Amendment_0003.pdf

N5005417NARRSPT

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Solicitation Amendment is to execute the follow ing:

1. Update Section C in response to Bidder's Questions 1-109,

2. Update Section J in response to ERRATA Packages #2 and #3,

3. Update Section J to incorporate a Revised Attachment J-3,

4. Provide Government Responses to Requests for Specif ication Clarif ication 1-109.

5. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 10

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 01-May-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N5005417R0003

X 9B. DATED (SEE ITEM 11)

03-Apr-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

01-May-2017

CODE

MID-ATLANTIC REGIONAL MAINTENANCE CENTER

CODE 411,

9727 AVIONICS LOOP

NORFOLK VA 23511-2124

N50054 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

N5005417R0003

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION C - DESCRIPTIONS AND SPECIFICATIONS

The following have been modified:

SECTION C

CONTRACT LINE ITEM NUMBER (CLIN) DESCRIPTIONS

CLIN 0001 Prepare for and accomplish the Docking Phased Maintenance Availability (DPMA) OF USNS

NARRAGANSETT (T-ATF 167) as delineated in the specification package MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed data provided by the government in accordance with Section J.

CLIN 0001

042-13-001 Accountability of Manhour and Material Reservation; accomplish

042-66-001 Work Completion Certification Data; provide

077-00-001 Hazardous Waste Produced on Naval Vessels; control

110-21-001 American Bureau of Shipping (ABS) 5 Year Hull Gauging Inspection (Exterior); provide

110-21-002 American Bureau of Shipping (ABS) 5 Year Hull Gauging Inspection (Interior); provide

110-21-003 American Bureau of Shipping (ABS) 5 Year Main Deck Gauging Exterior Inspection; accomplish

111-80-001 Training Operations Center and Berthing Installation, Boat Alt 226NS/3C; accomplish

123-11-001 Tank Inspection and repair; accomplish

123-11-002 Ballast Tank Inspection, repair, preserve; accomplish

150-11-001 Main Engine Room Soft Patch; repair

163-11-002 Sea Chest and Waster Sleeves; inspect and repair

167-11-001 Pilot House Weather Tight and 01 Level Weather Tight Doors; Repair

243-11-001 Propulsion Shafting; repair

245-11-001 Propeller; repair

259-11-002 Main and Ship Service Diesel Engine and Fire Pump Intake/Exhaust Piping system; repairs

262-11-001 Main Engine Lube Oil Coolers; clean, inspect, repair and test

321-80-001 Shore Power System Receptacle Replace and Relocate, BOATALT 226NS/4C; accomplish

(PREVIOUS OPTION ITEM. NOW PART OF WORK PACKAGE)

422-11-001 Navigation Sidelight Assembly/Shadow Box; replace

422-11-002 Fixed Post Stern Light and Towing Light Stanchion; repair and replace

426-80-001 Speed Log Replacement, B/A 226NS/6C: accomplish (PREVIOUS OPTION ITEM. NOW PART OF

WORK PACKAGE)

426-80-002 Standard Compass, Reflector, Binnacle and Foundation Removal; accomplish

428-90-001 Gyro Replacement; accomplish

437-21-001 Tank Level Indicating (TLI) Systems Inspection, repair, calibrate and test; accomplish

441-51-001 Pilot House Forward Antenna Sponsons; remove

443-11-001 Ship's Whistle Foundation, replace

508-11-001 Lagging and Insulation, Inside Machinery Space; replace

508-11-002 Lagging and Insulation, Outside Machinery Space; replace

514-11-001 Bilge and Ballast Overboard Discharge Piping; replace

520-11-002 Sea Valve; repair/replace (DRYDOCK)

521-11-001 Off Ship Firefighting System Removal B/A 226NS/1C; accomplish (PREVIOUS OPTION ITEM.

NOW PART OF WORK PACKAGE)

521-11-003 Seawater and Bilge and Ballast Piping; replace

526-11-001 Deck Drain Assembly; test, repair and replace

530-80-001 Reverse Osmosis Plant Replacement, B/A 226NS/5C; Accomplish (PREVIOUS OPTION ITEM.

