Sol_140P2024R0146.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION CALL

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

NPS, DSC Contracting Services Div

12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Shellie Murphy 7206102690

1x 09/10/2024

140P2024R0146

INVITATION FOR BID

REQUEST FOR PROPOSAL

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

ROMO 327127 - Bridge Preservation

NPS PM: Owen Snell

NPS PS: Jennifer Baker

NPS CO: Shellie Murphy

a) This acquisition is being solicited as a Small Business set-aside. The North

American Industrial Classification System (NAICS) code and the associated small business size standard are noted in clause 52.204-8 in section "K" of this solicitation.

b) Estimated Price Range: Between $1,000,000 and $5,000,000

c) Refer to section "L" for information regarding a pre-proposal site visit.

d) Information and requirements stated in sections "B" through "J" & attachments noted in section "J" apply to this solicitation and the subsequent contract.

e) Refer to section "L" for proposal submittal requirements.

f) This is currently an unfunded requirement with a high expectation that funds will be available. When and if funds become available a contract will be awarded at that time.

g) Offerors shall submit proposals and questions, and acknowledge solicitation

Continued ...

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 660 calendar days and complete it within ________________ ________________ calendar days after receiving

FAR Clause 52.211-10

10/24/2024

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 12/2022)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

DOI, NPS, DSC Contracting Services 12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

DSC

Shellie Murphy

28. NEGOTIATED AGREEMENT 29. AWARD

and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations,certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

10 U.S.C. 3204(a) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 12/2022) BACK

Continued...

and return

(Contractor is not required to sign this document.) Your offer on this

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 74

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140P2024R0146 amendments as stated in section "L" of this solicitation

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Date 31 July 2024

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

Page

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

SECTION B – BID SCHEDULE

SECTION C – SPECIFICATIONS / DRAWINGS

SECTION D – PACKAGING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014) .......... Error! Bookmark not defined.

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984) ......................... Error! Bookmark not defined.

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING PLATFORM

SYSTEM (FEB 2021)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: PROHIBITION OF ALL TERRAIN VEHICLES (ATV)S - INTERMOUNTAIN

REGION (JUN 2009)

SPECIAL REQUIREMENT 2: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED LINE

ITEMS

SPECIAL REQUIREMENT 3: DEFINITIONS

52.204-2 SECURITY REQUIREMENTS (MAR 2021) ............................................. Error! Bookmark not defined.

CONSTRUCTION CONTRACTION ADMINISTRATION - FEDERAL ACQUISITION REGULATIONS

36.211(B)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED ENTITIES (DEC 2023) .. 23

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES AND EQUIPMENT (NOV 2021)

52.204-30 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT ORDERS – PROHIBITION (DEC 2023)

52.215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER THAN

CERTIFIED OR PRICING DATA (NOV 2021)

52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER THAN

CERTIFIED OR PRICING DATA-MODIFICATIONS (NOV 2021)

52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS

CONCERNS (OCT 2022)............................................................................................. Error! Bookmark not defined.

52.219-14 LIMITATIONS ON SUBCONTRACTING (OCT 2022) (DEVIATION OCT 2022)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (FEB 2021)

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008) ............................................................................ Error! Bookmark not defined.

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS—ALTERNATE I (MAY 2008) .............................................. Error! Bookmark not defined.

52.223-11 OZONE-DEPLETING SUBSTANCES AND HIGH GLOBAL WARMING POTENTIAL

HYDROFLUOROCARBONS (JUNE 2016)

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (OCT 2022)

52.228-11 PLEDGES OF ASSETS (FEB 2021) (DEVIATION MAY 2023)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020) (DEVIATION MAY

2023)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984) ................................................................... Error! Bookmark not defined.

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984) ........ Error! Bookmark not defined.

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-17 LAYOUT OF WORK. (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES. (NOV 2020)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR 1984) .. 46

1452.228-70 LIABILITY INSURANCE. (JUL 1996)

1452.236-70 PROHIBITION AGAINST USE OF LEAD-BASED PAINT (JUL 1996)......... Error! Bookmark not defined.

1452.280-3 INDIAN ECONOMIC ENTERPRISE SUBCONTRACTING LIMITATIONS (FEB 2021) ...... Error!

Bookmark not defined.

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J – LIST OF ATTACHMENTS

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2024)

52.204-24 REPRESENTATIONS REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES AND EQUIPMENT (NOV 2021)

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES-REPRESENTATION

(OCT 2020)

52.204-29 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT ORDERS – REPRESENTATION

AND DISCLOSURES (DEC 2023)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2020)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION (NOV

2021)

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (FEB 2024)

52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS—NOTICE AND REPRESENTATION (JUN

2020)

52.230-1 COST ACCOUNTING STANDARDS NOTICES AND CERTIFICATION (JUN 2020).............. Error!

