DLA Energy Aerospace Provisions.pdf

DLA ENERGY AEROSPACE PROVISIONS FOR SOLICITATION SPE601-18-R-0303

PART I—THE SCHEDULE

SECTION B - SCHEDULE OF SUPPLIES/SERVICES

B-0001 B1.09-2 SUPPLIES TO BE FURNISHED (INDEFINITE QUANTITY) (AEROSPACE ENERGY) (DLA

ENERGY JAN 2012)

(a) This is an indefinite quantity contract for the purchase of supplies (and/or services, if applicable) to be furnished during the contract term. The delivery points, methods of delivery, and estimated quantities are specified in the Schedule as contract line item numbers (CLINs). The quantities shown are best estimates of required Government quantities only. Unless otherwise specified, the total quantity ordered and required to be delivered/loaded may be greater than or less than such quantities as allowed by the VARIATION IN QUANTITY clause.

(b) The following contract text apply ONLY if the applicable box is checked:

(1) [ X ] This is a REQUIREMENTS-TYPE contract. The Government agrees to order from the Contractor and the Contractor shall deliver, if orders are placed by the DLA Energy Contracting Officer during the contract period, all items awarded under this contract, as allowed by the REQUIREMENTS clause. A Blanket Delivery Order is considered “an order”, for the purposes of this contract text.

(2) [ ] This is an INDEFINITE DELIVERY/INDEFINITE QUANTITY contract. The Government agrees to order from the Contractor and the Contractor shall deliver, if orders are placed by the Contracting Officer during the contract period, at least the quantity of supplies or services designated in the Schedule as the “minimum”, as allowed by the INDEFINITE QUANTITY clause. A Blanket Delivery Order is considered “an order”, for the purposes of this contract text.

(3) [ ] Orders issued by the Ordering Officer at the destination location are considered extensions of the Blanket Delivery Order issued by the DLA Energy Contracting Officer and, as such, may be issued orally, by facsimile or by electronic commerce methods, as allowed by the ORDERING clause.

(4) [ X ] The unit prices specified below shall be fixed for the term of the contract.

(5) [ X ] The prices paid shall be the unit prices specified in subsequent price change modifications issued in accordance with the ECONOMIC PRICE ADJUSTMENT contract text, as contained in the solicitation and any resultant contract.

Applicable to CLINS 0001 thru 0020. See DLA Energy Aerospace Provision B-0002 B19.33 Economic Price Adjustment – Published Market Price – DLA Energy Domestic Bulk. (DLA Energy JUNE 2017).

(6) [ ] Items of this contract call for f.o.b. destination delivery, unless the item specifies otherwise. The destination for each item is the point of delivery shown in the particular item. Inspection for quality will be at origin with final acceptance at destination. Applicable to CLIN(s) ________________________________________.

(7) [ ] F.o.b. destination item(s) called for under this contract shall have shipment quantity determinations performed at destination.

(8) [ X ] Items of this contract call for f.o.b. origin delivery, unless the item specifies otherwise. Inspection and acceptance will be at origin. Applicable to CLIN(s) 0001 thru 0020.

(9) [ ] Any offers received for less than the full quantity for each line item will be rejected by the Government.

(10) [ ] A copy of the certified weight ticket shall accompany each shipment.

(11) [ ] A copy of the Certificate of Analysis shall accompany each shipment.

(12) [ X ] An original and one copy of the H-14 Transport Equipment Delay Certificate shall be provided with each shipment, if applicable.

B-0002 B19.33 Economic Price Adjustment – Published Market Price – DLA Energy Domestic Bulk. (DLA Energy JUNE 2017)

ECONOMIC PRICE ADJUSTMENT -- PUBLISHED MARKET PRICE - DLA ENERGY DOMESTIC BULK (JUNE 2017)

(a) Warranties. The Contractor warrants that—

(1) The base unit prices set forth in the Schedule do not include allowances for any portion of the contingency covered by this contract text; and

(2) The prices to be invoiced shall be computed in accordance with the wording of this contract text.

