S02 SOL-Att-09 - Relocate Electron Microscope Specifications Vol 1.pdf

PROJECT SPECIFICATIONS

FOR 100% CONSTRUCTION DOCUMENTS

Volume 1 Specifications (Div: 00- 12)

PROJECT TITLE: Relocate Electron Microscope VA PROJECT NO.: Project 607-19-115

Wm S. Middleton VA Medical Center Madison, Wisconsin

36C25221R0070 Attachment 9

01-01-20

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 12-18

01 32 16.15 Project Schedules 02-15 01 33 23 Shop Drawings, Product Data, and Samples 05-17 01 35 26 Safety Requirements 02-17 01 42 19 Reference Standards 09-19 01 74 19 Construction Waste Management 09-13

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17 02 82 11 Traditional Asbestos Abatement 04-19 02 82 13.13 Glovebag Asbestos Abatement 09-15 02 82 13.19 Asbestos Floor Tile and Mastic Abatement 09-15 02 82 13.31 Asbestos Transite Abatement 09-15

DIVISION 05 – METALS

05 50 00 Metal Fabrications 08-18

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17 06 20 00 Finish Carpentry 08-16

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 13 Thermal and Acoustical Insulation 10-17 07 60 00 Flashing and Sheet Metal 07-14 07 84 00 Firestopping 02-16 07 92 00 Joint Sealants 10-17

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16 08 14 00 Interior Wood Doors 02-16 08 31 13 Access Doors and Frames 02-16 08 71 00 Door Hardware 01-20

DIVISION 09 – FINISHES

00 01 10-2

SECTION NO. DIVISION AND SECTION TITLES DATE

09 05 16 Subsurface Preparation for Floor Finishes 02-15 09 06 00 Schedule for Finishes 04-15 09 22 16 Non-Structural Metal Framing 06-18 09 29 00 Gypsum Board 06-18 09 51 00 Acoustical Ceilings 12-18 09 65 13 Resilient Base and Accessories 02-16 09 65 16 Resilient Sheet Flooring 05-18 09 68 00 Carpeting 10-15 09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES

10 26 00 Wall and Door Protection 10-15

DIVISION 12 – FURNISHINGS

12 31 00 Manufactured Metal Casework 05-15 12 36 00 Countertops 12-18

DIVISION 21- FIRE SUPPRESSION

21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16 22 05 23 General-Duty Valves for Plumbing Piping 09-15 22 07 11 Plumbing Insulation 09-19 22 11 00 Facility Water Distribution 11-19 22 13 00 Facility Sanitary and Vent Piping 09-15 22 40 00 Plumbing Fixtures 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 08-17 23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment 08-17

23 05 41 Noise and Vibration Control for HVAC Piping and Equipment

02-15

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-15 23 05 93 Appendix

Existing HVAC Equipment Testing and Balancing Reference information

23 07 11 HVAC and Boiler Plant Insulation 02-15 23 09 23 Direct-Digital Control System for HVAC 09-11 23 21 13 Hydronic Piping 08-17 23 31 00 HVAC Ducts and Casings 03-13 23 34 00 HVAC Fans 02-15 23 36 00 Air Terminal Units 02-15 23 37 00 Air Outlets and Inlets 02-15

00 01 10-3

SECTION NO. DIVISION AND SECTION TITLES DATE

23 82 00 Convection Heating and Cooling Units 04-11 23 82 16 Air Coils 04-11

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17 26 05 26 Grounding and Bonding for Electrical Systems 01-17 26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 24 16 Panelboards 01-18 26 27 26 Wiring Devices 01-18 26 29 11 Motor Controllers 01-18 26 29 21 Enclosed Switches and Circuit Breakers 01-17 26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 09-19 27 05 26 Grounding and Bonding for Communications Systems 06-15 27 05 33 Raceways and Boxes for Communications Systems 10-18 27 10 00 Control, Communication and Signal Wiring 06-15

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety 04-18 28 05 13 Conductors and Cables for Electronic Safety 10-18 28 05 28.33 Conduits and Backboxes for Electronic Safety 09-11 28 31 00 Fire Detection and Alarm 10-11