Bookmark not defined.

52.230-7 PROPOSAL DISCLOSURE-COST ACCOUNTING PRACTICE CHANGES (APR 2005) ...... Error!

Bookmark not defined.

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

PROVISIONS INCORPORATED BY REFERENCE

52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS. (JUNE 1988)

52.211-6 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS. (JUNE 1988) ............ Error!

Bookmark not defined.

52.216-1 TYPE OF CONTRACT (APR 1984)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS – SECONDARY SITE OF THE WORK (MAY

2014)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS (MAY 2014)

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014) ......................................................................... Error! Bookmark not defined.

52.228-1 BID GUARANTEE (SEP 1996)

52.228-17 INDIVIDUAL SURETY – PLEDGE OF ASSETS (BID GUARANTEE) (FEB 2021)

52.232-38 SUBMISSION OF ELECTRONIC FUNDS TRANSFER INFORMATION WITH OFFER (JUL

2013)

52.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (JUL 1996) (DEVIATION)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

52.237-10 IDENTIFICATION OF UNCOMPENSATED OVERTIME (MAR 2015)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE

INTERIOR (APR 1984)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION – COMPETITIVE

SOURCE SELECTION

SECTION M – EVALUATION FACTORS FOR AWARD

SPECIAL PROVISION 1: EVALUATION OF OPTIONS

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

PART I – THE SCHEDULE

SECTION A – SOLICITATION / CONTRACT FORM

Solicitation, Offer, and Award (SF-1442) - pages 1- 3 of this package

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

SECTION B – BID SCHEDULE

CONTRACT BID SCHEDULE

SOLICITATION NUMBER: 140P2024R0146

PARK - PMIS: ROMO 327127

PROJECT TITLE: Bridge Preservation

Offerors are required to submit, at a minimum, one (1) Firm-Fixed-Price (FFP) offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Please complete Attachment XX Contract Price Schedule (include this sentence if not using table below). Failure to do so may render the proposal unacceptable.

On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of summation error, the total corrected amounts govern. Round totals and extended prices to whole dollars. Refer to section “H” of this solicitation for additional information regarding contract options.

CONTRACT

LINE-ITEM

NUMBER (CLIN)

CONTRACT LINE ITEM (CLI) TITLE QUANTITY UNIT OF

MEASURE

UNIT

PRICE

TOTAL

PRICE

0010 Chiquita Creek Bridge (1520-008P) 1 LS $0.00 0020 Little Horseshoe Park Bridge (1520-009S) 1 LS $0.00 0030 Bowen/Baker Trail Culvert (1520-015S) 1 LS

0040 Gubbins-Johnson Access Culvert (1520-

024S) 1 LS

0050 In-Holder Access Culvert (1520-022S) 1 LS 0060 Coyote Valley Trail Culvert (1520-026T) 1 LS 0070 Glacier Creek Livery Bridge (1520-028P) 1 LS

TOTAL BASE PRICE (Contract Line-Item Number 0010 through 0070) ------------------------------------ $0.00

0080 Big Thompson River Bridge (1520-002P) 1 LS $0.00

0090 Aspenglen Campground Bridge (1520-

006P) 1 LS

0100 Tonahutu Creek Culvert (1520-016P) 1 LS $0.00

TOTAL PRICE FOR ALL OPTIONS (Contract Line-Item Numbers 0080 through 0100) -------------------- -------- $0.00

TOTAL PROPOSED PRICE - BASE PLUS ALL OPTIONS (CLIN 0010 through 0100) $0.00

All measurement and payment information are included in the project specifications, Section 01 27 00.

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

SECTION C – SPECIFICATIONS / DRAWINGS

The work of this contract is for the construction of: Bridge Preservation

Rocky Mountain National Park, Colorado

The bridge preservation work includes concrete repair for spalling concrete, repair concrete curbs cracks, clean and reseal joint work, repair undermining at abutments, repointing and masonry repair, removing debris, and in-river scour countermeasures. Specifications and drawings are attached and incorporated herein by reference.

Refer to section J.

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

SECTION D – PACKAGING AND MARKING

Section Does Not Apply

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its Subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10-calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 660-calendar day. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,553.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

52.242-14 SUSPENSION OF WORK (APR 1984)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20-days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the Contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3-days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30-days to any notice made under paragraph (d) of this clause.

A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the

Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose.

The form provides for exception of specified claims from operation of the release.