(b) Definitions. As used throughout this contract text, the term—

(1) Base unit price means the unit price set forth opposite the item in the Schedule.

(2) Market price means the price to be used in determining an economic price adjustment of the base unit price of an individual product for the market area and time period specified in this contract text. The market price is derived from quotes, assessments, or sales prices in the market place for one or several items or commodity groups as reported in a consistent manner in a publication, electronic data base, or other form, as determined by an independent trade association, governmental body, or other third party independent of the Contractor.

(i) Base market price means the price as shown in Column V of the table below, which is the market price from which economic price adjustments are calculated pursuant to this contract text.

(ii) Adjusting market price means the market price for deliveries during the most recent period, as defined in the table below.

(3) Date of delivery is defined as follows:

(i) For tanker or barge deliveries.

(A) Free on board (f.o.b.) origin. The date and time vessel commences loading.

(B) F.o.b. destination. The date and time vessel commences discharging.

(ii) For pipeline deliveries. The date and time product commences to move past the specified f.o.b. point.

(iii) For all other types of deliveries. The date product is received.

(c) Adjustments.

(1) Subject to the wording of this contract text, the price payable shall be the base unit price in effect on the date of delivery increased or decreased by the same number of cents, or fraction thereof, that the adjusting market price applicable at date of delivery increases or decreases, per like unit of measure, from the base market price.

(2) Calculations. All calculations shall be rounded to six decimal places.

(3) Modifications. Any resultant price changes to the base market price and base unit price shall be executed by the Contracting Officer through a weekly price adjustment modification effective each Tuesday.

(4) Failure to deliver. Notwithstanding any other wording of this contract text, no upward adjustment shall apply to product scheduled under the contract to be delivered before the effective date of the adjustment, unless the Contractor’s failure to deliver according to the delivery schedule results from causes beyond the Contractor’s control and without its fault or negligence, within the meaning of paragraphs (f), Excusable Delays, and (m), Termination for Cause, of the Contract Terms And Conditions - Commercial Items clause of this contract, in which case the contract shall be amended to make an equitable extension of the delivery schedule.

(5) Upward ceiling on economic price adjustment. The Contractor agrees that the total increase in any contract unit price, pursuant to these economic price adjustment contract texts shall not exceed (Note 1) percent of the original base unit price in any applicable program year (whether a single year or multiyear program), except as provided hereafter.

(i) If at any time the Contractor has reason to believe that within the near future a price adjustment under the wording of this contract text will be required that will exceed the current contract ceiling price for any item, the Contractor shall promptly notify the Contracting Officer in writing of the expected increase. The notification shall include a revised ceiling which the Contractor believes is sufficient to permit completion of remaining contract performance, along with appropriate explanation and documentation as required by the Contracting Officer.

(ii) If an actual increase in the established market price would raise a contract unit price for an item above the current ceiling, the Contractor shall have no obligation under this contract to fill pending or future orders for such item, as of the effective date of the increase, unless the Contracting Officer issues a contract modification to raise the ceiling. If the contract ceiling will not be raised, the Contracting Officer shall so promptly notify the Contractor in writing.

(6) Revision of market price indicator. In the event—

(i) Any applicable market price indicator is discontinued or its method of derivation is altered substantially;

or

(ii) The Contracting Officer determines that the market price indicator consistently and substantially fails to reflect market conditions,-the parties shall mutually agree upon an appropriate and comparable substitute and the contract shall be modified to reflect such substitute effective on the date the indicator was discontinued, altered, or began to consistently and substantially fail to reflect market conditions. If the parties fail to agree on an appropriate substitute, the matter shall be resolved in accordance with paragraph (d), Disputes, of the Contract Terms And Conditions - Commercial Items contract text of this contract.

(d) Conversion factors. If this contract text requires quantity conversions for economic price adjustment purposes, the conversion factors for applicable products, as specified in the DLA Energy conversion factor instruction, apply unless otherwise specified in the Schedule.

