Construction_Clauses.pdf

UNITED STATES COAST GUARD

CIVIL ENGINEERING UNIT - JUNEAU

REQUEST FOR PROPOSAL

HSCG87-14-R-PJT675

NOTICE: OFFERORS MUST BE REGISTERED IN THE SYSTEM FOR AWARD

MANAGEMENT (SAM). FOR additional information visit https://www.sam.gov/portal/public/SAM/#1

PACKAGING AND MARKING

(a) All shipments of materials, equipment and/or supplies to the project site shall be addressed to the

Contractor and not the Government. Preservation, packaging and packing shall be in accordance with standard practices for commercial packaging.

(b) Government personnel are not authorized to accept deliveries for the contractor, nor are they responsible for off-loading shipments. A contractor representative must be present to accept deliveries.

INSTRUCTIONS REQUIREMENTS (FIRM FIXED-PRICE)

(a) Invoices shall be prepared and submitted in accordance with the provisions of FAR clause 52.232-27, "Prompt Payment for Construction Contracts." Payments will not be made more frequently than once per month.

(b) Each invoice shall contain the following information:

(1) Contract Number

(2) Name of the Contract Specialist or Contracting Officer

(3) Invoice Routing Code (IRC) assigned by the Coast Guard

(4) Annotate on the invoice indicating that the contractor represents a small business for accelerated payment purposes.

(c) The Coast Guard unique Invoice Routing Code (IRC) for this contract is: CEU-JUN

(d) Each invoice must be submitted to the designated billing office via one of the following modes, listed in descending order of preference:

https://www.sam.gov/portal/public/SAM/#1

(1) FINCEN Website invoice receipt form:

http://www.fincen.uscg.mil/centralinv/central_inv_contr.cfm

(2) Fax: (757-523-6900)

(3) Mailed to: Commercial Invoices

U.S. Coast Guard Finance Center

1430A Kristina Way

Chesapeake, VA 23326

(e) To facilitate processing, all proper invoices and any supporting information submitted electronically using the FINCEN web based invoice submission capability must be submitted as a single Adobe .pdf formatted file, or as otherwise specified in the contract.

(f) Supporting documentation along with a courtesy copy of the invoice shall also be e-mailed to the

Contract Specialist and/or COR at the addresses cited below:

leroy.w.rushing@uscg.mil

(g) In accordance with the Prompt Payment Act, for the purposes of determining a payment due date and the date on which interest will begin to accrue if a payment is late, a proper invoice shall be deemed to have been received:

(1) On the later of:

(i) For invoices that are mailed or transmitted via facsimile, the date a proper invoice is actually received by the designated billing office and annotates the invoice with date of receipt at the time of receipt.

(ii) For invoices electronically transmitted by the contractor via web based submission, the date a transmission is received by the designated billing office, and receipt confirmation is provided to the designated recipient; or

(ii) The seventh day after the date on which the property is actually delivered or performance of the services is actually completed; unless—

a) The agency has actually accepted the property or services before the seventh day in which case the acceptance date shall substitute for the seventh day after the delivery date; or

b) A longer acceptance period is specified in the contract, in which case the date of actual acceptance or the date on which such longer acceptance period ends shall substitute for the seventh day after the delivery date;

(2) On the date placed on the invoice by the contractor, when the agency fails to annotate the invoice with date of receipt of the invoice at the time of receipt (such invoice must be a proper invoice); or

(3) On the date of delivery, when the contract specifies that the delivery ticket may serve as an invoice.

(4) Web based submission by the contractor and receipt confirmation does not reflect Government review or acceptance of the invoice.

(5) Payment inquiries and status may be obtained - at the following website:

https://www.fincen.uscg.mil/secure/payment.htm.