07-01-15

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title General

G001 Title Sheet

G002 General, Infection Control Notes and Symbols and Abbreviations

Environmental HA100 A Wing and D Wing Fume Chase – Abatement

Demolition Plans

HA101 D Wing 8th and 9th Floor – Abatement Demolition Plans

ARCHITECTURAL

AD100 Demolition Floor Plans

A100 Construction A Wing Ground and D Wing Basement Floor and Ceiling Plans

A10G Construction D Wing Ground and A Wing 1st Floor Plan

A200 Interior Elevations

AQ100 Equipment Plan and Schedules

AQ101 Life Safety Plans

A500 Door Schedule, Frame and Partition Types Details

MECHANICAL

M001 Mechanical Notes, Symbols and Abbreviations

MD100 A Wing Ground Floor - Mechanical Demolition

MD101 D Wing Basement Floor - Mechanical Demolition

MH100 A Wing Ground Floor – Mechanical New Work Plan

MH101 D Wing Basement Floor – Mechanical New Work Plan

MH102 Ground Floor, 2nd Floor Roof/ 3rd Floor Plan – Mechanical New Work

MP100 A Wing Ground Floor – Mechanical Piping New Work Plan

MP102 A Wing 1st Floor – Mechanical Piping New Work Plan

00 01 15 - 2

M500 Mechanical Details

M501 Mechanical Details

M502 Mechanical Sections

M600 Mechanical Schedules

M700 Mechanical HVAC Balancing Plans and Notes

M701 Mechanical Controls

Plumbing PD100 A Wing Ground Floor - Plumbing Demolition Plan

PD100 D Wing Basement Floor - Plumbing Demolition Plan

PL101 D Wing Basement Floor - Plumbing New Work Plan

PL500 Plumbing Details

Fire Protection FP100 A Wing Ground Floor and D Wing Level 1 Basement-

Fire Protection Plans

Electrical E001 Electrical and Communications Symbols and

Abbreviations

E002 Electrical Lighting Schedules and Equipment Coordination

ED100 A Wing Ground – Electrical Power Demolition Plan

ED101 D Wing Basement– Electrical Power Demolition Plan

ED102 8 TH AND 9TH floor- Electrical Demolition Work

EP100 A Wing Ground – Electrical Power/Data New Work Plan

EP101 D Wing Basement– Electrical Power/Data New Work Plan

EP102 2nd Floor Roof/ 3rd Floor Plan – Electrical New Work

EP500 Electrical Power and Lighting Details

ET500 Electrical Communications Details

EP600 Electrical Power Distribution Riser Diagrams- A Wing

EP601 Electrical Power Distribution Riser Diagrams – D Wing

EL100 A Wing Ground and D Wing Basement Level 1 Floor Plans – Electrical Lighting New Work

Fire Alarm

00 01 15 - 3

FA100 A Wing Ground and D Wing Basement Level 1 Floor Plans – Fire Alarm New Work

- - - E N D - - -

03-01-20 i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 RESTORATION

1.10 PHYSICAL DATA

1.11 LAYOUT OF WORK

1.12 AS-BUILT DRAWINGS

1.13 USE OF ROADWAYS

1.14 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.15 TEMPORARY USE OF EXISTING ELEVATORS

1.16 TEMPORARY TOILETS

1.17 AVAILABILITY AND USE OF UTILITY SERVICES

1.18 TESTS

1.19 INSTRUCTIONS

1.20 GOVERNMENT-FURNISHED PROPERTY

1.21 RELOCATED EQUIPMENT ITEMS

1.22 PHOTOGRAPHIC DOCUMENTATION

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work as required by drawings and specifications. B. Visits to the site by Bidders may be made only by appointment with the Medical Center Engineering Officer.

C. Offices of USFin Development LLC, as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

D. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

See Bid Schedule

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense,.

01 00 00 -2

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

C. Document Control:

1. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

D. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

01 00 00 -3

2. A limited number of (2) permits shall be issued for General

Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The

Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

C. Working space and space available for storing materials shall be within the jobsite’s space being renovated..

D. Workers are subject to rules of Medical Center applicable to their conduct.

E. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

01 00 00 -4

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of

Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

F. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; . All such actions shall be coordinated with the COR or Utility Company involved.

G. Phasing:

The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur.

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks.

