P530 AIMF_SPECS_DRAFT_20250728.pdf

Solicitation/Contract No. W912HV-FY-X-000X

US Army Corps of Engineers

Japan District

PN FY27 AIRCRAFT INTERMEDIATE

MAINTENANCE FACILITY

KADENA AIR BASE, OKINAWA, JAPAN

SPECIFICATIONS

INTERMEDIATE Submittal

28 JULY 2025

DRAFT

This page intentionally left blank.

P530 Aircraft Intermediate Maintenance

Kadena AB, Okinawa, Japan

PROJECT TABLE OF CONTENTS Page 1

65% Design Submittal

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00.00 10 GENERAL CONTRACT REQUIREMENTS

01 11 00.00 10-A GOVERNMENT FURNISHED PROPERTY

01 11 00.00 10-B UXO EMERGENCY MITIGATION MEMO (KADENA AB)

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 33 00-A ENG FORM 4025-R

01 33 00-B SUBMITTAL REGISTER

01 33 29 SUSTAINABILITY REPORTING

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 35 26-A USACE ACCIDENT PREVENTION PLAN CHECKLIST

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 42 15 METRIC MEASUREMENTS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 35 SPECIAL INSPECTIONS

01 45 35-A STATEMENT OF SPECIAL INSPECTIONS

01 45 35-B SCHEDULE OF SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 50 00-A PROJECT SIGNAGE

01 57 19.01 TEMPORARY ENVIRONMENTAL CONTROLS - AIR FORCE PROJECTS

01 57 19.01-A DISPOSAL AND RECYCLING DATA SHEET

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

01 78 00-A DD 1354

01 78 23 OPERATION AND MAINTENANCE DATA

01 91 00.15 10 TOTAL BUILDING COMMISSIONING

01 91 00.15 10-A CONSTRUCTION PHASE COMMISSIONING PLAN

DIVISION 02 – EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 – CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

03 42 13.00 10 PLANT-PRECAST CONCRETE PRODUCTS FOR BELOW GRADE

CONSTRUCTION

DIVISION 05 – METALS

05 05 20 POST-INSTALLED CONCRETE AND MASONRY ANCHORS

05 12 00 STRUCTURAL STEEL

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 33 METAL LADDERS

05 52 00 METAL RAILINGS

PROJECT TABLE OF CONTENTS Page 2

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 41 16.00 10 PLASTIC-LAMINATE-CLAD ARCHITECTURAL CABINETS

06 61 16 SOLID SURFACING FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 05 23 PRESSURE TESTING AN AIR BARRIER SYSTEM FOR AIR TIGHTNESS

07 05 23-A AIR LEAKAGE TEST FORM

07 05 23-B AIR LEAKAGE TEST RESULTS FORM

07 05 23-C TEST AGENCY QUALIFICATIONS SHEET

07 13 53 ELASTOMERIC SHEET WATERPROOFING

07 14 00 FLUID-APPLIED WATERPROOFING

07 21 13 BOARD AND BLOCK INSULATION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 27 10.00 10 BUILDING AIR BARRIER SYSTEM

07 27 19.01 SELF-ADHERING AIR BARRIERS

07 32 13 ROOF TILES

07 60 00 FLASHING AND SHEET METAL

07 72 33 ROOF HATCHES

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 11 16 ALUMINUM DOORS AND FRAMES

08 31 00 ACCESS DOORS AND PANELS

08 33 23 OVERHEAD COILING DOORS

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL [WALL] [AND] [DOOR] LOUVERS

DIVISION 09 - FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 30 10 CERAMIC, QUARRY, AND GLASS TILING

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 67 23.14 CHEMICAL RESISTANT RESINOUS FLOORING

09 68 00 CARPETING

09 90 00 PAINTS AND COATINGS

PROJECT TABLE OF CONTENTS Page 3

DIVISION 10 - SPECIALTIES

10 14 00.20 INTERIOR SIGNAGE

10 21 13 TOILET COMPARTMENTS

10 26 00 WALL AND DOOR PROTECTION

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

10 51 26 PLASTIC LOCKERS AND BENCHES

10 71 13 EXTERIOR SUN CONTROL DEVICES

DIVISION 11 – EQUIPMENT

11 31 13 ELECTRIC KITCHEN EQUIPMENT

DIVISION 12 – FURNISHINGS

12 21 00 WINDOW BLINDS

12 48 13 ENTRANCE FLOOR MATS AND FRAMES

DIVISION 13 – SPECIAL CONSTRUCTION

13 48 73 SEISMIC CONTROL FOR MISCELLANEOUS EQUIPMENT

DIVISION 14 - CONVEYING EQUIPMENT

14 21 23 ELECTRIC TRACTION PASSENGER ELEVATORS

DIVISION 21 - FIRE SUPPRESSION

21 13 13 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 05 48.00 20 MECHANICAL SOUND, VIBRATION, AND SEISMIC CONTROL

