of the project.

21. Approval of the submittals.

22. Project closeout.

14. PROGRESS SCHEDULE (AF Form 3064): Within the 10 calendar days after the notice to proceed (DNTP) date or another period determined by the Contracting Officer, the Contractor shall develop and submit a practicable schedule to Construction Management for its approval by Contracting Officer or authorized representative. The plan shall show:

1. Activity sequence that the Contractor proposes to perform the work

2. Dates proposed by the Contractor for the start and completion of the salient features of the work (including the acquiring of materials, plant and equipment)

The progress schedule of the work shall be delivered in the line graphic format at an adequate scale indicating the percentage of work scheduled every 15 calendar for its execution during the performance period. The programmed works shall correspond to the line items of the cost estimate of the contract. If the Contractor fails to submit a progress schedule of the works within the established period, the Contracting Officer may withhold the approval of the progress payments

17/225

01 11 01 - 9 until the Contractor submits the required progress schedule.

15. PROGRESS REPORT (AF Form 3065): Every 15 calendar days progress report to be submitted to Construction Management Office in accordance with previously submitted

Progress Schedule AF Form 3064. If the Contractor fails to submit a progress report of the works within the established period, the Contracting Officer may withhold the approval of the progress payments until the Contractor submits the required progress schedule.

16. WORK PLAN

16.1. The Contractor shall submit a Work Plan within 7 calendar days after the Notice to Proceed

(CNTP) date. The Work Plan shall present the construction activities planned to take place. The Work

Plan shall be prepared in coordination with the Health and Safety Plan and the Quality Control Plan and shall contain the following:

1. The summary of the proposed methodology for the execution of each task required for the project completion.

2. The resources to be used for the execution of each task required for the project completion describing the equipment and personnel to be used.

3. Daily production for each task required for the project completion.

17. MOBILITY PLAN: The Contractor shall submit a mobility plan to Construction Management for its approval by Contracting Officer or authorized representative. Said plan shall show:

4. Location and area of the work site

5. Location and area of the offices

6. Location and area of the parking area

7. Location and area of the material storage areas

The Contractor shall include in the mobility plan the proposed system to supply the utilities required at each site.

17.1. Construction Site Fencing: The construction site, offices, parking area, latrines, and material storage areas shall be fenced in by means of a two-meter high fence with gates and locks, unless otherwise approved the Government. The Contracting Officer or authorized representative shall specify the type of fencing, height and color. Fences shall be screened with a green opaque mesh to prevent the view of the inside of the fenced area from the outside. Fencing shall be completely secured at top and bottom to prevent the access to the fenced area. The fence and mesh shall be adequately

18/225

01 11 01 - 10 anchored to prevent their failing during high wind gusts. The Contractor shall include in the

Mobilization Plan:

1. Photos, catalogs or samples of the fence to be used

2. Photos, catalog or samples of the mesh to be used

The Contractor shall not start the installation of the fencing and mesh until the plan is approved in writing by the Contracting Officer or authorized representative. The responsibility of providing, erecting, keeping and removing all the fences and meshes shall be solely the Contractor. The

Contractor shall replace or repair, within the following 24 hours or as determined by the

Contracting Officer or authorized representative, all fence or mesh sections that have been damaged or deteriorated. Once the works have been finalized, the Contractor shall remove the fences and meshes.

17.2. Offices: Temporary prefabricated buildings required for administrative reasons (office space, conference room and break room) shall be in good conditions. Temporary prefabricated buildings requiring paint, repairs or are in bad conditions shall not be allowed at the site. Said temporary prefabricated buildings shall show on the outside a plaque of 0.5 x 0.5 meters maximum dimensions, indicating the name of the company and telephone number (s) of the person (s) designated as POC for the Contractor. Once the works are finalized, the Contractor shall remove the temporary prefabricated buildings.

17.3. Latrines: Prefabricated temporary buildings required for personnel latrines shall be in good conditions. The prefabricated temporary buildings requiring paint, repairs or are in bad conditions shall not be allowed on the work site. These buildings shall be kept in perfect use conditions and sanitized, shall be treated for insects and shall be emptied and cleaned with a detergent for sanitary use once a week. The frequency of emptying and cleaning shall be adjusted according to needs. The prefabricated temporary buildings shall be located at no less than 50 meters from the existing buildings of Base if they cannot be located near a sewage manhole. Once the works have been completed, the Contractor shall remove the temporary facilities and shall leave the area clean and sanitized.