(End of clause)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in CPARS for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30-days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60-days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60-calendar days after receipt of the CPAR. On day 15, the evaluation will become available in CPARS marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60-days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the Contractor on (date). The Contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.cpars.gov/ https://www.cpars.csd.disa.mil/ https://www.cpars.gov/

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the Contracting Officer no later than seven (7)-days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of notice)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INVOICE PROCESSING

PLATFORM SYSTEM (FEB 2021)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

The Contractor shall submit a draft Invoice Package, including copies of the following documents, to the National Park Service’s (NPS) Construction Management Representative (CMR) a minimum of 5 working days prior to submittal of the formal Invoice through IPP. Within 5 working days of receipt, the CMR shall provide an acceptability recommendation to both the NPS Contracting Officer’s Representative (COR) and the Contractor. If the CMR recommends acceptance, the Contractor shall submit a copy of the final version of the CMR’s checklist and the Invoice Package to the NPS through IPP.

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP);

2. Completed copy of the Pay Estimate Form (including signed certification of Subcontractor payments);

3. Completed copy of the Limitations on Subcontracting Report

4. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts;

5. A copy of the current construction schedule (refer to project specification section 013216); and

6. A copy of the current Schedule of Values. (refer to project specification section 013216).

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of St. Louis (FRBSTL) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email Invoice Processing Platform - Contact Us (treasury.gov) or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Clause) https://www.ipp.gov/ https://www.ipp.gov/ https://www.fiscal.treasury.gov/ipp/contact.html https://www.fiscal.treasury.gov/ipp/contact.html

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL REQUIREMENT 1: PROHIBITION OF ALL TERRAIN VEHICLES (ATV)S -

INTERMOUNTAIN REGION (JUN 2009)

The Contractor is prohibited from utilizing All-Terrain Vehicles (ATV)s on National Park Service lands. ATV is defined as:

A motorized off-highway vehicle (OHV) traveling on four or more low-pressure tires, having a seat to be straddled by the operator and a handlebar for steering control.

Use of Utility Terrain Vehicles (UTVs) are permitted. UTV (also called a side-by-side) is defined as: A motorized OHV having four or more low pressure tires, designed with side-by-side seats, seatbelts, steering wheel, and optional cab, brush cage, or ROPS.

(End of Local Clause)

SPECIAL REQUIREMENT 2: OPTION FOR ADDITIONAL SERVICES—SEPARATELY PRICED

LINE ITEMS

The Government may require the delivery of the numbered line items identified in the Schedule as option items at the price stated in the Schedule. The Contracting Officer may unilaterally exercise the option by written notice to the Contractor within 90-days after contract award. Performance of added line-item tasks shall be at the price negotiated in the contract Schedule.

(End of clause)

SPECIAL REQUIREMENT 3: DEFINITIONS

For the purposes of this solicitation, any use of the following shall be synonymous with its identified counterpart below, pursuant to the FAR’s usage of the terms within FAR 15.

(a) Bid = Proposal;

(b) Bidder = Offeror; and

(c) Bid Option = Option.

(End of clause)

CONSTRUCTION CONTRACTION ADMINISTRATION - FEDERAL ACQUISITION REGULATIONS

36.211(B).

Federal Acquisition Regulation (FAR) 36.211(b) requires agencies provide description of policies and procedures that apply to definitization of equitable adjustments for change orders under construction contracts and data on the time required to definitize equitable adjustments for change orders under construction contracts. This information can be found at:

https://www.doi.gov/pam/acquisition/policy/constructioncontract.

https://www.doi.gov/pam/acquisition/policy/constructioncontract

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

The following contract clauses pertinent to this section are incorporated by reference (by Citation Number, Title, and Date) per the clause at FAR “52.252-2 CLAUSES INCORPORATED BY REFERENCE” in Section I of this contract. See FAR 52.252-2 for an internet address (if specified) for electronic access to a clause’s full text.

Federal Acquisition Regulation: https://www.acquisition.gov/far/

Department of the Interior Acquisition Regulation (CFR, Title 48, Chapter 14): http://www.ecfr.gov/cgi-bin/text-idx?SID=46fff09635987db3af784ea3c7efc2e0&mc=true&tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl#1400

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RECESSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (JUN 2020) 52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR

STATEMENTS (JAN 2017)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (OCT 2016)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) 52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (NOV 2021)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUNE 2023)

52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUB-CONTRACTING WITH CONTRACTOR’S

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (NOV 2021)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT

2018) 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (NOV 2015)

52.215-2 AUDIT AND RECORDS-NEGOTIATIONS (JUN 2020)

52.215-8 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST AND PRICING DATA (AUG 2011) 52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA—MODIFICATIONS (JUN

2020).