To ensure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such phasing dates to ensure accomplishment of this work in successive phases mutually agreeable to COR and Contractor, as follows:

Construction Sequence

This project shall require that the Contractor maintain continuous operation of the VA Hospital facility during Phase 1

01 00 00 -5 and Phase 2 construction. The contract drawings and specifications will require following the phasing provisions:

Phase 1 – Renovation of the DB1 Level – Rooms DB1-229 through

DB1-232.

Construct construction barriers as required.

Perform all work on DB1 Level – Rooms DB1-229 through DB1-

232 per contract documents.

Perform exterior exhaust duct work from 1st to 3rd Floors D-

Wing per contract documents.

Perform interior work on the 3rd Floor D-Wing, Drawing

EP102 and Ground Floor, D-Wing Room DG249, Drawing A10G.

This shall be performed and competed during afterhours.

Upon completion of Phase 1. Contractor to allow 5 days for the VA coordinate and relocate the A-Wing Electron

Microscope function to the new rooms on DB1 Level.

Phase 2 – Renovation of Ground Floor A-Wing, Rooms A23, A24, A25

& A26B. Including surrounding A-Wing rooms and work on 1st Floor

A-Wing as required.

Construct construction barrier.

Perform all interior work on the 1st Floor A/D-wing, Drawing MP101, Ground Floor Corridor, Drawing MH100, Room

A1035, Drawing A10G. This work shall be performed and competed during afterhours.

Upon completion of Phase 2. Contractor to allow 5 days for the VA coordinate and install furniture in new training room and new offices. After installation of new furniture, Contractor to make final electrical/data connections to the new furniture as required.

Contractor shall make the new branch conductor connections below slab and or in the conduit access pits. Contractor if necessary is required to saw cut floor and trench the concrete slab to install new conductors below the slab and/or in the access pit to

01 00 00 -6 make the new connections. Contractor to infill floor slab as necessary and/or modify the existing access pit metal panel covers.

H. Building (s) No. (s) 1 Part of Bldg. 1_A- Wing Ground and D-Wing

Basement Level 1 will be vacated by Government in accordance with above phasing beginning immediately after date of receipt of Notice to

Proceed and turned over to Contractor.

I. Building(s) No.(s) 1, All other areas will be occupied during performance of work.; but immediate areas of alterations will be vacated.

J. Utilities Services: Maintain existing utility services for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR . Electrical work shall be accomplished with all affected circuits or equipment de-energized.

When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, for additional requirements.

2. Contractor shall submit a request to interrupt any such services to

COR, in writing, 21 days in advance of proposed interruption.

Request shall state reason, date, exact time of, and approximate duration of such interruption.

01 00 00 -7

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 21 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

K. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

L. To minimize interference of construction activities with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the COR.

M. Coordinate the work for this contract with other construction operations as directed by COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF ROADWAYS.

01 00 00 -8

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR areas of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by the Contracting Officer. This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage and routes of access to areas within buildings where alterations occur and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR

, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by Contractor with new items in accordance with specifications which will be furnished by Government.

Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR

52.243-4).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls and other surfaces as compared with conditions of same as noted in first condition survey report:

01 00 00 -9

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and, will form basis for determining extent of repair work required of

Contractor to restore damage caused by Contractor's workers in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the Department of Veterans Affairs during the alteration period, 01 00 00 -10 such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

1.9 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the

COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4) and "DIFFERING SITE CONDITIONS" (FAR 52.236-2).

1.10 PHYSICAL DATA

A. Data and information furnished or referred to below is for the

Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

01 00 00 -11

B. Government does not guarantee that other materials will not be encountered nor that proportions, conditions or character of several materials will not vary from those indicated by explorations. Bidders are expected to examine site of work and logs of borings; and, after investigation, decide for themselves character of materials and make their bids accordingly. Upon proper application to Department of

Veterans Affairs, bidders will be permitted to make subsurface explorations of their own at site.

1.11 LAYOUT OF WORK

A. The Contractor shall lay out the work from Government established base lines and bench marks, indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The

Contractor shall furnish, at Contractor's own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them.