17.4. Parking: The Contractor, their employees and subcontractors shall park all vehicles, including heavy machinery, equipment y vehicles, in areas where they do not pose an obstruction in the corresponding work site. All possible efforts must be made so that the vehicles are not parked in an area where they will be clearly visible from the outside.

17.5. Material Storage: Material storage containers shall be in good conditions. The storage of materials, in containers or not, at the work site shall be at the Contractor’s risk. The use of private security guards at the work site shall require the previous Spanish Air Force Security Forces approval.

The Contractor shall not use the work site to store material. Once the works have finished, the

Contractor shall remove the excess stored material.

19/225

01 11 01 - 11

18. PROJECT SIGN: Within 15 calendar days after the notice to proceed (CNTP) date, the Contractor shall install an identifying work/project sign in accordance with Figure 1 no later than one day after the work site fencing is completed. The sign shall be mounted on two wooden posts of 10 cm x 10 cm, as minimum, fastened to the ground and adequately anchored. The location of said sign shall be determined by the Contracting Officer or his representative. During final cleanup of the work site, the sign, posts, fasteners and anchoring elements shall be removed. Unless otherwise specified, the sign shall have white background and the lettering shall be dark blue.

FIGURE 1: PROJECT SIGN

19. QUALITY CONTROL PLAN: Within 15 calendar days after the notice to proceed (CNTP) date and after the approval of the Work Plan, the Contractor shall submit for its approval a complete

Quality Control Plan in English and Spanish which may be consulted by the workers at the

Contractor's offices at the site.

19.1. Content: The plan shall contain at minimum the following:

1. Names and qualifications of the proposed quality control chief and inspectors.

2. Organization Chart: Include the teaming partners/key subcontractors, and the works required for the project. The team partners/key subcontractors indicated shall be those that participate in the project and the same as those submitted in the contract bid. The lack of this information or variation with previously submitted teaming partners/key subcontractors is cause for the disapproval of the QC Plan.

20/225

01 11 01 - 12

3. Responsibility of the Quality Control Inspectors, Quality Control Manager and the Project Manager.

4. Inspection types to be performed. The Contractor shall fully develop a

Program of Points Inspection (PPI) covering all types of works involved in the project. Development of the PPI shall be based in any and all of the following documents:

a. Project drawings and specifications.

b. Applicable regulations, standards and industry codes.

c. Specific regulations for certain products, installations or facilities.

d. Manufacturer’s recommendations.

The type and number of Inspection Points (IP) shall be the required to obtain an acceptable level of inspection for achieving the best quality results. The Contracting

Officer or authorized representative shall evaluate if the type and number of

Inspection Points are sufficient to obtain the acceptable quality level.

5. Inspection procedures and actions to be taken for failed or unsatisfactory inspections.

6. Inspection Reporting Forms. Submit all reporting forms for any type of inspection to be performed under this project. As a minimum, a specific form shall be developed for each section of the specifications, covering all necessary inspection points for such work. Minimum information required for each IP shall be:

a. Description of the IP

b. Applicable documents

c. Type and frequency of inspection

d. Lot applied for the inspection

e. Responsible of the performed inspection

f. Inspection result

g. Date of inspection

21/225

01 11 01 - 13

h. Reference to non-compliance document/register, if not in compliance

i. Information about pass/rejection criteria for the IP

j. Other.

7. List of planned "Hold Inspection Points" with the estimated dates from the construction schedule.

8. "Schedule of Material Submittals" form of the project with column titled

"Required Submission Date" filled in by the Contractor with the dates estimated by the Contractor for the submission of the corresponding item. Said estimated dates shall be based on the period for the delivery and review of the submissions and re-submissions, the period for the purchase orders, acquisitions and receptions at the work site of the items, the approved Work Plan of the Contractor and the completion date of the contract (see clause 30, Material, Equipment and/or Plan Submissions).

