Solicitation W25G1V-21-R-0011.pdf

CODE

(Hour)

PAGE(S)

until 04:00 PM local time 07 Jun 2021

X

A

X B

C

D

E

X

G

F 39 - 67

68 - 74

H 75 mark.a.buonomo.civ@mail.mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

1 81

(If other than Item 7) W25G1V

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

W25G1V 8. ADDRESS OFFER TO

9. Sealed offers in original and 1 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and

See Instructions to Offerors conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

MARK BUONOMO (570) 615-9781

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

1 - 3

4 - 8

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE 9 - 10

X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 11 - 13 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror)

X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

14 - 37

PART II - CO NTRACT CLAUSES

ACC-APG, TOBYHANNA DIVISION

11 HAP ARNOLD BLVD

TOBYHANNA PA 18466-5100

ACC-APG, TOBYHANNA DIVISION

MARK BUONOMO

MARK.A.BUONOMO.CIV@MAIL.MIL

F-570-615-7525 P-570-615-9781

TOBYHANNA PA 18466-5100

FAX:

TEL:

(570) 615-7525FAX:

TEL: (570) 615-9781

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.5. DATE ISSUED

07 May 2021

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

W25G1V21R0011

Section SF 30 - BLOCK 14 CONTINUATION PAGE

ADDENDUM

Addendum to FAR 52.212-1 – Instructions to Offerors

1. Introduction. Army Contracting Command – Aberdeen Proving Ground (ACC-APG), Tobyhanna Division hereby issues solicitation W25G1V-21-R-0011 for the procurement of a new Automated Storage and Retrieval

System (ASRS), referred to as ASRS Modernization, in support of Tobyhanna Army Depot (TYAD).

2. Authority. This solicitation is issued in accordance with Federal Acquisition Regulation (FAR) Part 12 –

Acquisition of Commercial Items and FAR Part 15 – Contracting by Negotiation.

3. Contract Type and Basis for Award. This solicitation will result in a one (1) Firm-Fixed Price contract using full and open competition. Award will be made to the Offeror whose proposal is determined to be most beneficial to the Government using the best value, trade-off approach. The Government reserves the right to award to other than the lowest price Offeror. The Government reserves the right to award a contract resulting from this solicitation without discussions (except clarifications described in FAR 52.306(a)). See Solicitation Section M for more information on Basis for Award.

4. Site Visit. IAW FAR Clause 52.237-1 -- Site Visit, one (1) site visit will be conducted. The site visit will be held on Monday, 24 May 2021 at 1:00PM EST. This solicitation includes a single scheduled site visit for all interested

Offerors to attend. The Government will not consider any requests for separate or individual site visits. Though the site visit is not mandatory, it is highly recommended. It’s anticipated the Offeror would face extreme difficulties in formulating an accurate proposal for the requirement without examining the existing equipment and conditions as well as determining the existence of other potential obstacles. Potential Offerors are expected to inspect the site to gather all possible information regarding the general and local conditions which may affect the cost/price of contract performance (to the extent that the information is reasonably obtainable). In no event shall failure to attend the site visit and/or inspect the site constitute grounds for a claim after contract award.

Interested Offerors are required to make a reservation by emailing the name, company, and e-mail address for each of the attendees to the Contract Specialist at mark.a.buonomo.civ@mail.mil NLT Friday, 21 May 2021 at 2:00PM

EST. Each interested Offeror is limited to a maximum of three (3) individuals. Attendees are encouraged to arrive at least 15-30 minutes early in order to check in. Visitors will be required to present a valid, Government issued photo

ID in order to gain access to the base (vehicle registration and insurance may also be required).

The starting location for the site visit is Building 20 (Security) at Tobyhanna Army Depot. Attendees may use the following address as a destination for purposes of navigation/traveling directions: 11 Hap Arnold Blvd, Tobyhanna, PA 18466. Prior to proceeding through security at this gate, attendees will be required to check in at the Visitor

Control Center (building on the right when facing the gate), where they will present the required ID and vehicle information and in order to obtain a temporary visitor pass. Attendees will then go through security at the gate and proceed straight along Hap Arnold Blvd, which leads to the main parking lot. At the end of this lot is the starting location for this site visit, Building 20 (Security). All Government personnel and attendees will then walk to the location of the existing ASRS and the worksite for this project.