(e) Examination of records. The Contractor agrees that the Contracting Officer or designated representative shall have the right to examine the Contractor's books, records, documents, or other data the Contracting Officer deems necessary to verify Contractor adherence to the wording of this contract text.

(f) Final invoice. The Contractor shall include a statement on the final invoice that the amounts invoiced hereunder have applied all decreases required by this contract text.

(g) Table.

I.

HEADING UNDER WHICH

MARKET INDICATOR IS

PUBLISHED

II.

BASE

MARKET

PRICE

(FY 2018)

III.

LOCATION WHERE

MARKET PRICE IS

APPLICABLE

(EXCLUDES ALL

TAXES)

IV.

ITEM NUMBER

AND/OR

NAME OF PRODUCT

V.

NAME

OF

PUBLICATION

www.blm.gov Federal Helium Operations Crude Helium Auctions & Sales Crude Helium Price

In-Kind $86.00 per Mcf

Continental United States

(CONUS)

0001 -0005 BLM Type I Grade A 9135-00-890-2011

Bureau Of Land Management Crude Helium Price www.blm.gov Federal Helium Operations Crude Helium Auctions & Sales Crude Helium Price

In-Kind $86.00 per Mcf

Continental United States

(CONUS)

0006-0010 BLM Type I Grade N 6830-01-598-7274

Bureau Of Land Management Crude Helium Price www.blm.gov Federal Helium Operations Crude Helium Auctions & Sales Crude Helium Price

Conservation Helium $119.00 per Mcf

Continental United States

(CONUS)

0011-0015 NON-BLM Type I Grade A 9135-00-890-2011

Bureau Of Land Management Crude Helium Price www.blm.gov Federal Helium Operations Crude Helium Auctions & Sales Crude Helium Price

Conservation Helium $119.00 per Mcf

Continental United States

(CONUS)

0016-0020 NON-BLM Type I Grade N 6830-01-598-7274

Bureau Of Land Management Crude Helium Price http://www.blm.gov/

(End of Text)

SECTION C – DESCRIPTION/SPECIFICATION

C-0001 Refer to DLA Energy Quality Assurance Provisions (QAPs) Attachment

C-0002 Refer to DLA Energy Quality Assurance Provisions (QAPs) Attachment

SECTION D- PACKAGING AND MARKING

D-0001 D10 PACKAGING REQUIREMENTS (AEROSPACE ENERGY) (DLA ENERGY MAR 2009)

(a) The Contractor shall be responsible for ensuring the hazardous materials shipment is in full compliance with all applicable packaging/packing, marking, labeling, placarding, blocking and bracing, and palletizing and shipping certifications in force and effect on the date of the shipment in accordance with the following applicable rules and regulations for the individual hazard, ultimate destination, and mode of transportation:

(1) Title 49 of the Code of Federal Regulations (49 CFR) -- Packaging.

(2) DLAI 4145.3, Preparing Hazardous Materials for Military Air Shipments.

(3) International Air Transport Association (IATA) -- Dangerous Goods Regulations.

(4) International Civil Aviation Organization (ICAO) -- Technical Instructions for the Safe Transportation of Dangerous Goods by Air.

(5) International Maritime Organization (IMO) -- International Maritime Dangerous Goods (IMDG) Code (for overseas shipments by vessel).

(6) MIL-STD 129, Standard Practice for Military Marking (for military destinations).

(7) MIL-STD-147, Department of Defense Standard Practice, Palletized Unit Loads.

(8) ASME MH 1.8, Wood Pallets.

(b) Contractor commercial packaging (ASTM D 3951) shall also be in compliance with the requirements listed.

D-0002 D15 CONTRACTOR SEAL REQUIREMENT (AEROSPACE ENERGY) (DLA ENERGY OCT

2006)

(a) The Contractor shall place tamper indicating devices (TIDs) such as a seal or cap on the shipping container(s) immediately after filling and sampling. The TIDs shall be placed on the containers in such a manner that pilferage or tampering of the product could only be accomplished by breaking or otherwise destroying the TID. This may require the application of several TIDs on each shipment container.

