S02_36C78622B0023 IFB.pdf

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION 3. DATE ISSUED PAGE OF PAGES

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014) STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within ____________ calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES NO

a. Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________

(hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C78622B0023 X

8/28/2022

806CM3028

36C786

Department of Veterans Affairs National Cemetery Administration Contracting Services 18434 Joplin Road Triangle VA 22172

Department of Veterans Affairs National Cemetery Administration Contracting Services 18434 Joplin Road Triangle VA 22172

Shane Hilts N/A

Project Title: Gravesite Expansion (Camp Butler) Project Location: Camp Butler National Cemetery

The contractor shall provide all transportation, tools, materials, components, permits, license, labor, and supervision To construct the gravesite expansion The gravesite expansion will provide for the creation of 1,000 inground cremains burial section, 1,500 niche columbarium plaza, and 150 marker memorial wall.

NAICS code 237990 is applicable for this procurement with the small business size standard of $39.5 million.

The magnitude of construction for this project is estimated to be between $1,000,000 and $5,000,000.

Please submit all RFI's/questions via e-mail to shane.hilts@va.gov prior to 10:00AM (CST) on Friday, September 9, 2022.

Answers will be provided via a solicitation amendment posted to www.sam.gov. The Government reserves the right not to answer any RFIs/questions submitted after the due date/time.

NOTICE OF SERVICE-DISABLED VETERAN-OWNED SMALL BUSINESS (SDVOSB) SET ASIDE:

This solicitation is issued in accordance with Public Law 109-461, the Veterans Benefits, Healthcare Information and Technology Act of 2006, Sections 502 and 503, as a set-aside for Service-Disabled Veteran-Owned Small Business (SDVOSB) contractors. Pursuant to 38 USC 8127(d), competition is restricted to SDVOSB construction firms, as there is a reasonable expectation that two or more offers from SDVOSB contractors will be received under this solicitation. All prospective offerors must be verified in the VetBiz.gov database as an SDVOSB to be considered for award. The offeror MUST be registered in the System for Award Management (SAM)www.sam.gov at time of proposal submission and maintain that registration to be eligible for award.

10 480

X X 52.211-10

X 10

1 10:00 AM (CT)

09-26-2022

X

14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

PHONE: FAX:

28. NEGOTIATED AGREEMENT 29. AWARD Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code)

(Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

(Type or print)

(4 copies unless otherwise specified)

(Type or print) (Type or print)

(Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror)

(To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

Lump Sum $________________________________

36C786

Department of Veterans Affairs National Cemetery Administration Contracting Services 18434 Joplin Road Triangle VA 22172 http://www.tungsten-network.com/customer -campaigns/veterans-affairs/

1-877-752-0900

ALL

Table of Contents

PART I - THE SCHEDULE

SECTION A - SOLICITATION/CONTRACT FORM

SF 1442 SOLICITATION, OFFER, AND AWARD (Construction, Alteration, or Repair) .. 1

SF 1442 SOLICITATION, OFFER, AND AWARD (CONSTRUCTION, ALTERATION,

OR REPAIR)– BACK

BID SCHEDULE

CONTRACT ADMINISTRATION DATA

FAR 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO

ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

FAR 52.228-1 BID GUARANTEE (SEP 1996)

FAR 52.228-17 INDIVIDUAL SURETY—PLEDGE OF ASSETS (BID GUARANTEE)

(FEB 2021)

FAR 52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS—NOTICE AND

REPRESENTATION (JUN 2020)

FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

FAR 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2022)

(JUL 2020) (DEVIATION)

FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

FAR 52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS—

CERTIFICATION (NOV 2021)

FAR 52.216-1 TYPE OF CONTRACT (APR 1984)

FAR 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE

OF THE WORK (MAY 2014)

FAR 52.233-2 SERVICE OF PROTEST (SEP 2006)

FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB

1998)

VAAR 852.209-70 ORGANIZATIONAL CONFLICTS OF INTEREST (OCT 2020)

VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE RESOLUTION

(OCT 2018)

VAAR 852.233-71 ALTERNATE PROTEST PROCEDURE (OCT 2018)

FAR 52.211-12 Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,178.35

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause (End of clause)

FAR 52.219-14 LIMITATIONS ON SUBCONTRACTING (SEP 2021)

FAR 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION

(SEP 2021)

FAR 52.223-21 FOAMS (JUN 2016)