If such marks are destroyed by the Contractor or through Contractor's negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

B. Whenever changes from contract drawings are made in line or grading requiring certificates, record such changes on a reproducible drawing bearing the registered land surveyor or registered civil engineer seal, and forward these drawings upon completion of work to COR

1.12 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

01 00 00 -12

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets ofas-built drawings in the electronic version (scanned PDF) to the COR [Chief

Engineer][Chief of Facilities Management] within 15 calendar days after beneficial occupancy and before the acceptance of the project by the

COR

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.13 USE OF ROADWAYS

A. For hauling, use only established public roads and roads on Medical

Center property and, when authorized by the COR such temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed and restoration performed by the Contractor at Contractor's expense. When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.14 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical equipment to provide heat, ventilation, plumbing, light and power will be permitted subject to written approval and compliance with the following provisions:

1. Permission to use each unit or system must be given by COR in writing. If the equipment is not installed and maintained in accordance with the written agreement and following provisions, the

COR will withdraw permission for use of the equipment.

2. Electrical installations used by the equipment shall be completed in accordance with the drawings and specifications to prevent damage to the equipment and the electrical systems, i.e. transformers, relays, circuit breakers, fuses, conductors, motor controllers and their overload elements shall be properly sized, coordinated and adjusted.

Installation of temporary electrical equipment or devices shall be in accordance with NFPA 70, National Electrical Code, (2014

Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be correct and it shall be determined that motors are not overloaded. The electrical

01 00 00 -13 equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuum cleaning and wiping clean interior and exterior surfaces.

3. Units shall be properly lubricated, balanced, and aligned.

Vibrations must be eliminated.

4. Automatic temperature control systems for preheat coils shall function properly and all safety controls shall function to prevent coil freeze-up damage.

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elements shall be replaced at completion of construction and prior to testing and balancing of system.

6. All components of heat production and distribution system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the GovernmentB.

Prior to final inspection, the equipment or parts used which show wear and tear beyond normal, shall be replaced with identical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the mechanical and electrical specifications sections.

D. Any damage to the equipment or excessive wear due to prolonged use will be repaired replaced by the contractor at the contractor’s expense.

1.15 TEMPORARY USE OF EXISTING ELEVATORS

A. Use of existing freight and patient elevators for handling building materials and Contractor's personnel will be permitted subject to following provisions:

1. Contractor makes all arrangements with the COR for use of elevators.

The COR will ascertain that elevators are in proper condition.

Contractor may use elevators Nos. 5,8,9,10 in Building Nos. 1 for use for daily use between the hours of 8am-5 pm. and for special nonrecurring time intervals when permission is granted. Personnel

01 00 00 -14 for operating elevators will not be provided by the Department of

Veterans Affairs.

2. Contractor covers and provides maximum protection of following elevator components:

a. Entrance jambs, heads soffits and threshold plates.

b. Entrance columns, canopy, return panels and inside surfaces of car enclosure walls.

c. Finish flooring.

3. Place elevator in condition equal, less normal wear, to that existing at time it was placed in service of Contractor as approved by

Contracting Officer.

1.16 TEMPORARY TOILETS

A. Contractor may have for use of Contractor's workers, such toilet accommodations as may be assigned to Contractor by Medical Center.

Contractor shall keep such places clean and be responsible for any damage done thereto by Contractor's workers. Failure to maintain satisfactory condition in toilets will deprive Contractor of the privilege to use such toilets.

1.17 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the Government. The Contractor shall carefully conserve any utilities furnished without charge.

B. The Contractor, at Contractor's expense and in a workmanlike manner, in compliance with code and as satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of electricity used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and

01 00 00 -15 associated paraphernalia and repair restore the infrastructure as required.

C. Contractor shall install meters at Contractor's expense and furnish the

Medical Center a monthly record of the Contractor's usage of electricity as hereinafter specified.

D. Heat: Furnish temporary heat necessary to prevent injury to work and materials through dampness and cold. Use of open salamanders or any temporary heating devices which may be fire hazards or may smoke and damage finished work, will not be permitted. Maintain minimum temperatures as specified for various materials:

1. Obtain heat by connecting to Medical Center heating distribution system.

E. Electricity (for Construction and Testing): Furnish all temporary electric services.

1. Obtain electricity by connecting to the Medical Center electrical distribution system. The Contractor shall meter and pay for electricity required for electric cranes and hoisting devices, electrical welding devices and any electrical heating devices providing temporary heat. Electricity for all other uses is available at no cost to the Contractor.