NOW PART OF WORK PACKAGE)

542-00-002 CONVERT INTERIOR TANK TO STORE AND DISPENSE JP5, BOAT ALT 226NS 10C;

accomplish (PREVIOUS OPTION ITEM. NOW PART OF WORK PACKAGE)

562-11-001 Rudders, Steering Gear, and Skeg; clean, inspect and repair (DRYDOCK)

568-11-002 Bow Thruster and Gear Box; Inspect and Repair (DRYDOCK)

575-11-001 Stern Roller Foundations and aft structural damage; repair, replace

581-11-002 Anchor, Anchor Handling Assembly, chain locker and sump; repair and preserve

583-11-001 Allied Marine Davit (D-5300); repair and test

583-80-001 Towing Machinery Removal, B/A 226NS/2C; accomplish (PREVIOUS OPTION ITEM. NOW PART

OF WORK PACKAGE)

589-11-001 Allied Marine Crane; repair and test

593-11-001 Collecting, Holding and Transfer (CHT) Piping, tank, level sensors and lift stations; repair and replace

623-12-001 Exterior Incline Ladder support clips; replace.

625-11-001 Wheel house Windows; repair

631-10-001 Potable Water Tanks; preserve

631-11-001 Bilge; Preserve

631-11-002 Main Deck and Mission Deck Preservation and repair; accomplish

631-21-001 Superstructure, Masts and Stack Repairs and Preservation: accomplish

631-31-001 Underwater Hull and Freeboard; Repair and Preserve;

633-21-001 Impressed Current Cathodic Protection (ICCP) System; inspect and repair

672-00-001 Convert Line Load Lockers To Storage Spaces BOATALT 226NS/8C; accomplish (PREVIOUS

OPTION ITEM. NOW PART OF WORK PACKAGE)

843-11-001 Weight and Moment Change Data; provide

980-11-001 Light Off Assistance (LOA); provide

980-31-001 Office Space Without Computer for In-Plant Availability; provide

982-31-001 Dock Trial, Fast Cruise, and Sea Trial; accomplish

992-11-001 Fuel Assistance and Towboat Service for Fuel Barge; provide

992-11-003 Temporary Services; provide

992-31-001 Cleaning and Pumping: accomplish

993-31-001 Temporary Deck Covering; install

997-11-001 Drydocking and Undocking; accomplish

CLIN 0002 OPTION ITEM – Prepare for and accomplish SPEC ITEM 321-80-001; Shore Power System

Receptacle Replace and Relocate, BoatAlt 226NS/4C; (OPTION ITEM) for the Docking Phased Maintenance

Availability (DPMA) OF USNS NARRAGANSETT (T-ATF 167) as delineated in the specification package

MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed data provided by the government in accordance with Section J.

CLIN 0003 OPTION ITEM – Prepare for and accomplish SPEC ITEM 426-80-001; Speed Log Replacement, B/A

226NX/6C; (OPTION ITEM) for the Docking Phased Maintenance Availability (DPMA) OF USNS

NARRAGANSETT (T-ATF 167) as delineated in the specification package MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed

CLIN 0004 OPTION ITEM – Prepare for and accomplish SPEC ITEM 521-11-001; Off Ship Firefighting System

Removal, B/A 226NS/1C; (OPTION ITEM) for the Docking Phased Maintenance Availability (DPMA) OF USNS

NARRAGANSETT (T-ATF 167) as delineated in the specification package MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed

CLIN 0005 OPTION ITEM – Prepare for and accomplish SPEC ITEM 530-80-001; Reverse Osmosis Plant

Replacement, 226NS/5C; (OPTION ITEM) for the Docking Phased Maintenance Availability (DPMA) OF USNS

NARRAGANSETT (T-ATF 167) as delineated in the specification package MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed

CLIN 0006 OPTION ITEM – Prepare for and accomplish SPEC ITEM 542-00-002; Convert Interior Tank To

Store And Dispense JP5, BOAT ALT 226NS 10C; (OPTION ITEM) for the Docking Phased Maintenance

Availability (DPMA) OF USNS NARRAGANSETT (T-ATF 167) as delineated in the specification package

MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed data provided by the government in accordance with Section J.