CLAUSES INCORPORATED BY FULL TEXT:

52.211-13 TIME EXTENSIONS (OCT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

http://www.fincen.uscg.mil/centralinv/central_inv_contr.cfm mailto:leroy.w.rushing@uscg.mil https://www.fincen.uscg.mil/secure/payment.htm

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

Also, the full text of a clause may be accessed electronically at this/these address(es):

www.acquisition.gov/FAR and http://www.dhs.gov/xlibrary/assets/opnbiz/cpo- acquisition-regulation-0606.pdf and http://www.dhs.gov/xlibrary/assets/opnbiz/cpo-acquisition-anual-

1206.pdf

52.204-7 SYSTEMS FOR AWARD MANAGEMENT (JUL 2013)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER

SUBCONTRACT AWARDS (JUL 2013)

52.204-13 SYSTEMS FOR AWARD MANAGEMENT MAINTENANCE (Jul 2013)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING

WITH CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR

DEBARMENT (AUG 2013)

52.215-8 ORDER OF PRECEDENCE - UNIFORM CONTRACT FORMAT (OCT 1997)

52.219-6 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (NOV 2011)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REPRESENTATION (JUL 2013)

52.222-6 DAVIS-BACON ACT (MAY 2014)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (MAY 2014)

52.222-9 APPRENTICES AND TRAINEES (JULY 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

52.222-12 CONTRACT TERMINATION-DEBARMENT (FEB 1988)

52.222-13 COMPLIANCE WITH DAVIS-BACON AND RELATED ACT

REGULATIONS (FEB 1988)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

http://www.acquisition.gov/FAR http://www.dhs.gov/xlibrary/assets/opnbiz/cpo-acquisition-regulation-0606.pdf http://www.dhs.gov/xlibrary/assets/opnbiz/cpo-acquisition-regulation-0606.pdf http://www.dhs.gov/xlibrary/assets/opnbiz/cpo-acquisition-anual-1206.pdf http://www.dhs.gov/xlibrary/assets/opnbiz/cpo-acquisition-anual-1206.pdf

52.222-21 PROHIBITION OF SEGREGATED FACILITES (FEB 1999)

52.222-26 EQUAL OPPORTUNITY (MAR 2007)

52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR

CONSTRUCTION (FEB 1999)

52.222-30 DAVIS-BACON ACT – PRICE ADJUSTMENT (NONE OR SEPARATELY

SPECIFIED METHOD (DEC 2001)

52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS (FEB 2009)

52.223-2 AFFIRMATIVE PROCUREMENT OF BIO-BASED PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (SEP 2013)

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY

2011)

52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (DEC 2007)

52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE

AND CONSTRUCTION CONTRACTS (MAY 2008)

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING

WHILE DRIVING (AUG 2011)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

52.225-25 PROHIBITION ON CONTRACTING WITH ENTITIES ENGAGING IN

SANCTIONED ACTIVITIES RELATING TO IRAN– REPRESENTATION AND

CERTIFICATION (NOV 2011)

52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (SEPT

2002)

52.232-17 INTEREST (OCT 2010)

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

52.232-23 ASSIGNMENT OF CLAIMS (JAN 1986)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JUL 2013)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER - CENTRAL CONTRACTOR

REGISTRATION (JUL 2013)

52.233-1 DISPUTES (MAY 2014) ALTERNATE I (JUL 2002)

52.233.3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK

(APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES,

EQUIPMENT, UTILITIES AND IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991) ALTERNATE I (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997) W/

ALTERNATE II: (APR 1984)

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

52.243-5 CHANGES AND CHANGED CONDITIONS (APR 1984)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

ALTERNATE I (APR 1984)

52.247-64 PREFERENCE FOR PRIVATELY OWNED U.S. FLAG COMMERICAL VESSELS

(FEB 2006)

52.249-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-

PRICE)(SHORT FORM) (APR 2012)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation

(48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 19) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

DEPARTMENT OF HOMELAND SECURITY ACQUISITION REGULATION (HSAR) CLAUSES

(48 CFR CHAPTER 30)

3052.204-71 CONTRACTOR EMPLOYEE ACCESS (JUN 2006)

3052.211-70 INDEX FOR SPECIFICATIONS (DEC 2003)

3052.228-70 INSURANCE (DEC 2003)

3052.242-72 CONTRACTING OFFICER'S TECHNICAL REPRESENTATIVE

(DEC 2003)

52.222-30 DAVIS-BACON ACT – PRICE ADJUSTMENT (NONE OR SEPARATELY SPECIFIED

METHOD) (DEC 2001)

(a) The wage determination issued under the Davis-Bacon Act by the Administrator, Wage and Hour Division, Employment Standards Administration, U.S. Department of Labor, that is effective for an option to extend the term of the contract, will apply to that option period.