Information provided at each site visit, as well as answers to any general questions, shall not affect the terms and conditions of the solicitation and/or specifications. Terms remain unchanged unless the solicitation is amended in writing. See Paragraph 4, below, for more information regarding Questions and Answers.

5. Questions and Answers. Offerors may submit any and all questions pertaining to this solicitation by submitting them via e-mail to the Contract Specialist at mark.a.buonomo.civ@mail.mil. Questions must be received no later

Tuesday, 25 May 2021 at 2:00PM EST; no further questions will be accepted after this time. All questions and answers will then be provided via amendment to the solicitation and will be posted at beta.sam.gov. Questions and answers will then be incorporated into the solicitation and any resultant contract.

mailto:mark.a.buonomo.civ@mail.mil mailto:mark.a.buonomo.civ@mail.mil

6. Closing Date/Time. All responses to this solicitation are due no later than 7 June 2021 at 4:00PM EST. All responsive and responsible proposals must be received prior to the closing date and time in order to be considered for award. Offerors are encouraged to not wait until the last hour to send proposals due to the high potential for technical difficulties and/or other delays. The Government shall not be responsible for, and reserves the right to not consider, any proposals that were received beyond the due date as a result of technical issues or delays. The Government does not anticipate extending the solicitation response date.

7. Subcontracting. IAW DFARS 215.304(c)(i), all Offerors, regardless of business size, shall submit an acceptable

Small Business Participation Plan in order to be considered for award. Separately, IAW FAR 19.702(a)(1)(i) the apparently successful Offeror shall be required to submit an acceptable Subcontracting Plan prior to issuance of an award. Failure to negotiate an acceptable plan will result in the Offeror being ineligible for award.

8. Use of Non-Government Advisors. Offeror’s are informed that Michael Baker International and Boston Industrial

Consulting, Inc. are excluded from competition as they provided support in the development of the requirements and will provide support as Non-Government Advisors. The Non-Government Advisors are not part of the proposal analysis or Source Selection decision making process. The Non-Government Advisors will only be providing advisory services in evaluation of the Technical factor (including subfactors) and will not have access to any proposal information that includes pricing or past performance information. Any objection shall be provided in writing to the

Contracting Officer within 10 days of solicitation issuance; and shall include a detailed statement of the basis for the objection.

9. Proposal Submission. Proposals must be submitted in accordance with Solicitation Section L, specifically

Instructions to Offeror’s. Proposals not adhering to the format and requirements specified may not be considered for award.

10. Reps and Certs. Offeror’s shall review and complete (as required) the necessary representations and certifications in Solicitation Section K in order to be considered for award.

11. Amendments. Any amendment issued to this solicitation will be synopsized in the same manner as this solicitation. Offerors are advised that they must acknowledge all amendments issued to the solicitation in order to be considered for award. Any proposal response failing to acknowledge all solicitation amendments may be deemed inadequate by the Contracting Officer and may not be evaluated or further considered by the Government.

12. CLIN Structure. Though the requirement will not change, the Government reserves the right to revise and/or modify the CLIN structure prior to contract award, as necessary.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot ASRS Modernization Design

FFP

This CLIN shall include all design costs associated with and required to meet the

Government's requirement for Modernization of the existing Automated Storage and Retrieval System (ASRS). Reference Attachment 1 - Specification, Paragraphs 1.4; 2.1.1; 2.1.2; 2.4; 4; 6.2.

FOB: Destination

PSC CD: N039

NET AMT

0002 1 Lot ASRS Modernization Software

FFP

This CLIN shall include all software costs necessary to meet the Government's requirement, including any associated design. Reference Attachment 1 -

Specification, Paragraphs 1.4; 4; 5.1; 5.2; 5.3.4; 7; 9.

0003 8 Each Automated Guided Vehicles (AGVs)

FFP

This CLIN shall include all costs associated with the supply and installation of

Automated Guided Vehicles (AGVs) which meet the Government's requirement.

Reference Attachment 1 - Specification, Paragraphs 4; 4.4; 6.3.