If the Work Plan is modified, the Contractor shall update the "Schedule of Material

Submittals" form.

9. Material Testing: Submit the name and qualifications of the testing agency or laboratory planned for testing. All test reports shall be submitted in time for review and approval. The work activity related to these tests can only be continued when the test report has been approved. If any test report fails, the following work activities shall not be executed until after the fault has been corrected. The

Contractor shall be responsible for checking that all reports are reviewed by him and taking the necessary actions to resolve any failed test.

10. Perform daily reports of all activities carried out during the contract term.

These daily reports shall be kept at the work site and shall be available for review at all times. A copy of the daily reports performed from Monday to Friday (or

Sunday if the Contractor works during the weekend) shall be submitted weekly to

Construction Management. The daily report shall include, at least, the following:

22/225

01 11 01 - 14

a. Inspection date

b. Weather conditions

c. Inspection of the equipment and materials delivered at the work site and their delivery date

d. Names of people who have visited the work site during the day and visit date

e. Inspection of the deficiencies found during the day and the taken corrective actions

f. Inspection and acceptance of the materials and workmanship.

g. Work performed during the day, including the used personnel and equipment

h. Any field change or modification approved by the

Contracting Officer.

19.2. Daily Report electronic file naming. Each Daily Report shall be named as indicated on this paragraph, failure in doing so will result in rejection of the daily report and the Contractor has to resubmit it. Daily Report file names shall have the following format: XX-X-XXXX, YY-YYYY, Daily Report, from ZZZZ WW VV to SSSS UU TT, where:

1. XX-X-XXXX stands for the contract number last seven digits, after removing the first “FA5575-“digits.

2. YY-YYYY stands for the project number

3. ZZZZ stands for the year in which the inspection is made on Monday

4. WW stands for the month in which the inspection is made on Monday

5. VV stands for the month in which the inspection is made on Monday

6. SSSS stands for the year in which the inspection is made on the last day of the weekly period (Friday or Sunday)

7. UU stands for the month in which the inspection is made on the last day of

23/225

01 11 01 - 15

8. TT stands for the month in which the inspection is made on the last day of

19.3. Acceptance of the Construction Quality Control (QC) Plan: Acceptance of the QC Plan is required before the start of the work. The Contracting Officer reserves the right to require changes in the QC Plan, operations and key personnel, including the dismissal of personnel, to ensure the specified work quality.

19.4. The Contractor shall be responsible for keeping the records.

20. LABORATORY TESTING:

20.1. Laboratory: All sampling and testing shall be performed by an approved laboratory, independent from the Contractor, that is accredited in accordance with a current UNE-EN

9001:2000 and registered by Junta de Andalucía for the following tests. The laboratory shall be the responsible to perform the entire quality control of the project, shall be as a consultant and shall provide the technical assistance that can be required.

20.2. Laboratory Tests: Laboratory tests performed more than 6 months before the submission date shall not be accepted.

21. PRE-FINAL AND FINAL INSPECTIONS: The pre-final and final inspections shall be conducted jointly with the Contractor, the Government inspector and a representative of the

Contracting Office. The Contractor shall request a pre-final inspection once the works are completed in accordance with the inspector's judgement. After the solving of all the discrepancies found during the pre-final inspection, if any, the Contractor shall request a final inspection. All punch list items must have been completely fixed before final acceptance of the project works.

The Contractor shall request to Construction Management the pre-final or final inspection at least

15 calendar days in advance of the desired date.

22. WORKDAY:

22.1. Normal Working Hours: The Contractor shall perform all work during normal working hours unless the Contracting Officer or authorized representative issues a special authorization to deviate from said work schedule. Normal working hours shall be from 08:00 to 17:00, from

Monday to Friday, except holidays.

22.2. Special Working Hours: If the Contractor wishes to work outside the normal working hours, on Saturdays, Sundays or holidays, he shall submit a request to the Contracting Officer with at least 10 calendar days in advanced.