CLIN 0007 OPTION ITEM – Prepare for and accomplish SPEC ITEM 583-80-001; Towing Machinery Removal

226NS/2C; (OPTION ITEM) for the Docking Phased Maintenance Availability (DPMA) OF USNS

NARRAGANSETT (T-ATF 167) as delineated in the specification package MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed

CLIN 0008 OPTION ITEM – Prepare for and accomplish SPEC ITEM 672-00-001; Convert Line Load Lockers

To Storage Spaces, BoatAlt 226NS/8C; (OPTION ITEM) F for the Docking Phased Maintenance Availability

(DPMA) OF USNS NARRAGANSETT (T-ATF 167) as delineated in the specification package MARMCN-801-17 and as specified herein and in accordance with standard items, work item specifications, drawings, test procedures and other detailed data provided by the government in accordance with Section J.

CLIN 0009 CONTRACT DATA REQUIREMENTS LIST (CDRLs) FOR ITEMS 0001 – 0008 (SEE

EXHIBITS A and B – CDRLs ATTACHED)

The Contractor shall furnish data required hereunder in accordance with the Contract Data Requirements List

(CDRL), DD Form 1423, Exhibit A and B attached hereto. The CDRLs form a part of the schedule of this solicitation.

NAVSEA Standard Items have been furnished to each MSRA and ABR Contractor under separate cover for retention. The current NAVSEA Standard Items applicable to work items of this specification are listed in the Index of Specifications, contained in the Specification Package, Attachment J-1 of Section J.

Category I NAVSEA FY-17 Standard Items are applicable to all items without further reference. Category II

NAVSEA FY-17 Standard Items are part of the specification package when invoked and/or referenced in individual work items specified in SSP MARMCN-801-17. NAVSEA Standard Items may be found at http://www.navsea.navy.mil/Home/RMC/CNRMC/Our-Programs/SSRAC/NSI/FY17-NSI/ http://www.navsea.navy.mil/Home/RMC/CNRMC/Our-Programs/SSRAC/NSI/FY17-NSI/

ADDITIONAL ALLOWANCES

(a) Offerors are required to include allowance of an additional 10% for electrical /electronic cable lengths and associated hardware for material ordering and shipboard installation over and above the drawing requirements in their price.

(b) Offerors are required to include allowance of an additional 10% for piping and associated fittings for material ordering and shipboard installation over and above the drawing requirements in their price.

NON SMOKING POLICY

Contractors are advised that in light of the Navy's policy regarding smoke-free facilities, the entire vessel, topside and below decks, is to be considered a "No Smoking Area" unless otherwise indicated by shipboard policy.

PERSONAL PROTECTIVE EQUIPMENT

Whenever work is performed aboard U.S. Naval Ships or vessels at piers or drydocks of a Naval Shipyard or Naval

Station, Contractor employees (including management personnel) shall have and use at all times the following personal protective equipment:

(a) Protective hard hats that meet the following specifications:

(1) Protective helmets purchased after July 5, 1994 shall comply with ANSI Z89.1-1986, "American National Standard for Personnel Protection-Protective Headware for Industrial Workers-Requirements," or shall be demonstrated to be equally effective.

(2) Protective helmets purchased before July 5, 1995 shall comply with ANSI Standard

"American National Standard Safety requirements for Industrial Head Protection," Z89.1-1969, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CFR 1910.135 Head Protection]

(b) Approved type plano or prescription glasses meeting the following specifications:

(1) Protective eye and face devices purchased after July 5, 1994 shall comply with ANSI standard

Z87.1-1989, "American National Standard Practice for Occupational and Educational Eye and Face Protection", or shall be demonstrated by the employer to be equally effective.

(2) Protective eye and face devices purchased before July 5, 1994 shall comply with ANSI "USA standard for Occupational and Educational Eye and Face Protection", Z87.1-1968, or shall be demonstrated by the employer to be equally effective. [Ref. 29 CRF 1910.133 Protective eye and face devices.]