F. Water (for Construction and Testing): Furnish temporary water service.

1. Obtain water by connecting to the Medical Center water distribution system. Provide reduced pressure backflow preventer at each connection as per code. Water is available at no cost to the

Contractor.

2. Maintain connections, pipe, fittings and fixtures and conserve water-use so none is wasted. Failure to stop leakage or other wastes will be cause for revocation (at COR discretion) of use of water from Medical Center's system.

01 00 00 -16

1.18 TESTS

A. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such systems before requesting final tests. Final test will not be conducted unless pre-tested.

B. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Contracting Officer.

Contractor shall furnish all labor, materials, equipment, instruments, and forms, to conduct and record such tests.

C. Mechanical and electrical systems shall be balanced, controlled and coordinated. A system is defined as the entire system which must be coordinated to work together during normal operation to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provides comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, controls and electricity, etc. Another example of a system which involves several components of different disciplines is a boiler installation. Efficient and acceptable boiler operation depends upon the coordination and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

D. All related components as defined above shall be functioning when any system component is tested. Tests shall be completed within a reasonably period of time during which operating and environmental conditions remain reasonably constant and are typical of the design conditions.

E. Individual test result of any component, where required, will only be accepted when submitted with the test results of related components and of the entire system.

1.19 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals (hard copies and electronic) and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

B. Manuals: Maintenance and operating manuals and one compact disc (four hard copies and one electronic copy each) for each separate piece of

01 00 00 -17 equipment shall be delivered to the COR coincidental with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include "exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed training to assigned

Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment. All such training will be at the job site. These requirements are more specifically detailed in the various technical sections. Instructions for different items of equipment that are component parts of a complete system, shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed.

This is to assure proper instruction in the operation of inter-related systems. All instruction periods shall be at such times as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough coverage. The contractor shall submit a course outline with associated material to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the contractual requirements. The Department of Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in

01 00 00 -18 the opinion of the COR , does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.20 GOVERNMENT-FURNISHED PROPERTY

A. The Government shall deliver to the Contractor, the

Government-furnished property shown on the drawings .

B. Equipment furnished by Government to be installed by Contractor will be furnished to Contractor at the Medical Center .

C. Notify Contracting Officer in writing, 60 days in advance, of date on which Contractor will be prepared to receive equipment furnished by

Government. Arrangements will then be made by the Government for delivery of equipment.

1. Immediately upon delivery of equipment, Contractor shall arrange for a joint inspection thereof with a representative of the Government.

At such time the Contractor shall acknowledge receipt of equipment described, make notations, and immediately furnish the Government representative with a written statement as to its condition or shortages.

2. Contractor thereafter is responsible for such equipment until such time as acceptance of contract work is made by the Government.

D. Equipment furnished by the Government will be delivered in a partially assembled (knock down) condition in accordance with existing standard commercial practices, complete with all fittings, fastenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the like) necessary to make the connection between the Government furnished equipment item and the utility stub-up shall be furnished and installed by the contractor at no additional cost to the Government.

E. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

01 00 00 -19

1.21 RELOCATED EQUIPMENT ITEMS

A. Contractor shall disconnect, dismantle as necessary, remove and reinstall in new location, all existing equipment and items indicated by symbol "R" or otherwise shown to be relocated by the Contractor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR .

C. Suitably cap existing service lines, such as steam, condensate return, water, drain, gas, air, vacuum and/or electrical, at the main whenever such lines are disconnected from equipment to be relocated. Remove abandoned lines in finished areas and cap as specified herein before under paragraph "Abandoned Lines".

D. Provide all mechanical and electrical service connections, fittings, fastenings and any other materials necessary for assembly and installation of relocated equipment; and leave such equipment in proper operating condition.

E. Contractor shall employ services of an installation engineer, who is an authorized representative of the manufacturer of this equipment to supervise assembly and installation of existing, lAB HOOD, AND

CASEWORK. equipment, required to be relocated.

F. All service lines such as noted above for relocated equipment shall be in place at point of relocation ready for use before any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

1.22 PHOTOGRAPHIC DOCUMENTATION

A. During the construction period through completion, furnish the VA's COR an average of 25 views of digital color images per month. These digital views shall be taken of the exterior and/or interior depending on the location of the progress made during the construction. The subject matter of these pictures shall be representative of the work being done during the construction period through to the end of the construction. Provide the photos taken for the month to the COR electronically, or on a CD. A CD that contains all of the photos taken for the project is also required at

01 00 00 -20 the end of the project. Note: Ensure that no patients, license plates, VA employees or personal identifiable information are in the pictures.

