RFQ N4008523Q2540-0001 HVAC Controllers C29_C68.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to extend the offer due date, update the scope of w ork and request fresh quotes. Please see SOW entitled: 23303472-Spec-HVAC Controllers replacement at buildings C29 and C68.

1. CONTRACT ID CODE PAGE OF PAGES

1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 08-Nov-2023

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X N4008523Q2540

X 9B. DATED (SEE ITEM 11)

03-Aug-2023

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

08-Nov-2023

CODE

NAVFACSYSCOM MID-ATLANTIC

PWD EARLE

201 HIGHWAY SOUTH

BLDG C-9 NWP STATION EARLE

COLTS NECK NJ 07722-5017

N40085 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

joseph.henrius@navy.milEMAIL:732.866.2152TEL:

JOSEPH P. HENRIUS / SUPERVISORY CONTRACT SPECIALIS

N4008523Q2540

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been modified:

ADDITIONAL INFORMATION

1. This Request for Quote (RFQ) is being solicited as a total Small Business Set-Aside

2. The Contract Completion Date will be set at: 30 days after issuance of contract.

3. Bid must be valid for at least 60 days.

4. One site visit is scheduled for: TBD.

5. Passes are required for this visit. SECNAV 5512-1 access requests forms shall be sent to the project ET, Azeb Hailu (azeb.a.hailu.civ@us.navy.mil). Passes shall be picked up at the Mainside VCC in Colts Neck in advance of the visit. If you already have an active pass for NWS Earle Mainside, you are only required to submit names of attendees for the site visit. Access requests and attendees lists are due no later than 13 November 2023.

6. Enclosed to this Request for Quotation and subsequent contract is the following:

a. Attachment 1 – 23303472-Spec-HVAC Controllers replacement at buildings C29 and C68.

7. Quote is due no later than 5:00 PM local time on 17 November 2023. Quote may be e-mailed to Joe Henrius at joseph.p.henrius.civ@us.navy.mil. Quotes may NOT be mailed or faxed at this time.

8. Contractors may experience delays at the gates when entering and/or exiting the installation.

The Government shall not compensate for any such delays. All vehicles are subject to search upon entry, exit and while on the installation. Refusal to comply with a DoD police request to search a vehicle will result in denial of access to the installation and may result in criminal prosecution.

9. Wage Determination, dated 06/30/2023 has been incorporated in this RFQ.

10. All terms and conditions from this solicitation shall be included in the contract award by reference.

SECTION A - SOLICITATION/CONTRACT FORM

The required response date/time has changed from 24-Aug-2023 05:00 PM to 17-Nov-2023 05:00 PM.

N4008523Q2540

SECTION C - DESCRIPTIONS AND SPECIFICATIONS

The following have been deleted:

SOW

(End of Summary of Changes)