(b) Where possible, the TID shall be printed with a serial number. The container number and TID number(s) shall be recorded on the certificate of analysis and on the shipping documents. Monthly equipment inventory reports provided to DLA Energy by the Contractor shall include container numbers as well as corresponding TID numbers.

(c) TIDs shall not be removed from a container unless authorized by DLA Energy. If a TID is broken or no longer intact, the Contractor shall contact the Contracting Officer for further instructions. If the Contractor is instructed to place a new TID on the container, the new TID number (if applicable) shall be noted, along with the container number, as stated in paragraph (b) above.

SECTION E – INSPECTION AND ACCEPTANCE

E-0001 Refer to DLA Energy Quality Assurance Provisions (QAPs) Attachment

E-0002 Refer to DLA Energy Quality Assurance Provisions (QAPs) Attachment

E-0003 Refer to DLA Energy Quality Assurance Provisions (QAPs) Attachment

E-0004 Refer to DLA Energy Quality Assurance Provisions (QAPs) Attachment

SECTION F – DELIVERIES AND PERFORMANCE

F-0001 F1.36 DETERMINATION OF QUANTITY (PROPELLANTS, CRYOGENICS AND GASES)

(AEROSPACE ENERGY) (DLA ENERGY APR 2006)

(a) QUANTITY. The quantity of supplies furnished under this contract shall be determined according to one of the following methods:

(1) DELIVERIES INTO OR BY PIPELINE.

(i) F.O.B. ORIGIN.

(A) On items requiring delivery at the Contractor's terminal or plant, the quantity shall be determined by a calibrated flow meter.

(B) The Government retains the right to have a representative witness quantity measurements performed by the Contractor.

(ii) F.O.B. DESTINATION.

(A) At the Government’s option, quantity determinations will be made at the receiving activity on the basis of a calibrated flow meter.

(B) The Contractor has the right to have a representative witness quantity measurements performed by the Government.

(C) If the Government does not opt to perform quantity determinations at the destination (see schedule), the Contractor shall determine quantity on the basis of a calibrated flow meter.

(D) The Government retains the right to have a representative witness quantity measurements performed by the Contractor.

(2) DELIVERIES BY OTHER THAN PIPELINE.

(i) F.O.B. ORIGIN.

(A) On items requiring delivery at the Contractor's terminal or plant, the quantity shall be determined (at the Contractor's option) on the basis of--

(a) Calibrated flow meter.

(b) Weight using calibrated scales.

(c) Pressure Temperature Fill Charts/Calculations (for gaseous cylinders and tube trailers).

(B) The Government retains the right to have a representative witness quantity measurements performed by the

(ii) F.O.B. DESTINATION.

(A) At the Government’s option, quantity determinations will be made at the receiving activity on the basis of—

(a) Calibrated flow meter.

(b) Weight using calibrated scales.

(c) Pressure Temperature Fill Charts/Calculations (for gaseous cylinders and tube trailers).

(B) The Contractor has the right to have a representative witness quantity measurements performed by the Government.

(C) If the Government does not opt to perform quantity determinations at the destination (see Schedule), the Contractor shall determine quantity on the basis of--

(a) Calibrated flow meter.

(b) Weight using calibrated scales.

(c) Pressure Temperature Fill Charts/Calculations (for gaseous cylinders and tube trailers).