(c) Safety toe shoes, with built-in protective toe box that meet the following specifications:

(1) Protective footwear purchased after July 5, 1994 shall comply with ANSI Standard Z41-1991, "American National Standard for Personal Protection-Protective Footwear", or shall be demonstrated by the employer to be equally effective.

(2) Protective footwear purchased before July 5, 1994 shall comply with the ANSI standard "USA

Standard for Men's Safety Toe Footwear", Z41.1 1967, or shall be demonstrated by the employer to be equally effective [Ref. 29 CFR 1910.136 Protective eye and face devices.]

SAFETY INSPECTOR / FIRE MARSHALL

The Contractor is responsible for providing an experienced Safety Inspector/Fire Marshall who will accomplish daily inspections of the Contractor's entire work area on the ship, together with the Contracting Office’s Safety

Representative. This Inspector or Fire Marshall shall not be one of the Contractor's supervisors or superintendents normally assigned to the ship.

USE OF BLACK OXIDE COATED BRASS THREADED FASTENERS (BOCBTFs)

Due to safety concerns, use of BOCBTFs is not authorized when installing or replacing threaded fasteners in the accomplishment of any work required by any Work Item in this contract.

COSAL CONFIGURATION CHANGE DOCUMENTATION (NAVSEA) (JUN 1992)

The contractor shall document all changes to the ship's configuration and prepare all documentation required to bring the ship's COSAL and SPCC Weapons Systems Files (WSF) into agreement with the actual end of availability configuration. Perform COSAL/WSF maintenance action on all planned and actual equipments/components/equipage, whether furnished by the Government or the Contractor.

PICK-UP OF GOVERNMENT FURNISHED MATERIAL (GFM) BY CONTRACTOR

(a) Upon notification of job order award by a Mid-Atlantic Regional Maintenance Center (MARMC) Contract

Department representative, the contractor will accept delivery of the (GFM) Government Furnished Material cited in the solicitation package from any and all locations within a 65-mile radius of MARMC, Norfolk, VA. Please contact the cognizant Project Manager to coordinate the pickup of GFM.

(b) The contractor will be required to make an initial pickup of all available GFM at the start of availability and no more than six (6) additional trips for the pickup of GFM for ship availabilities. After initial pickup, growth GFM will be included in the six (6) trips. MARMC Material Department will notify the contractor when additional GFM will be available for pickup, the approximate number of pieces, and the size of the GFM.

(c) These requirements do not supersede specific requirements stated in the work specifications.

LABOR AND MATERIAL RESERVATIONS IN SPECIFICATION ITEMS

Whenever a specification item includes a reservation work scope which requires that a specified amount of labor mandays and material be provided, the requirements for recordkeeping, approvals, and reconciliations are provided in Specification Item 042-13-001, Accountability of Manhour and Material Reservation.

DELIVERY OF GOVERNMENT PROPERTY

(a) All Government property as designated by the Government Property Administrator (GPA) will be delivered or shipped by the Contractor to one or more location(s) designated by the GPA. The designated location shall be within a 65-mile radius of MARMC (Norfolk Naval Base, Norfolk, VA).

(b) The contractor will be required to make up to five (5) such deliveries with no increase in the Job Order price. A delivery is defined as a designation of specific property to a specific place, but may require multiple loads.

(c) These requirements do not supersede requirements stated in work specifications.

POST-AWARD SUBMISSION

After receipt of award and prior to starting work aboard the vessel, the contractor must submit a list of employees who will work aboard ship to the Commanding Officer of the ship VIA the Project Manager. The list should be on company letterhead, include each employee's name, social security number, and security clearance when required, and bear the signature of a company official.

CITIZENSHIP REQUIREMENTS

The contractor shall comply with the Department of Defense Industrial Security Manual (DoD 5220.22), and any revisions to that manual as of the Bid Opening Date prescribed, for verification of all U. S. Citizens.

Prospective offerors shall refer all questions pertaining to the above to MARMC Security Manager (Code 1123, 757-400-0357).

ADDITIONAL DEFINITIONS

Wherever the term “Job Order” is used in this solicitation/award, it also means “Contract.”

