Solicitation - FA568224Q0009.pdf
PDF 2 MB Posted
- Attached to
- AMENDMENT 0002 - Fire Protection System Maintenance and Repair Service, Aviano and Ghedi AB
- Solicitation number
- FA568224Q0009
About this file
This is a solicitation (FA568224Q0009) for a firm-fixed price contract for Fire Protection System Maintenance and Repair services at Aviano and Ghedi Air Bases in Italy. The contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform scheduled inspection, test and maintenance services on fire protection systems in accordance with the Performance Work Statement. The service is being acquired using FAR Part 12 procedures for commercial items. The contract will have a base period of 11 months and may include up to 4 option periods. Offers are due on the date specified in the solicitation. The procurement is unrestricted but has a women-owned small business set-aside. The agency involved is the Department of the Air Force United States Air Forces in Europe - Air Forces Africa.
View the file
Other files
Show all 17
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
WOMEN-OWNED SMALL
BUSINESS (WOSB)
SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES
1. REQUISITION NUMBER PAGE 1 OF
2. CONTRACT NUMBER 3. AWARD/EFFECTIVE
DATE
4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE
DATE
7. FOR SOLICITATION
INFORMATION CALL:
a. NAME b. TELEPHONE NUMBER (No collect calls)
8. OFFER DUE DATE/
LOCAL TIME
9. ISSUED BY
13b. RATING
14. METHOD OF SOLICITATION
CODE
15. DELIVER TO 16. ADMINISTERED BY CODE
18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/
OFFEROR
CODE
FACILITY
CODE
CODE
TELEPHONE NUMBER
17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN
OFFER
18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK
BELOW IS CHECKED
REQUEST
FOR QUOTE
(RFQ)
INVITATION
FOR BID
(IFB)
REQUEST
FOR
PROPOSAL
(RFP)
SEE ADDENDUM
19.
ITEM NUMBER
20.
SCHEDULE OF SUPPLIES/SERVICES
21.
QUANTITY
22.
UNIT
23.
UNIT PRICE
24.
AMOUNT
(Use Reverse and/or Attach Additional Sheets as Necessary)
25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)
28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN
COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH
AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND
ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS
SPECIFIED
29. AWARD OF CONTRACT: REFERENCE OFFER
DATED . . YOUR OFFER ON SOLICITATION
(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE
SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:
30a. SIGNATURE OF OFFEROR/CONTRACTOR
30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED
31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)
31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED
AUTHORIZED FOR LOCAL REPRODUCTION
PREVIOUS EDITION IS NOT USABLE
STANDARD FORM 1449 (REV. 11/2021)
Prescribed by GSA - FAR (48 CFR) 53.212
10. THIS ACQUISITION IS UNRESTRICTED OR
NORTH AMERICAN
INDUSTRY CLASSIFICATION
STANDARD (NAICS):
SIZE STANDARD:
13a. THIS CONTRACT IS A
RATED ORDER UNDER
THE DEFENSE PRIORITIES
AND ALLOCATIONS
SYSTEM - DPAS (15 CFR 700)
SET ASIDE: % FOR:
11. DELIVERY FOR FREE ON
BOARD (FOB) DESTINATION
UNLESS BLOCK IS MARKED
SEE SCHEDULE
12. DISCOUNT TERMS
ARE ARE NOT ATTACHED
ARE ARE NOT ATTACHED
27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3
AND 52.212-5 ARE ATTACHED. ADDENDA
27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA
8(A)
ECONOMICALLY
DISADVANTAGED
WOMEN-OWNED SMALL
BUSINESS (EDWOSB)
SERVICE-DISABLED
VETERAN-OWNED
SMALL BUSINESS
(SDVOSB)
HUBZONE SMALL
BUSINESS
SMALL BUSINESS
NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.