(D) The Government retains the right to have a representative witness quantity measurements performed by the

(b) MEASUREMENT STANDARDS. Weight scales used in determining net shipping volumes shall be certified as calibrated within the frequency required by local regulation. If no local regulation exists, the frequency of calibration shall be conducted in accordance with weight scale manufacturer recommendation or every six months, whichever is more frequent. All flow meters used in determining product volume shall be calibrated within the frequency required by local regulation (foreign or domestic). If no local regulation exists, then the frequency of calibration shall be that recommended by the meter manufacturer or every six months, whichever is more frequent. Pressure gauges and thermometers used to calculate fill quantities for gaseous cylinders and tube trailers shall be calibrated at least every six months. The net quantity shipped shall be reported on the DD Form 250 or commercial equivalent, whichever is applicable.

F-0002 F3.04 TRANSPORTATION OF HAZARDOUS MATERIALS (AEROSPACE ENERGY) (DLA

ENERGY APR 2006)

The Contractor shall be responsible for ensuring the transportation of hazardous materials is in full compliance with all applicable rules and regulations below that are in force and effect on the date of the shipment for the individual hazard, ultimate destination, and mode of transportation:

(a) Title 49 of the Code of Federal Regulations (49 CFR) -- Transportation.

(b) DLAI 4145.3, Preparing Hazardous Materials for Military Air Shipments.

(c) International Air Transport Association (IATA) -- Dangerous Goods Regulations.

(d) International Civil Aviation Organization (ICAO) -- Technical Instructions for the Safe Transportation of Dangerous Goods by Air.

(e) International Maritime Organization (IMO) -- International Maritime Dangerous Goods (IMDG) Code (for overseas shipments by vessel).

F-0003 F7 DELAY OF CARRIER EQUIPMENT (DETENTION) (AEROSPACE ENERGY) (DLA

ENERGY APR 2006)

Detention charges at the Contractor’s facility for delay of the carrier’s equipment in excess of the carrier’s tariff/tender allowable free time is to be documented on the carrier’s Transport Equipment Delay Certificate. Both the carrier driver and the Contractor must sign the certificate. Documentation shall include the time and date the carrier driver arrived, the time and date the carrier driver departed, and the reason(s) for the delay. Documentation shall be provided to the carrier driver prior to his departure from the facility.

F-0004 F21 CONTRACTOR NOTICE REGARDING LATE DELIVERY (DLA ENERGY May 2009)

In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery Schedule or date, it shall immediately notify the Contracting Officer, in writing, giving pertinent details. This data shall not be construed as a waiver by the Government of any delivery Schedule or date or of any rights or remedies provided by law or under this contract.

SECTION G- CONTRACT ADMINISTRATION DATA

G-0001 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

COMBO .

Note: If a “Combo” document type is identified but not supportable by the Contractor’s business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

ORIGIN .

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* http://www.acq.osd.mil/dpap/dars/dfars/html/current/252232.htm https://www.sam.gov/portal/SAM/#1 https://wawf.eb.mil/ https://wawf.eb.mil/

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC SL4701 Issue By DoDAAC SPE601 Admin DoDAAC SPE601 Inspect By DoDAAC See Schedule Ship To Code See Schedule Ship From Code See Schedule Mark For Code See Schedule Service Approver (DoDAAC) Not applicable Service Acceptor (DoDAAC) Not applicable Accept at Other DoDAAC See Schedule LPO DoDAAC See Schedule DCAA Auditor DoDAAC Not applicable Other DoDAAC(s) See Schedule

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the e-mail address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

erica.numa@dla.mil and kenneth.marsh@dla.mil .

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

Not Applicable .

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

H-0001 H15 TRANSPORTATION REQUIREMENTS FOR F.O.B. ORIGIN SHIPMENTS BY TANK

TRUCK, TRUCKLOAD, AND/OR LESS THAN TRUCKLOAD (CYLINDER/DRUM)

(AEROSPACE ENERGY) (DLA ENERGY MAR 2016)

(a) The address for the Transportation Office (TO) referred to in this contract text is—

ATTN: DLA ENERGY-QEMC

BUILDING 1621

mailto:erica.numa@dla.mil mailto:kenneth.marsh@dla.mil

1014 BILLY MITCHELL BLVD

SAN ANTONIO, TX 78226-1859

PHONE: (210) 925-1579

FAX: (210) 925-1319

(b) For the purposes of this contract text and shipments made under the contract, a cylinder/drum may be considered “truckload” or “less than a truckload.”

