FY21 AFD Main Unit Transformer Installation Specifications.pdf

AFD Main Unit Transformer Installation 20027 Pend Oreille River, ID W912DW21R0021

PROJECT TABLE OF CONTENTS

DI VI SI ON 01 - GENERAL REQUI REMENTS

01 11 10.00 26 SUMMARY OF WORK

01 12 16.00 27 WORK SEQUENCE

01 14 00 WORK RESTRICTIONS

01 22 00 MEASUREMENT AND PAYMENT

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 82 00 DEMONSTRATION AND TRAINING

DI VI SI ON 02 - EXI STI NG CONDI TI ONS

02 41 00.00 26 DEMOLITION

DI VI SI ON 03 - CONCRETE

03 30 53.00 26 CAST-IN-PLACE CONCRETE

03 60 00.01 26 CONCRETE DEMOLITION, REPAIR OF CONCRETE SURFACES

DI VI SI ON 05 - METALS

05 05 23.16 26 STRUCTURAL STEEL WELDING AND FABRICATION

05 50 04.00 26 METALS: MATERIALS, PRODUCTS, AND MISCELLANEOUS ITEMS

DI VI SI ON 09 - FI NI SHES

09 90 00.01 26 PAINTS AND COATINGS

DI VI SI ON 13 - SPECI AL CONSTRUCTI ON

13 48 00.00 26 SEISMIC RESTRAINT FOR MECHANICAL AND ELECTRICAL EQUIPMENT

DI VI SI ON 26 - ELECTRI CAL

26 05 00.00 26 BASIC ELECTRICAL MATERIALS AND METHODS

26 05 19.00 26 INSULATED WIRE AND CABLE

26 05 26.00 26 GROUNDING AND GROUND TESTING

26 08 01.00 26 SYSTEMS TESTING AND COMMISSIONING

26 28 00.00 26 PANELBOARDS

DI VI SI ON 31 - EARTHWORK

31 00 00.00 26 EARTHWORK

DI VI SI ON 32 - EXTERI OR I MPROVEMENTS

32 11 23.01 26 CRUSHED ROCK SURFACING AND QUENCH ROCK

PROJECT TABLE OF CONTENTS Page 1

DI VI SI ON 33 - UTI LI TI ES

33 00 00.01 26 SWITCHYARD CIVIL STRUCTURES

DI VI SI ON 44 - POLLUTI ON AND WASTE CONTROL EQUI PMENT

44 42 52.00 26 OIL-STORM WATER PROCESSING

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 10.00 26

SUMMARY OF WORK

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section Table of Contents --

SECTION 01 11 10.00 26 Page 1

SECTION 01 11 10.00 26

SUMMARY OF WORK

PART 1 GENERAL

1.1 DESCRIPTION OF WORK

The scope of work for this contract consists of the Contractor furnishing all supervision, engineering, labor, materials, and equipment to perform the following required work in strict accordance with the detailed requirements of this contract:

a. Remove and dispose of three existing three-phase GSU transformers and the associated neutral current transformers and surge arresters.

b. Remove and dispose of three existing panelboards designated 440VAC Power Cabinet, 120VAC panelboard LC14, and 120/240V panelboard LC15.

Provide two new panelboards designated 480VAC Power Cabinet and 120/240V panelboard LC14.

c. Remove and Provide new cables and conductors originating from the 440VAC power cabinet, and the 120VAC cabinet LC14 to the nearest point of termination. Remove cables originating from the 120VAC cabinet LC15 and Provide new cables to existing LC15 loads from new panelboard LC14.

d. Modify 15kV tubular bus to make connection with the new transformer bushings.

e. Install oil containment, quench stone, and new transformer pads for each of the three new GSU transformers. Design of transformer support base, per contract drawings.

f. Make external connections to new GSU transformers.

g. Provide and install new neutral current transformers and surge arresters for each new GSU transformer.

h. Remove three existing nitrogen cabinets and install Government Furnished nitrogen cabinets.

i. Provide, install and commission Dissolved Gas Analyzer.

j. Provide and install new MOD switch operator grounding pad and new switchyard tower lights.

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section --

SECTION 01 11 10.00 26 Page 2

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 12 16.00 27

WORK SEQUENCE

11/24/20

PART 1 GENERAL

1.1 COORDINATION

1.2 SUBMITTALS

1.3 EQUIPMENT REPLACEMENT AND CUTOVER PLAN

1.4 TEMPORARY POWER

1.5 OUTAGES

1.5.1 Generating Unit Outage Requests

1.5.2 Initial Total Plant Outage

1.6 SEQUENCE OF WORK

PART 2 PRODUCTS

2.1 Temporary Power Cables

PART 3 EXECUTION

SECTION 01 12 16.00 27 Page 1

01 12 16.00 27

WORK SEQUENCE

11/24/20

PART 1 GENERAL

The work covered by this section of the specifications consists of work common to more than one section of these TECHNICAL SPECIFICATIONS.