SUPPLEMENTAL INSURANCE REQUIREMENTS

FAR 52.228-5 INSURANCE—WORK ON A GOVERNMENT INSTALLATION (JAN

1997)

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

FAR 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

VAAR 852.204-70 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR

PERSONNEL (MAY 2020)

VAAR 852.219-10DEV VA NOTICE OF TOTAL SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS SET-ASIDE (JUL 2019) (NOV 2020) (DEVIATION)

VAAR 852.219-11DEV VA NOTICE OF TOTAL VETERAN-OWNED SMALL BUSINESS

SET-ASIDE (JUL 2019) (NOV 2020) (DEVIATION)

VAAR 852.219-74 LIMITATIONS ON SUBCONTRACTING—MONITORING AND

COMPLIANCE (JUL 2018)

VAAR 852.219-77 VA NOTICE OF LIMITATIONS ON SUBCONTRACTING—

CERTIFICATE OF COMPLIANCE FOR SERVICES AND CONSTRUCTION (SEP 2021)

(DEVIATION)

VAAR 852.228-70 BOND PREMIUM ADJUSTMENT (JAN 2008)

VAAR 852.228-72 ASSISTING SERVICE-DISABLED VETERAN-OWNED AND

VETERAN-OWNED SMALL BUSINESSES IN OBTAINING BONDS (DEC 2009)

VAAR 852.232-72 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (NOV

2018)

VAAR 852.236-71 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (APR

2019)

VAAR 852.236-72 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 2019) 45

VAAR 852.236-79 CONTRACTOR PRODUCTION REPORT (APR 2019)

VAAR 852.236-80 SUBCONTRACTS AND WORK COORDINATION (APR 2019)

VAAR 852.242-70 GOVERNMENT CONSTRUCTION CONTRACT ADMINISTRATION

(OCT 2020)

VAAR 852.242-71 ADMINISTRATIVE CONTRACTING OFFICER (OCT 2020)

VAAR 852.243-70 CONSTRUCTION CONTRACT CHANGES—SUPPLEMENT (SEP

2019)

VAAR 852.270-1 REPRESENTATIVES OF CONTRACTING OFFICERS (JAN 2008) .. 48

H.1 DIGNITY STANDARDS

LIST OF ATTACHMENTS

BID SCHEDULE

Item No Description Quantity Unit of

Measure Unit Price

The contractor shall provide all labor, material, and equipment necessary to construct the gravesite expansion. The gravesite expansion will provide for the creation of 1,000 inground cremains burial section, 1,500 niche columbarium plaza, and 150 marker memorial wall.

1 JB $

Total $

CONTRACT ADMINISTRATION DATA

1. CONTRACT ADMINISTRATION: All contract administration matters will be handled by the following individual(s):

a. CONTRACTOR: ____________________________________

Unique Entity ID: _______________________________ DUNS Number: __________________________________ Tax Identification Number: _________________________

Contact Person: __________________ Telephone #: __________________ e-Mail Address: __________________

NOTE: Starting Monday, April 4, 2022, the new Unique Entity ID from SAM.gov will be the official, Federal Government-wide identifier used for Federal contract awards.

b. GOVERNMENT: Contracting Officer (36C786)

Department of Veterans Affairs, National Cemetery Administration Contracting Service 18434 Joplin Road Triangle, VA 22172

2. CONTRACTOR REMITTANCE ADDRESS: Effective January 1, 1999, all payments by the Government to the Contractor will be made in accordance with Federal Acquisition Regulation (FAR) Clause 52.232-34, Payment by Electronic Funds Transfer. Contractor must be registered in the System for Award Management (SAM) database in accordance with FAR Clause 52.212-1(k).

3. INVOICES: Invoices shall be submitted within ten (10) business days after performance and acceptance of services and must include the VA Project Number, Contract Number, Purchase Obligation Number, Dates of Service, Detailed description of the services provided and Total Amount Due. Payment for services provided under the terms of this contract will be made in arrears, within thirty (30) calendar days, upon receipt of properly executed invoice(s) in accordance with:

852.232-72 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (NOV 2012)

UPON ACCEPTANCE OF SERVICES

In order to comply with the Improper Payment Elimination and Recovery Act of 2010 (IPERA), the VA has mandated electronic invoice submission to the Veterans Affairs Financial Services Center (VAFSC). VAFSC has partnered with OB10 e-Invoicing network, for submissions of all electronic invoices to VA. OB10 electronic invoicing is free to all VA vendors. In order to submit electronic invoices, all VA vendors must register with OB10 by submitting an email to VA.Registration@ob10.com or calling 1- 877-752-0900 option 2 for Enrollment.