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING

23 05 48.19 SEISMIC BRACING FOR HVAC

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 08 00 COMMISSIONING OF MECHANICAL [ AND PLUMBING] SYSTEMS

23 09 00 INSTRUMENTATION AND CONTROL FOR HVAC

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.02 BACNET DIRECT DIGITAL CONTROL FOR HVAC AND OTHER BUILDING

CONTROL SYSTEMS

23 21 23 HYDRONIC PUMPS

23 23 00 REFRIGERANT PIPING

23 25 00 CHEMICAL TREATMENT OF WATER FOR MECHANICAL SYSTEMS

23 30 00 HVAC AIR DISTRIBUTION

23 64 10 WATER CHILLERS, VAPOR COMPRESSION TYPE

23 64 26 CHILLED, CHILLED-HOT, AND CONDENSER WATER PIPING SYSTEMS

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT

PROJECT TABLE OF CONTENTS Page 4

DIVISION 25 – INTEGRATED AUTOMATION

25 05 11.01 CYBERSECURITY OF FACILITY-RELATED CONTROL SYSTEMS – HVAC

DDC

25 05 11.01-A CYBERSECURITY INTERCONNECTION SCHEDULE TEMPLATE

25 05 11.01-B NETWORK COMMUNICATION REPORT TEMPLATE

25 05 11.01-C INVENTORY REPORT TEMPLATE

25 05 11.01-D CONTRACTOR COMPUTER CYBERSECURITY COMPLIANCE STATEMENT

25 05 11.01-E CONTRACTOR TEMPORARY NETWORK COMPLIANCE STATEMENT

25 05 11.01-F WIRELESS NETWORK REQUEST FORM TEMPLATE

25 05 11.02 CYBERSECURITY OF FACILITY-RELATED CONTROL SYSTEMS - UMCS

25 05 11.02-A CYBERSECURITY INTERCONNECTION SCHEDULE TEMPLATE

25 05 11.02-B NETWORK COMMUNICATION REPORT TEMPLATE

25 05 11.02-C INVENTORY REPORT TEMPLATE

25 05 11.02-D CONTRACTOR COMPUTER CYBERSECURITY COMPLIANCE STATEMENT

25 05 11.02-E CONTRACTOR TEMPORARY NETWORK COMPLIANCE STATEMENT

25 05 11.02-F WIRELESS NETWORK REQUEST FORM TEMPLATE

DIVISION 26 - ELECTRICAL

26 05 48.00 10 SEISMIC PROTECTION FOR ELECTRICAL EQUIPMENT

26 05 73 POWER SYSTEM STUDIES

26 08 00 APPARATUS INSPECTION AND TESTING

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 41 00 LIGHTING PROTECTION SYSTEM

26 51 00 INTERIOR LIGHTING

26 56 00 EXTERIOR LIGHTING

DIVISION 27 – COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

27 41 00 AUDIO-VISUAL SYSTEM

27 51 16 PUBLIC ADDRESS SYSTEM

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 08 10 ELECTRONIC SECURITY SYSTEM ACCEPTANCE TESTING

28 10 05 ELECRONIC SECURITY SYSTEMS (ESS)

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM,

ADDRESSABLE

DIVISION 31 – EARTHWORK

31 00 00 EARTHWORK

31 11 00 CLEARING AND GRUBBING

31 21 13 RADON MITIGATION

31 62 13.20 PRECAST/PRESTRESSED CONCRETE PILES

PROJECT TABLE OF CONTENTS Page 5

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 01 16.71 COLD MILLING ASPHALT PAVING

32 01 19.61 SEALING OF JOINTS IN RIGID PAVEMENT

32 05 33 LANDSCAPE ESTABLISHMENT

32 11 20 BASE COURSE FOR RIGID AND SUBBASES FOR FLEXIBLE PAVING

32 11 23 AGGREGATE BASE COURSE

32 12 13 BITUMINOUS TACK AND PRIME COATS

32 12 16.16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 13 13.06 PORTLAND CEMENT CONCRETE PAVEMENT FOR ROADS AND SITE

FACILITIES

32 15 00 AGGREGATE SURFACING

32 16 19 CONCRETE CURBS, GUTTERS, AND SIDEWALKS

32 17 23 PAVEMENT MARKINGS

32 31 13 CHAIN LINK FENCES AND GATES

32 92 19 SEEDING

32 92 23 SODDING

DIVISION 33 - UTILITIES

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 30 00 SANITARY SEWERS

33 31 23.00 10 SANITARY SEWER FOURCE MAIN PIPING

33 32 16 PACKAGED UTILITY WASTEWATER PUMPING STATIONS

33 40 00 STORM DRAINAGE UTILITIES

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

DIVISION 41 – MATERIAL PROCESSING AND HANDLING EQUIPMENT

41 22 13.14 BRIDGE CRANES, OVERHEAD ELECTRIC, TOP RUNNING

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 6

This Page Intentionally Left Blank

JD P530 AIMF

SECTION 01 11 00.00 10

GENERAL CONTRACT REQUIREMENTS

PART 1 GENERAL

1.1 DEFINITIONS

The term "Government" refers to "United States Government" whenever the term "Government" appears in this Contract, unless otherwise indicated within the Contract.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN SOCIETY OF HEATING, REFRIGERATING AND AIR-CONDITIONING

ENGINEERS (ASHRAE)

ASHRAE 189.1 (2017) Standard for the Design of High-Performance Green Buildings Except Low-Rise Residential Buildings

ASHRAE 52.2 (2017) Method of Testing General Ventilation Air-Cleaning Devices for Removal Efficiency by Particle Size

ASTM INTERNATIONAL (ASTM)

ASTM D6245 (2012) Using Indoor Carbon Dioxide Concentrations to Evaluate Indoor Air Quality and Ventilation

ASTM D6345 (2010) Standard Guide for Selection of Methods for Active, Integrative Sampling of Volatile Organic Compounds in Air

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 10 (2022; ERTA 1 2021) Standard for Portable Fire Extinguishers

NFPA 241 (2022) Standard for Safeguarding Construction, Alteration, and Demolition Operations

SHEET METAL AND AIR CONDITIONING CONTRACTORS' NATIONAL ASSOCIATION

(SMACNA)

ANSI/SMACNA 008 (2007) IAQ Guidelines for Occupied Buildings Under Construction, 2nd Edition

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 Safety -- Safety and Health Requirements

SECTION 01 11 00.00 10 Page 1

Manual

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only . Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Initial Site Conditions Photos

Key Personnel Qualifications ; G

INDOOR AIR QUALITY (IAQ) MANAGEMENT PLAN ; G

SD-07 Certificates

Monthly Progress Photos ;

SD-11 Closeout Submittals

Construction Completion Photos ;

1.4 ACCEPTABLE ALTERNATIVE JAPANESE STANDARDS

Where indicated in the technical specifications REFERENCES paragraphs, acceptable Japanese standards are listed which are considered acceptable alternatives to the US Standards within the Contract Specifications.