1.1 COORDINATION

The construction sequence is critical in maintaining operability of Albeni Falls Dam's main unit generators, transformers and transmission lines during this work. Equipment and systems outages shall be kept to a minimum and shall be coordinated with the Contracting Officer's Representative (COR). Temporary outages will be required as loads are transferred from existing equipment to new equipment. Proper sequencing of the work shall be required to minimize the duration of these outages.

All loads must be supported by Government approved temporary power sources furnished by the Contractor 24 hours a day, 7 days a week during the affected work.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals having an "I" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00, SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

EQUIPMENT REPLACEMENT AND CUTOVER PLAN; G, HDC

SD-03 Product Data

Temporary Power Cables; I, HDC

1.3 EQUIPMENT REPLACEMENT AND CUTOVER PLAN

Submit at least 90 days prior to the start of equipment installation the proposed step-by-step removal and installation procedure and system cutover schedule. This schedule's format shall match the Contractor's project schedule submissions as required in section 01 32 01.00 28 "PROJECT SCHEDULE." The plan shall include a detailed sequential list of activities, duration of each activity, duration of all outages required, and temporary power plan if required. The plan shall reflect the coordination with the Government's safe clearance procedure (LOCK-OUT/TAG-OUT) for de-energizing equipment. The plan shall be coordinated with the overall project schedule required by SECTION 01 32 01.00 28 PROJECT SCHEDULE. No work will be allowed to commence until the plan is approved. Any revisions to the approved plan shall be submitted for approval.

SECTION 01 12 16.00 27 Page 2

The Contractor shall provide information regarding what temporary power equipment that will be used. The plan shall include a connecting means for existing cabling that utilizes bolt on connections via a termination enclosure.

1.4 TEMPORARY POWER

Contractor must provide Temporary Power to Low Voltage 480V Switchyard Panel loads and Panelboards LC-14 and LC-15 loads. This will require but is not limited to:

1. Temporary 480VAC power panel.

2. Temporary 480-120/240VAC transformer.

3. Temporary 120/240VAC power panel.

Temporary equipment may be set up in the cable tunnel. Additional equipment may require temporary power. The Government will not pay additional compensation for equipment requiring temporary power not specifically listed here. Electric power will be available at project site for work to be performed under these specifications.

1. 480-volt power cabinet feeder cables:

a. Existing feeder cables to the 480V power cabinet to be disconnected and reused for this purpose. Provide continuity of power by disconnecting and reterminating only one of the redundant feeders at a time.

1.5 OUTAGES

1.5.1 Generating Unit Outage Requests

The Government must provide notice to Bonneville Power Administration (BPA) 30 days in advance of any time main generating units are unable to provide power. Due to this requirement, all main generating unit outage requests will require notice to the Contracting Officer 24 work days in advance. Work days are Monday thru Thursday. Notice provided after 1630 will be considered received on the next business day. This requirement does not apply to outages which will not affect the ability to produce power from generating units.

1.5.2 Initial Total Plant Outage

The initial total plant outage to replace all lightning arresters and tower lighting shall be limited to three (3) weeks.

1.6 SEQUENCE OF WORK

This section lists portions of work that must be completed at specific times or in a specific order. It includes the recommended sequence of work to minimize outages and disruptions during the required installations. The sequence of work represents the major elements of work that require additional considerations and is not to be construed as all-inclusive. All ancillary work required for a complete and functional installation as defined by the contract documents and sequence of work shall be the responsibility of the Contractor and shall be incorporated

SECTION 01 12 16.00 27 Page 3 into the proposed "Equipment Replacement and Cutover Plan." The Contractor may propose changes to the sequence of work, for approval, if the changes improve installation schedules, reduce system or equipment outages, or result in improved functional reliability. The Contractor must incorporate these requirements into the work plan and schedule.

a. Replace all lightning arresters and tower lighting during the initial total plant outage. Subsequent work will maintain a sufficient physical separation from the 115kV bus and will not require the 115kV bus to be deenergized.

b. The 480V power panel and LC-14 may be replaced concurrently, or in either order, at the contractor's preference, provided that temporary power is available to all affected loads.

c. LC-15 cannot be removed until both the 480V power panel and LC-14 are replaced.

d. When replacing 480V power panel feeder cables, maintain continuity of power to station service loads to the maximum extent possible by ensuring that one station service bus remains in service at all times.

PART 2 PRODUCTS

2.1 Temporary Power Cables

Temporary power cables must comply with specification 26 05 19.00 26

INSULATED WIRE AND CABLE.

PART 3 EXECUTION

Not used.