Contractor shall submit an electronic invoice within ten (10) business days after performance and acceptance of services to the Veterans Affairs Financial Services Center (VAFSC) e-Invoice through the website at https://portal.tungsten-network.com/Login.aspx . For questions regarding the submission of VA electronic invoices, OB10 customer service may be contacted at 1-877-489-6135.

All invoices shall reference the vendor name and address, customer name, contract number, appropriate obligation/funding order number, description of services provided, quantity provided, unit price, and total invoice amount (any additional info). Invoices shall also include any payment discount terms.

For questions regarding invoice receipt or payment, please call VAFSC directly at 1-877- 353-9791 or email vafsccshd@va.gov

4. GOVERNMENT INVOICE ADDRESS: All invoices from the Contractor shall be submitted electronically in accordance with VAAR Clause 852.232-72 “Electronic Submission of Payment Requests.” to the following web address: http://www.fsc.va.gov/einvoice.asp.

FACSIMILE, E-MAIL, AND SCANNED DOCUMENTS ARE NOT ACCEPTABLE

FORMS OF SUBMISSION FOR PAYMENT REQUESTS.

For assistance setting up e-Invoice, the below information is provided:

* Tungsten Network e-Invoice Setup Information: 1-877-489-6135

* Tungsten Network e-Invoice email: VA.Registration@ob10.com <http://VA.Registration@ob10.com/>

* FSC e-Invoice Contact Information: 1-877-353-9791

* FSC e-invoice email: vafsccshd@va.gov <http://va.gov/>

5. CONTRACT AUTHORITY: The Contracting Officer acting within the scope of the contract and his/her duties and responsibilities is the only person authorized to approve changes or modify any of the requirements of this request. The Contractor shall communicate with the Contracting Officer on all matters pertaining to Contract Administration. Only the Contracting Officer is authorized to make commitments or issue changes that affect pricing, quantities or quality of performance, delivery terms and conditions, or the term of the contract.

6. CONTRACTING OFFICER’S REPRESENTATIVE: Notwithstanding the

Contractor’s responsibility for total management during the performance of the contract, the administration of the contract will require maximum coordination between the Government and the Contractor. The Contracting Officer will designate a Contracting Officer’s Representative (COR) for the project, of which all work coordination shall be made through the COR. The Contractor shall be provided a copy of the COR’s Delegation of Authority letter outlining the scope of the COR’s duties and responsibilities. No other person shall be authorized to act in such capacity unless appointed in writing by the Contracting Officer.

7. SUBMITTAL OF BIDS: All bids must be submitted to the attention of the Contracting Officer identified No Later Than the date/time specified. E-mail bids will be acceptable at shane.hilts@va.gov.

A public bid opening will occur by telephone conference using the following:

Call Line: tel:+18727010185 Conference ID: 211 050 83#

a. All bids shall be submitted electronically via the Department of Veterans Affairs eCMS Vendor Portal by the due date and time outlined in the solicitation. All Interested Bidders must be registered with the Department of Veterans Affairs eCMS Vendor Portal at https://www.vendorportal.ecms.va.gov.

b. Bidders who require registration shall proceed to the Vendor Portal’s Login section and shall click on Request a user account to register. In the event an Offeror is unable to submit a proposal through the vendor portal domain, prior to the proposal closing date, contact the VAAS helpdesk at 1-877-634-3739, or via email at VA.Acquisition.Systems@va.gov.

c. DO NOT wait until the last day to upload bid documents. Bidders are highly encouraged to submit bid packages 2-3 days in advance to avoid system lock outs:

If an Offeror experience difficulty in submitting its bid via the Vendor Portal the Contracting Officer may accept an Offeror’s quote via email under the following circumstances:

1. Bidder must provide evidence that an email discussions or verbal discussion with the

VAAS helpdesk could not resolve registration issues.