B. Upon completion of the project, final copies of the documentation (the

“Permanent Record”) with the indexing and navigation system embedded

(and active) shall be provided in an electronic media format, typically a DVD or external hard-drive. Permanent Record shall have Building

Information Modeling (BIM) interface capabilities. On-line access terminates upon delivery of the Permanent Record.

01 32 16.15 - 1

SECTION 01 32 16.15

PROJECT SCHEDULES

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officer's Representative (COTR).

B. The Contractor's representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements of this specification section.

1.3 COMPUTER PRODUCED SCHEDULES

A. The contractor shall provide monthly, to the Department of Veterans

Affairs (VA), all computer-produced time/cost schedules and reports generated from monthly project updates. The schedules must be submitted with and substantively support the contractor’s monthly payment request and the signed look ahead report.

B. The contractor shall be responsible for the correctness and timeliness of the computer-produced reports. The Contractor shall also responsible for the accurate and timely submittal of the updated project schedule and all CPM data necessary to produce the computer reports and payment request that is specified.

C. The VA will report errors in computer-produced reports to the

Contractor’s representative within ten calendar days from receipt of reports. The Contractor shall reprocess the computer-produced reports and associated diskette(s), when requested by the Contracting Officer’s representative, to correct errors which affect the payment and schedule for the project.

01 32 16.15 - 2

1.4 THE COMPLETE PROJECT SCHEDULE SUBMITTAL

A. Within 30 calendar days after receipt of Notice to Proceed, the

Contractor shall submit for the Contracting Officer's review; schedule on sheets of paper 11 x 17 inches and an electronic file in the previously approved CPM schedule program. The submittal shall also a computer-produced activity/event ID schedule showing project durations;

phase completion dates; and other data, including event cost. Each activity/event on the computer-produced schedule shall contain as a minimum, but not limited to, activity/event ID, activity/event description, duration, budget amount, early start date, early finish date, late start date, late finish date and total float. Work activity/event relationships shall be restricted to finish-to-start or start-to-start without lead or lag constraints. Activity/event date constraints, not required by the contract, will not be accepted unless submitted to and approved by the Contracting Officer. The contractor shall make a separate written detailed request to the Contracting

Officer identifying these date constraints and secure the Contracting

Officer’s written approval before incorporating them into the network diagram. The Contracting Officer’s separate approval of the Project

Schedule shall not excuse the contractor of this requirement. Logic events (non-work) will be permitted where necessary to reflect proper logic among work events, but must have zero duration. The complete working schedule shall reflect the Contractor's approach to scheduling the complete project. The final Project Schedule in its original form shall contain no contract changes or delays which may have been incurred during the final network diagram development period and shall reflect the entire contract duration as defined in the bid documents.

These changes/delays shall be entered at the first update after the final Project Schedule has been approved. The Contractor should provide their requests for time and supporting time extension analysis for contract time as a result of contract changes/delays, after this update, and in accordance with Article, ADJUSTMENT OF CONTRACT

COMPLETION.

B. Within 30 calendar days after receipt of the complete project interim

Project Schedule and the complete final Project Schedule, the

Contracting Officer or his representative, will do one or both of the following:

01 32 16.15 - 3

1. Notify the Contractor concerning his actions, opinions, and objections.

2. A meeting with the Contractor at or near the job site for joint review, correction or adjustment of the proposed plan will be scheduled if required. Within 14 calendar days after the joint review, the Contractor shall revise and shall submit copies of the revised Project Schedule, copies of the revised computer-produced activity/event ID schedule and a revised electronic file as specified by the Contracting Officer. The revised submission will be reviewed by the Contracting Officer and, if found to be as previously agreed upon, will be approved.

C. The approved baseline schedule and the computer-produced schedule(s) generated there from shall constitute the approved baseline schedule until subsequently revised in accordance with the requirements of this section.

1.5 WORK ACTIVITY/EVENT COST DATA

A. The Contractor shall cost load all work activities/events except procurement activities. The cumulative amount of all cost loaded work activities/events (including alternates) shall equal the total contract price.