24/225

01 11 01 - 16

23. CONSERVATION AND MAINTENANCE OF THE EXISTING FACILITIES:

Before the start of any work activity, the Contractor will carry out an inspection of the existing facilities at the work site (or adjacent to it), as well as the pavements proposed by the Contractor on the Transit Control Plan and on the Access Route Plan. The Contractor shall submit a report in writing, attaching photographs, to Construction Management of all the defects found during said inspection. The Contractor shall conserve and protect all existing facilities at the work site and adjacent to the work site. The Contractor shall repair all the defects that were not documented in the original report or have been further damaged by the Contractor's construction activities or negligence. These repairs will be completed without additional cost to the Government and before the final acceptance of the project.

24. ENVIRONMENTAL PROTECTION PLAN: Within 15 calendar days after the notice to proceed (CNTP) date, the Contractor shall submit to Construction Management for its approval by

Contracting Officer or authorized representative an Environmental Protection Plan, in English and

Spanish versions, which may be consulted by the workers at the Contractor's offices at the site.

The program shall comply with applicable Spanish regulations and the below standards.

24.1. Integrated Natural Resources Management Plan for Morón Air Base (2015 - 2020)

24.2. Final Environmental Governing Standards for Spain, May 2014

24.3. Conservation and Maintenance of the Existing Vegetation: The Contractor shall conserve and protect the existing vegetation (trees, shrubs, grass) on the work site or adjacent to it that has not to be removed or has not to be affected by the works required by this contract. The Contractor shall only remove the trees and/or shrubs when specifically indicated on the specifications and drawings and shall avoid damaging the remaining vegetation. If any tree branch is split during the execution of the works due to the handling of the equipment or due to some carelessness of the workers, the Contractor shall prune those affected branches with a clean cut and apply a pruning paste to said cut. The Contractor shall cut the vegetal cover and/or turf at the work site to include a minimum of 1 meter outside of fencing so that it does not exceed 10 cm in height. The Contractor shall restore, at no additional cost to the Government, to its original condition the area affected during the execution of the project works before the final acceptance of project works.

24.4. Site Cleaning: The Contractor shall remove debris, waste materials and garbage and shall keep the site always tidy. All waste materials and garbage shall be placed in containers provided by the Contractor, which shall be removed daily outside of the Base to an authorized dump during the progress of the work. The Contractor shall ensure that all volatile wastes are placed in suitable containers to prevent that the wind blows them to adjacent areas and/or the aerodrome. Once the works are completed, the Contractor shall remove the containers.

25/225

01 11 01 - 17

24.5. Access Route Cleaning: The Contractor shall be solely responsible for any material dumped/spilled by trucks, vehicles, machinery or equipment on the access routes. Said material deposited on the access routes shall be removed by the Contractor immediately. The Contractor shall be responsible for ensuring that all access routes are kept clean at all times. No amount of material deposited on the access routes shall be tolerated.

24.6. Waste and Debris: The Contractor, within 15 calendar days after the Notice to Proceed date, shall submit a certificate from the authorized dump or waste management plant to the

Construction Management for its approval by Contracting Officer or authorized representative with the estimated quantities of waste and debris managed during the period of the execution of the works. The delivery tickets shall be previously delivered to Construction Management for their review during the work execution. A report detailing the types and quantities of construction debris removed will be provided to the environmental section upon completion of the works.

24.7. Hazardous Material: The contractor shall provide SDSs to the environmental section for review for each chemical they will be using to execute the project. Estimated quantities of each chemical to be used will also be provided. Before transporting any hazardous material, the

Contractor shall contact the Chief of Construction Management to coordinate its handling, transportation and storage. The Contractor shall be responsible for complying with all applicable environmental regulations related to handling, transportation and storage of hazardous materials and/or waste.

24.8. Noise Control and Prevention: The Contractor shall comply with all applicable state, autonomous community, municipality and Base regulations related to the control and prevention of the noise. The Contractor shall take the measures required to prevent and control the noise in the vicinity of the construction area.

24.9. Dust Control and Prevention: The Contractor shall comply with all applicable state, autonomous community, municipality and Base regulations related to the control and prevention of the dust. The Contractor shall take the measures required to prevent and control the dust in the vicinity of the construction area.

24.10. Storm Water Pollution Control and Prevention: The Contractor shall comply with all applicable state, autonomous community, municipality and Base regulations related to the control and prevention of the pollution of the storm water.