HanleyUpperEnvelopeAgreement.pdf

GSA Solicitation No. GS-02P-17-PW-C-0001 GSA Contract No.

Document: C101-SB I DEC 2016

(The Agreement)

Pages 1 of 28

Construction Contract for James M. Hanley Federal Building Upper

Envelope Construction

The Agreement

Table of Contents

I. Project Information

A Project Summary

B. The Contract

C. Period of Performance D. Work Conditions/Site Requirements

E. Authorized Representative

F. Liquidated Damages Rate

G. Buy American Exceptions

H. Statement of Work, Specifications, Drawings, Exhibits and Other Attachments

II. Prices

A Basis of Pricing B. Contract Price Form

Ill.Terms and Conditions

A Commencement, Prosecution, and Completion of Work

B. Contractor Responsibilities

C. Contractor Management and Personnel

D. Project Schedule

E. Extensions of Time

F. Interpretation of Specifications and Drawings

G. Submittals

H. Substantial Completion and Contract Completion

I. Use and Possession Prior to Substantial Completion

J. Finality of Contract Modifications

K. Liquidated Damages

L. Insurance Requirements

M. Order of Precedence

N. Administrative Matters

0. Non-Compliance with Contract Requirements

P. Safeguarding Sensitive Data and Information Technology Resources

Q. Options and Allowances

R. Additional Terms and Conditions

IV. Contract Clauses

A Clauses Incorporated in Full Text

B. Clauses Incorporated by Reference

C. Subcontract Requirements

Pages 2 of 28

I. Project Information

I.A. Project Summary

The Contractor shall provide all labor, material, equipment, tools, management, and supervision. Three (3) main work areas comprising approximately 20,000 SF are identified for roofing replacement at the James M. Hanley Federal Building and Annex located in Syracuse, NY: North Tower, South Tower and Annex (including bridge). .

The base work shall be conducted in phases where the Contractor must complete one roof replacement work area before another roof replacement work area can be performed. Demolition consists of removal (and where indicated abatement) of all roof areas identified on plans and specifications. Existing counter-flashings will be removed and new installed, unless noted otherwise. Roof replacement will include the installation of new fully adhered single-ply thermoplastic membrane system, and new retrofit roof drains into existing drain leaders/bodies. New insulation will be extruded polystyrene (XPS). Areas of fa9ade impacted by or left exposed due to roof replacement work activities shall be recoated with exact coating product and color to match existing. Existing skylights are to be replaced with new. Existing abandoned mechanical equipment will be removed and disposed of. Existing active mechanical equipment currently in use shall be disconnected and reconnected as required to replace the roof. Existing rooftop equipment that cannot be taken out of service shall be left in place and roof shall be replaced up to this equipment and its supports.

Communications Antenna and Satellite Dish will be temporarily disconnected to facilitate roof replacement operations. After roof is replaced, equipment will be reconnected/refastened and recalibrated for proper operation/function. Existing lighting protection system will be disconnected and reconnected. The lighting protection system will need to be re-certified as part of this project once the new roof system is installed.

Base work shall include; but is not limited to, roof demolition, disconnect and reconnect of electrical, HVAC and plumbing systems, sealant and concrete coating repairs, roof installation, roof drains, roof deck repairs (as required), and flashing repairs. Exact work descriptions are identified and indicated in the Contract Documents. Products to be used are specified within the drawings and individual specification· sections. The contractor shall comply with the project's design specifications and drawings. The work will be constructed under a single prime contract.

1.8. The Contract

(1) The Contract consists of the SF 1442, the Agreement, the Statement of Work, Specifications, Drawings, Exhibits, Amendments, Modifications, and other Attachments identified herein (collectively, the Contract Documents). The Contract contains the entire agreement of the Parties, and no prior written or oral agreement, express or implied, shall be admissible to contradict or modify any part of the Contract.

(2) The Contractor shall provide and pay for all labor, materials, equipment, tools, water, heat, utilities, transportation, and other facilities and services necessary for the proper execution of

Pages 3 of 28 the work described in and reasonably inferable from the Contract Documents (the Work), whether temporary or permanent. In consideration for, and upon condition of, the Contractor's completion of the Work, GSA shall pay the Contractor the price or prices established in Section

II, subject to the terms and conditions set forth in this Contract.

l.C. Period of Performance

(1) Commencement. The Contractor shall commence performance of the Work within 1 day after the Contractor receives the Notice to Proceed (NTP).

2) Substantial Completion. The Contractor shall achieve Substantial Completion of the Work, as that term is defined in this Agreement, no later than 120 calendar days from issuance of

Notice to Proceed (NTP).

