Amendment0003_20R0128.pdf

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. PROJECT NO. (If applicable) 0003 08/21/2020

6. ISSUED BY Code N40085 7. ADMINISTERED BY (If other than item 6.) Code

NAVFAC MID ATLANTIC

ACQUISITION CORE

9324 VIRGINIA AVENUE

NORFOLK, VA 23511

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) 9A. AMENDMENT OF SOLICITATION NO.

N40085-20-R-0128

9B. DATED (SEE ITEM 11)

08/03/2020

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning _1 _ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE

PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (if required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14. ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATION CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103 (b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER: (specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

N40085-20-R-0128, DESIGN-BID-BUILD BUILDING 420 FIRE ALARM REPAIRS, DAM NECK ANNEX, VIRGINIA BEACH, VIRGINIA

SEE SF 30 BLOCK 14 CONTINUATION PAGE

Contract POC: Gary Milton gary.milton1@navy.mil, Tel: 757-341-2074

Laura Thomas laura.e.thomas4@navy.mil, Tel: 757-341-1624

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR (Same as Item 8) 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070 30-105 STANDARD FORM 30 (REV.1-83) 0224-3(10-90)

PREVIOUS EDITION UNUSABLE Prescribed by GSA mailto:gary.milton1@navy.mil mailto:laura.e.thomas4@navy.mil

N40085-20-R-0128

SF 30 BLOCK 14 CONTINUATION PAGE

The purpose of this amendment is to provide the following:

1. Provide PPI responses (below)

2. Revised Liquidated Damages in General Requirements.

3. Revised Drawings and Specifications

1. PPI Responses:

PPI #

Date

Submitted

LEAVE

BLANK

Reference

Question Response Page Section Paragraph

1 08/03/20 Pg 2 General

Requirements

Liquidated

Damages

In review of the

General

Requirements, Liquidated Damages are listed at

$5,370.00, is this correct?

Update

Liquidated

Damages to

$488 per day.

2 08/07/20 2 General

Requirements

Liquidated

Damages

Are the liqudated damages really

$5,370.00?

Update

Liquidated

Damages to

$488 per day.

3 8/19/2020 pg 4 01 45 00.00 20 1.5.1.2

Due to the size and scope of the project, is the following requirement for QC

Mananger necessary? Four year degree and 10 years experience.

Delete requirement for

4 year degree.

10 year experience remains.

4 8/19/2020

Can the

Superintendent perform the duties of

QC Manager and

SSHO for the project? Yes

5 8/19/2020 01 78 24.00 20

Is eOMSI required for this project? Yes

2. Revisions to General Requirements:

Liquidated Damages: In accordance with FAR 52.211-12 Liquidated Damages, if the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $488 for each calendar day of delay until the work is completed or accepted.

3. Revised Drawings and Specifications:

The following drawings and specifications shall be revised as indicated below:

NAVFAC DWG NUMBER 12818998 – FA001

Drawing FA001 Note 24 Remove requirement for “twisted shielded pair” for SLC circuit.

N40085-20-R-0128

SPECIFICATION 01 30 00 ADMINISTRATIVE REQUIREMENTS

Paragraph 1.6.2 Superintendent Qualifications

DELETE “The superintendent shall be a separate entity from the QC manager.” And INSERT “The superintendent may be same entity as the SSHO and QC manager.”

SPECIFICATION 01 45 00.00 20 QUALITY CONTROL

Paragraph 1.5.1.2 Qualifications

DELETE “…graduate of a four year accredited college or university program in one of the following disciplines: Engineering, Architecture, Construction Management, Engineering Technology, Building Construction, or Building Science, with a…”

(End of Summary Changes)