Wherever SUPERVISOR OF SHIPBUILDING, C&R, USN, SUPSHIP PORTSMOUTH, SUPERVISOR or

NORFOLK SHIP SUPPORT ACTIVITY (NSSA) is used in this solicitation/award, all attachments and documents incorporated by reference, it also means MID-ATLANTIC REGIONAL MAINTENANCE CENTER (MARMC).

THREAT CONDITIONS

A Threat Condition has been set for this area. We are currently in force protection Bravo for the Hampton Roads area. Any changes to the FPCON level will be provide when necessary by MARMC security to the private shipyards or effected contractors. The parking of vehicles will be away from the immediate vicinity of the ship.

When submitting a proposal for this solicitation, consider that delays will be normal for gaining access onto the installation and/or facility where the ships may be located. Any costs associated with delays, disruptions, or security precautions associated with Bravo shall be included in your proposal. Contractors will not receive additional compensation for delays, disruptions, or security precautions associated with Bravo. Please direct any inquiries to

MARMC Security Manager, telephone (757) 400-0357.

USE/POSSESSION OF PERSONAL ELECTRONIC DEVICES (PEDS)

The possession and use of portable electronic devices (PEDs) within the confines of any naval vessel, or in the contractor's facility where equipment removed from the vessel is being worked, is strictly controlled.

PEDs include:

mobile computing devices such as personal digital assistants (PDAs);

hand-held or laptop computers;

mobile telephone devices such as data-enabled cellular telephones;

two-way pagers, including those with e-mail capability;

WI-FI Routers

Stand Alone Computers analog and digital sound recorders; and digital cameras, including cellular phones with digital imaging capabilities.

Cellular phones with digital imaging capabilities are strictly prohibited. PEDs may not be connected to any Navy-owned or controlled network. PEDs may not be used to store or process any digital information associated with the conduct of the contract without written authorization from the Naval Supervising Activity (NSA).

SUBMISSION OF POST AWARD INFORMATION

When requested by the Contracting Officer, offerors shall submit within 3 days after such request, any or all of the post award information below. Data required by paragraph (a) shall be submitted to the Administrative Contracting

Officer. Data required by paragraph (b) shall be submitted directly to the designated Project Manager and the

Administrative Contracting Officer. Contact Code 300A at (757) 443-2650 ext 4001, for applicable telephone/fax number.

(a). A procedure and schedule for accomplishing the requirements of the DELIVERY/REDELIVERY

SCHEDULE (B) in Section F, of this solicitation, to permit coordinating the necessary preparations with the ship's force.

(b). A breakdown of the total proposed price by specification item. Each work specification item should show the specification work item number, the specification work item title, the applicable contract line item number

(CLIN), mandays (prime and subcontractor), labor dollars (prime and subcontractor), and material dollars (prime and subcontractor). The contractor shall not create any additional work items and costs shall not be shown for standard items. This data may be provided by hard copy or on an executable disk formatted and provided by the

Government.

For ships worked in contractors’ facilities, contractors shall submit the heavy weather plan, including engineering calculations, in accordance with NAVSEA Standard Item 009-69 fifteen days prior to the start of the contract availability and anytime an update or change is required (e.g. change in mooring location or arrangement).

UTILIZATION OF THE NAVY MAINTENANCE DATABASE (NMD)

1. The successful offeror shall utilize the Navy Maintenance Database (NMD) program to perform administrative functions with the Government. The Contractor shall be responsible for submitting electronic reports, retrieving answered reports, and retrieving requests for contract changes (RCC’s) using NMD. Each individual needing access to NMD will require a PKI certificate and AISC User Account Request Form. The successful offeror must have access within 10 days of contract award.

a. Contractor is required to have internet access for connectivity to NMD and each company personnel using

NMD shall acquire a PKI certificate.

b. Each individual needing access to NMD will require approval. The Access Request and Non-Disclosure

Forms may be obtained by sending an email request to Sean Williams at

MARMC_NRFK_NMD_helpdesk@navy.mil.

2. The contractor will identify needed repairs and recommend corrective action during contract performance for those deficiencies discovered which are not covered by the work specifications. Needed repairs and corrective action reported will be submitted to the Government in the form of a Condition Found Report (CFR).