Contract specifications authorize the use of specified acceptable alternative Japanese standards. A limited set of modified UFGS incorporating previously identified and accepted Japanese standards and methods (also known as Japan Edited Specifications, or JES) can be found at https://www.poj.usace.army.mil/Business-With-Us/References/. Other portions of the specifications also authorize the use of specified acceptable alternative Japanese standards. The use of products not meeting the applicable US standards of the Contract or alternative Japanese standards specifically authorized by the Contract is prohibited unless authorized by the Contracting Officer. Japanese standards not identified in these specifications as being acceptable alternatives to US standards may be submitted to the Contracting Officer for consideration as acceptable alternatives after award using the variation request process set forth in Section 01 33 00 SUBMITTAL PROCEDURES. Prior to the use of such proposed additional alternative Japanese standards, written approval by the Contracting Officer is required. Incorporation of methods, materials, and equipment that will promote cost-effective and timely maintenance, and that are otherwise authorized by the contract, is highly encouraged.

[ 1.5 GOVERNMENT FURNISHED CONTRACTOR INSTALLED ITEMS

Attachment 01 11 00.00 10-A "Government Furnished Property" provides the items that shall be Government Furnished, Contractor Installed (GFCI).

] 1.6 MANDATORY U.S. TESTED PRODUCTS

The following items shall meet U.S. testing methods (e.g. UL listed, FM approved, ASTM, etc.) and shall be labeled as required. These items shall not be substituted with Japanese testing methods (e.g. JIS, JASS, etc.)

SECTION 01 11 00.00 10 Page 2 for certification:

a. Fire suppression systems, including valves, alarm valves, sprinklers.

Fire suppression systems includes wet chemical, dry chemical, mist, deluge, pre-action, foam, and clean agent, in addition to standard sprinkler systems.

b. Fire pumps, including motors, controllers, drives, and valves.

c. Fire alarm and mass notification systems, including panels, initiating devices, notification appliances, smoke alarms.

d. Engineering technician requirements for development of fire suppression systems and alarm system shop drawings, calculations, and material submittals.

e. Fire doors, smoke doors, and frames.

f. Fire dampers and smoke dampers.

g. Interior finishes with flame spread and smoke development ratings required for installation of rated assemblies.

h. Insulation with flame spread and smoke development ratings.

i. Fire proofing and fire stopping materials.

j. Plenum rated cables.

k. Domestic water supply piping in the building and plumbing fixtures that directly dispense potable drinking water (NSF stamped and/or labeled). Plumbing fixtures conforming to Japanese standards that do not directly dispense potable drinking water are allowed, such as urinals and water closets , bath and shower faucets, utility/janitor faucets, lavatories and sinks .

1.7 KEY PERSONNEL QUALIFICATIONS

The Contractor's Project Key personnel shall not be assigned duties to any other Contracts (excluding the project manager) without approval from the Contracting Officer. The Project Superintendent, CQC System Manager, and Site Safety Health Officer shall all be separate persons, and shall not have other duties assigned. Within five (5) working days after receipt of the Notice to Proceed, the Contractor shall submit in writing to the Contracting Officer an organizational chart, the qualifications and background history of the proposed Key Personnel for approval. The Contracting Officer shall have the explicit right to determine acceptability (or rejection) of the proposed individuals. In addition, the Contractor shall be responsible to replace said individuals upon notification by the Government should performance become inadequate during the Contract period. Key Personnel shall attend the Preconstruction conference.

1.7.1 Project Manager

The Project Manager shall have a minimum of five (5) years experience as a Project Manager on construction projects similar in size and scope to this Contract. The Project Manager shall maintain oversight of Contract proposals prepared by the Contractor staff and be authorized to negotiate

SECTION 01 11 00.00 10 Page 3

Contract terms and sign Contract documents on behalf of the Contractor.

The project manager does not need to be present on the site daily, but shall attend weekly progress meetings and be available on site within 24 hours upon request. Project Manager shall not have other duties assigned.

1.7.2 Project Superintendent (Supervisor)

The Project Superintendent shall be on the work site when on-site work is being performed and shall be available to the Contracting Officer or his representatives upon request. The Project Superintendent shall have overall responsibility for all operations at the job site and be authorized to make decisions, negotiate Contract terms and sign Contract documents on behalf of the Contractor. The Project Superintendent shall have a minimum of five (5) years experience as a superintendent on construction projects similar in size and scope to this Contract[.][, and have at least one the following qualifications:]

[ a. U.S. Registered Structural Engineer or U.S. Registered Architect or 1 Kyu Kenchikushi (1st Class Qualified Architect).

][ b. U.S. Registered Civil Engineer or 1 Kyu Doboku Sekou Kanrigishi (1st Class Civil Engineering Works Management Engineer).

][ c. U.S. Registered Mechanical or Electrical Engineer or 1 Kyu Kankouji Sekou Kanrigishi (1st Class Building Mechanical and Electrical Engineer).