2. Bid submitted must meet the time constraints as set forth in the solicitation.

3. Bids submitted via email without set requirements will not be accepted and will be considered to be NONRESPONSIVE.

4. Late or incomplete Bids will NOT be considered and deemed to be nonresponsive.

d. Document /transmittal naming convention. Solicitation number, Project Description, and Company name

EXAMPLE: 36C78622B0013_Construction Services _ ABC 123 Corp.

e. Bid package shall consist of the following minimum required documents:

Company cover letter identifying the Solicitation number, Project Description, Company name and address, POC name, Phone number, eMail address, and Company’s Unique Entity ID number;

Completed blocks 14-20c of the back of the SF 1442, ensuring full completion of all blocks;

Completed Price/Cost Schedule;

Completed, signed and attached SF30 Amendments (if applicable);

Attached scanned digital copy of the Bid Bond (if applicable); (ensure to lightly darken raised seals)

NO FAX/ FACSIMILE SUBMITTED BIDS WILL BE ACCEPTED.

Bids shall be subject to the terms and conditions of this solicitation.

8. QUESTIONS: All questions regarding this solicitation must be submitted in writing (email is acceptable) to: Shane Hilts (shane.hilts@va.gov). Any prospective bidder desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing. No phone responses will be accepted. NOTE: All questions must reference the Solicitation number, Project number (if applicable) and the Description of the project in the Header or Opening Statement.

9. CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM:

a. FAR 42.1502 directs all Federal agencies to collect Past Performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation.

One (1) or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

b. The Past Performance evaluation process is a totally paperless process using CPARS.

CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

c. It is requested that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than thirty (30) days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

d. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

e. Within sixty (60) days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

1. Contractor Representatives may then provide comments in response to the evaluation or return the evaluation without comment.

2. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

3. All information provided should be reviewed for accuracy prior to submission.

4. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

5. Your response is due within sixty (60) calendar days after receipt of the CPAR.

On day fifteen (15), the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

6. If you do not sign and submit the CPAR within sixty (60) days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

f. The following guidelines apply concerning your use of the past performance evaluation:

1. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

2. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

g. If you wish to discuss a Past Performance evaluation, you should request a meeting in writing to the CO no later than seven (7) days following your receipt of the evaluation. The meeting will be held via telephone or other means during your sixty (60)-day review period.

h. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of Administration Data)

FAR

Number

Title Date

52.204-7 SYSTEM FOR AWARD MANAGEMENT OCT 2018

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE

REPORTING

AUG 2020

52.211-6 BRAND NAME OR EQUAL AUG 1999

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS DEC 2016

52.214-4 FALSE STATEMENTS IN BIDS APR 1984

52.214-5 SUBMISSION OF BIDS DEC 2016

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS APR 1984

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND

WITHDRAWALS OF BIDS

NOV 1999

52.214-18 PREPARATION OF BIDS—CONSTRUCTION APR 1984

52.214-19 CONTRACT AWARD—SEALED BIDDING—

CONSTRUCTION

AUG 1996

52.215-5 FACSIMILE PROPOSALS OCT 1997

52.215-16 FACILITIES CAPITAL COST OF MONEY JUN 2003

FAR 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO

ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION

(FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

2.4 % 6.9 % These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

(End of Provision)

FAR 52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3 million, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of Provision)

FAR 52.228-17 INDIVIDUAL SURETY—PLEDGE OF ASSETS (BID

GUARANTEE) (FEB 2021)

(a) Offerors shall obtain from each person acting as an individual surety on a bid guarantee—

(1) A pledge of assets that meets the eligibility, valuation, and security requirements described in the Federal Acquisition Regulation (FAR) 28.203–1; and

(2) Standard Form 28, Affidavit of Individual Surety.

(b) The Offeror shall include with its offer the information required at paragraph (a) of this provision within the timeframe specified in the provision at FAR 52.228–1, Bid Guarantee, or as otherwise established by the Contracting Officer.

(c) The Contracting Officer may release the security interest on the individual surety’s assets in support of a bid guarantee based upon evidence that the offer supported by the individual surety will not result in contract award.

FAR 52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS—NOTICE

AND REPRESENTATION (JUN 2020)

(a) Definitions. As used in this provision—

Foreign person means any person other than a United States person.

Specified Federal procurement payment means any payment made pursuant to a contract with a foreign contracting party that is for goods, manufactured or produced, or services provided in a foreign country that is not a party to an international procurement agreement with the United States. For purposes of the prior sentence, a foreign country does not include an outlying area.