3. CFR’s supporting data will be submitted via NMD within five workings days of identification of the requirement. As a minimum, the CFR will include the following:

a. Identify contract number, ship, and hull number

b. Serialized by CFR number

c. Identification of the applicable Work Item number

d. Date requirement was discovered

e. Description of work requirement

f. Specific location of the work

g. Recommendation for corrective action

h. Recommendation for the appropriate/best time to accomplish the work (with or without schedule change). Provide supporting rational for the recommendation, such as price efficiencies, availability of the work force, availability of material, premium expenditures etc.

i. Identification of related changes, if any, to the internal milestones and production and contract completion dates.

If none, so state.

j. The surveillance of the contract resulting from this solicitation may be accomplished in part, by contractor personnel.

k. After the Project Manager has approved a Request for Contract Change (RCC), Contractor shall provide a Class

“F” estimate within three (3) business days and/or followed by a Class “C” estimate within five (5) business days for a total of eight (8) estimating days. Contractor’s proposal shall be submitted in Four-E-format, paragraph and sub-paragraph estimating using labor hours and material dollars for each.

mailto:MARMC_NRFK_NMD_helpdesk@navy.mil

SPECIAL REQUIREMENTS

The place of performance is restricted to the Norfolk, VA Homeport Area.

PAST PERFORMANCE

The contractor, in performing this Contract, will be subject to a past performance assessment in accordance with

FAR 42.15 and the Department of the Defense Contractor Performance Assessment Reporting System (CPARS)

Policy Guide in effect on the date of award and when each option year is invoked. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the Government for future source selection in accordance with FAR 15.304 when past performance is an evaluation factor for award.

SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

The following have been modified:

SECTION J

PART III

SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

(a) Any job order awarded as a result of this solicitation shall consist of the following sections of this solicitation, and the documents, exhibits, and attachments described below:

I. Part I - The Schedule (Sections A through H)

II. Part II - Contract Clauses (Section I)

III. Part III - List of Documents, Exhibits and other Attachments (Section J)

IV. Part IV - Representations and Instructions

(b) Part IV of the solicitation will not be physically incorporated into the resulting contract. However, Section K, "Representations, Certifications and Other Statements of Offerors or Quoters" will be retained in the contract file, and acceptance of a proposal under this solicitation incorporates Section K by reference into the resultant contract. (FAR 15.204-1(b))

(c) Documents, exhibits, and other attachments that will form part of this contract are as follows:

Exhibit "A" Contract Data Requirements List (CDRL) (DD Form 1423)

Exhibit "B" Contract Data Requirements List (CDRL) (DD Form 1423)

J-1 Specification Package SSP No. MARMCN-801-17

Previous ERRATAS:

593-11-001 ERRATA 1 – issued 13 April 2017

ERRATAs for NARRAGANSETT – issued 13 April 2017

ERRATAs for NARRAGANSETT 997-11-001 – issued 19 April 2017

ERRATAs for NARRAGANSETT 589-11-001 – issued 19 April 2017

ERRATAs for NARRAGANSETT 583-11-001 – issued 19 April 2017

ERRATAs for NARRAGANSETT 562-11-001 – issued 24 April 2017

ERRATA Package #1 – issued 24 April 2017

(Offeror’s must request to revieve ERRATA Packages at

MARMC_NRFK_411_PROCUREMENT@navy.mil)

ERRATA Package #2 – issued 01 May 2017

ERRATA Package #3 – issued 01 May 2017

J-2 Work Item Plans, Drawings, and Other References

J-3 Commencement & Completion Dates

Revised on May 1, 2017

(Offeror’s must request to the revised J-3 at

In addition to the documents listed above, the Successful Offeror’s accepted/approved Small Business subcontracting plan will be incorporated at contract award.

The following documents are included as part of the solicitation:

J-4 Past Performance Information Form

J-5 Request for Specification Clarification

J-6 Ship Access Procedures

J-7 Ship Access Forms

(End of Summary of Changes) mailto:MARMC_NRFK_411_PROCUREMENT@navy.mil