Solicitation/Contract Form
Fire Protection System Maintenance and Repair Service - AVIANO & GHEDI
Product Service Code: J012 Date: 15 May 2024
FA568224Q0009
Supplies or Services & Prices or Costs
Additional Information/Notes
Item Supplies / Services Quantity Unit Unit Price Amount
WEEKLY ITM SERVICES - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems listed in PWS -Appendix A requiring weekly Inspection, Test and Maintenance (ITM) service in accordance with (IAW) the performance work statement (PWS) attached in section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
WEEKLY ITM SERVICES - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems listed in PWS -Appendix A requiring weekly Inspection, Test and Maintenance (ITM) service in accordance with (IAW) the performance work statement (PWS) attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
MONTHLY ITM SERVICES - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems listed in PWS -Appendix A requiring monthly Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
MONTHLY ITM SERVICES - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform
Scheduled service on all systems listed in PWS -Appendix A requiring monthly Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
QUARTERLY ITM SERVICES - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems listed in PWS -Appendix A requiring quarterly Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
QUARTERLY ITM SERVICES - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service to be performed on all systems listed in PWS -Appendix A requiring quarterly Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
SEMIANNUAL ITM SERVICES - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service to be performed on all systems listed in PWS -Appendix A requiring semiannual Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
SEMIANNUAL ITM SERVICES - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems listed in PWS -Appendix A requiring 11 Months semiannual Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
ANNUAL ITM SERVICES - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems listed in PWS -Appendix A requiring annual Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
ANNUAL ITM SERVICES - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service to be performed on all systems listed in PWS -Appendix A requiring annual Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
3-YEARS ITM SERVICES - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service to be performed on all systems listed in PWS -Appendix A requiring 3-years Inspection, Test and Maintenance (ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
3-YEARS ITM SERVICES - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service to be performed on all systems listed in PWS -Appendix A requiring 3-years Inspection, Test and Maintenance
11 Months
(ITM) service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12-YEARS ITM SERVICES - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform General Verification of the System in compliance with UNI 11224 IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
12-YEARS ITM SERVICES - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform General Verification of the System in compliance with UNI 11224 IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
BACKUP BATTERIES SCHEDULED
REPLACEMENT - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
BACKUPBATTERIES SCHEDULED
REPLACEMENT - GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Scheduled service on all systems IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
EXTRAORDINARY MAINTENANCE - AVIANO
AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Maintenance and repairs not included in the mandatory ITM service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
EXTRAORDINARY MAINTENANCE- GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Maintenance and repairs not included in the mandatory ITM service IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
EMERGENCY - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Emergency Requests (During and After Normal Working Hours) IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
EMERGENCY- GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Emergency Requests (During and After Normal Working Hours) IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
TECHNICAL ASSISTANCE - AVIANO AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Civil Engineer Squadron (CES) Support - Fire Drill support, Generator Maintenance, etc.
Providing Fire Protection Training, Other COR Requests - Surveying, evaluating, generating facility
11 Months records, etc." IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
TECHNICAL ASISTANCE- GHEDI AB
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Civil Engineer Squadron (CES) Support - Fire Drill support, Generator Maintenance, etc.
Providing Fire Protection Training, Other COR Requests - Surveying, evaluating, generating facility records, etc." IAW the PWS attached in Section J.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
11 Months
PRE-WORK REQUIREMENTS
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor and management necessary to perform Duties Required Prior to Commencement of Work - Submittal of all documents listed in Para.
1.5.2. of the PWS, Review of base maps and facilities included in contract, Transition between both contractors, etc.
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
1 Months
Option Line Item
OPTION 1 - Weekly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Weekly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Monthly ITM Services -
AVIANO AB
Product Service Code: J012 12 Months
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
Option Line Item
OPTION 1 Monthly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Quarterly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Quarterly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Semiannual ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Semiannual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Annual ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Annual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 - 2-Years ITM Services -
AVIANO AB
Product Service Code: J012 12 Months
Option Line Item
OPTION 1 - 2-Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 - 12-Years ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 - 12-Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 - Extraordinary Maintenance - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Extraordinary Maintenance
- GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Emergency - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Emergency - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Technical Assistance -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 1 Technical Assistance -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Weekly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Weekly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Monthly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Monthly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Quarterly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Quarterly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Semiannual ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
OPTION 2 Semiannual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Annual ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Annual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - 5-Years ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - 5 -Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - 12-Years ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - 12-Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - Extraordinary Maintenance - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
OPTION 2 - Extraordinary Maintenance - GHEDI AB
2016 Product Service Code: J012
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - Emergency - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - Emergency - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 - Technical Assistance -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 2 Technical Assistance -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Weekly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Weekly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Monthly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Monthly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
OPTION 3 Quarterly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Quarterly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Semiannual ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Semiannual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Annual ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Annual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - 2-Years ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - 2-Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
OPTION 3 - 3-Years ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - 3 -Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - 12-Years ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - 12-Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - Extraordinary Maintenance - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - Extraordinary Maintenance - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - Emergency - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 - Emergency - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
OPTION 3 - Technical Assistance -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 3 Technical Assistance -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Weekly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Weekly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Monthly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Monthly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Quarterly ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Quarterly ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Semiannual ITM Services -
AVIANO AB
Product Service Code: J012 12 Months
Option Line Item
OPTION 4 Semiannual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Annual ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Annual ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 - 12-Years ITM Services -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 - 12-Years ITM Services -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 - Extraordinary Maintenance - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 - Extraordinary Maintenance - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 - Emergency - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
OPTION 4 - Emergency - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 - Technical Assistance -
AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
OPTION 4 Technical Assistance -
GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
12 Months
Option Line Item
6 MO EXTENSION - Weekly ITM Services - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION Weekly ITM Services
- GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION Monthly ITM Services
- AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION Monthly ITM Services
- GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION Quarterly ITM Services - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
6 MO EXTENSION Quarterly ITM Services - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION Annual ITM Services
- AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION Annual ITM Services
- GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - 2-Years ITM Services - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - 2-Years ITM Services - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - 12-Years ITM Services - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - 12-Years ITM Services - GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - Extraordinary Maintenance - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
6 MO EXTENSION - Extraordinary Maintenance - GHEDI AB
5014 Product Service Code: J012
Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - Emergency - AVIANOAB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - Emergency - GHEDIAB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION - Technical Assistance - AVIANO AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Option Line Item
6 MO EXTENSION Technical Assistance
- GHEDI AB
Product Service Code: J012 Claimant Program Code: S1 Pricing Arrangement: Firm Fixed Price
6 Months
Description/Specifications/Statement of Work
Requirements Fire Protection System Maintenance and Repair Service - AVIANO, GHEDI
The Contractor shall provide all supervision, tools, supplies, equipment, transportation, labor, and management necessary to perform the following mandatory services pertaining to the Fire Protection Systems at Aviano AB and Ghedi AB, in accordance with (IAW) the requirements specified in the Performance Work Statement and attachments in Section J.