][ e. U.S. Bachelors Degree in Construction Management or 1 Kyu Kenchiku Sekou Kanrigishi (1st Class Building Construction Management Engineer)

][ f. U.S. Bachelors Degree in Construction Management or AI*DD Sougoushu (AI*DD Construction Engineer).

] 1.7.3 English Speaking Representative (Interpreter)

At all times during the Contract period the Contractor shall have an employee capable of fluent bilingual speech in the Japanese and English languages at the job site. The bilingual interpreter shall have the capability to receive and issue concise and technical explanation and instructions between the Government representative(s) and Contractor supervisory personnel concerning all aspects of Contract administration and construction. Within fifteen (15) days after receipt of the Notice to Proceed, the Contractor shall submit in writing to the Contracting Officer the qualifications and background history of the proposed interpreter for approval. The Contracting Officer shall have the explicit right to determine acceptability or rejection of the proposed individual. In addition, the Contractor shall be responsible to replace said individual upon notification by the Government should performance become inadequate during the Contract period. The interpreter shall attend the preconstruction conference. Interpreter shall not have other duties assigned.

1.7.4 Contractor Quality Control

1.7.4.1 Contractor Quality Control System Manager (CQCSM)

The CQC System Manager is required to be a graduate of an accredited college with an engineering, architecture, or construction management degree, with a minimum of 5 years construction experience on construction

SECTION 01 11 00.00 10 Page 4 of similar size and scope to this Contract. Refer to Section 01 45 00.00 10 QUALITY CONTROL, Paragraph "CQC System Manager" for additional requirements.

1.7.4.2 Contractor Quality Control Personnel

The following Contractor Quality Control (CQC) Personnel are required:

Civil, Mechanical, Electrical, Structural, Architectural, Fire Protection, Communications, Submittals, Concrete, Pavements, and Soils, Testing, Adjusting, and Balancing, . All other specialties in section 01 45 00.00 10 not identified in this paragraph does not apply to this project.

See Section 01 45 00.00 10 QUALITY CONTROL for qualification requirements for CQC personnel. These individuals or specialized technical companies may be employed by the prime contractor or a subcontractor on this project.

These individuals shall have no other duties other than quality control .

A single person can cover more than one area provided that the single person is qualified to perform quality control activities in each designated and that workload allows..

1.7.5 Site Safety and Health Officer (SSHO)

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS.

1.7.6 TPC SUSTAINABILITY PROFESSIONAL

See Section 01 33 29 SUSTAINABILITY REPORTING.

1.8 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

a. This paragraph specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Contract clause entitled "DEFAULT (FIXED-PRICE CONSTRUCTION)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the Contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

b. The listing below defines the monthly anticipated adverse weather days for the Contract period and is based upon 20th Weather Squadron (MAC), U.S. Air Force; Iwakuni U.S. Marine Corps Air Station, Weather Service; Sasebo Naval Pacific Meteorology and Oceanography Detachment;

JASDF (Japan Air Self Defense Force), or similar data for the geographic location of the project. (More specific information may be obtained as specified under Special Contract Requirements Clause entitled "Physical Data.")

MONTHLY ANTICIPATED ADVERSE WEATHER DELAYS

WORK DAYS BASED ON (5) DAY WORK WEEK

SECTION 01 11 00.00 10 Page 5

The above schedule of anticipated adverse weather days shall constitute the base line for monthly (or portion thereof) weather time evaluations.

c. Upon acknowledgment of the Notice-to-Proceed (NTP) and continuing throughout the Contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b), above, the Contracting Officer shall convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the Contract clause entitled "DEFAULT

(FIXED PRICE CONSTRUCTION)".

e. For all work under this Contract, adverse weather is defined as:

(1) Rainfall - Number of occurrences of precipitation greater than or equal to 0.10 inches (2.54mm).

( 2) Wind - Number of occurrences when the wind is gusting 30 knots (56 kilometers/hour) or greater.

f. The Contractor's schedule must reflect the above anticipated adverse weather delays on all weather-dependent activities.

1.9 PERMITS AND RESPONSIBILITIES

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any laws, codes, and regulations (including the requirements of material, prefectural, and local Government of Japan, and associated military installation) applicable to the performance of work.

The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence.

These damages shall be repaired or replaced by the Contractor at no cost to the Government. The Contractor shall take proper safety and health precautions to protect all work and workers.

Submit a schedule of planned road closures to the Contracting Officer with the initial project schedule. Notification of specific road closures shall be in writing to the Contracting Officer not less than thirty (30) calendar days in advance of the intended closure. The road closure request shall include the planned traffic control measures as well as the general information about the closure. All road closures shall be coordinated with base officials and are subject to base requirements. No road closure shall be permitted until the Contractor receives written approval from the Contracting Officer. Full road closures is generally not permitted (at least one way traffic shall always be provided).