(b) The Contracting Officer will make no adjustment in contract price, other than provided for elsewhere in this contract, to cover any increases or decreases in wages and benefits as a result of—

(1) Incorporation of the Department of Labor’s wage determination applicable at the exercise of the option to extend the term of the contract;

(2) Incorporation of a wage determination otherwise applied to the contract by operation of law; or

(3) An increase in wages and benefits resulting from any other requirement applicable to workers subject to the Davis-Bacon Act.

BUY AMERICAN ACT—CONSTRUCTION MATERIALS (FAR 52.225-9) (SEP 2010)

(a) Definitions. As used in this clause— “Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101); (ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 ( 46 U.S.C.

App. 1702), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means—

(3) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(4) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material. “United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the Buy American Act (41 U.S.C. 10a - 10d) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)).

The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: None [Contracting Officer to list applicable excepted materials or indicate “none”]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material.

However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

FOREIGN AND DOMESTIC CONSTRUCTION MATERIALS PRICE COMPARISON

Construction Material Description Unit of Measure Quantity Price (Dollars)* Item 1:

Foreign construction material

Domestic construction material

Item 2:

Foreign construction material

Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] [* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).] (End of clause)

52.252-5 Authorized Deviations in Provisions.

As prescribed in 52.107(e), insert the following provision in solicitations that include any FAR or supplemental provision with an authorized deviation. Whenever any FAR or supplemental provision is used with an authorized deviation, the contracting officer shall identify it by the same number, title, and date assigned to the provision when it is used without deviation, include regulation name for any supplemental provision, except that the contracting officer shall insert “(DEVIATION)” after the date of the provision.

Authorized Deviations in Provisions (Apr 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the provision.

(b) The use in this solicitation of any ______________ [insert regulation name] (48 CFR Chapter ______) provision with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

(End of provision) http://www.acquisition.gov/far/html/52_000_107.html#wp1114174

52.252-6 Authorized Deviations in Clauses.

As prescribed in 52.107(f), insert the following clause in solicitations and contracts that include any FAR or supplemental clause with an authorized deviation. Whenever any FAR or supplemental clause is used with an authorized deviation, the contracting officer shall identify it by the same number, title, and date assigned to the clause when it is used without deviation, include regulation name for any supplemental clause, except that the contracting officer shall insert “(DEVIATION)” after the date of the clause.

Authorized Deviations in Clauses (Apr 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any _____. [insert regulation name] (48 CFR _____) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

(End of clause)

3052.209-70 PROHIBITION ON CONTRACTS WITH CORPORATE EXPATRIATES (JUN 2006)

(a) Prohibitions.

Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity.

The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security.

(b) Definitions. As used in this clause:

Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 1504(b) of such Code), except that section 1504 of such Code shall be applied by substituting `more than 50 percent' for `at least 80 percent' each place it appears.

Foreign Incorporated Entity means any entity which is, or but for subsection (b) of section 835 of the Homeland Security Act, 6 U.S.C. 395, would be, treated as a foreign corporation for purposes of the Internal Revenue Code of 1986.

