N64498-18-R-4002_Amend_0004.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See description of Amendment on page 2.

1. CONTRACT ID CODE PAGE OF PAGES

S 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 05-Nov-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N6449818R4002

X 9B. DATED (SEE ITEM 11)

22-Sep-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

05-Nov-2018

CODE

NAVAL SURFACE WARFARE CENTER PHILA

CODE 0214, DAVID RHOADS

215-897-7702, DAVID.RHOADS@NAVY.MIL

5001 SOUTH BROAD STREET

PHILADELPHIA PA 19112

N64498 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N6449818R4002

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

The purpose of Amendment 0004 is to provide response to submitted questions, inclusion of additional CDRL to the PWS, and to extend the RFP due date.

Q1. Page 110, Section L.2.3 (2) d. references an Attachment 2 - Cost Summary Format. We looked through the conformed solicitation and do not see this attachment. Can the government please provide the attachment or clarify?

A1. Omit reference to Attachment 2 - Cost Summary Format. As this requirement is a Firm Fixed Price type contract, a Cost Summary Format is not required.

Q2. Request a one (1) week extension of time to submit the proposal.

A2. A seven (7) day time extension has be granted for response to the RFP.

Q3. Hawaii only has a tax exemption on ship repair work for Government Surface Vessels. As the proposed SOW is not for surface vessels, please advise on the applicability of the Hawaii GET of 4.712% to the proposed effort and if this applies, how should this be represented in the cost proposal.

A3. It is encumbant upon the offeror to determine all applicable costs associated with their Firm Fixed Price work.

The following language has been added to Section C - PWS under Paragraph 4.0 DATA REQUIREMENTS.

4.13 Request for Waiver (A013)

4.13.1 The CDRL shall be delivered electronically, unless otherwise stated, and while Contractor’s format is acceptable, Government’s approval is required from the COR

4.13.2 The Request for Waiver (RFW) shall be used during or after manufacture/production to obtain authorization to deliver nonconforming items to the Government which do not comply with the applicable technical requirements.

Additionally, CDRL A013 has been attached to this amendment.

The Request for Proposal (RFP) due date has been extended to no later than 4:00PM, 13 November 2018.

All other terms and conditions remain unchanged.