0004 5 Each Mini Load Cranes

FFP

This CLIN shall include all costs associated with the supply and installation of

Mini Load Cranes which meet the Government's requirement. Reference

Attachment 1 - Specification, Paragraphs 1.4; 4; 6.4.

0005 1 Each OPTION Mini Load Cranes (OPTION)

FFP

This CLIN shall include all costs associated with the supply and installation of

Mini Load Cranes which meet the Government's requirement. Reference

Attachment 1 - Specification, Paragraphs 1.4; 4; 6.4.

This Option CLIN is for 1 additional Mini Load Crane. Offeror's Proposed Price shall reflect the same unit price in CLIN 0004. If in the Government's interest, the

Option must exercised within 180 calendar days of contract award. The

Government is not required to exercise this option.

0006 4 Each Unit Load VNA Fork Trucks

FFP

This CLIN shall include all costs associated with the supply and installation of Unit

Load VNA Fork Trucks which meet the Government's requirement. Reference

Attachment 1 - Specification, Paragraphs 1.4; 4; 6.6.

0007 1 Lot Miscellaneous Support Equipment

FFP

This CLIN shall include all costs associated with the supply and installation of

Miscellaneous Support Equipment that meets the Government's requirement.

Reference Attachment 1 - Specification, Paragraphs 1.4; 4; 5.3; 6.1.12; 6.4; 6.4.6;

6.4.7; 6.5; 6.7; 6.8; 9; 10.

0008 1 Lot Installation

FFP

This CLIN shall include any/all installation costs necessary to complete the

Government's requirement, to include, but not limited to, all material, labor, supervision, management, and any other necessary miscellaneous tasks/items that may not be explicitly stated. Reference Attachment 1 - Specification, Paragraphs

1.4; 3.2.1.1; 5.3; 6.1.12; 6.4.6; 6.4.7; 6.5; 6.7; 6.8; 9; 10

0009 1 Lot CDRL: Technical Data Package (TDP)

FFP

Contract Data Requirements List (CDRL): Technical Data Package (TDP)

This CLIN is not separately priced. Reference Attachment 3 - Contract Data

Requirements List (CDRL) for a list of all data requirements and deliverables required by Attachment 1 - Specification. The Contractor shall be responsible for reviewing and providing all data requirements specified in the Attachment 1 and

Attachment 3.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

0007 Destination Government Destination Government

0008 Destination Government Destination Government

0009 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 365 dys. ADC 1 SEE BELOW FOR SEPARATE SHIPPING

INSTRUCT

XXX

XXX PA 00000

W25G1V

0002 365 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0003 365 dys. ADC 8 (SAME AS PREVIOUS LOCATION)

0004 365 dys. ADC 5 (SAME AS PREVIOUS LOCATION)

0005 365 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0006 365 dys. ADC 4 (SAME AS PREVIOUS LOCATION)

0007 365 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0008 365 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0009 365 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

CLAUSES INCORPORATED BY REFERENCE

52.242-15 Stop-Work Order AUG 1989

52.247-34 F.O.B. Destination NOV 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEP

2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the

Contractor shall, in place of actual damages, pay to the Government liquidated damages of $1,246.94 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default--Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default--Fixed-Price Supply and

Service clause in this contract.

(End of clause)

Section G - Contract Administration Data

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area

WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of

Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-

7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data

Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting

Officer.

https://www.sam.gov/ https://wawf.eb.mil/ https://wawf.eb.mil/

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the

Contracting Officer.

(Contracting Officer: Insert either “Invoice 2in1” or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC ____

Issue By DoDAAC ____

Admin DoDAAC** ____

Inspect By DoDAAC ____

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert

“See Schedule” or “Not applicable.”)

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the

DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition

Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s

WAWF point of contact.

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other

Covered Entities.