SECTION 01 12 16.00 27 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00

WORK RESTRICTIONS

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 WORK AREAS AND ACCESS

1.3.1 Access By Government Personnel

1.3.2 Contractor's Staging Area and Employee Access

1.3.3 Government Roadways

1.3.4 Use of Government Cranes

1.4 VEHICLES

1.4.1 Use of Private Vehicles

1.5 PLANT AND EQUIPMENT LIST

1.6 CONTRACTOR'S EQUIPMENT AND MATERIAL

1.7 TOOLS AND MISCELLANEOUS EQUIPMENT

1.7.1 General

1.7.2 Damage to Tools

1.7.3 Protective Coatings

1.8 DAMAGED EQUIPMENT OR ABNORMAL CONDITIONS

1.9 PROTECTION OF MATERIAL AND WORK

1.10 CARE OF DRAINS

1.11 WORK BY THE GOVERNMENT CONCURRENT WITH CONTRACTOR WORK

1.12 DISPOSAL AND SALVAGE OF ELECTRICAL AND MECHANICAL EQUIPMENT AND

MISCELLANEOUS MATERIALS

1.13 SITE WORKING HOURS

1.13.1 Government Project Personnel Working Hours

1.13.2 Contractor's Working Hours

1.14 SITE INVESTIGATIONS AND CONDITIONS AFFECTING THE WORK

1.15 PAYMENT

1.16 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (ER 415-1-15 31 OCT

89)

1.16.1 Recording daily Adverse Weather

1.17 SUPPLEMENTAL ANTITERRORISM/OPERATIONS SECURITY REQUIREMENTS

1.17.1 AT Level I Training

1.17.2 Access and General Protection/Security Policy and Procedures

1.17.3 iWATCH Training

1.17.4 OPSEC Training

1.17.5 Access to Sensitive/Restricted Areas

1.17.6 E-Verify Pre-Screening

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

SECTION 01 14 00 Page 1

SECTION 01 14 00

WORK RESTRICTIONS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referenced to in the text by basic designation only.

U.S. DEPARTMENT OF TRANSPORTATION (DOT)

AASHTO HS-20-44 American Association of State Highway Transportation Officials

1.2 SUBMITTALS

Submit the following in accordance with SECTION 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

Loading Diagram for Heavy Vehicles; G A minimum of 30 calendar days prior to use.

Plant and Equipment List A minimum of 30 calendar days prior to on-site work and with end-of-month request for payment throughout the life of the contract.

Contractor Working Hours; G Working hours, shifts, and days of the week to be worked, including an estimate of the number of employees working per shift, a minimum of 30 calendar days prior to the start of site work.

1.3 WORK AREAS AND ACCESS

1.3.1 Access By Government Personnel

Clear access shall be maintained for Government personnel and equipment through all work areas.

1.3.2 Contractor's Staging Area and Employee Access

The Albeni Falls dam worksite has limited staging areas. The area off-limits to contractor will be discussed at the preconstruction conference prior to work start. Salespersons or personnel seeking employment will not be permitted inside the powerhouses. Signs may be erected outside the powerhouses containing instructions for personnel seeking the Contractor. The content and location of the signs must be approved. All Contractor site facilities shall be disposed of before final acceptance of all work.

SECTION 01 14 00 Page 2

1.3.3 Government Roadways

Access to the intake decks and tailrace decks by heavy construction vehicles, such as truck cranes, shall be limited. These areas and roadways are load limited to AASHTO HS-20-44 loading. Prior coordination with the COR is required for any vehicles in excess of this capacity, in accordance with a Loading Diagram for Heavy Vehicles. Vehicles in excess of the HS-20-44 AASHTO load shall not cross the gate slots.

1.3.4 Use of Government Cranes

Government will provide operator and riggers to lower equipment and materials into powerhouse. Contractor shall coordinate deliveries and request for crane assistance at least 7 calendar days in advance. No crane support will be available outside normal government work hours/days.

1.4 VEHICLES

1.4.1 Use of Private Vehicles

Private vehicles of the Contractor and their employees shall enter and leave the project as directed. Parking of private vehicles shall be restricted to the areas shown on the drawings unless otherwise designated by the COR.

1.5 PLANT AND EQUIPMENT LIST

An up-to-date Plant and Equipment List shall be submitted with the end-of-the-month request for payment, throughout the life of the contract. The lists shall include rented equipment as well as lease-purchase or sale-leaseback equipment. The list shall indicate dates equipment is assigned to or removed from the project, dates scheduled for repairs and returned for use, and adequate identification or description of each item of equipment including manufacturer's name (abbreviated), model number, manufacturer's serial number, year of manufacture, and Contractor's assigned serial or record number.

1.6 CONTRACTOR'S EQUIPMENT AND MATERIAL

Unless otherwise specifically cited elsewhere in these specifications, the Contractor shall provide cranes, rigging, lifts, operators, and other necessary means to unload, load, and move equipment or materials as required to pursue and complete work.