SECTION 01 11 00.00 10 Page 6

1.10 SPECIAL CONTRACT REQUIREMENTS

1.10.1 Meetings

a. Preconstruction Conference. A Preconstruction Conference per FAR

42.503 shall be held. The chairperson shall be the Contracting Officer or his/her designee. The chairperson shall be responsible for providing minutes of the meeting.

a. Post Award Orientation. A post award orientation (often referred to as a Preconstruction Conference) per FAR 42.503 shall be held. The chairperson shall be the Contracting Officer or his/her designee. The chairperson shall be responsible for providing minutes of the meeting.

b. Weekly Progress Meetings. A weekly progress meeting shall be conducted, with the day, time, and location to be determined at the Preconstruction Conference. The Contractor's Project Manager, Superintendent, Interpreter, and Quality Control Manager shall attend. Representatives from the Government may include, but are not limited to, Director of Public Works/Facilities Engineering personnel, Project's Resident Office personnel, and Project Manager. The Contractor shall be prepared to discuss work completed during the previous week, work currently in progress, and work forecasted for the following week, as well as the status of any construction issues and open action items. Provide the meeting agenda for review 24 hours prior to the meeting, take notes during the meeting, and provide electronic copies of the meeting minutes in English within 24 hours of the progress meeting for review.

c. Red Zone Meeting. A Red Zone meeting shall be conducted for Contracts with a value in excess of 55,000,000 JPY or those deemed sufficiently complex by the Contracting Officer to warrant one. The purpose of the Red Zone meeting is to discuss closeout requirements for the contract and to establish a timeline to get those items completed (see Section 01 78 00 CLOSEOUT SUBMITTALS for typical closeout requirements). The meeting is a good time for the Contractor to gain approval on format for items such as Operations and Maintenance manuals, the equipment-in-place list, the warranty plan, and any other items. The Initial Red Zone is typically scheduled when project reached 75 percent completion milestone. Provide the meeting agenda for review 24 hours prior to the meeting, take notes during the meeting, and provide electronic copies of the meeting minutes in English within 24 hours of the Red Zone meeting.

d. Safety and Quality Control Meetings. Safety and quality control meetings shall be held as needed and determined by the Contractor.

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS and Section 01 45 00.00 10 USACE QUALITY CONTROL for specific requirements.

e. Construction Waste Management Meetings. See Section 01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT for requirements.

1.10.2 CONSTRUCTION INDOOR AIR QUALITY (IAQ) MANAGEMENT PLAN

Submit an IAQ Management Plan within 15 days after Notice to Proceed and not less than 10 days before the preconstruction meeting. The Plan shall include IAQ management practices implemented during construction and preoccupancy phases and describe how each requirement in ANSI/SMACNA 008 [and TPC requirements ]will be met, addressed, and managed on the job

SECTION 01 11 00.00 10 Page 7 site. The plan shall cover the following additional items:

a. Identify the key players and person(s) responsible for implementing the plan.

b. Specify procedures for protecting stored and installed absorptive materials from moisture damage.

c. Prohibit the use of tobacco products inside the building and within

7.5 meters (50 feet) of the building entrance at all times during construction. Consider prohibiting smoking on the entire job site. If smoking will be allowed, locate on a site plan the designated locations and signage. Comply with the tobacco use policy of the local jurisdiction.

d. Indicate whether air handlers will be operated during construction, and specify compliant filtration procedures for permanent equipment that will be used.

e. Take photographs of each IAQ measure for documentation. Annotate photographs to indicate each IAQ measure depicted and its general location. Provide photographs of the methods employed to protect stored and installed absorptive materials from moisture damage during construction and preoccupancy.

Revise and resubmit the Plan as required by the Contracting Officer. Make copies of the final plan available to all workers on site. Include provisions in the Plan to meet the requirements specified below and to ensure safe, healthy air for construction workers and building occupants.

1.10.2.1 Requirements During Construction

Provide for evaluation of indoor Carbon Dioxide concentrations in accordance with ASTM D6245. Provide for evaluation of volatile organic compounds (VOCs) in indoor air in accordance with ASTM D6345. Use filters with a Minimum Efficiency Reporting Value (MERV) of 8 in permanently installed air handlers during construction.

1.10.2.1.1 Control Measures

Meet or exceed the requirements of ANSI/SMACNA 008 , Chapter 3, to help minimize contamination of the building from construction activities. The five requirements of this manual which must be adhered to are described below:

a. HVAC protection: Isolate return side of HVAC system from surrounding environment to prevent construction dust and debris from entering the duct work and spaces.

b. Source control: Use low emitting paints and other finishes, sealants, adhesives, and other materials as specified. When available, cleaning products must have a low VOC content and be non-toxic to minimize building contamination. Utilize cleaning techniques that minimize dust generation. Cycle equipment off when not needed. Prohibit idling motor vehicles where emissions could be drawn into building.

Designate receiving/storage areas for incoming material that minimize IAQ impacts.

c. Pathway interruption: When pollutants are generated use strategies

SECTION 01 11 00.00 10 Page 8 such as 100 percent outside air ventilation or erection of physical barriers between work and non-work areas to prevent contamination.

d. Housekeeping: Clean frequently to remove construction dust and debris. Promptly clean up spills. Remove accumulated water and keep work areas dry to discourage the growth of mold and bacteria. Take extra measures when hazardous materials are involved.

e. Scheduling: Control the sequence of construction to minimize the absorption of VOCs by other building materials.

1.10.2.1.2 Moisture Contamination

a. Remove accumulated water and keep work dry.

b. Use dehumidification to remove moist, humid air from a work area .

c. Do not use combustion heaters or generators inside the building.

d. Protect porous materials from exposure to moisture.

e. Remove and replace items which remain damp for more than a few hours.

1.10.2.2 Requirements after Construction

After construction ends and prior to occupancy, conduct IAQ testing in accordance with ASHRAE 189.1 Section 10.3.1.4.