(3) Contract Completion. The Contractor shall achieve Contract Completion, as the term is defined in this Agreement, within 60 calendar days of Substantial Completion.

l.D. Work Conditions/Site Requirements

N/A

I.E. Authorized Representative

(1) This Contract is between the United States of America, acting by and through the

Administrator of General Services (GSA), and the Contractor (the Parties). References in this

Contract to "the Owner" or "the Government" shall be understood to refer to GSA. The following individual is designated as the only authorized GSA representative under this Contract, unless other warranted contracting officers are designated in writing:

Contracting Officer

Name: Katherine Wheeler

Address: 100 South Clinton Street, Syracuse, NY 13261

Telephone: (315)448-0605

Email: Katherine.wheeler@gsa.gov

(2) GSAR 552.236-71, Authorities and Limitations, is incorporated by reference in this Contract.

l.F. Liquidated Damages Rate

In accordance with the "Liquidated Damages" clause in Section Ill (Terms and Conditions), liquidated damages shall be calculated at the rate of $ 2,005.16 per calendar day.

l.G. Buy American Exceptions

For the applicable Buy American clause and any exceptions, see Section IV of this Agreement.

l.H. Statement of Work, Specifications, Drawings, Exhibits, and Other Attachments

The following documents are incorporated by reference into this Contract.

(1) Project Manual for Hanley Upper Envelope Project, Dated October 21, 2016

(2) Construction Drawings for Hanley Upper Envelope Project, Dated October 21, 2016

(3) Wage Determination NY170016, Dated 01/06/2017 mailto:Katherine.wheeler@gsa.gov

Pages 4 of 28

II. Prices

II.A. Basis of Pricing

(1) Contract Prices. All Contract prices set forth in this Section include all costs necessary to complete the work for which the price is established (e.g., Base Contract, Unit Price, Options) in accordance with the Contract Documents, including, but not limited to, the cost of work performed by subcontractors and consultants, indirect costs, fees, expenses, taxes, and profit.

(2) Knowledge of Conditions Affecting Price. FAR 52.236-3, Site Investigations and ·Conditions Affecting the Work, is incorporated by reference in this Contract. The Contractor shall be presumed to have established all prices with knowledge of general and local conditions that may affect the cost of Contract performance at the site where the Work is to be performed, to the extent that such information is reasonably obtainable.

(3) Unit Prices and Allowances. If any portion of the Work is to be performed on a unit price basis, the Unit Price shall include all costs of coordinating and incorporating the unit-priced portion of the Work into the Base Contract Work. The Contractor shall only be obligated to perform unit-priced work to the extent that an Allowance has been established. The Contractor shall be obligated to perform such work in excess of a unit quantity for which an Allowance is established only if directed by the Contracting Officer in writing. The Contractor shall be bound to the unit price or prices set forth herein in all equitable adjustments for changes including unit priced work, and no markups shall be applied to such unit prices.

(4) Options. If any portion of the Work is to be performed upon the timely exercise of an

Option, the Option Price shall include all costs of coordinating and incorporating the Option priced portion of the Work into the Base Contract Work. An adjustment to the Contract price for such additional work shall be computed solely on the basis of the Option price or prices set forth herein. Unless otherwise specified, all options may be exercised within 90 days of Contract award.

(5) Bid Rates. If this Contract includes Bid Rates to be used in determination of equitable adjustments (e.g., overhead, profit, daily rates for time-related costs), such rates shall be deemed to include all costs recoverable as components of an equitable adjustment consistent with the requirements, definitions, and exclusions applicable to equitable adjustments set forth in this Contract, and consistent with the Contractor's cost accounting practices. Unless otherwise specified, the bid rates shall be deemed to include only the Contractor's costs, and not the costs of any subcontractors.

11.B. Contract Price Form See Standard Form 1442

Pages 5 of 28

Ill. Terms and Conditions

Ill.A. Commencement, Prosecution, and Completion of Work

FAR 52.211-10, Commencement, Prosecution, and Completion of Work, is supplemented as follows:

The Contractor shall not commence the Work until the Contracting Officer has issued NTP. The

Contractor shall diligently prosecute the Work so as to achieve Substantial Completion of the

Work, as defined in Section Ill (Terms and Conditions), "Substantial Completion and Contract

Completion" clause, within the time specified in Section I (Project Information), "Period of

Performance" clause. If the Contract specifies different completion dates for different phases or portions of the Work, the Contractor shall diligently prosecute the Work so as to achieve

Substantial Completion of such phases or portions of the Work within the times specified.

111.B. Contractor Responsibilities

(1) Unless otherwise expressly stated in the Contract, the Contractor shall be responsible for all means and methods employed in the performance of the Contract.

(2) The Contractor shall be responsible for providing professional design services in connection with performance of the Work or portions of the Work only if this responsibility is expressly stated and the Contract Documents provide the performance and design criteria that such services will be required to satisfy. In the performance of such work, the Contractor shall be responsible for retaining licensed design professionals, who shall sign and seal all drawings, calculations, specifications and other submittals that the licensed professional prepares. The

Contractor shall be responsible for, and GSA shall be entitled to rely upon, the adequacy and completeness of all professional design services provided under this Contract.

(3) The Contractor shall be responsible for coordinating all activities of subcontractors. This responsibility includes coordination of: preparation of shop drawings produced by different subcontractors where their work interfaces or may potentially conflict or interfere and the installation of such work; scheduling of work by subcontractors; and use of the Project site for staging and logistics.

