Amendment N3220520R4037-0002.docx
DOCX document 29 KB Posted
- Attached to
- USNS MIGUEL KEITH PSA
- Solicitation number
- N3220520R4037
About this file
This document amends a solicitation for the Post Award Shakedown Availability of the USNS MIGUEL KEITH. The amendment modifies the liquidated damages clause, increasing the daily rate to $129,154 with total liquidated damages not to exceed 50% of the contract value. Interested contractors must complete a non-disclosure agreement to receive work items, drawings, and references for the solicitation. The Department of the Navy Military Sealift Command seeks proposals for the 120-calendar day PSA availability of the USNS MIGUEL KEITH commencing on or about August 3, 2020. Respondents must review attached documents including the solicitation, J-attachments, contract data requirements, and redacted justification and approval.
View the file
Other files
Show 40 more
Latest 50 of 58 listed here. See the rest on GovTribe.
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
N3220520R4037
SECTION SF 30 BLOCK 14 CONTINUATION PAGE
SUMMARY OF CHANGES
SECTION I - CONTRACT CLAUSES
The following have been modified:
52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEP 2000)
(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of not exceeding $129,154.00 per calendar day of delay. Total Liquidated Damages shall not exceed 50% of the contract value.
(b) If the Government terminates this contract in whole or in part under the Default--Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default--Fixed-Price Supply and Service clause in this contract.
(End of clause)
(End of Summary of Changes) image1.wmf
File details come from the government source that posted it. Updated .