In the event that IAQ testing fails, conduct a building flush-out in accordance with ASHRAE 189.1 Section 10.3.1.3[ and TPC requirements]. The space shall be ventilated at a minimum rate of 1.5 Liters per second per square meter of outdoor air while maintaining an internal temperature of at least 15 degrees C (60 degrees F) and no higher than 27 degrees C (80 degrees F) and relative humidity no higher than 60%. Total air volume of outdoor air will be determined by ASHRAE 189.1 Section 10.3.1.4 Equation 10-1. Total volume of outdoor air shall be approved by the Contracting Office prior to building flush-out

Air contamination testing must be consistent with EPA's current Compendium of Methods for the Determination of Air Pollutants in Ambient Air. After building flush-out or testing and prior to occupancy, replace filtration media. Filtration media must have a MERV of 13 as determined by ASHRAE 52.2 .

1.11 PROGRESS AND COMPLETION PHOTOGRAPHS

Photographically document site conditions prior to start of construction operations. Provide monthly, and within one month of the completion of work, digital photographs, 1600 by 1200 by 24 bit true color 300 DPI minimum resolution in JPEG file format showing the sequence and progress of work. Take a minimum of 20 digital photographs each week throughout the entire project and 20 digital photographs at completion of project.

Submit the Initial Site Conditions Photos , Monthly Progress Photos , and Construction Completion Photos . Indicate photographs demonstrating environmental procedures. Provide photographs for each month in a separate monthly directory and name each file to indicate its location on the view location sketch. Include a date designator in file names. Cross reference submittals in the appropriate daily report. Photographs provided are for unrestricted use by the Government.

SECTION 01 11 00.00 10 Page 9

1.12 BASE REGULATIONS

The Contractor and Subcontractor(s) shall become familiar with and obey all base regulations, including fire, traffic, safety, and security regulations. All Contractors shall keep within the limits of the work (and avenues of ingress and egress), and shall not enter any restricted areas unless required to do so and are cleared for such entry. The Contractor's equipment shall be conspicuously marked for identification.

1.12.1 Request for Contractor's Employee Passes and Vehicle Passes

No employee or representative of the Contractor shall be admitted to the work site without a Contracting Officer's furnished authorized admittance. Prior to the start of on-site work, submit applications for base passes to the Contracting Officer for key employees (project manager, site supervisor, interpreter, etc.) for long term DBIDS passes. The Contractor, with assistance from the Resident Office, is responsible for securing sufficient passes for other workers, including subcontractor's employees and vehicles, required to access the base for the project duration. Additional personnel data shall also be furnished.

Provide all information required for background checks to meet base access requirements to be accomplished by Base Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. The Government reserves the right to make changes to the Contractor security requirements or processes due to a change in the Force Protection Condition (FPCON).

Upon completion of this Contract, return all employee and vehicle passes to the base, and obtain a certification of receipt. Final payment shall be withheld until all passes have been returned.

1.12.2 No Smoking Policy

Smoking is prohibited on installations except in designated smoking areas. This applies to existing buildings, buildings under construction, and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer shall identify designated smoking areas.

1.12.3 Unexploded Ordnance (UXO) Procedures on Kadena Air Base

Kadena Air Base 718 CES/CEN assesses the area as UXO unlikely with a low probability of uncovering UXO's on the site. However, since there is always a possibility of encountering UXOs anywhere on Okinawa, albeit unlikely at this location, excavations and other construction activities related earth work on the project site, require a measure of caution. The Ground Penetrating Radar (GPR) survey specified in 01 35 26 paragraph "Utilities Within and Under Concrete, Bituminous Asphalt, and Other Impervious Surfaces" for the identification of underground utilities will identify anomalies. Best practices of conducting GPR surveys are to repeat them in areas greater than the used method's level of detection (LOD), down to a depth of 2 meters, to ensure no utility lines or other suspicious objects are present. If suspected UXOs are identified, the construction team needs to follow the standard UXO notification procedures per the Kadena policies identified in attachment 01 11 00.00 10-B "UXO Emergency Mitigation Steps and Survey Policies." The contact number for the Emergency Dispatch Center for Kadena Air Base is 098-934-5911. See the

SECTION 01 11 00.00 10 Page 10 following website for additional information:

www.kadena.af.mil/About-Us/Emergency-Actions/ .

1.13 ORDER OF WORK

1.13.1 Schedule

Schedule all work to cause the least amount of interference with activity operations. Permission to interrupt any activity or roads shall be requested in writing a minimum of 30 calendar days prior to the desired date of interruption. Interruptions of activities, roads, and utility services shall be allowed only when they will not cause interference with the operations of the activity. The Contractor shall remove and dispose off Government property all Contractor generated debris at the end of each shift, or more frequently if required, to keep the space usable. Upon award of this Contract, the Contractor shall begin and complete all required work; ready for use and including cleanup, within the time period specified on this Contract. All work scheduled in occupied areas shall be accomplished in such a manner as to cause the least possible inconvenience to the occupants.

1.13.2 Working Hours

Normal Working Hours and Days are Monday through Friday, 0800 hours through 1700 hours. Saturday work is allowed on this contract and does not require additional approvals. Notify the Contracting Officer at least three days in advance when scheduling Saturday work.

1.13.3 Noise and Vibration

Noise greater than 70 decibels and vibration producing work in occupied buildings shall be conducted outside core school/business hours (0700 - 1430) unless written permission is given by the Contracting Officer.

1.13.4 Work Outside of Regular Hours

If the Contractor desires to carry on work outside the regular hours, on Sundays, or holidays, a written application shall be submitted to the Contracting Officer or his representative for approval. The Contractor shall allow three working days notice to enable satisfactory arrangements to be made by the Government for inspecting the work in progress. If work is to be accomplished after daylight hours, the Contractor shall illuminate the area in a manner approved by the Contracting Officer or their representative and in accordance with EM 385-1-1 . Unless directed by a Contracting Officer, work accomplished outside regular working hours shall be at no additional cost to the Government.