(4) Where installation of separate Work components as shown in the Contract Documents will result in conflict or interference between such components or with existing conditions, including allowable tolerances, it is the Contractor's responsibility to bring such conflict or interference to the attention of the Contracting Officer and seek direction before fabrication, construction, or installation of any affected work. If the Contractor fabricates, constructs, or installs any work prior to receiving such direction, the Contractor shall be responsible for all cost and time incurred to resolve or mitigate such conflict or interference.

(5) Where drawings show work without specific routing, dimensions, locations, or position relative to other work or existing conditions, and such information is not specifically defined by reference to specifications or other information supplied in the Contract Documents, the

Contractor is responsible for routing, dimensioning, and locating such work in coordination with other work or existing conditions in a manner consistent with Contract requirements.

Pages 6 of 28

(6) It is not the Contractor's responsibility to ensure that the Contract Documents comply with applicable laws, statutes, building codes and regulations. If it comes to the attention of the

Contractor that any of the Contract Documents do not comply with such requirements, the

Contractor shall promptly notify the Contracting Officer in writing. If the Contractor performs any of the Work prior to notifying and receiving direction from the Contracting Officer, the Contractor shall assume full responsibility for correction of such work, and any fees or penalties that may be assessed for non-compliance.

(7) The Contractor shall immediately bring to the Contracting Officer's attention any hazardous materials or conditions not disclosed in the Contract Documents discovered by or made known to the Contractor during the performance of the Contract.

(8) The Contractor must submit a safety plan before commencing work.

111.C. Contractor Management and Personnel

FAR 52.236-6, Superintendence by the Contractor, is supplemented as follows:

(1) The Contractor shall employ sufficient management and contract administration resources, including personnel responsible for project management, field superintendence, change order administration, estimating, coordination, inspection, and quality control, to ensure the proper execution and timely completion of the Work. The Contractor shall designate a principal of the firm or other senior management official to provide executive oversight and problem resolution resources to the Project for the life of the Contract.

(2) The Contractor shall employ, and require its subcontractors to employ, qualified personnel to perform the Work. The Government reserves the right to exclude, or remove from the site or building, any personnel for reasons of incompetence, carelessness, or insubordination, who violate rules and regulations concerning conduct on federal property, or whose continued employment on the site is otherwise deemed by the Government to be contrary to the public interest.

(3) Repeated failure or excessive delay by the Contractor to provide qualified personnel shall be deemed a default for the purposes of the Termination for Default clause.

111.D. Project Schedule

(1) The Contractor shall use a Critical Path Method ("CPM") Project Schedule to plan, coordinate, and perform the Work. The Project Schedule shall be produced using widely used, commercially available computer software that is capable of generating and monitoring a CPM schedule and is compatible with Meridian Proliance.® For example, compatible software includes Microsoft Project,® Primavera SureTrak,® and Primavera Project Planner.®

(2) The Project Schedule shall be a rational, reasonable and realistic plan for completing the

Work, and conform to requirements specified in this clause and elsewhere in this Contract.

(3) The Contractor understands and acknowledges that the preparation and proper management of the Project Schedule is a material component of the Work, and that the

Contract price includes all costs of compliance with Project Schedule requirements.

Pages 7 of 28

(4) The Project Schedule shall depict all activities necessary to complete the Work, including, as applicable, all submittal and submittal review activities, all procurement activities, and all field activities, including mobilization, construction, start-up, testing, balancing, commissioning, and punchlist. Activities shall be sufficiently detailed and limited in duration to enable proper planning and coordination of the Work, effective evaluation of the reasonableness and realism of the Project Schedule, accurate monitoring of progress, and reliable analysis of schedule impacts.

(5) Within thirty (30) days of NTP, or such other time as may be specified herein, the Contractor shall submit its Project Schedule to the Contracting Officer, together with a written narrative describing the major work activities, activities on the critical path, and major constraints underlying the sequence and logic of the Project Schedule. The Contractor shall submit the

Project Schedule in both electronic and hardcopy print format.

(6) The Contractor should anticipate that its initial submittal of the Project Schedule shall be subject to review and revision as contemplated by Paragraph (11) of this clause, and the

Contractor shall devote sufficient resources for meetings, revisions, and resubmissions of the

Project Schedule to address exceptions taken by the Contracting Officer to the initial submittal.

The Contractor understands and acknowledges that the purpose of the initial review and resolution of exceptions is to maximize the usefulness of the Project Schedule for the Parties during Contract performance.

(7) Activity durations shall be based upon reasonable and realistic allocation of the resources required to complete each activity, given physical and logistical constraints on the performance of the Work. All logic shall validly reflect physical or logistical constraints on relationships between activities. Except for the first and last activities in the Project Schedule, each activity shall have at least one predecessor and one successor relationship to form a logically connected network plan from NTP to the Contract Completion date.

(8) The Project Schedule shall incorporate milestone events specified in the Contract, including, as applicable, NTP, Substantial Completion, and milestones related to specified work phases and site restrictions. The Project Schedule shall also include Contractor-defined milestones to identify target dates for critical events, based upon the Contractor's chosen sequence of work.