1.7 TOOLS AND MISCELLANEOUS EQUIPMENT

1.7.1 General

Government tools and equipment in the powerhouse machine shop, i.e., lathes, drill presses, etc., are not available for use. Any other special tools or devices required for the work shall be furnished and shall then be turned over to the Government upon completion of this contract.

Special tools are defined as non-standard or unique tools necessary to perform removal or installation of the components.

1.7.2 Damage to Tools

Any Government or Contractor-furnished special tools, equipment, and

SECTION 01 14 00 Page 3 lifting devices damaged during the performance of this work shall be repaired or replaced.

1.7.3 Protective Coatings

Protective coatings, including Cosmoline grease, shall be removed from applicable items prior to use. Upon completion of the work to be performed under this contract, all protective coatings, including painted surfaces, shall be returned to a satisfactory condition as directed and as suitable for long term storage.

1.8 DAMAGED EQUIPMENT OR ABNORMAL CONDITIONS

The COR shall be informed immediately upon finding any damaged equipment or other abnormal conditions involving additional work in which the Contractor believes he has no responsibility. The failure or abnormality shall not be disturbed until witnessed by the COR. Damage or abnormal conditions not reported as specified above but discovered at a later date, shall be corrected at the Contractor's expense.

1.9 PROTECTION OF MATERIAL AND WORK

Materials, supplies, tools, equipment and Government property (including all tools, equipment, and special devices supplied by the Contractor and to be turned over to the Government at the end of the Contract) shall be protected and preserved in accordance with manufacturer's recommendations. If material, equipment, supplies, and work performed are not adequately protected, such property may be protected by the Government and the cost thereof will be charged to the Contractor or deducted from any payment due.

1.10 CARE OF DRAINS

Existing powerhouse floor drains including the unwatering drains and transformer cell drains shall not be used for disposal of any solid material or any liquids other than clear water. The Contractor shall clean Contractor-obstructed drains. All costs incurred in the cleaning and clearing of plugged drains, shall be borne by the Contractor.

1.11 WORK BY THE GOVERNMENT CONCURRENT WITH CONTRACTOR WORK

The Government will limit interference with the Contractor's work to the maximum reasonable extent and the Government and Contractor shall coordinate as necessary.

1.12 DISPOSAL AND SALVAGE OF ELECTRICAL AND MECHANICAL EQUIPMENT AND

MISCELLANEOUS MATERIALS

Title to all materials and equipment to be disposed of, excepting materials salvaged for the Government, will be vested in the Contractor when beginning disassembly work or when such materials and equipment are designated as scrap. The Government will not be responsible for the condition, loss, or damage to such property after title transfer. The Contractor may retain these items in usable form and take possession of them providing that there is no subsequent cost or inconvenience to the Government. The Government does not guarantee that these items are complete or in working order, and the Contractor shall assume responsibility for any damages caused by their use immediately upon taking possession of them.

SECTION 01 14 00 Page 4

1.13 SITE WORKING HOURS

1.13.1 Government Project Personnel Working Hours

The scheduled working hours of the Project staff are Mondays through Thursdays from 6:30 a.m. until 5:00 p.m. Fridays, Saturdays and Sundays are non-work days. All Project support required by the Contractor shall be scheduled during the Project staff working hours.

1.13.2 Contractor's Working Hours

The Contractor's desired working hours are between 6:30 a.m. and 5:00 p.m., Monday through Thursday. The schedule of Contractor Working Hours, shifts and days of the week shall be coordinated with the COR.

Notification of any proposed changes of the schedule of regular work hours, overtime work hours, and shifts of work crews and personnel at the site shall be coordinated with the COR at least one week in advance of any changes and shall be incorporated in the Contractor Schedule.

1.14 SITE INVESTIGATIONS AND CONDITIONS AFFECTING THE WORK

The Contractor shall take steps reasonably necessary to ascertain the nature and location of the work, the general and local conditions shall be investigated which can affect the work or its cost, including but not limited to the following. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expenses to the Government. The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless the understanding or representation is expressly stated in this contract.

a. Conditions bearing upon transportation, disposal, handling, and storage of materials.

b. The availability of labor, water, electrical power, and roads.

c. Uncertainties of weather, river stages, or similar physical conditions at the site.

d. The conformation and conditions of the ground and equipment and facilities to be replaced and/or rehabilitated.

e. The character of equipment and facilities needed preliminary to and during work performance.

f. The amount of work space, accessibility, lighting, etc.

1.15 PAYMENT

Separate or direct payment will not be made for compliance with this section. All costs thereof are incidental to and included in the contract prices and payment for the various items listed in the price schedule.

