Sol_140L6226Q0014.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NO.

5. REQUISITION/PURCHASE REQUEST NO.

CODE

6. PROJECT NO.

8. ADDRESS OFFER TO

4. CONTRACT NO.

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

NEGOTIATED (RFP) REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF

SEALED BID (IFB) INVITATION FOR BID

9. FOR

INFORMATION CALL

PAGES

140L6226Q0014

BLM WY-STATE OFC BUS MGMT BR(WY951)

5353 YELLOWSTONE RD.

CHEYENNE WY 82009

0044039391

LYA

Huong Le 0000000000

05/19/2026

06/09/2026

0 120

1 3

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Continued...

AMENDMENT

NUMBER

DATE.

BLM WY-STATE OFC BUS MGMT BR(WY951)

5353 YELLOWSTONE RD.

CHEYENNE WY 82009

LYA

Laura Park

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

140L6226Q0014

Delivery: 12/31/2026

Delivery Location Code: 0011276734

BLM-WY BUFFALO FIELD OFFICE

1425 FORT ST

BUFFALO WY 82834-2436 US

Period of Performance: 07/01/2026 to

12/31/2026

00010 FENCE CONSTRUCTION AND LABOR

Product/Service Code: Z2QA

Product/Service Description: REPAIR OR

ALTERATION

OF RESTORATION OF REAL PROPERTY (PUBLIC OR

PRIVATE)

00020 FENCE CONSTRUCTION AND LABOR

Product/Service Code: Z2QA

Product/Service Description: REPAIR OR

ALTERATION

OF RESTORATION OF REAL PROPERTY (PUBLIC OR

PRIVATE)

U.S. DEPARTMENT OF THE INTERIOR

Bureau of Land Management | Buffalo Field Office | Wyoming

REQUEST FOR QUOTATION (RFQ)

Fence Replacement

Solicitation No. 140L6226Q0013

NAICS Code 238990 – All Other Specialty Trade Contractors (Fence Construction)

Size Standard $19.0 Million (Small Business Set-Aside – Total SB)

Contract Type Firm-Fixed-Price (FFP) Construction

Period of Performance July 1, 2026 – December 31, 2026

Questions Due June 1, 2026 at 2:00pm MST— Submit in writing via email only

Quotes Due June 9, 2026 at 2:00pm MST

Contracting Officer Laura Park, Bureau of Land Management

Contracting Specialist Huong Tiffany Le, hhle@ios.doi, Bureau of Land Management

COMBINED SYNOPSIS/SOLICITATION NOTICE

This is a combined synopsis/solicitation for commercial services prepared in accordance with RFO FAR Part 12. This announcement constitutes the only solicitation. Quotes are being requested and a separate written solicitation will not be issued.

This acquisition IS set aside for small business concerns (NAICS 238990; Size Standard: $19M). This solicitation incorporates provisions and clauses by reference. The full text of provisions and clauses may be accessed electronically at www.acquisition.gov.

mailto:hhle@ios.doi http://www.acquisition.gov/

TABLE OF CONTENTS

PART I – THE SCHEDULE

Section A: Solicitation / Contract Form (SF 1442) Section B: Bid Schedule Section C: Specifications / Statement of Work Section D: Packaging and Marking Section E: Inspection and Acceptance Section F: Deliveries or Performance Section G: Contract Administration Data Section H: Special Contract Requirements

PART II – CONTRACT CLAUSES

Section I: Contract Clauses

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

Section J: List of Attachments

PART IV – REPRESENTATIONS AND INSTRUCTIONS

Section K: Representations, Certifications, and Other Statements of Offerors Section L: Instructions, Conditions, and Notices to Offerors Section M: Evaluation Factors for Award

PART I – THE SCHEDULE

SECTION A: SOLICITATION / CONTRACT FORM

Refer to Standard Form (SF) 1442, Solicitation, Offer, and Award (Construction, Alteration, or Repair), incorporated herein and attached as Attachment A-1. Offerors shall complete Blocks 14, 15, 16, 17, 19, 20a, 20b, 20c, 30a, 30b, and 30c of the SF 1442. An authorized official must sign Block 30a. Failure to complete and sign all required blocks may result in the offer being deemed unacceptable.

(END OF SECTION A)

SECTION B: BID SCHEDULE

See Attachment 2 for bid schedule

(END OF SECTION B)

SECTION C: SPECIFICATIONS / STATEMENT OF WORK

See Attachment 1 for Statement of Work

(END OF SECTION C)

SECTION D: PACKAGING AND MARKING

Not Applicable. No Government-furnished packaging or marking requirements apply to this construction contract.

(END OF SECTION D)

SECTION E: INSPECTION AND ACCEPTANCE

Clauses Incorporated by Reference Clause Title Date 52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994

Final Inspection and Acceptance:

The Contracting Officer (CO) or authorized Contracting Officer's Representative (COR) will perform final inspection. Final acceptance will occur only upon written notice from the CO. The Contractor shall notify the CO in writing at least three (3) working days before the anticipated completion date so the Government can schedule final inspection. The Contractor's superintendent shall be present during the final inspection. Final payment may be withheld subject to CO approval of finished site conditions.

(END OF SECTION E)

SECTION F: DELIVERIES OR PERFORMANCE

Clauses Incorporated by Reference Clause Title Date 52.242-14 Suspension of Work APR 1984

F-1. Commencement, Prosecution, and Completion of Work (52.211-10):

The Contractor shall: (a) commence work no earlier than July 1, 2026, and within ten (10) calendar days after receipt of Notice to Proceed (NTP); (b) prosecute the work diligently; and (c) complete all work, including final cleanup, no later than December 31, 2026, or within four (4) weeks of commencing construction, whichever is earlier. The period of performance reflects a Wildlife Timing Limit Stipulation (TLS) for sage-grouse protection that prohibits work before July 1.

F-2. Liquidated Damages:

Liquidated damages are assessed for failure to complete the work within the required performance period. The CO has evaluated this requirement and established a liquidated damages rate. The rate for this contract is $[CO TO COMPLETE] per calendar day of unexcused delay beyond the completion date, reflecting the Government's assessed impact of delayed fence completion on livestock management and wildlife habitat objectives.

F-3. Place of Performance:

Johnson County, Wyoming, approximately 35 miles southeast of Buffalo, WY. Exact location identified in the SOW and project maps.

(END OF SECTION F)

SECTION G: CONTRACT ADMINISTRATION DATA

G-1. Authorities and Delegations (DIAR 1452.201-70, SEP 2011) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition, waive any requirement, or accept nonconforming work. The COR will be designated at time of award and is responsible for technical monitoring of contractor performance. The COR is NOT authorized to: (1) promise, award, or execute any contract modification; (2) waive the delivery schedule; (3) make final decisions on Disputes clause matters; (4) terminate the contractor's right to proceed; or (5) obligate payment of money. The Contractor shall comply with written or oral direction of the CO or COR within the scope of their authority and shall notify the CO in writing within 3 days if it believes the COR has exceeded their authority.

G-2. Government Points of Contact Contracting Officer (CO) Laura Park, Bureau of Land Management, Wyoming State Office

Contracting Specialist

(CS)

Huong Tiffany Le, Bureau of Land Management, Wyoming State Office

Contracting Office Address

Bureau of Land Management | 5353 Yellowstone Road | Cheyenne, WY 82003

G-3. Electronic Invoicing – Invoice Processing Platform (IPP) Payment requests must be submitted electronically through the U.S. Department of the Treasury's Invoice Processing Platform (IPP) at https://www.ipp.gov. The Contractor's Government Business Point of Contact (as listed in SAM) will receive enrollment instructions from the Federal Reserve Bank within 3–5 business days of award. Contact IPP Customer Support at IPPCustomerSupport@fiscal.treasury.gov or (866) 973-3131 for enrollment assistance. Invoices submitted outside IPP will not be processed unless the CO has granted a written waiver. Each invoice must include: (1) invoice date and contract number; (2) billing period (beginning and ending dates); (3) accounting following the approved CLIN schedule; (4) total amount due; (5) certification of progress payment; (6) weekly certified payrolls; (7) substantiation of subcontractor payments; and (8) Limitations on Subcontracting Worksheet (with final payment invoice).

G-4. Payment Status Hotline To check payment status, contact the Payment Hotline at (877) 480-9724 or (303) 236-2850. Have available: company name, contract number, invoice number, invoice amount, and reason for call. If no callback within 72 hours, contact the Contracting Officer.

G-5. Contractor Performance Assessment Reporting System (CPARS) FAR 42.1502 requires collection of past performance information. The Contractor shall provide the CO with the name, title, phone number, and email for each person designated to access CPARS evaluations no later than 30 days after award. Performance evaluations will be conducted in CPARS at https://www.cpars.gov/. The Contractor has 60 days to respond to each evaluation after receipt.

(END OF SECTION G)

SECTION H: SPECIAL CONTRACT REQUIREMENTS

Refer to Statement of Work

(END OF SECTION H)

PART II – CONTRACT CLAUSES

SECTION I: CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

NOTE: Clauses marked 'DEVIATION' implement Executive Orders or RFO class deviations. The full text of all clauses incorporated by reference is available at https://www.acquisition.gov/far/ and https://www.acquisition.gov/diar/.

SAM System Note: The System for Award Management (SAM) may continue to prompt entities to complete representations based on provisions not included in this solicitation, including 52.223-22 and paragraph (t) of 52.212-3. Agencies will not consider or use these representations. Entities are not required to update their SAM registration to remove them.

CLAUSE NO. TITLE DATE

DIAR 1452.201-70 Authorities and Delegations SEP 2011

DIAR 1452.203-70 Restrictions on Endorsements – DOI JUL 1996

DIAR 1452.204-70 Release of Claims – DOI JUL 1996

DIAR 1452.236-70 Prohibition Against Use of Lead-Based Paint JUL 1996

DIAR 1452.237-70 Information Collection – DOI JUL 1996

52.202-1 Definitions JUN 2020

52.203-3 Gratuities APR 1984

52.204-7 System for Award Management NOV 2024

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018

52.204-18 Commercial and Government Entity Code Maintenance AUG 2020

52.204-19 Incorporation by Reference of Representations and Certifications

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab

DEC 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.209-6 Protecting the Government's Interest When Subcontracting with Debarred Contractors

NOV 2021

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations

NOV 2015

52.219-1 Small Business Program Representations FEB 2024

52.219-6 Notice of Total Small Business Set-Aside NOV 2020

52.219-14 Limitations on Subcontracting MAR 2020

52.219-28 Post-Award Small Business Program Representation JAN 2025

52.222-3 Convict Labor JUN 2003

52.222-6 Construction Wage Rate Requirements (Davis-Bacon Act) AUG 2018 https://www.acquisition.gov/diar/

52.222-7 Withholding of Funds MAY 2014

52.222-8 Payrolls and Basic Records JUL 2021

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) JUL 2005

52.222-12 Contract Termination – Debarment MAY 2014

52.222-13 Compliance with Davis-Bacon and Related Act Regulations MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility MAY 2014

52.222-21 Prohibition of Segregated Facilities APR 2015

52.222-26 Equal Opportunity SEP 2016

52.222-27 Affirmative Action Compliance Requirements for Construction APR 2015

52.222-35 Equal Opportunity for Veterans JUN 2020

52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020

52.222-37 Employment Reports on Veterans FEB 2016

52.222-50 Combating Trafficking in Persons NOV 2021

52.223-6 Drug-Free Workplace MAY 2001

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021

52.228-1 Bid Guarantee SEP 1996

52.228-5 Insurance – Work on a Government Installation JAN 1997

52.228-11 Pledges of Assets JAN 2012

52.228-14 Irrevocable Letter of Credit NOV 2014

52.228-15 Performance and Payment Bonds – Construction OCT 2010

52.229-3 Federal, State, and Local Taxes FEB 2013

52.232-5 Payments Under Fixed-Price Construction Contracts MAY 2014

52.232-17 Interest MAY 2014

52.232-23 Assignment of Claims MAY 2014

52.232-33 Payment by Electronic Funds Transfer – SAM OCT 2018

52.233-1 Disputes MAY 2014

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-15 Schedules for Construction Contracts APR 1984

52.236-21 Specifications and Drawings for Construction FEB 1997

52.236-26 Preconstruction Conference (DEVIATION FEB 2025) FEB 1995

52.236-28 Preparation of Proposals – Construction OCT 1997

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Products and Commercial Services

JAN 2023

52.246-12 Inspection of Construction AUG 1996

52.246-21 Warranty of Construction MAR 1994

52.249-2 Termination for Convenience of the Government (Fixed- Price)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

(END OF SECTION I)

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J: LIST OF ATTACHMENTS

ATTACH. DESCRIPTION PAGES

1 STATEMENT OF WORK 30

2 BID SCHEDULE 1

3 MAPS 3

3 SPECIFICATIONS 6

4 WAGE DETERMINATION 5

(END OF SECTION J)

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K: REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF

OFFERORS

Provisions Incorporated by Reference

PROVISION TITLE DATE

52.203-11 Certification and Disclosure Regarding Payments to Influence

Certain Federal Transactions

SEP 2007

52.204-3 Taxpayer Identification OCT 1998

52.204-8 Annual Representations and Certifications MAY 2024

52.204-17 Ownership or Control of Offeror AUG 2020

52.209-5 Certification Regarding Responsibility Matters OCT 2015

52.219-1 Small Business Program Representations FEB 2024

52.222-22 Previous Contracts and Compliance Reports FEB 1999

52.222-25 Affirmative Action Compliance APR 1984

52.223-22 Public Disclosure of Greenhouse Gas Emissions and Reduction Goals – Representation

DEC 2022

52.225-2 Buy American Certificate OCT 2022

52.225-18 Place of Manufacture AUG 2018

52.227-6 Royalty Information APR 1984

Offerors shall complete all representations and certifications in SAM.gov and confirm completion in the SF 1442. Offerors must complete and return Section K provisions that require manual certification. Note that FAR 52.204-8 applies to this solicitation – completing annual reps and certs in SAM.gov satisfies most provisions.

(END OF SECTION K)

SECTION L: INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

Quote Submission Requirements

• Email your complete quote package to hhle@ios.doi.gov.

• Include the solicitation title and number in the email subject line.

• Provide your UEI number on your quote.

• Complete and sign the SF-1442 with prices listed per the Bid Schedule (Attachment 2).

• Confirm that your SAM.gov registration is active at time of submission.

• Submit all questions by June 1, 2026 at 2:00 PM MST to hhle@ios.doi.gov.

(END OF SECTION L)

mailto:hhle@ios.doi.gov

SECTION M: EVALUATION FACTORS FOR AWARD

Basis for Award — RFO FAR 12.201-1 Comparative Evaluation

This acquisition uses simplified procedures under RFO FAR 12.201-1. The Government will conduct a comparative evaluation of quotations in accordance with RFO FAR 12.203(c)(2). The Government is not required to establish a competitive range, score quotations, or produce formal evaluation plans. The contracting officer has broad discretion in evaluating quotations.

Award will be made to the responsible quoter whose quotation provides the best value to the Government, considering price and the non-price factors identified below. When combined, the non-price factors are more important than price.

Evaluation Factors

• Technical approach: The quoter shall describe its approach for meeting all Bureau of Land Management specifications and contract requirements.

• Relevant experience: The quoter shall demonstrate experience constructing wire fencing in rangeland conditions and provide descriptions of similar projects and references. Experience with metal-post fencing is preferred.

• Capability and resources: The quoter shall demonstrate the ability to furnish the materials, tools, equipment, and other resources necessary to construct open-range/livestock-control barrier fence lines.

• Schedule: The quoter shall describe how it will complete the work within the required performance period and provide a proposed project schedule.

• Project management and supervision: The quoter shall describe how the work will be managed and supervised, including the proposed workforce, key roles, and responsibilities.

• The Government may communicate with quoters, request clarifications, and seek revised quotations if determined necessary. Past performance references that are not relevant to the requirement may be given less weight in the comparative evaluation.

(END OF SOLICITATION)

Offeror phone number

Standard form 1442 backside

Sponsored by GSA FAR (48 CFR) 53.110