(9) Unless a shorter period for updates is specified elsewhere, the Contractor shall update the

Project Schedule monthly to reflect its actual progress in completing the Work, and submit the updated Project Schedule to the Contracting Officer within five (5) working days of the end of each month or other specified period.

(10) If the Contractor revises the Project Schedule after initial submission, the Contractor shall provide in writing to the Contracting Officer a narrative describing the substance of the revision, the rationale for the revision, and the impact of the revision on the projected Substantial

Completion date and the available float for all activities. The Contractor shall only revise prospective activities, durations and logic, but addition of detail to prospective activities shall not be deemed a revision if the overall duration of the detailed activity does not change.

(11) If at any time the Contracting Officer finds that the Project Schedule does not comply with any Contract requirement, the Contractor shall, upon written notice of exceptions taken by the

Contracting Officer, revise the Project Schedule, adjust activity progress, or provide sufficient information demonstrating compliance. Regardless of whether the Contracting Officer takes any such exception, the Contractor shall not be relieved of its responsibility for the rationality, Pages 8 of 28 reasonableness or realism of the Project Schedule, or its responsibility to achieve Substantial

Completion within the time specified by this Contract.

(12) If the Contractor fails to sufficiently address the Contracting Officer's exceptions to the

Project Schedule within thirty (30) calendar days of written notice of same, the Contracting

Officer may withhold retainage until the Project is Substantially Complete or until such time as the Contractor has complied with Project Schedule requirements.

(13) The Contracting Officer shall be entitled, but not required, to rely upon the Project

Schedule to evaluate the Contractor's progress, evaluate entitlement to extensions of time and determine the criticality or float of any activities described in such Project Schedule.

111.E. Extensions of Time

FAR 52.211-13, Time Extensions, is supplemented as follows:

(1) If the Contractor requests an extension of the time for Substantial Completion, the

Contractor shall base its request on analysis of time impact using the Project Schedule as its baseline, and shall propose as a new Substantial Completion date to account for the impact.

The Contractor shall submit a written request to the Contracting Officer setting forth facts and analysis in sufficient detail to enable the Contracting Officer to evaluate the Contractor's entitlement to an extension of time.

(2) The Contractor shall only be entitled to an extension of time to the extent that (a)

Substantial Completion of the Work is delayed by causes for which the Contractor is not responsible under this Contract, and (b) the actual or projected Substantial Completion date is later than the date required by this Contract for Substantial Completion.

(3) The Contractor shall not be entitled to an extension of time if the Contractor has not updated the Project Schedule in accordance with this Contract.

(4) The Government shall not be liable for any costs to mitigate time impacts incurred by the

Contractor that occur less than 30 calendar days after the date the Contractor submits a request for extension of time in compliance with this clause.

111.F. Interpretation of Specifications and Drawings

FAR 52.236-21, Specifications and Drawings for Construction, and GSAR 552.236-77, Specifications and Drawings, are supplemented as follows:

(1) Different requirements within the Contract Documents shall be deemed inconsistent only if compliance with both cannot be achieved.

(2) Unless otherwise noted, the drawings shall be interpreted to provide for a complete construction, assembly, or installation of the Work, without regard to the detail with which material components are shown in the drawings.

111.G. Submittals

FAR 52.236-21, Specifications and Drawings for Construction, GSAR 552.236-78, Shop

Drawings, Coordination Drawings, and Schedules, and GSAR 552.236-79, Samples are supplemented as follows:

Pages 9 of 28

(1) The Contractor shall prepare and submit to the Contracting Officer shop drawings, samples, calculations, product information, mockups, and other submittals (collectively, "submittals") demonstrating compliance with Contract requirements for all Work components as specified elsewhere in this Contract. If particular submittal requirements are not specified for a component of the Work, the Contractor shall prepare submittals for such Work as directed by the Contracting Officer.

(2) The Contractor shall not proceed with work or procure products or materials described or shown in submittals until the Contracting Officer has indicated approval of the submittal. Any work or activity undertaken prior to approval shall be at the Contractor's risk; should the

Contracting Officer subsequently determine that the work or activity does not comply with the

Contract, the Contractor shall be responsible for all cost and time required to comply with the

Contracting Officer's determination. The Contracting Officer shall have the right to order the

Contractor to cease execution of work for which submittals have not been approved. The

Government shall not be liable for any cost or delay incurred by the Contractor attributable to the proper exercise of this right.

(3) The Contractor shall be entitled to receive notice of action on submittals within a reasonable time, given the volume or complexity of the submittals and the criticality of the affected activities to Substantial Completion as may be indicated in the Project Schedule. The Contractor shall not be entitled to receive notice of action on submittals containing variations from Contract requirements in less than twenty (20) working days.