(c) Shipments will be made on Commercial Bills of Lading (CBLs) in accordance with appropriate regulations. A CBL will be furnished by the TO in advance of the anticipated shipping date. In the event that a CBL is not provided prior to the shipment and under the direction of the TO, a carrier/contractor bill of lading may be used. The Contractor shall complete and distribute the CBLs as noted on the routing instructions furnished by the TO. The Contractor shall annotate on the CBL the weight/gallons, seal numbers, and signature of the agent. The Contractor shall fax the completed CBL to the TO.

(d) The Contractor is responsible for—

(1) Contacting and scheduling the carrier in for loading, when directed by the TO in the routing instructions;

(2) Inspecting all shipping conveyances prior to loading to insure that product loaded will not be lost or contaminated by the condition of the equipment. Tank truck inspection must be performed by qualified Contractor personnel. Delegation of this responsibility shall not be passed to the tank truck operator/driver; and

(3) Loading of transport equipment shall be in accordance with 49 CFR. The Contractor is liable for reimbursement to the Government for damage to any equipment caused by the failure to load, block, and brace the shipment in accordance with acceptable standards set forth therein.

(4) DD Form 626, Motor Vehicle Inspection (Transporting Hazardous Materials). The Contractor is required to fill out the DD Form 626 using one of the options provided below for all shipments of hazardous materials:

(i) The carrier will submit a copy of the vehicle mechanical inspection performed at the carrier’s terminal. Annotate in Block 15 of the DD Form 626 that “the carrier performed the vehicle mechanical inspection (Section II) and a copy of the inspection is attached to the DD Form 626” (making sure the shipper knows he/she is to attach the inspection to the DD Form 626). The Contractor is required to sign in Block 16.

(ii) If the carrier does not have a copy of the vehicle mechanical inspection, the Contractor should annotate in Block 15 of the DD Form 626 that “the vehicle mechanical inspection (Section II) was performed by the carrier” and the driver shall sign the DD Form 626.

(iii) A copy of the signed and dated DD Form 626, along with a completed CBL, shall be faxed or emailed to the TO.

(5) On the day of shipment, the Contractor shall provide a Report of Shipment within 4 hours of departure or within 2 hours the next day (if contact cannot be made on the day of shipment) to the TO. The Report of Shipment may be made by fax or phone and must include the following information:

(i) CBL Number.

(ii) Name of Carrier.

(iii) Carrier Progressive (Pro) Number.

(iv) Tractor and Trailer Name.

(v) Departure Date and Time.

PART II—CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

I-0001 FAR 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL ITEMS

Contract Terms and Conditions -- Commercial Items (Jan 2017)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights --

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71,Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include --

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer— System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt Payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice.

For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period at fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b.

destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause.

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments.

(9) The specification.

(t) System for Award Management (SAM).

(1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(2)

(i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to:

(A) Change the name in the SAM database;

(B) Comply with the requirements of Subpart 42.12 of the FAR;

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims).

Assignees shall be separately registered in the SAM database. Information provided to the Contractor’s SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of payment” paragraph of the EFT clause of this contract.

(4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov.

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End Use License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar https://www.acquisition.gov/ legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause)

I-0002 I11.01-2 ADMINISTRATIVE COST OF TERMINATION FOR CAUSE – COMMERCIAL ITEMS (DLA

ENERGY FEB 1996)

(a) In the event this contract is terminated for cause, in whole or in part, the Government will incur administrative costs.

(b) The Contractor agrees to pay all administrative costs associated with a contract termination action. The minimum amount the Contractor shall pay for each termination action is $500. This payment for administrative costs is in addition to any excess re-procurement costs and any other remedies or damages resulting from the termination.