SECTION 01 14 00 Page 5

1.16 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (ER 415-1-15 31 OCT 89)

This Paragraph specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSE entitled "Default (Fixed Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The actual adverse weather delays must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

c. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

The following schedule of anticipated adverse weather delays per month is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

ANTICIPATED ADVERSE WEATHER DELAY PER MONTH FOR ALBENI FALLS DAM, ID

WORK DAYS BASED ON A 5-DAY WORK WEEK

|JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC |

| 17 14 13 9 5 4 1 1 4 7 12 15 |

1.16.1 Recording daily Adverse Weather

Upon acknowledgment of the notice to proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC Report, the occurrence of adverse weather and resultant impact to normally scheduled work. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)".

1.17 SUPPLEMENTAL ANTITERRORISM/OPERATIONS SECURITY REQUIREMENTS

The Contractor shall be responsible for compliance with all applicable Antiterrorism/Operations Security Items as outlined below.

1.17.1 AT Level I Training

All contractor employees, to include subcontractor employees, requiring access to Army installations, facilities and controlled access areas shall

SECTION 01 14 00 Page 6 complete AT Level I awareness training within 30 calendar days after contract start date. The contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR within 45 calendar days after completion of training by all employees and subcontractor personnel. AT level I awareness training is available at the following website:

https://atlevel1.dtic.mil/at.

1.17.2 Access and General Protection/Security Policy and Procedures

All contractor and all associated sub-contractors employees shall comply with applicable installation, facility, and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05 / AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative, as NCIC and TSDB are available), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

1.17.3 iWATCH Training

The contractor and all associated sub contractors shall brief all employees on the local iWATCH program (training standards will be provided by the requiring activity Antiterrorism Officer(ATO)). This local developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR.

This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 45 calendar days after contract award.

1.17.4 OPSEC Training

Per AR 530 -1, Operations Security, new contractor employees must complete Level I OPSEC training within 30 calendar days of their reporting for duty. All contractor employees must complete annual OPSEC awareness training.

1.17.5 Access to Sensitive/Restricted Areas

All contract employees, including subcontractor employees who are not in possession of the appropriate security clearance, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

SECTION 01 14 00 Page 7

The contractor will coordinate with the COR and/or the facility security office for access when required.

1.17.6 E-Verify Pre-Screening

The Contractor must pre-screen Candidates using the E-verify Program (http://www.dhs.gov/E -Verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to ensure the correct information is entered into the E -verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award.

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

SECTION 01 14 00 Page 8

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 22 00

MEASUREMENT AND PAYMENT

PART 1 General

1.1 GENERAL INFORMATION

1.2 RETAINAGE OF PAYMENT

1.3 MEASUREMENT

1.3.1 Unit Definitions

1.3.1.1 Job

1.4 MEASUREMENT AND PAYMENT

1.4.1 CLIN 0001 Mobilization And Demobilization

1.4.1.1 Payment

1.4.1.2 Measurement

1.4.2 CLIN 0002 Remove three existing three-phase GSU Transformers.

1.4.2.1 Payment

1.4.2.2 Measurement

1.4.3 CLIN 0003 Install oil containment and Transformer pad.

1.4.3.1 Payment

1.4.3.2 Measurement

1.4.4 CLIN 0004 Make external connections to new GSU Transformers.

1.4.4.1 Payment

1.4.4.2 Measurement

1.4.5 CLIN 0005 Modify Transformer 15kV tubular bus.

1.4.5.1 Payment

1.4.5.2 Measurement

1.4.6 CLIN 0006 Remove existing 440VAC Power Panel and two 120VAC

Panels, associated step-down transformers, and feeder cables.

1.4.6.1 Payment

1.4.6.2 Measurement

1.4.7 CLIN 0007 Furnish new 480VAC Power Panel and one new

single-phase 120/240V Power Panel, step-down transformer, and cables.

1.4.7.1 Payment

1.4.7.2 Measurement

1.4.8 CLIN 0008 Furnish new neutral current transformer, new surge arrester, and Dissolved Gas Analyzer for each new GSU transformer.

1.4.8.1 Payment

1.4.8.2 Measurement

1.4.9 CLIN 0009 Install Government Furnished nitrogen cabinets.

1.4.9.1 Payment

1.4.9.2 Measurement

1.4.10 CLIN 0010 Furnish new MOD switch operator grounding platform and switchyard tower lights.

1.4.10.1 Payment

1.4.10.2 Measurement

1.4.11 CLIN 0011 Provide training For Government personnel

1.4.11.1 Payment

1.4.11.2 Measurement

1.4.12 CLIN 0012 Operations and Maintenance (O&M) Manuals

1.4.12.1 Payment

1.4.12.2 Measurement

1.4.13 CLIN 0013 As-Built Drawings

SECTION 01 22 00 Page 1

1.4.13.1 Payment

1.4.13.2 Measurement

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

SECTION 01 22 00 Page 2

SECTION 01 22 00

MEASUREMENT AND PAYMENT

PART 1 General

1.1 GENERAL INFORMATION

In each instance, the contract price for a CLIN shall constitute full compensation for furnishing all plant, labor, equipment, and materials, and for performing all operations required to complete the work included in the item as herein specified, or as otherwise approved. Movement of GSU transformers into place will be performed by the manufacturing contract.