111.H. Substantial Completion and Contract Completion

FAR 52.211-10, Commencement, Prosecution, and Completion of Work, FAR 52.211-12, Liquidated Damages (Construction), and GSAR 552.246-72, Final Inspection and Tests, are supplemented as follows:

(1) For the purposes of FAR 52.211-10, Commencement, Prosecution and Completion of Work, and FAR 52.211-12, Liquidated Damages (Construction), the Work shall be deemed complete when it is "Substantially Complete." The Work shall be deemed "Substantially Complete" if and only if the Contractor has completed the Work and related Contract obligations in accordance with the Contract Documents, such that the Government may enjoy the intended access, occupancy, possession, and use of the entire Work without impairment due to incomplete or deficient work, and without interference from the Contractor's completion of remaining work or correction of deficiencies in completed work. In no event shall the Work be deemed

Substantially Complete if all fire and life safety systems are not tested and accepted by the

Authority Having Jurisdiction, where such acceptance is required under the Contract.

(2) With reasonable advance notice, the Contractor shall submit to the Contracting Officer a written proposal recommending a Substantial Completion date (Notice of Substantial

Completion). The Contracting Officer shall conduct inspections and make a determination of

Substantial Completion within a reasonable time. If the Contracting Officer takes exception to the Notice of Substantial Completion, the Contractor shall be entitled to a written notice of conditions precluding determination of Substantial Completion.

(3) The Contractor shall only be entitled to an extension of time to address such conditions if, and to the extent that, the Contracting Officer provides notice of such conditions more than thirty

(30) calendar days after receipt of the Notice of Substantial Completion.

(4) Substantial Completion shall be established by the Contracting Officer's issuance of a written determination specifying the date upon which the Work is Substantially Complete.

(5) The Contract is complete (Contract Completion) if and only if the Contractor has completed all Work and related Contract obligations, corrected all deficiencies and all punch list items, and complied with all conditions for final payment.

(6) Unless otherwise specifically noted, or otherwise clear from context, all references in this

Contract to "acceptance" shall refer to issuance of a written determination of Substantial

Completion.

(7) The Contractor shall not be entitled to final payment or release of any retainage held by the

Government until after Contract Completion. If the Contractor does not achieve Contract

Completion within the time required by this Contract, the Government shall be entitled, after providing notice to the Contractor, to complete any work remaining unfinished. The Contractor shall be liable to the Government for all costs incurred by the Government to complete such work.

III.I. Use and Possession Prior to Substantial Completion

FAR 52.236-11, Use and Possession Prior to Completion, is supplemented as follows:

Exercise by the Government of the right conferred by FAR 52.236-11 shall not relieve the

Contractor of responsibility for completing any unfinished components of the Work.

111.J. Finality of Contract Modifications

As set forth elsewhere in this Contract, the Contractor is entitled to additional consideration under certain conditions, including the issuance of change orders. It is the Contractor's duty to include in proposals for equitable adjustment or other consideration all compensation to which it may be entitled, including cost and time. Unless otherwise explicitly stated in a modification to the Contract providing such consideration, adjustments to the Contract price or time agreed upon therein shall be deemed to provide all compensation to which the Contractor is entitled, and shall constitute final settlement of the Contractor's entitlement to compensation on account of the change or other condition giving rise to the modification.

111.K. Liquidated Damages

FAR 52.211-12, Liquidated Damages is supplemented as follows:

(1) The Contractor acknowledges that time is of the essence for the performance of the Work, and that determining actual damages from delay would be extremely difficult and impractical. If the Contractor fails to achieve Substantial Completion of the Work within the time specified in this Contract, the Contractor shall be liable to the Government for liquidated damages at the rate specified in Section I (Project Information), paragraph entitled, "Liquidated Damages Rate," for each calendar day following the required completion date that the Work is not Substantially

Complete.

(2) If the Contract requires different completion dates for different phases or portions of the

Work, the Contractor shall be liable for liquidated damages at the specified rate for each calendar day following the required completion date that the phase or portion of Work is not

Substantially Complete. If a single rate is specified, the specified rate shall be apportioned between the different phases or portions of the Work.

Pages 1o of 28

Pages 11 of 28

(3) If the Government elects to accept any portion of the Work not specifically designated as a phase or portion of Work with its own required completion date, the liquidated damage rate shall be apportioned between accepted work and uncompleted work, and the Contractor's liability for liquidated damages shall be computed accordingly.

111.L. Insurance Requirements

(1) The Contractor shall obtain and maintain for the entire life of the Contract, in addition to any insurance required by law, the following minimum kinds and amounts of insurance required pursuant to FAR clause 52.228-5, Insurance - Work on a Government Installation, and GSAR

552.228-5, Government as Additional Insured.

(a) Workers' compensation insurance in the amount required by the jurisdiction in which the Contract is performed. The Contractor shall obtain Employers' liability coverage of at least

$2,000,000. If occupational diseases are not covered by workers' compensation insurance, Employers' liability coverage shall include occupational diseases.

(b) Broad form comprehensive commercial general liability insurance in the amount of at least $5,000,000 per occurrence. Such insurance shall include, but not be limited to, contractual liability, bodily injury ar:id property damage.

(c) Comprehensive automobile liability covering the operation of all automobiles used in connection with performing the Contract in the amount of at least $1,000,000 per person and

$2,500,000 per occurrence for bodily injury and $1,000,000 per occurrence for property damage.