(c) The term termination action, as used herein, means the termination for cause, including any associated re-procurement effort, involving--

(1) Any single order or any group of orders terminated together;

(2) Any item or group of items terminated together; or

(3) The entire contract.

I-0003 I28.01 FEDERAL, STATE, AND LOCAL TAXES (DLA ENERGY NOV 2011) (DEVIATION)

(a) As used in this contract text--

(1) After-imposed tax means any new or increased Federal, State, or local tax that the Contractor is required to pay or bear the burden of as the result of legislative, judicial, or administrative action taking effect after the contract date.

(2) After-relieved tax means any amount of Federal, State, or local tax that would otherwise have been payable on the transactions or property covered by this contract, but which the Contractor is not required to pay or bear the burden of, or for which the Contractor obtains a refund or drawback, as the result of legislative, judicial, or administrative action taking effect after the contract date.

(3) All applicable Federal and State taxes means all excise taxes that the taxing authority is imposing and collecting on the transactions or property covered by this contract pursuant to written ruling or regulation in effect on the contract date.

(4) Contract date means the date set for bid opening or, if this is a negotiated contract or a modification, the date set for final revised prices.

(5) Local taxes means taxes levied by the political subdivisions of the States, District of Columbia, or outlying areas of the United States, e.g., cities and counties.

(6) Outlying areas means—

(i) Commonwealths. Puerto Rico and the Northern Mariana Islands;

(ii) Territories. American Samoa, Guam, and the U.S. Virgin Islands; and

(iii) Minor outlying islands. Baker Island; Howland Island, Jarvis Island; Johnston Atoll; Kingman Reef;

Midway Islands; Navassa Island; Palmyra Atoll; and Wake Atoll.

(7) State taxes means taxes levied by the States, the District of Columbia, or outlying areas of the United States.

(8) Tax means taxes, duties and environmental or inspection fees, except social security or other employment taxes.

(b) The contract price includes all applicable Federal, State, and local taxes, except as otherwise provided. (See either the FEDERAL AND STATE TAXES/FEES or FEDERAL, STATE, AND LOCAL TAXES AND FEES contract text.)

(c) The contract price shall be increased by the amount of any after-imposed tax if the Contractor states in writing that the contract price does not include any contingency for such tax.

(d) The contract price shall be decreased by the amount of any after-relieved tax.

(e) The contract price shall also be decreased by the amount of any tax that the Contractor is required to pay or bear the burden of, or does not obtain a refund of, through the Contractor's fault, negligence, or failure to follow instructions of the Contracting Officer.

(f) The Contractor shall promptly notify the Contracting Officer of all matters relating to any tax that reasonably may be expected to result in either an increase or decrease in the contract price and shall take appropriate action as the Contracting Officer directs.

(g) The Government shall, without liability, furnish evidence appropriate to establish exemption from any Federal, State, or local tax when the Contractor requests such evidence and a reasonable basis exists to sustain the exemption.

I-0004 I190.06 MATERIAL SAFETY DATA SHEETS -- COMMERCIAL ITEMS (DLA ENERGY APR 2006)

(a) The Contractor agrees to submit to the Contracting Officer, upon request, a Material Safety Data Sheet (MSDS) that meets the requirements of 29 CFR 1910.1200(g) and the latest revision of Federal Standard No. 313 for all requested contract items. MSDSs must cite the contract number, the applicable CAGE code of the manufacturer, and, where so identified, the National Stock Number

(NSN).

(b) The data on the MSDSs must be current and complete, reflecting the final composition of the product supplied. Should the description/composition of the product change in any manner from a previously submitted MSDS, the Contractor shall promptly provide a new MSDS to the Contracting Officer.

I-0005 I209.09 EXTENSION PROVISIONS (DLA ENERGY JAN 2012)

(a) The Government shall have the right to extend this contract on the same terms and conditions one or more times for a total of no more than six months. Notice of contract extension will be furnished to the Contractor not later than 30 days prior to expiration of the contract ordering period or any extension thereof.