52.215-12 SUBCONTRACTOR CERTIFIED COST AND PRICING DATA (JUN 2020)

52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA—MODIFICATIONS (JUN 2020) I

52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)

52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER THAN

PENSIONS (JUL 2005)

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (MAR 2020)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (FEB 2024)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS-OVERTIME COMPENSATION (MAR 2018)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (AUG 2018)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (JUL 2021)

https://www.acquisition.gov/far/ http://www.ecfr.gov/cgi-bin/text-idx?SID=46fff09635987db3af784ea3c7efc2e0&mc=true&tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl#1400 http://www.ecfr.gov/cgi-bin/text-idx?SID=46fff09635987db3af784ea3c7efc2e0&mc=true&tpl=/ecfrbrowse/Title48/48cfrv5_02.tpl#1400

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

52.222-12 CONTRACT TERMINATION - DEBARMENT (MAY 2014)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIRMENTS AND RELATED REGULATIONS

(MAY 2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-19 CHILD LABOR-COOPERATION WITH AUTHORITIES AND REMEDIES (FEB 2024)

52.222-20 CONTRACTS FOR MATERIALS, SUPPLIES, ARTICLES AND EQUIPMENT EXCEEDING $15,000 (JUNE

2020)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

52.222-26 EQUAL OPPORTUNITY (SEP 2016)

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (APRIL 2015)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUN 2020)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT (DEC 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (MAY 2022)

52.222-55 MINIMUM WAGES UNDER EXECUTIVE ORDER 14026 (JAN 2022)

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JAN 2022)

52.223-1 BIOBASED PRODUCT CERTIFICATION (MAY 2024)

52.223-7 NOTICE OF RADIOACTIVE MATERIALS (JAN 1997)

52.223-10 WASTE REDUCTION PROGRAM (MAY 2024)

52.223-11 OZONE-DEPLETING SUBSTANCES AND HIGH GLOBAL WARMING POTENTIAL

HYDROFLUOROCARBONS (MAY 2024)

52.223-12 MAINTENANCE, SERVICE, REPAIR, OR DISPOSAL OF REFRIGERATION EQUIPMENT AND AIR

CONDITIONERS (MAY 2024)

52.223-19 COMPLIANCE WITH ENVIRONMENTAL MANAGEMENT SYSTEMS (MAY 2011)

52.223-20 AEROSOLS (MAY 2024)

52.223-21 FOAMS (MAY 2024)

52.223-22 PUBLIC DISCLOSURE OF GREENHOUSE GAS EMISSIONS AND REDUCTION GOALS -

REPRESENTATION (DEC 2016)

52.223-23 SUSTAINABLE PRODUCTS AND SERVICES (MAY 2024)

52.224-1 PRIVACY ACT NOTIFICATION (APR 1984)

52.224-2 PRIVACY ACT (APR 1984)

52.224-3 PRIVACY TRAINING (JAN 2017)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.226-1 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN-OWNED ECONOMIC ENTERPRISES (JUN 2000)

52.226-7 DRUG-FREE WORKPLACE (MAY 2024)

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (MAY 2024)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JUN 2020)

52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC 2007)

52.227-17 RIGHTS IN DATA – SPECIAL WORKS (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (DEC 2022)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

52.229-12 TAX ON CERTAIN FOREIGN PROCUREMENTS (FEB 2021)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

Solicitation No.

140P2024R0146

National Park Service (NPS) – Denver Service Center (DSC) ROMO 327127 – Bridge Preservation

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER – SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS CONTRACTORS (MAR 2023)

52.233-1 DISPUTES (MAY 2014) – ALTERNATE 1 (DEC 1991)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-4 CHANGES (JUN 2007)

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (FEB 2024)

52.245-9 USE AND CHARGES (APR 2012)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.248-3 VALUE ENGINEERING – CONSTRUCTION (OCT 2020)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012),

ALT 1 (SEP 1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

52.203-14 DISPLAY OF HOTLINE POSTER(S) (NOV 2021)

(a) Definition.

United States, as used in this clause, means the 50 States, the District of Columbia, and outlying areas.

(b) Display of fraud hotline poster(s). Except as provided in paragraph (c)—

(1) During contract performance in the United States, the Contractor shall prominently display in common work areas within business segments performing work under this contract and at contract work sites-

(i) Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this clause; and

(ii) Any DHS fraud hotline poster subsequently identified by the Contracting Officer.

(2) Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the poster(s) at the website.

(3) Any required posters may be obtained as follows:

Poster(s) Obtain From

CO shall insert-

(i) Appropriate agency name(s) and/or title of applicable Department of Homeland Security fraud hotline poster); and

(ii) The website(s) or other contact information for obtaining the poster(s).

(c) If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.

(d) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed the…