(2) The Contractor shall promptly provide to the Contracting Officer proof that it has obtained insurance required by the Contract in the form of certificates of insurance. The Contractor shall submit to the Contracting Officer all renewal certificates issued during the life of this Contract immediately upon issuance.

111.M. Order of Precedence

Different requirements within this Contract shall be deemed inconsistent only if compliance with both cannot be achieved. In case of inconsistency between Contract Documents, the following order of precedence shall apply:

(1) Section IV of the Agreement

(2) Sections I, II, and Ill of the Agreement

(3) The Statement of Work

(4) The Specifications

(5) The Drawings

(6) Exhibits and Other Attachments

111.N. Administrative Matters

(1) Project Meetings. The Contractor shall attend a preconstruction conference and shall participate in regularly scheduled Project meetings.

(2) Schedule of Values. The Contractor shall prepare and submit for approval a detailed cost breakdown of the Contract price, to be referred to as the Schedule of Values, assigning values

Pages 12 of 28 to each component of the Work. Values must include all direct and indirect costs, although a separate value for bond costs may be established. The Schedule of Values must contain sufficient detail to enable the Contracting Officer to evaluate applications for payment. If this

Contract requires that the Project Schedule be cost loaded, the Schedule of Values will be derived from the Project Schedule.

(3) Payments. FAR clause 52.232-5, Payments under Fixed-Price Construction Contracts, is supplemented as follows:

(a) Before submitting a request for payment, the Contractor shall attend preinvoice payment meetings each month, as scheduled, with the designated Government representative for the purpose of facilitating review and approval of payment requests. Payment meetings may be conducted in person or by telephone. The Contractor shall provide documentation to support the prospective payment request.

(b) The Contractor shall submit its invoices to the Contracting Officer. Separate payment requests shall be submitted for progress payments, payments of retainage, and partial or final payments.

(c) If the invoice does not meet the requirements of FAR Clause 52.232-27 (a)(2) and the requirements specified in Subparagraphs (3)(a),(d),{e),and(f) of the Administrative Matters clause, the Contracting Officer may return the invoice to the Contractor without payment for correction. If the Contracting Officer disputes the requested payment amount, the Government may pay the portion of the requested payment that is undisputed.

(d) Invoices shall be submitted in an original and two (2) copies to the designated billing office specified in this Contract or in individual delivery/work orders.

(e) Invoices must include the Account Document Number (AON) assigned at award.

(f) The Contractor shall submit the following information or documentation with each invoice:

(i) GSA Form 184A and/or 1848 - Construction Progress Report (Construction Phases Only) or AIA Form G702, including the updated Schedule of Values upon which the payment request is based;

(ii) GSA Form 2419 - Certification of Progress Payments Under Fixed-Price

Construction Contract;

(iii) The payment terms that apply for the particular services rendered;

(iv) Additional documentation:

N/A

Pages 13 of 28

(g) GSA will not be obligated to issue final payment unless the Contractor has furnished to the Contracting Officer a release of claims against the Government relating to this Contract, and submitted all required product warranties, as-built drawings, operating manuals, and other items as specified in the Contract. The

Contractor may reserve from the release specific claims only if such claims are explicitly identified with stated claim amounts. All release forms must bear the original signature of the signer and must be affixed with the Contractor's corporate seal or the seal of a Notary Public.

(4) Prompt Payment. In accordance with FAR clause 52.232-27, the period for payments is as follows:

(a) Progress Payments: 14 days

(b) Subsequent Subcontractor Payments: 7 days

(5) Payment Information. The General Services Administration (GSA) makes information on contract payments available electronically at http://www.finance.gsa.gov. The Contractor may register at the site and review its record of payments. This site provides information only on payments made by GSA, not by other agencies.

(6) Security Clearances. Contractor shall comply with the following requirements pertaining to security clearances:

(a) All personnel performing work under the Contract on the Project site must obtain an

Enter on Duty (EOD) determination before they will be granted access to the site.

(b) To obtain an EOD determination, Contractor shall submit for all such personnel fingerprints on Form SF87 and a completed Contractor Information Worksheet (CIW). Detailed information is available at http://www.gsa.gov/portal/category/107203 . USAccess Credentialing

Centers can be located at http://www.fedidcard.gov/centerlist.aspx .

(c) In addition, all such personnel who will be on site 6 months or longer must apply for and receive clearance in accordance with Homeland Security Presidential Directive 12 (HSPD-

12). See Section IV, Contract Clauses, GSAR 552.204-9.

(7) Safeguarding and Dissemination of Sensitive But Unclassified (SBU) Building Information.

This clause applies to all recipients of SBU building information, including offerers, bidders, awardees, contractors, subcontractors, lessors, suppliers and manufacturers.

(a) Marking SBU. Contractor-generated documents that contain building information must be reviewed by GSA to identify any SBU content, before the original or any copies are disseminated to any other parties. If SBU content is identified, the Contracting Officer (CO) may direct the contractor, as specified elsewhere in this contract, to imprint or affix SBU document markings to the original documents and all copies, before any dissemination.

(b) Authorized recipients.