Inverted Domestic Corporation. A foreign incorporated entity shall be treated as an inverted domestic corporation if, pursuant to a plan (or a series of related transactions)—

(1) The entity completes the direct or indirect acquisition of substantially all of the properties held directly or indirectly by a domestic corporation or substantially all of the properties constituting a trade or business of a domestic partnership;

(2) After the acquisition at least 80 percent of the stock (by vote or value) of the entity is held—

(i) In the case of an acquisition with respect to a domestic corporation, by former shareholders of the domestic corporation by reason of holding stock in the domestic corporation; or

(ii) In the case of an acquisition with respect to a domestic partnership, by former partners of the domestic partnership by reason of holding a capital or profits interest in the domestic partnership;

and

(3) The expanded affiliated group which after the acquisition includes the entity does not have substantial business activities in the foreign country in which or under the law of which the entity is created or organized when compared to the total business activities of such expanded affiliated group.

Person, domestic, and foreign have the meanings given such terms by paragraphs (1), (4), and

(5) of section 7701(a) of the Internal Revenue Code of 1986, respectively.

(c) Special rules. The following definitions and special rules shall apply when determining whether a foreign incorporated entity should be treated as an inverted domestic corporation.

(1) Certain Stock Disregarded. For the purpose of treating a foreign incorporated entity as an inverted domestic corporation these shall not be taken into account in determining ownership:

(i) Stock held by members of the expanded affiliated group which includes the foreign incorporated entity; or http://www.acquisition.gov/far/html/52_000_107.html#wp1114174

(ii) stock of such entity which is sold in a public offering related to the acquisition described in subsection (b)(1) of Section 835 of the Homeland Security Act, 6 U.S.C. 395(b)(1).

(2) Plan Deemed In Certain Cases. If a foreign incorporated entity acquires directly or indirectly substantially all of the properties of a domestic corporation or partnership during the 4-year period beginning on the date which is 2 years before the ownership requirements of subsection (b)(2) are met, such actions shall be treated as pursuant to a plan.

(3) Certain Transfers Disregarded. The transfer of properties or liabilities (including by contribution or distribution) shall be disregarded if such transfers are part of a plan a principal purpose of which is to avoid the purposes of this section.

(d) Special Rule for Related Partnerships. For purposes of applying section 835(b) of the Homeland Security Act, 6 U.S.C. 395(b) to the acquisition of a domestic partnership, except as provided in regulations, all domestic partnerships which are under common control (within the meaning of section 482 of the Internal Revenue Code of 1986) shall be treated as a partnership.

(e) Treatment of Certain Rights.

(1) Certain rights shall be treated as stocks to the extent necessary to reflect the present value of all equitable interests incident to the transaction, as follows:

(i) warrants;

(ii) options;

(iii) contracts to acquire stock;

(iv) convertible debt instruments; and

(v) others similar interests.

(2) Rights labeled as stocks shall not be treated as stocks whenever it is deemed appropriate to do so to reflect the present value of the transaction or to disregard transactions whose recognition would defeat the purpose of Section 835.

(f) Disclosure. The offeror under this solicitation represents that [Check one]: __ it is not a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.104-70 through 3009.104-73;

__ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.104-70 through 3009.104-73, but it has submitted a request for waiver pursuant to 3009.104-74, which has not been denied; or __ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.104-70 through 3009.104-73, but it plans to submit a request for waiver pursuant to 3009.104-74.

(g) A copy of the approved waiver, if a waiver has already been granted, or the waiver request, if a waiver has been applied for, shall be attached to the bid or proposal.

(End of clause) http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P19_695 http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P32_3050 http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P19_695 http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P32_3050 http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P48_5212 http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P19_695 http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P32_3050 http://farsite.hill.af.mil/reghtml/regs/other/hsar/3009.htm#P48_5212

NOTICE FOR FILING AGENCY PROTESTS

United States Coast Guard Ombudsman Program

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency

Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or

Ombudsman.

Informal Forum with the Ombudsman. Interested parties who believe a specific

USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the

Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the

Contracting Officer through open and frank discussions. If the protester’s concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for reasons of unusual and compelling urgency or is determined in writing to be in the best interest of the Government. The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted to OPAP@uscg.mil or by hand delivery to the Contracting Officer.

The Ombudsman Hotline telephone number is 202.372.3695.

https://www.acquisition.gov/far/index.html https://www.acquisition.gov/far/index.html mailto:OPAP@uscg.mil