1.14 NUCLEAR DENSOMETER TESTING

Nuclear densometer testing and all forms of radiography are not permitted on U.S. Navy installations in Japan because such testing may interfere with Government of Japan monitoring activities.

1.15 FIRE PREVENTION DURING CONSTRUCTION

1.15.1 General

Comply with all pertinent fire prevention provisions of the US Army Corps of Engineers Manual EM 385-1-1 , NFPA 241 and shall follow the Installation

SECTION 01 11 00.00 10 Page 11 fire regulations. Prior to commencement of welding or other hot work operations, obtain approval from the Installation Fire Chief.

1.15.2 Supply

No more than one day's supply of paint, paint materials, or compounds shall be allowed within the area of the building, and shall be removed from the job site after each working day. No gasoline or similar low flash point flammable liquid shall be allowed within the building area.

After proper coordination with the Facility's Emergency Services (to confirm the maximum allowable quantities and location of storage), storage of additional product may be authorized.

1.15.3 Fire Extinguishers

Provide, as a minimum, the number, size, and type of fire extinguishers in accordance with the latest NFPA 10 . The Contractor shall comply with the Installation Fire Chief's policies if they are more stringent than NFPA 10 .

Fire extinguishers shall remain the property of the Contractor and shall be removed upon completion of the project.

1.15.4 Housekeeping

Accumulations of combustible material shall be removed from the building area on a daily basis.

1.15.5 Handling of Gasoline

Gasoline shall be stored in industry standard approved safety containers.

Adequate ventilation shall be provided to safely dispose of flammable vapors where flammable liquids are utilized. Gasoline powered equipment shall be refueled a minimum 6 meters away from the building area.

1.15.6 Notification of Fire

Be familiar with methods for notifying the Installation Fire Department.

The Installation's fire poster shall be posted in conspicuous locations and at telephones in construction shacks.

1.16 CONTRACTOR FURNISHED MATERIAL AND WORKMANSHIP

The Contractor shall furnish all materials necessary for performance of the work of this contract unless otherwise specified. Materials procured shall be new and shall meet any specifications and standards listed in these specifications. If no specification for a material needed to perform this contract are stated, the material shall be new, of acceptable industrial grade and quality, equal to or better than the manufacturer's original equipment for equipment being repaired or replaced, and will be compatible with existing materials and systems. All materials provided under this contract shall be free of asbestos, lead in paint, and PCB.

The Contracting Officer reserves the right to request submittal of any material being provided under this contract. The Contracting Officer shall make the final determination of the acceptability of any material used on this contract.

1.17 CORRESPONDENCE

All correspondence addressed to the Government shall be made through serialized letters furnished with one original and two copies. Serialized

SECTION 01 11 00.00 10 Page 12 letters shall begin with the number S-0001 and shall be continuous without a break in numbering. Serialized letters shall include the contract title and number, date, subject, and shall be signed by an authorized representative of the Contractor.

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 11 00.00 10 Page 13

THIS PAGE INTENTIONALLY LEFT BLANK

SECTION 01 11 00.00 10 Page 14

Japan Edited Specifications JES

ATTACHMENT 01 11 00.00 1-A Page 1

Japan Edited Specifications JES

ATTACHMENT 01 11 00.00 1-A Page 2

This page intentionally left blank.

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

PART 1 GENERAL

1.1 GENERAL

Payment items for the work of this Contract for which payments shall be made are listed in the CONTRACT LINE ITEM NUMBER (CLIN) SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, topographic surveys, cost of bond premiums, and for performing all work required by drawings and specifications for which separate payment is not otherwise provided. Work paid for under one item shall not be paid for under any other item. No separate payment shall be made for the work, services, or operations required by the Contractor, as specified in DIVISION 01, GENERAL REQUIREMENTS, to complete the project in accordance with these specifications; all costs thereof shall be considered as incidental to the work.

1.2 Submittals

Government approval is required for submittals with a "G" designation;

DESIGN-BID-BUILD:submittals not haveing a "G" designation are for information only. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-07 Certificates

Bill Of Lading ; G

1.3 LINE ITEMS

1.3.1 CLIN 0001, Construction of Primary Facility

1.3.1.1 Payment

Payment shall be made at the Contract job price for CLIN 0001 "Construction of Primary Facility" for work completed including, but not limited to []. Payment for work completed shall constitute full compensation of CLIN 0001, complete.

1.3.1.2 Unit of Measure

Unit of measure: job.

SECTION 01 20 00 Page 1

1.3.2 CLIN 0002, Construction of Supporting Facilities, 1.5 meters outside of Buildings

1.3.2.1 Payment

Payment shall be made at the Contract job price for CLIN 0002 "Construction of Supporting Facilities, 1.5 meters outside of buildings" for work completed including, but not limited to, construction of Supporting Facilities including special construction features [Pile Foundations], canopies, electrical utilities, communication utilities, water/sewer/utilities, site preparation, roads, sidewalks and parking, site improvements, AT/FP, demolition, low impact development, and environmental mitigation as shown on the drawings and specifications 1.5 meter outside of buildings, complete. Payment for work completed shall constitute full compensation of CLIN 0002, complete.

1.3.2.2 Unit of Measure

Unit of measure: job.

1.3.3 CLIN 0003, Excavation

1.3.3.1 Payment

Payment will be made for costs associated with excavation for the channel and for the structure, which includes performing required excavation and other operations incidental thereto, Contractor-furnished disposal area(s) and disposition of excess excavated material and unsuitable and frozen materials.