(i) Building information designated SBU must be protected with access strictly controlled and limited to those individuals having a legitimate business need to know such information.

Those with a need to know may include Federal, State and local government entities, and nongovernment entities engaged in the conduct of business on behalf of or with GSA

Nongovernment entities may include architects, engineers, consultants, contractors, subcontractors, suppliers, utilities, and others submitting an offer or bid to GSA, or performing work under a GSA contract or subcontract. Recipient contractors must be registered as "active" http://www.finance.gsa.gov/ http://www.gsa.gov/portal/category/107203 http://www.fedidcard.gov/centerlist.aspx

Pages 14 of 28 in the System for Award Management (SAM) database at www.sam.gov and have a legitimate business need to know such information. If a subcontractor is not registered in the SAM and has a need to possess SBU building information, the subcontractor shall provide to the contractor its

DUNS number or its tax ID number and a copy of its business license. The contractor shall keep this information related to the subcontractor for the duration of the contract and subcontract.

(ii) All GSA personnel and Contractors must be provided SBU building information when needed for the performance of official Federal, State, and local government functions, such as for code compliance reviews and for the issuance of building permits. Public safety entities such as fire and utility departments may require access to SBU building information on a need to know basis. This clause must not prevent or encumber the dissemination of SBU building information to public safety entities.

c. Dissemination of SBU building information:

(i) By electronic transmission. Electronic transmission of SBU information outside of the

GSA network must use session encryption (or alternatively, file encryption). Encryption must be via an approved NIST algorithm with a valid certification, such as Advanced Encryption

Standard (AES) or Triple Data Encryption Standard (3DES), in accordance with Federal

Information Processing Standards Publication (FIPS PUB) 140-2, Security Requirements for

Cryptographic Modules per GSA policy.

(ii) By nonelectronic form or on portable electronic data storage devices. Portable electronic data storage devices include, but are not limited to CDs, DVDs, and USB drives.

Nonelectronic forms of SBU building information include paper documents, among other formats.

1) By mail. Contractors must utilize only methods of shipping that provide services for monitoring receipt such as track and confirm, proof of delivery, signature confirmation, or return receipt.

2) In person. Contractors must provide SBU building information only to authorized recipients with a need to know such information. Further information on authorized recipients is found in Section 2 of this clause.

d. Record keeping. Contractors must maintain a list of all entities to which SBU is disseminated, in accordance with sections 2 and 3 of this clause. This list must include at a minimum: (1) the name of the State, Federal, or local government entity, utility, or firm to which

SBU has been disseminated; (2) the name of the individual at the entity or firm who is responsible for protecting the SBU building information, with access strictly controlled and limited to those individuals having a legitimate business need to know such information; (3) contact information for the named individual; and (4) a description of the SBU building information provided. Once "as built" drawings are submitted, the contractor must collect all lists maintained in accordance with this clause, including those maintained by any subcontractors and/or suppliers, and submit them to the CO. For Federal buildings, final payment may be withheld until the lists are received.

e. Safeguarding SBU documents. SBU building information (both electronic and paper formats) must be protected, with access strictly controlled and limited to those individuals having a legitimate business need to know such information. GSA contractors and subcontractors must not take SBU building information outside of GSA or their own facilities or network, except as necessary for the performance of that contract. Access to the information must be limited to those with a legitimate business need to know.

http://www.sam.gov/

Pages 15 of 28

f. Destroying SBU building information. When no longer needed, SBU building information must be destroyed so that marked information is rendered unreadable and incapable of being restored, in accordance with guidelines provided for media sanitization within

GSA CIO IT Security 06-32, Media Sanitization Guide and Appendix A of NIST Special

Publication 800-88, Guidelines for Media Sanitization. Alternatively, SBU building information may be returned to the CO.

g. Notice of disposal. The contractor must notify the CO that all SBU building information has been returned or destroyed by the contractor and its subcontractors or suppliers in accordance with paragraphs 4 and 6 of this clause, with the exception of the contractor's record copy. This notice must be submitted to the CO at the completion of the contract to receive final payment. For leases, this notice must be submitted to the CO at the completion of the lease term. The contractor may return the SBU documents to the CO rather than destroying them.

h. Incidents. All improper disclosures of SBU building information must be immediately reported to the CO at <insert address and contact information> . If the contract provides for progress payments, the CO may withhold approval of progress payments until the contractor provides a corrective action plan explaining how the contractor will prevent future improper disclosures of SBU building information. Progress payments may also be withheld for failure to comply with any provision in this clause until the contractor provides a corrective action plan explaining how the contractor will rectify any noncompliance and comply with the clause in the future.

i. Subcontracts. The contractor and subcontractors must insert the substance of this clause in all subcontracts.

111.0. Non-Compliance with Contract Requirements

In the event the Contractor, after receiving written notice from the Contracting Officer of non compliance with any requirement of this Contract, fails to initiate promptly such action as may be appropriate to comply with the specified requirement within a reasonable period of time, the

Contracting Officer shall have the right to order the Contractor to stop any or all work under the

Contract until the Contractor has complied or has initiated such action as may be appropriate to comply within a reasonable period of time. The Contractor will not be entitled to any extension of

Contract time or payment for any costs incurred as a result of being ordered to stop work for such cause.