Coordination of transformer movement with the manufacturing contractor will be required. In the event any work is required by the specifications sections or by the drawings and not specifically mentioned in the measurement and payment paragraphs, separate or direct payment will not be made and all costs thereof are incidental to and included in the contract prices and payments for the CLINs listed in the proposal schedule. The word "provided" shall be understood to mean "furnished and installed" when used in this section or elsewhere in the technical sections.

1.2 RETAINAGE OF PAYMENT

Retainage in the amount of at least 20% of present contract value will be withheld until the final submittals for Final Operation and Maintenance Manuals and Parts Catalogs, Final Approved Versions of Contractor Prepared Drawings and AS-BUILT CONTRACT DRAWINGS AND FIO DRAWINGS have been approved by the Government.

1.3 MEASUREMENT

1.3.1 Unit Definitions

1.3.1.1 Job

CLINs measured as a Job will be measured for payment as a completed job in the locations indicated. This measurement includes all incidental work and materials, such as fittings, fasteners, and electrical materials that are necessary to make a complete installation. Unless the payment CLIN paragraph makes a specific exception of an item, incidental items will not be measured under another CLIN, even though there is another listing for the work or material.

PAYMENT

Payment for all work specified, shown or incidental to complete the work will be made as follows:

1.4 MEASUREMENT AND PAYMENT

1.4.1 CLIN 0001 Mobilization And Demobilization

1.4.1.1 Payment

Payment for Mobilization and Demobilization will be paid for under CLIN

SECTION 01 22 00 Page 3

0001. Price and payment shall constitute full compensation for:

a. Site mobilization of all materials, equipment, and labor required to accomplish the work. Mobilization will be considered complete when the Contractor is ready to commence work. 50 percent of this CLIN 0001 shall be made upon completion of mobilization.

b. Site demobilization will be considered complete when the Contractor has removed all construction equipment, cleaned the area, and restored the work area to "as-found" pre-contract conditions, unless otherwise approved. 50 percent of this CLIN 0001 shall be made upon completion of de-mobilization.

1.4.1.2 Measurement

Unit of Measure: Job.

1.4.2 CLIN 0002 Remove three existing three-phase GSU Transformers.

1.4.2.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: disconnect the external electrical and mechanical connections, drain oil, handle residual oil, and remove and dispose of the existing three phase transformers from the Albeni Falls Project will be paid for under CLIN 0002 "Remove three existing three-phase GSU Transformers." Price and payment shall constitute full compensation for the furnishing of all equipment, material, and labor required to disconnect, remove from the site and dispose of the existing three single phase oil filled transformers and oil at the Albeni Falls Project.

Payment shall constitute full compensation for this item, complete.

1.4.2.2 Measurement

Unit of Measure: Job.

1.4.3 CLIN 0003 Install oil containment and Transformer pad.

1.4.3.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: install new transformer oil containment, quench stone, and transformer pad for each transformer will be paid for under CLIN 0003 "Install oil containment and Transformer pad."

Price and payment shall constitute full compenation for the furnishing of all equipment, material, and labor required to install new transformer oil containment and transformer pad.

Payment shall constitute full compensation for this item, complete.

SECTION 01 22 00 Page 4

1.4.3.2 Measurement

Unit of Measure: Job.

1.4.4 CLIN 0004 Make external connections to new GSU Transformers.

1.4.4.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: install all wire and cable to connect the new transformers to the new and existing equipment from the switchyard to the powerhouse will be paid under CLIN 0004 "Make external connections to new GSU Transformers." Price and payment shall constitute full compensation for installing all cabling from the new transformers to the new and existing equipment to make a complete operational system.

Payment shall constitute full compensation for this item, complete.

1.4.4.2 Measurement

Unit of Measure: Job.

1.4.5 CLIN 0005 Modify Transformer 15kV tubular bus.

1.4.5.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: modify the existing 15kV tubular bus will be paid under CLIN 0005 "Modify Transformer 15kV tubular bus."

Price and payment shall constitute full compensation for the work as required by contract plans and specifications.

Payment shall constitute full compensation for this item, complete.

1.4.5.2 Measurement

Unit of Measure: Job.

1.4.6 CLIN 0006 Remove existing 440VAC Power Panel and two 120VAC Panels, associated step-down transformers, and feeder cables.

1.4.6.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: remove and dispose of the existing 440VAC Power Panel, and the two 120VAC Panels LC14 and LC15, and the associated step-down transformers, and the removal of all feeder cables to the first point of termination. Price and payment shall constitute full compensation for the work as required by contract plans

SECTION 01 22 00 Page 5 and specifications.

Payment shall constitute full compensation for this item, complete.