1.3.3.2 Measurement

The total quantity of excavated material for which payment will be made will be the theoretical quantity between the ground surface as determined by a survey and the grade and slope of the theoretical cross sections indicated. No allowance will be made for overdepth excavation or for the removal of any material outside the required slope lines unless authorized.

1.3.3.3 Unit of Measure

Unit of measure: cubic yard (CY).

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION

3.1 PROGRESS PAYMENT INVOICE

Requests for payment shall be submitted in accordance with Federal Acquisition Regulations (FAR) Subpart 32.9, entitled "PROMPT PAYMENT", and Paragraphs 52.232-5 and 52.232-27, entitled "Payments Under Fixed-Price Construction Contracts", and "Prompt Payment for Construction Contracts", respectively. In addition each request shall be submitted in the number of copies and to the designated billing office as shown in the Contract.

When submitting payment requests, the Contractor shall complete Blocks 1 through 12 of the "PROGRESS PAYMENT INVOICE" Form as directed by the Contracting Officer (provided in RMS CM). The completed form shall then become the cover document to which all other support data shall be

SECTION 01 20 00 Page 2 attached.

One additional copy of the entire request for payment, to include the "PROGRESS PAYMENT INVOICE" cover document, shall be forwarded to a separate address as designated by the Contracting Officer.

The Contractor shall submit with each pay request, a list of subcontractors that have worked during that pay period. The listing shall be broken down into weeks, identifying each subcontractor that has worked during a particular week, and indicate the total number of employees that have worked on site for each subcontractor for each week. The prime Contractor shall also indicate the total number of employees for its on site staff for each week.

Formal invoices shall be submitted every month between the first and the tenth of the month. Any invoice received after the tenth will be considered as not meeting the contract requirements and rejected. It may be resubmitted on the first of the following month.

3.2 TRANSPORTATION OF SUPPLIES BY SEA, BILL OF LADING

The Contractor shall, within 30 days after each shipment covered by Defense Federal Acquisition Regulation (DFAR) Subpart 252.247-7023, provide the Contracting Officer and the Maritime Administration (MARAD) one copy of the rated on board vessel operating carrier's ocean Bill of Lading . See DFAR 252.247-7023 for information required in the bill of lading. MARAD contact information: usarmy.scott.sddc.mbx.g3-ffw-team@mail.mil and msc.n101.ffw@navy.mil.

The Contractor shall use U.S.-flag vessels when transporting any supplies by sea under this contract. If U.S.-flag vessels are not available, the Contractor may submit a request for use of foreign-flag vessels in writing to the Contracting Officer at least 45 days prior to the sailing date necessary to meet its delivery schedules. Refer to DFAR 252.247-7023 for required documentation when making this request. The Contracting Officer will process requests submitted as expeditiously as possible, but the Contracting Officer's failure to grant approvals to meet the shipper's sailing date will not of itself constitute a compensable delay. Failure to get approval prior to the use of foreign-flag vessels may result in monetary penalty.

3.3 CONTRACT COST BREAKDOWN

The Contractor must furnish within 30 days after the date of Notice to Proceed, and prior to the submission of its first partial payment estimate, a breakdown of its single job pay item or items which will be reviewed by the Contracting Officer as to propriety of distribution of the total cost to the various accounts. Any unbalanced items as between early and late payment items or other discrepancies will be revised by the Contracting Officer to agree with a reasonable cost of the work included in the various items. This contract cost breakdown will then be utilized as the basis for progress payments to the Contractor.

3.4 CONTRACT ADMINISTRATION

3.4.1 Contracting Officer (KO)

This Contract shall be administered by a Contracting Officer (KO) assigned to the U.S. Army Corps of Engineers, Japan Engineer District, APO AP

SECTION 01 20 00 Page 3

96338-5010.

3.4.2 Administrative Contracting Officer (ACO)

In accordance with the USACE Acquisition Instruction (UAI) 5101.603-3-100, Appointment, Administrative Contracting Officer(s) (ACO's) may be delegated a part of the Contracting Officer's authority to modify this Contract and perform Contract administration functions under Federal Acquisition Regulation (FAR) Section 42.302, subject to the authority and limitations set forth in the appointment and delegation letter.

3.4.3 Contracting Officer's Representative (COR)

The Contracting Officer may designate one or more individuals as his/her authorized representatives in administering this Contract. Refer to the clause in Section 00 70 00 CONDITIONS OF THE CONTRACT entitled CONTRACTING OFFICER'S REPRESENTATIVE (DFARS 252.201-7000) for the definition and limited authority of CORs.

3.5 DESIGNATED BILLING OFFICE

The designated billing office for this Contract is:

Kanagawa Resident Office U.S. Army Corps of Engineers, Japan Engineer District Unit 45010

APO AP 96343-5010

USAED-J

Bldg. 250 Camp Zama Zama-City, Kanagawa

252-8511 JAPAN

-- End of Section --

SECTION 01 20 00 Page 4

SECTION 01 32 01.00 10

PROJECT SCHEDULE

08/23

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AACE INTERNATIONAL (AACE)

AACE 29R-03 (2011) Forensic Schedule Analysis

AACE 52R-06 (2006) Time Impact Analysis - As Applied in Construction

AACE 84R-13 (2015) Planning and Accounting for Adverse Weather

AMERICAN SOCIETY OF CIVIL ENGINEERS (ASCE)

ASCE 67-17 (2017) Schedule Delay Analysis

U.S. ARMY CORPS OF ENGINEERS (USACE)

ER 1-1-11 (2017) Administration -- Project Schedules

1.2 SUBMITTALS

Government approval is required for submittals with a "G" or "S"…