JUL 2018

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.211-11 Liquidated Damages--Supplies, Services, or Research and

Development

SEP 2000

52.212-4 Contract Terms and Conditions--Commercial Items OCT 2018

52.217-6 Option For Increased Quantity MAR 1989

52.219-4 (Dev) Notice of Price Evaluation Preference for HUBZone Small

Business Concerns (DEVIATION 2020-O0008)

MAR 2020

52.222-3 Convict Labor JUN 2003

52.222-19 (Dev) Child Labor - Cooperation with Authorities and Remedies

(DEVIATION 2020-O0019)

JUL 2020

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-26 Equal Opportunity SEP 2016

52.222-35 Equal Opportunity for Veterans JUN 2020

52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020

52.222-37 Employment Reports on Veterans JUN 2020

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons OCT 2020

52.222-54 Employment Eligibility Verification OCT 2015

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021

52.229-12 Tax on Certain Foreign Procurements FEB 2021

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.237-1 Site Visit APR 1984

52.242-5 Payments to Small Business Subcontractors JAN 2017

52.242-13 Bankruptcy JUL 1995

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991

252.211-7008 Use of Government-Assigned Serial Numbers SEP 2010

252.225-7012 Preference For Certain Domestic Commodities DEC 2017

252.225-7048 Export-Controlled Items JUN 2013

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7017 Accelerating Payments to Small Business Subcontractors--

Prohibition on Fees and Consideration

APR 2020

252.237-7010 Prohibition on Interrogation of Detainees by Contractor

Personnel

JUN 2013

252.239-7001 Information Assurance Contractor Training and Certification JAN 2008

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC

2014)

The Contractor's representations and certifications, including those completed electronically via the System for

Award Management (SAM), are incorporated by reference into the contract.

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL ITEMS (JAN 2021)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017)

(section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by

Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or

Equipment. (AUG 2020) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(6) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19

U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (Oct 1995) (41

U.S.C. 4704 and 10 U.S.C. 2402).

X (2) 52.203-13, Contractor Code of Business Ethics and Conduct (JUN 2020) (41 U.S.C. 3509).

X (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN

2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment

Act of 2009.)

X (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-

282) (31 U.S.C. 6101 note).

___ (5) [Reserved]

___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L.

111-117, section 743 of Div. C).

X (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (JUN 2020) (31 U.S.C. 6101 note).

____ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) (41

U.S.C. 2313).

____ (10) [Reserved]

____ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (MAR 2020) (15 U.S.C. 657a).

____ (ii) Alternate I (MAR 2020) of 52.219-3.

X (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (MAR 2020) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (ii) Alternate I (MAR 2020) of 52.219-4.

____ (13) [Reserved]

____ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-6.

____ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-7.

X (16) 52.219-8, Utilization of Small Business Concerns (OCT 2018) (15 U.S.C. 637(d)(2) and (3)).

X (17)(i) 52.219-9, Small Business Subcontracting Plan (JUN 2020) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (NOV 2016) of 52.219-9.

____ (iii) Alternate II (NOV 2016) of 52.219-9.

____ (iv) Alternate III (JUN 2020) of 52.219-9.

____ (v) Alternate IV (JUN 2020) of 52.219-9.

____ (18) (i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) (15 U.S.C. 644(r)).

____ (ii) Alternate I (MAR 2020) of 52.219-13.

____ (19) 52.219-14, Limitations on Subcontracting (MAR 2020) (15 U.S.C. 637(a)(14)).

____ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

____ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (MAR 2020) (15

U.S.C. 657f).

____ (22) (i) 52.219-28, Post Award Small Business Program Rerepresentation (NOV 2020) (15 U.S.C. 632(a)(2)).

____ (ii) Alternate I (MAR 2020) of 52.219-28.

____ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-

Owned Small Business (EDWOSB) Concerns (MAR 2020) (15 U.S.C. 637(m)).

____ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns

Eligible Under the Women-Owned Small Business Program (MAR 2020) (15 U.S.C. 637(m)).

____ (25) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) (15 U.S.C. 644(r)).

____ (26) 52.219-33, Nonmanufacturer Rule (MAR 2020) (15 U.S.C. 637(a)(17)).

____ (27) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

____(28) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (JAN 2020) (E.O. 13126).

____ (29) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

____ (30)(i) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

____ (ii) Alternate I (FEB 1999) of 52.222-26.

____ (31)(i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

____ (ii) Alternate I (JUL 2014) of 52.222-35.

____ (32)(i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

____ (ii) Alternate I (JUL 2014) of 52.222-36.

____ (33) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

____ (34) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O.

13496).