In accordance with the exception at FAR Part 5.202(a)(12) this contract will be performed outside of the United States and its outlying areas therefore, as per Contracting Officer determination, this acquisition will on be solicited to local sources.
Packaging and Marking
Inspection and Acceptance
DFARS Clauses Incorporated by Full Text
252.229-7003 Tax Exemptions (Italy). (Mar 2012)
As prescribed in 229.402-70(c)(1), use the following clause:
TAX EXEMPTIONS ( ITALY ) (MAR 2012)
(a) As the Contractor represented in its offer, the contract price, including the prices in subcontracts awarded under this contract, does not include taxes from which the United States Government is exempt.
(b) The United States Government is exempt from payment of Imposta Valore Aggiunto (IVA) tax in accordance with Article 72 of the IVA implementing decree on all supplies and services sold to United States Military Commands in Italy .
(1) The Contractor shall include the following information on invoices submitted to the United States Government:
(i) The contract number.
(ii) The IVA tax exemption claimed pursuant to Article 72 of Decree Law 633, dated October 26, 1972 .
(iii) The following fiscal code(s): 91000190933[Contracting Officer must insert the applicable fiscal code(s) for military activities within Italy :
80028250241 for Army, 80156020630 for Navy, or 91000190933 for Air Force].
(2)(i) Upon receipt of the invoice, the paying office will include the following certification on one copy of the invoice:
"I certify that this invoice is true and correct and reflects expenditures made in Italy for the Common Defense by the United States Government pursuant to international agreements. The amount to be paid does not include the IVA tax, because this transaction is not subject to the tax in accordance with Article 72 of Decree Law 633, dated October 26, 1972 ."
An authorized United States Government official will sign the copy of the invoice containing this certification.
(ii) The paying office will return the certified copy together with payment to the Contractor. The payment will not include the amount of the IVA tax.
(iii) The Contractor shall retain the certified copy to substantiate non-payment of the IVA tax.
(3) The Contractor may address questions regarding the IVA tax to the Ministry of Finance, IVA Office, Rome (06) 520741.
(c) In addition to the IVA tax, purchases by the United States Forces in Italy are exempt from the following taxes:
(1) Imposta di Fabbricazione (Production Tax for Petroleum Products).
(2) Imposta di Consumo (Consumption Tax for Electrical Power).
(3) Dazi Doganali (Customs Duties).
(4) Tassa di Sbarco e d'Imbarco sulle Merci Transportate per Via Aerea e per Via Maritima (Port Fees).
(5) Tassa de Circolazione sui Veicoli (Vehicle Circulation Tax).
(6) Imposta di Registro (Registration Tax).
(7) Imposta di Bollo (Stamp Tax).
(End of clause)
Overall Contract Inspection/Acceptance Locations
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Mr. Claudio Tassan Caser Email: claudio.tassan_caser@us.af.mil Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO, AE 09604-3014
UNITED STATES
Telephone: 0434 30 2350/5770
Option Line Item
Inspection and Acceptance Location
Both Destination Instructions: See Statement of Work (SOW) or Performance Work Statement (PWS) for Acceptance/inspection criteria.
DoDAAC: F1F3B1 CountryCode: USA
31 CES CEOE
AF BPN NO MILSBILLS PROCESSES, UNIT 6110 BOX 14
APO,…
This is the start of the file's text. The full file is on GovTribe.
File details come from the government source that posted it. Updated .