111.P. Safeguarding Sensitive Data and Information Technology Resources

In accordance with FAR 39.105, this section is included in the contract. This section applies to all users of sensitive data and information technology (IT) resources, including awardees, contractors, subcontractors, lessors, suppliers and manufacturers. The following GSA policies must be followed.

These policies can be found at http://www.gsa.gov/directives.

1. CIO P 2100.1 GSA Information Technology (IT) Security Policy

2. CIO P 2100.28 GSA Wireless Local Area Network (LAN) Security

3. CIO 2100.38 Mandatory Information Technology (IT) Security Training Requirement for

Agency and Contractor Employees with Significant Security Responsibilities

4. CIO 2104.1A GSA Information Technology IT General Rules of Behavior http://www.gsa.gov/directives

Pages 17 of 28

5. CIO 2105.1 B GSA Section 508: Managing Electronic and Information

Technology for Individuals with Disabilities

6. CIO 2106.1 GSA Social Media Policy

7. CIO 2107.1 Implementation of the Online Resource Reservation Software

8. CIO 2160.4 Provisioning of Information Technology (IT) Devices

9. CIO 2162.1 Digital Signatures

10. CIO P 2165.2 GSA Telecommunications Policy

11. CIO P 2180.1 GSA Rules of Behavior for Handling Personally

Identifiable Information (Pll)

12. CIO 2182.2 Mandatory Use of Personal Identity Verification (PIV) Credentials

13. CIO P 1878.2A Conducting Privacy Impact Assessments (PIAs) in GSA

14. CIO IL-13-01 Mobile Devices and Applications

15. CIO IL-14-03 Information Technology (IT) Integration Policy

16. HCO 9297.1 GSA Data Release Policy

17. HCO 9297.28 GSA Information Breach Notification Policy

18. ADM P 9732.1 D Suitability and Personnel Security

The contractor and subcontractors must insert the substance of this section in all subcontracts.

IV. Contract Clauses

IV.A. Clauses Incorporated In Full Text

(1) FAR 52.222-55 Establishing a Minimum Wage for Contractor (Dec 2015)

(a) Definitions. As used in this clause–

“United States” means the 50 states and the District of Columbia.

“Worker” –

(1) Means any person engaged in performing work on, or in connection with, a contract covered by Executive Order 13658, and—

(i) Whose wages under such contract are governed by the Fair Labor Standards Act (29 U.S.C.

chapter 8), the Service Contract Labor Standards statute (41 U.S.C. chapter 67), or the Wage Rate

Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter IV);

(ii) Other than individuals employed in a bona fide executive, administrative, or professional capacity, as those terms are defined in 29 CFR part 541; and

(iii) Regardless of the contractual relationship alleged to exist between the individual and the employer.

(2) Includes workers performing on, or in connection with, the contract whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c).

http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/

Pages 18 of 28

(3) Also includes any person working on, or in connection with, the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor’s

Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship

Agency recognized by the Office of Apprenticeship.

(b) Executive Order Minimum wage rate.

(1) The Contractor shall pay to workers, while performing in the United States, and performing on, or in connection with, this contract, a minimum hourly wage rate of $10.10 per hour beginning January

1, 2015.

(2) The Contractor shall adjust the minimum wage paid, if necessary, beginning January 1, 2016, and annually thereafter, to meet the applicable annual E.O. minimum wage. The Administrator of the

Department of Labor’s Wage and Hour Division (the Administrator) will publish annual determinations in the Federal Register no later than 90 days before the effective date of the new E.O. minimum wage rate. The Administrator will also publish the applicable E.O. minimum wage on www.wdol.gov (or any successor website), and a general notice on all wage determinations issued under the Service

Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, that will provide information on the E.O. minimum wage and how to obtain annual updates. The applicable published E.O. minimum wage is incorporated by reference into this contract.

(3)(i) The Contractor may request a price adjustment only after the effective date of the new annual E.O. minimum wage determination. Prices will be adjusted only for increased labor costs

(including subcontractor labor costs) as a result of an increase in the annual E.O. minimum wage, and for associated labor costs (including those for subcontractors). Associated labor costs shall include increases or decreases that result from changes in social security and unemployment taxes and workers’ compensation insurance, but will not otherwise include any amount for general and administrative costs, overhead, or profit.

(ii) Subcontractors may be entitled to adjustments due to the new minimum wage, pursuant to paragraph (b)(2). Contractors shall consider any subcontractor requests for such price adjustment.

(iii) The Contracting Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (b)(3)(i) of this clause, and will not provide duplicate price adjustments with any price adjustment under clauses implementing the Service Contract Labor

Standards statute or the Wage Rate Requirements (Construction) statute.

(4) The Contractor warrants that the prices in this contract do not include allowance for any contingency to cover increased costs for which adjustment is provided under this clause.

(5) A pay period under this clause may not be longer than semi-monthly, but may be shorter to comply with any…