United States person as defined in 26 U.S.C. 7701(a)(30) means—

(1) A citizen or resident of the United States;

(2) A domestic partnership;

(3) A domestic corporation;

(4) Any estate (other than a foreign estate, within the meaning of 26 U.S.C. 701(a)(31)); and

(5) Any trust if—

(i) A court within the United States is able to exercise primary supervision over the administration of the trust; and

(ii) One or more United States persons have the authority to control all substantial decisions of the trust.

(b) Unless exempted, there is a 2 percent tax of the amount of a specified Federal procurement payment on any foreign person receiving such payment. See 26 U.S.C. 5000C and its implementing regulations at 26 CFR 1.5000C-1 through 1.5000C-7.

(c) Exemptions from withholding under this provision are described at 26 CFR 1.5000C- 1(d)(5) through (7). The Offeror would claim an exemption from the withholding by using the Department of the Treasury Internal Revenue Service Form W-14, Certificate of Foreign Contracting Party Receiving Federal Procurement Payments, available via the internet at www.irs.gov/w14. Any exemption claimed and self-certified on the IRS Form W-14 is subject to audit by the IRS. Any disputes regarding the imposition and collection of the 26 U.S.C. 5000C tax are adjudicated by the IRS as the 26 U.S.C. 5000C tax is a tax matter, not a contract issue.

The IRS Form W-14 is provided to the acquiring agency rather than to the IRS.

(d) For purposes of withholding under 26 U.S.C. 5000C, the Offeror represents that—

(1) It [ ] is [ ] is not a foreign person; and

(2) If the Offeror indicates “is” in paragraph (d)(1) of this provision, then the Offeror represents that—I am claiming on the IRS Form W-14 [ ] a full exemption, or [ ] partial or no exemption [Offeror shall select one] from the excise tax.

(e) If the Offeror represents it is a foreign person in paragraph (d)(1) of this provision, then—

(1) The clause at FAR 52.229-12, Tax on Certain Foreign Procurements, will be included in any resulting contract; and

(2) The Offeror shall submit with its offer the IRS Form W-14. If the IRS Form W-14 is not submitted with the offer, exemptions will not be applied to any resulting contract and the Government will withhold a full 2 percent of each payment.

(f) If the Offeror selects “is” in paragraph (d)(1) and “partial or no exemption” in paragraph (d)(2) of this provision, the Offeror will be subject to withholding in accordance with the clause at FAR 52.229-12, Tax on Certain Foreign Procurements, in any resulting contract.

(g) A taxpayer may, for a fee, seek advice from the Internal Revenue Service (IRS) as to the proper tax treatment of a transaction. This is called a private letter ruling. Also, the IRS may publish a revenue ruling, which is an official interpretation by the IRS of the Internal Revenue Code, related statutes, tax treaties, and regulations. A revenue ruling is the conclusion of the IRS on how the law is applied to a specific set of facts. For questions relating to the interpretation of the IRS regulations go to https://www.irs.gov/help/tax-law-questions.

(End of Provision)

FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Jessie Magee

Email: Jessie.magee@va.gov

(End of Provision)

FAR 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY

2022) (JUL 2020) (DEVIATION)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $39.5 Million.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition—

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services—Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations— Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219‐2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with

19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at

52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-- Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate.

(Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $92,319, the provision with its Alternate II applies.

(C) If the acquisition value is $92,319 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan— Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[X](i) 52.204-17, Ownership or Control of Offeror.

[X](ii) 52.204-20, Predecessor of Offeror.

[](iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[](iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[](v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Certification.

[](vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

[](vii) 52.227-6, Royalty Information.

[](A) Basic.

[](B) Alternate I.

[](viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision)

FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS

(OCT 2018)

(a) Definitions. As used in this provision—

"Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

FAR 52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR

AGREEMENTS—CERTIFICATION (NOV 2021)

(a) This provision does not apply to acquisitions at or below the simplified acquisition threshold or to acquisitions of commercial products and commercial services as defined in Federal Acquisition Regulation 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

_____ (1) The Offeror certifies that—

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C.

2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available at https://www.state.gov/bureaus-offices/under-secretary-for-arms-control-and-international-security-affairs/bureau-of-arms-control-verification-and-compliance/; or

(2) The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there.

Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If there may have been such activity, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of noncompliance is equivalent to a determination of violation. However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

(3) If so, determine whether the Offeror or…