Respondent's_Reference_&_Statement_of_Experience.pdf

This is a Respondent's Reference and Statement of Experience form for the City of Hayward, California, required for participation in a bidding process for construction-related services. The form is designed to document a bidder's qualifications and past project experience relevant to the proposed contract work. Specifically, the document requires respondents to provide detailed information about four qualified commercial references, including company names, contacts, addresses, telephone numbers, brief project descriptions, project completion dates, and contract amounts. The form emphasizes that bidders must demonstrate their responsibility, experience, skill, and business standing through disclosure of similar work previously completed. This document must be completed, executed, and submitted with the formal bid form as a mandatory requirement for bid consideration.

The form itself contains no pricing information, set-asides, funding sources, or contract terms, as it serves solely as a qualification and experience documentation tool. Bidders are required to populate the template with verifiable references that demonstrate their capability to perform work of similar character to that included in the proposed contract. The form provides a standardized framework for evaluating contractor qualifications and experience relevant to construction projects, allowing the City of Hayward to assess potential vendors' track records and professional standing prior to contract award.