X (35)(i) 52.222-50, Combating Trafficking in Persons (OCT 2020) (22 U.S.C. chapter 78 and E.O. 13627).

____ (ii) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (36) 52.222-54, Employment Eligibility Verification (OCT 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in

22.1803.)

____ (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (MAY

2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (MAY 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN

2016) (E.O. 13693).

____ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners

(JUN 2016) (E.O. 13693).

____ (40) (i) 52.223-13, Acquisition of EPEAT® Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and

13514).

____ (ii) Alternate I (OCT 2015) of 52.223-13.

____ (41)(i) 52.223-14, Acquisition of EPEAT® Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

____ (ii) Alternate I (JUN 2014) of 52.223-14.

____ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b).

____ (43)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s

13423 and 13514).

____ (ii) Alternate I (JUN 2014) of 52.223-16.

X (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) (E.O.

13513).

____ (45) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

____ (46) 52.223-21, Foams (JUN 2016) (E.O. 13693).

____ (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

____ (48) 52.225-1, Buy American--Supplies (JAN 2021) (41 U.S.C. chapter 83).

____ (49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (JAN 2021) (41 U.S.C. chapter

83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I (JAN 2021) of 52.225-3.

____ (iii) Alternate II (JAN 2021) of 52.225-3.

____ (iv) Alternate III (JAN 2021) of 52.225-3.

____ (50) 52.225-5, Trade Agreements (OCT 2019) 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

____ (51) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016)

(Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

____ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (NOV 2007) (42 U.S.C. 5150

____ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (NOV 2007) (42 U.S.C.

5150).

____ (55) 52.229-12, Tax on Certain Foreign Procurements (JUN 2020).

____ (56) 52.232-29, Terms for Financing of Purchases of Commercial Items (FEB 2002) (41 U.S.C. 4505, 10

U.S.C. 2307(f)).

____ (57) 52.232-30, Installment Payments for Commercial Items (JAN 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

____ (58) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (OCT 2018) (31

U.S.C. 3332).

____ (59) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (JUL

2013) (31 U.S.C. 3332).

____ (60) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (61) 52.239-1, Privacy or Security Safeguards (AUG 1996) (5 U.S.C. 552a).

____ (62) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(13)).

____ (63)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C.

Appx. 1241(b) and 10 U.S.C. 2631).

____ (ii) Alternate I (APR 2003) of 52.247-64.

____ (iii) Alternate II (FEB 2006) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

_____ (1) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67).

_____ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

_____ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple

Year and Option Contracts) (AUG 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY

2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

_____ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (7) 52.222-55, Minimum Wages Under Executive Order 13658 (NOV 2020) (E.O. 13658).

_____ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

_____ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and

Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the

Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1)in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (JUN 2020) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017)

(section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by

Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iv) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or

Equipment. (AUG 2020) (Section 889(a)(1)(A) of Pub. L. 115-232).

(v) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vii) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(viii) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

(x) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xii) 52.222-41, Service Contract Labor Standards (Aug 2018), (41 U.S.C. chapter 67).

(xiii) _____ (A) 52.222-50, Combating Trafficking in Persons (OCT 2020) (22 U.S.C. chapter 78 and E.O. 13627).

_____ (B) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Requirements (May 2014) (41 U.S.C. chapter 67)

(xvi) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xvii) 52.222-55, Minimum Wages Under Executive Order 13658 (NOV 2020) (E.O. 13658).

(xviii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).

(xix) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section

862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (JUN 2020) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx

1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (NOV 2020)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_222_62 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_224_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_224_3 cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13

CFR part 121 and the size standard in paragraph (d) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, when the Contracting Officer explicitly requires it for an order issued under a multiple-award contract.

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraph (b) and (c) of this clause by validating or updating all its representations in the Representations and

Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the

Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in

SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code assigned to contract number .

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the

Contractor represented itself as a women-owned small business concern in paragraph (h)(3) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(4)(i) of this clause is accurate for each WOSB concern eligible under the WOSB

Program participating in the joint venture.

[The Contractor shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: .] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the

WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the

Contractor represented itself as a women-owned small business concern eligible under the WOSB Program in (h)(4) of this clause.] The Contractor represents that--

(i) It [ ] is, [ ] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (h)(5)(i) of this clause is accurate for each…