1.4.6.2 Measurement

Unit of Measure: Job.

1.4.7 CLIN 0007 Furnish new 480VAC Power Panel and one new single-phase 120/240V Power Panel, step-down transformer, and cables.

1.4.7.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: provide and install one new 480VAC Power Panel and one new 120/240V Power Panel, associated step-down transformers, and all feeder cables. Price and payment shall constitute full compensation for the work as required by contract plans and specifications.

Payment shall constitute full compensation for this item, complete.

1.4.7.2 Measurement

Unit of Measure: Job.

1.4.8 CLIN 0008 Furnish new neutral current transformer, new surge arrester, and Dissolved Gas Analyzer for each new GSU transformer.

1.4.8.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: provide and install new neutral current transformer, new surge arrester, and Dissolved Gas Analyzer for each new GSU transformer. Price and payment shall constitute full compensation for the work as required by contract plans and specifications.

Payment shall constitute full compensation for this item, complete.

1.4.8.2 Measurement

Unit of Measure: Job.

1.4.9 CLIN 0009 Install Government Furnished nitrogen cabinets.

1.4.9.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: install nitrogen cabinets provided by the Government. Price and payment shall constitute full

SECTION 01 22 00 Page 6 compensation for the work as required by contract plans and specifications.

Payment shall constitute full compensation for this item, complete.

1.4.9.2 Measurement

Unit of Measure: Job.

1.4.10 CLIN 0010 Furnish new MOD switch operator grounding platform and switchyard tower lights.

1.4.10.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work.

All work includes, but is not limited to: provide and install MOD switch operator grounding platforms and switchyard tower lights. Price and payment shall constitute full compensation for the work as required by contract plans and specifications.

Payment shall constitute full compensation for this item, complete.

1.4.10.2 Measurement

Unit of Measure: Job.

1.4.11 CLIN 0011 Provide training For Government personnel

1.4.11.1 Payment

Price and payment will constitute full compensation for furnishing all plant, labor, materials, equipment, services, supplies, and performing all work to provide training For Government personnel.

Payment shall constitute full compensation for this item, complete.

1.4.11.2 Measurement

Unit of Measure: Job.

1.4.12 CLIN 0012 Operations and Maintenance (O&M) Manuals

1.4.12.1 Payment

Payment will be made at the contract job price for CLIN 0012: All work for O&M Manuals as specified in Section 01 78 23 OPERATIONS AND MAINTENANCE DATA from preparation to final approval. Payment shall constitute full compensation for this item, complete.

1.4.12.2 Measurement

Unit of Measure: Job.

SECTION 01 22 00 Page 7

1.4.13 CLIN 0013 As-Built Drawings

1.4.13.1 Payment

Payment will be made at the contract job price for CLIN 0013: All work for As-Built Drawings as specified in Section 01 78 00 CLOSEOUT SUBMITTALS from preparation to final approval. Payment shall constitute full compensation for this item, complete.

1.4.13.2 Measurement

Unit of Measure: Job.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

SECTION 01 22 00 Page 8

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

08/15

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 VIEW LOCATION MAP

1.4 MINIMUM INSURANCE REQUIREMENTS

1.4.1 REQUIRED INSURANCE IN ACCORDANCE WITH FAR 28.307-2

1.5 FIELD OFFICE OVERHEAD

1.5.1 Field Office Overhead - Per Diem Rate

1.5.2 Field Office Overhead - Percentage Markup

1.6 SUPERVISION

1.6.1 Minimum Communication Requirements

1.6.2 Superintendent Qualifications

1.6.2.1 Duties

1.6.3 Non-Compliance Actions

1.7 PRECONSTRUCTION CONFERENCE

1.8 PARTNERING

1.8.1 Formal Partnering

1.9 CONTRACT DRAWINGS AND SPECIFICATIONS (DOD FAR SUPP 252.236-7001)

1.10 EPA ENERGY STAR

1.11 ELECTRONIC MAIL (E-MAIL) ADDRESS

1.12 PERFORMANCE EVALUATIONS

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 30 00 Page 1

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

08/15

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

View Location Map; G

1.3 VIEW LOCATION MAP

Submit, prior to or with the first digital photograph submittals, a sketch or drawing indicating the required photographic locations. Update as required if the locations are moved.

1.4 MINIMUM INSURANCE REQUIREMENTS

Provide the minimum insurance coverage required by FAR 28.307-2 Liability, during the entire period of performance under this contract. Provide other insurance coverage as required by State law.

1.4.1 REQUIRED INSURANCE IN ACCORDANCE WITH FAR 28.307-2

a. Workers' compensation and employer's liability: Contractors are required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when Contract operations are so commingled with a Contractor's commercial operation that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 shall be required, except in states with exclusive or monopolistic funds that do not permit workers' compensation to be written by private carriers.

b. General Liability:

SECTION 01 30 00 Page 2

1. The Contracting Officer shall require bodily injury liability insurance coverage written on the comprehensive form of policy of at least $500,000 per occurrence.

