SECTION F - DELIVERIES OR PERFORMANCE - module entrance.pdf
PDF 96 KB Posted
- Attached to
- Building 5 Module Entrances Construction Services Federal contract opportunity
- Solicitation number
- 15F06724R0000141
About this file
This document is the SECTION F - DELIVERIES OR PERFORMANCE from a federal contract opportunity. It outlines the deliverable items, location, term, work schedule, and notice requirements for the contract.
The key details are:
- All services and reports listed under Section C of the contract shall be executed per the contract requirements and at the direction of the Contracting Officer's Representative (COR).
- The work will be primarily performed at the CJIS Division in Clarksburg, WV.
- The contract is for a base period of one (1) year with one 6-month option.
- The contractor's normal workday is 8:00 a.m. to 4:30 p.m. Monday through Friday, with deviations requiring prior approval. No work is to be scheduled on weekends or federal holidays without prior approval.
- The contractor must notify the Contracting Officer and COR immediately of any difficulties meeting performance requirements or delivery schedules.
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| Pre Bid RFIs.xlsx | XLSX spreadsheet | |
| 15F06724R0000141_Mod 2.pdf | ||
| SECTION L Instructions Conditions and Notices to Offerors - Module Entrance - 060624.pdf | ||
| SECTION L Instructions Conditions and Notices to Offerors - Module Entrance.pdf | ||
| 15F06724R0000141_Mod_1.pdf | ||
| SECTION L Instructions Conditions and Notices to Offerors - Module Entrance -.pdf | ||
| Question Template.xlsx | XLSX spreadsheet | |
| SECTION E - INSPECTION AND ACCEPTANCE - Module Entrance.pdf | ||
| SECTION H - SPECIAL CONTRACT REQUIREMENTS - module entrance.pdf | ||
| Attachment H-Pricing Template.xlsx | XLSX spreadsheet | |
| SECTION M - EVALUATION CRITERIA - Module Entrance - .pdf | ||
| Wage Determination.pdf | ||
| Section B.pdf | ||
| Section C .pdf | ||
| SECTION G - CONTRACT ADMINISTRATION DATA - Module Entrances .pdf | ||
| SECTION L Instructions Conditions and Notices to Offerors - Module Entrance - .pdf |
Show all 16
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
SECTION F – DELIVERIES OR PERFORMANCE
F.1 DELIVERABLE ITEMS
All the services and reports listed under Section C of this contract shall be executed in accordance with the requirements of the contract and at the direction of the COR.
F.2 LOCATION
The work performed under this contract will be primarily located at the CJIS
Division in Clarksburg, WV.
F.3 TERM OF CONTRACT
The contract is for base period of one (1) year, with one 6-month option.
F.4 WORK SCHEDULE
The Contractor’s normal workday will typically be within the hours of 8:00 a.m.
and 4:30 p.m. Monday through Friday. The Contractor shall not change approved work schedules without the prior consent of the Contracting Officer or their designated representative. Whenever nonessential services have been scheduled on the date a holiday occurs, such services shall be performed on the following working day. Deviation from the work schedules is permissible only when approved by the Contracting Officer or their designated representative. For all unscheduled work the contractor shall obtain Contracting Officer or their designated representative approval.
F.5 WORK OUTSIDE REGULAR WORKING HOURS
All work shall be performed during regular working hours. No work shall be scheduled and/or planned to be done on Saturdays, Sundays or Federal holidays, unless otherwise specified herein or directed by the Contracting Officer or their designated representative. Whenever periodic services have been scheduled on a date a Federal holiday occurs, then such services may be performed on the next normal working day. If the Contractor, without additional costs to the Government, desires to work Saturday, Sunday, holidays or outside the station's regular working hours, he must submit an application to the Contracting Officer or their designated representative, in writing, at least seventy-two (72) hours in advance. In no event shall the Contractor work outside of regular working hours without prior approval.
F.6 NOTICE TO THE GOVERNMENT OF DELAYS
In the event the Contractor encounters difficulty in meeting performance requirements, or when the Contractor anticipates difficulty in complying with the contract delivery schedule or completion date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the
Contracting Officer and the COR, in writing, giving pertinent details; provide, however, that this data shall be informational only in character and that this provision shall not be construed as a wavier by the Government or any delivery schedule or date, or any rights or remedies provided by law or under this contract.
File details come from the government source that posted it. Updated .