2. Property damage liability insurance shall be required only in special circumstances as determined by the agency.

c. Automobile liability: The Contracting Officer shall require automobile liability insurance written on the comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the Contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

d. Aircraft public and passenger liability: When aircraft are used in connection with performing the Contract, the Contracting Officer shall require aircraft public and passenger liability insurance. Coverage shall be at least $200,000 per person and $500,000 per occurrence for bodily injury, other than passenger liability, and $200,000 per occurrence for property damage. Coverage for passenger liability bodily injury shall be at least $200,000 multiplied by the number of seats or passengers, whichever is greater.

e. Environmental Liability: If this contract includes the transport, treatment, storage, or disposal of hazardous material waste the following coverage is required.

The Contractor shall ensure the transporter and disposal facility have liability insurance if effect for claims arising out of the death or bodily injury and property damage from hazardous material/waste transport, treatment, storage and disposal, including vehicle liability and legal defense costs in the amount of $1,000,000.00 as evidenced by a certificate of insurance for General, Automobile, and Environmental Liability Coverage. Proof of this insurance shall be provided to the Contracting Officer.

1.5 FIELD OFFICE OVERHEAD

Notice to Offerors: You must declare below the accounting practice that you apply to contracts to calculate field office overhead for all change orders, modifications, and requests for equitable adjustment. Pursuant to Federal Acquisition Regulation (FAR) Parts 31.105(d)(3) and 31.203(d)(1), an accounting practice that varies from modification to modification is not allowable. Select one of the following:

a. If you use Time Distribution Base for Per Diem Rate practice, see Special Contract Requirement "Field Office Overhead - Per Diem Rate".

b. If you use Direct Cost Distribution Base for a Percentage Mark-up practice, see Special Contract Requirement "Field Office Overhead - Percentage Markup".

c. If you choose Other Accounting Practice That is Allowed Under the FAR and That Uses a Single Distribution Base, you must describe the

SECTION 01 30 00 Page 3 accounting practice in sufficient detail below to allow the Contracting Officer to determine what accounting practice is being utilized by your company and that it complies with the criteria for acceptable accounting practices as set out in FAR Parts 31.105(d)(3) and 31.203(d)(1).

1.5.1 Field Office Overhead - Per Diem Rate

The Contracting Officer shall make an equitable adjustment and modify the contract in writing for any change to the contract, issued pursuant to the Changes clause or otherwise, for which the Government is responsible, and which causes either an increase or decrease in the Contractor's costs as to time or performance under the contract. Under such an equitable adjustment, the Contractor's field office overhead shall be an allowable cost, in accordance with the Contractor's accounting practice as identified by the Contractor.

The Contractor shall declare which standard form of accounting practice it applies to field overhead costs: if a contractor indicates that it follows a per diem basis, no overhead percentage markup rate for office overhead costs shall be allowed.

Under such an equitable adjustment, the Contractor shall be reimbursed for field office overhead on a per diem basis when the completion of the contract is extended by reason of the change issued under any clause, except the Default clause, subject to the Contractor substantiating the variable expense by providing a detailed breakdown of its proposed increase or decrease of costs as required by the Contract Clause DFARS 252.236-7000 MODIFICATION OF PROPOSALS - PRICE BREAKDOWN. No payment of field office overhead on a per diem basis shall be allowed for any change when the completion of the contract is not extended by reason of the change.

1.5.2 Field Office Overhead - Percentage Markup

The Contracting Officer shall make an equitable adjustment and modify the contract in writing for any change to the contract, issued pursuant to the Changes clause or otherwise, for which the Government is responsible, and which causes either an increase or decrease in the Contractor's costs as to time or performance under the contract. Under such an equitable adjustment, the Contractor's field office overhead shall be an allowable cost, in accordance with the Contractor's accounting practice as identified by the Contractor.

The Contractor shall declare which standard form of accounting practice it applies to field overhead costs: if a contractor indicates that it follows a percentage basis, no per diem rate for office overhead costs shall be allowed.

Under such an equitable adjustment, payment of office overhead costs shall be allowed for any change on a percentage markup basis regardless of whether the completion of the contract is, or, is not, extended by reason of the change, except for modifications issued pursuant to the Default Clause. The Contractor shall provide a detailed breakdown of its proposed increase or decrease of costs as required by Contract Clause DFARS

252.236-7000 MODIFICATION PROPOSALS - PRICE BREAKDOWN.

SECTION 01 30 00 Page 4

1.6 SUPERVISION

1.6.1 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of contract work. In addition, if a Quality Control (QC) representative is required on the contract, then that individual must also have fluent English communication skills.

1.6.2 Superintendent Qualifications

The project superintendent must have a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent.