RFP 00-1044P2 RPR HVAC System Billeting Facility 1082.doc

Section B - Supplies or Services and Prices

RFP-LJYC 00-1044P2, RPR HVAC System

FFP

RFP-LJYC 00-1044P2, RPR HVAC System, Billeting Facility #1082. The work includes but not limited to the following:

Remove existing HVAC system complete with all accessories and connections. Provide and install new HVAC system complete with all accessories and connections. Provide and install all related auxillary equipment such as flow meter, gauges, fittings, thermometer, pressure gauges, etc. in accordance with the contract terms and conditions and project specifications.

FOB: Destination

NSN: Z299-98-019-A001

SIGNAL CODE: A

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLAUSES INCORPORATED BY REFERENCE

Section F - Deliveries or Performance

DELIVERY INFORMATION

ZEYNEP KIS

39CES/CECEP BLDG 444 UNIT 7065

APO AE 09824

676-6333

FOB: Destination F2G3C2

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 262 calendar days after issuance of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $287.11for the first day and $176.96 each day thereafter until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer's approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer's approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor's expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

(End of clause)

Section H - Special Contract Requirements

SPECIAL CONTRACT REQUIREMENTS

IMPORT MATERIALS APPROVAL

In accordance with the Defense and Economic Cooperation Agreement between the Government of Turkey and the United States of America, materials produced in Turkey shall be used in all construction contracts. If justification is substantiated, import materials may be used after approval is granted by 10th Tanker Base Command, Turkish Air Force (TuAF) and Turkish General Staff (TGS).

Successful offeror will be required to submit com pleted import material lists (IML) to the Contracting Officer upon issuance of Administrative Notice to Proceed (ANTP). Specific instruction will be provided to the contractor during the ANTP phase. Construction Notice to Proceed (CNTP) will be issued within 30 days after receipt of approved IML. Receipt of local TuAF approval may take 1-3 months. TGS approval may take up to 9 months or longer.

If CNTP is not issued within 9 months of the date of submitting IML, the contractor may claim an economic price adjustment covering any increased prices between the end of the trial month and the actual date of issuance of CNTP. Economic price adjustments are not claimable for any price increases within the first 9 months after the contract award.

(End of Special Contract Requirements)

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.225-14 INCONSISTENCY BETWEEN ENGLISH VERSION AND TRANSLATION OF CONTRACT (FEB 2000)

In the event of inconsistency between any terms of this contract and any translation into another language, the English language meaning shall control.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JULY 2000)

(a) The Contractor shall submit one of the following payment protections:

Bank Letter of Guarantee

(b) The amount of the payment protection shall be 15 percent of the contract price not to exceed $100,000.

(c) The submission of the payment protection is required within 10 days prior to CNTP issuance.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

(End of clause)

Addendum to 52.228-13

BANK LETTER OF GUARANTEE

21 APR 07

a. Within ten (10) calendar days after the date of contract/order, the contractor shall furnish the Contracting Officer a Bank Letter of Guarantee for the performance of the work in the amount specified below and conforming to the format of the sample letter provided (Attachment 3). Failure to furnish the Letter of Guarantee may be deemed a breach of contract.

AMOUNT OF CONTRACT

BANK LETTER OF GUARANTEE

Up to $10,000.00

None

$10,000.01 - $25,000.00

25%, not to exceed $5,000.00

$25,000.01 - $100,000.00

20%, not to exceed $15,000.00

$100,000.01 - $500,000.00

15%, not to exceed $50,000.00 over $500,000.00

15%, not to exceed $100,000.00

(a) The Bank Letter of Guarantee will be dated as of the contract/order date or as soon thereafter as possible. The Bank Letter of Guarantee shall state that a guarantee has been issued against the awarded contract/order and that the following conditions are in force:

1. When presented by a representative of the U.S. Government against debts due, redemption cannot be contested.

2. Value of the guarantee is to be cited in U.S. Dollars, or if Turkish Lira it shall include the statement “Value in Turkish Lira will correspond to the current exchange rate to U.S. Dollars in effect at the time of redemption”. And it will be equal at all times to the percentage as stated in the criteria above.

3. The Bank Letter of Guarantee shall also state that the bank agrees and consents that the contract/order may be modified by change order or supplemental agreement without affecting the validity of the Bank Letter of Guarantee. The Notice to Proceed (Construction) will not be issued until the approval and acceptance by the Contracting Officer.

(b) The Bank Letter of Guarantee will continue in effect throughout the performance period, satisfactory completion of requirements and until expiration of any applicable guarantee period or extension thereof. During the period of warranty an amount equal to five (5) percent of the original contract/ order price shall be applicable.

(End of Addendum)

Sample Bank Letter of Guarantee:

DEPARTMENT OF THE AIR FORCE

39TH AIR BASE WING (USAFE)

LETTER OF GUARANTEE

INCIRLIK AB TURKEY

CONTRACTING OFFICER

39 CONS/LGCA

INCIRLIK HAVA USSA

ADANA, TURKEY

LETTER OF GUARANTEE NO:

We are advised that you have concluded a contract with firm Company name, hereinafter called the "contractor," contract reference number Contract number, on Date.

The contract is to Contract Requirements. The total contract price is $Total Contract Value Pursuant to the contract, the contractor must provide security in the amount of 15 % of the total contract price not to exceed $50,000.00, ($Total Contract Value X 15%) for timely and satisfactory performance of the contract. Pursuant to the contract, the contractor is authorized to provide such security in the form of a bank guarantee.

Having premised this, we, the Bank Bank Name of City, Country do, hereby covenant to pay to you the sum of $ Dollar Value of Guarantee immediately upon receipt of a written demand by your contracting officer, in which you confirm that the contractor has failed to meet his obligations under the above reference contract. The sum of the guarantee will be paid by check made payable to the Treasurer of the United States within 15 days from receipt of the written demand by the contracting officer. If payment is made after this date, it shall) include 8 1/8% percent interest starting the 16th day after receipt of this written demand. This letter of guarantee will continue in effect until the contract work has been finally accepted by the US Government and will continue thereafter in an amount equal to (5%) of the original contract price, until all applicable guarantees, or extension thereof under the contract have expired. At that time, this document will be given back to us.

We understand that the contract may be modified by change order or supplemental agreement affecting the contract price and/or performance time and we consent to such modifications. If the contract price is thereby increased by at least $15,000, we agree to provide an additional letter of guarantee in the amount 15 percent of the increased contract amount.

This is a Guarantee. Our obligation as the guarantor is independent of the existence and extent of the Contractor's obligation. The rights and obligations arising out of this guarantee are subject of the laws of Turkey.

(Name and address of Guarantor)

Signed by:_________________________

Seal or stamp of Guarantor

(Name typed underneath signature)

Typed Title:________________________

By:______________________________

(Name typed underneath signature)

CLAUSES INCORPORATED BY FULL TEXT

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 60 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by . . . . . . . . . N/A

(b) Weather conditions . . . . . . . . . N/A

(c) Transportation facilities . . . . . . . . . N/A

(d) . . . . . . . . . . Drawings last revised and site inspected January 2011.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

CLAUSES INCORPORATED BY FULL TEXT

252.225-7044 BALANCE OF PAYMENTS PROGRAM--CONSTRUCTION MATERIAL (DEC 2010)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item--

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition of ``commercial item'' in section 2.101 of the Federal Acquisition Regulation);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. 40102), such as agricultural products and petroleum products.

“Component” means any article, material, or supply incorporated directly into construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means--

(1) An unmanufactured construction material mined or produced in the United States; or

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

``United States'' means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. This clause implements the Balance of Payments Program by providing a preference for domestic construction material. The Contractor shall use only domestic construction material in performing this contract, except for—

(1) Construction material valued at or below the simplified acquisition threshold in part 2 of the Federal Acquisition Regulation;

(2) Information technology that is a commercial item; or

(3) The construction material or components listed by the Government as follows:

None.

(End of clause)

252.229-7001 TAX RELIEF (JUN 1997)

(a) Prices set forth in this contract are exclusive of all taxes and duties from which the United States Government is exempt by virtue of tax agreements between the United States Government and the Contractor's government. The following taxes or duties have been excluded from the contract price:

NAME OF TAX: Valued Added Tax RATE (PERCENTAGE): Not Applicable

(b) The Contractor's invoice shall list separately the gross price, amount of tax deducted, and net price charged.

(c) When items manufactured to United States Government specifications are being acquired, the Contractor shall identify the materials or components intended to be imported in order to ensure that relief from import duties is obtained. If the Contractor intends to use imported products from inventories on hand, the price of which includes a factor for import duties, the Contractor shall ensure the United States Government's exemption from these taxes. The Contractor may obtain a refund of the import duties from its government or request the duty-free import of an amount of supplies or components corresponding to that used from inventory for this contract.

(End of clause)

Addendum to 252.229-7001

INSTRUCTIONS TO FOREIGN VENDORS

NOTE 1: Authorization to Foreign Vendors

The contract warrants that it has been duly authorized to operate and do business in the country or countries in which this contract is to be performed, and that it has obtained, at no cost to the United States Government, all necessary licenses and permits required in connections with this contract, and that it will fully comply with all laws, decrees, labor standards and regulations of this country or countries during the performance of this contract.

NOTE 2: Law Governing Contracts

In any dispute arising out of this contract, the decision of which requires consideration of questions of law, the rights and obligations of the parties shall be interpreted in accordance with the substantive laws of the United States of America.

NOTE 3: Invoices

All invoice amounts shall be reflected in US Dollars or payment may be delayed.

VAT-EXEMPT PURCHASE

I certify that this purchase (delivery of goods or service) is made for the purpose of common defense and in accordance with the Tax Relief Agreement between Turkey and The United States of America, which was ratified by Law Number 6426 of June 1954. This purchase is exempt from Value Added Tax according to the Council of Ministers of the Republic of Turkey decision number 92/2958 or 22 April 1992, published in the Official Gazette dated 21 May 1992, number 21234.

KDV’DEN MUAF SATINALMA

Isbu satinalmanin (mal teslimi veya hizmet); Turkiye ile Amerika Birlesik Devletleri arasinda imzalanmis bulunan ve 30 Haziran 1954 tarihli ve 6426 sayili kanunla onaylanmis Vergi Muafiyetleri Anlasmasina uygun olarak ve ortak savunma amaciyla yapildigini onaylariz. Isbu satinalma: 21 Mayis 1992 tarih ve 21234 sayili Resmi Gazetede yayinlanmis olan 22 Nisan 1992 tarih ve 1992/2958 sayili Bakanlar Kurulu Kararina gore katma deger vergisinden mustesnadir.

NOTE TO TURKISH VENDORS:

It is recommended contractors attach their VAT exempt form when submitting their invoices to Defense Finance Accounting System (DFAS) in Wide Area WorkFlow (WWAF) and/or handcarry to 39 CONS for certification. For the Turkish Government to accept it, a duly appointed Contracting Officer must first certify the VAT exempt form.

(End of Addendum)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

See Section J, Attachments 1, 2 and 3 (End of clause)

5352.201-9101 Ombudsman. OMBUDSMAN (APR 2010)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, concerned parties may contact the Center/MAJCOM ombudsmen:

Primary:

Ms Tara Petersen

HQ USAFE/A7K, UNIT 3050, Box 10, APO AE 09094-0110

HQ USAFE/A7K, Flugplatz Ramstein, 66877 Ramstein Germany

E-mail: tara.petersen@ramstein.af.mil

Tel: 0049-637-147-2209, Fax: (49)-6731-47-2025

Alternate:

Heidi Hoehn

HQ USAFE/A7K, UNIT 3050, Box 10, APO AE 09094-0110

HQ USAFE/A7K, Flugplatz Ramstein, 66877 Ramstein Germany

E-mail: heidi.hoehn@ramstein.af.mil

Tel: 0049-637-147-9330, Fax: (49)-6731-47-2025

Concerns, issues, disagreements, and recommendations that cannot be resolved at the MAJCOM/DRU level, may be brought by the concerned party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (703) 588-7004, facsimile number (703) 588-1067.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

(End of clause)

5352.223-9000 Elimination of Use of Class I Ozone Depleting Substances (ODS).

ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODSs) (APR 2003)

(a) Unless the requiring activity has obtained prior Senior Acquisition Official (SAO) approval, contractors may not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

(c) The requiring activity has obtained SAO approval to permit the contractor to use the following Class I ODS(s):

Class I ODS/ Application or Use/Quantity (lbs.) per contract period of performance

None

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

(End of clause)

5352.242-9000 Contractor access to Air Force installations.

CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (JUN 2002)

(a) The contractor shall obtain base identification and vehicle passes for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, and valid vehicle insurance certificate to obtain a vehicle pass.

(c) Our office will certify applications for gate passes for Turkish pass and ID. The Turkish Air Force will coordinate with contractors to attain the necessary documents and information to grant access to the installation. The U.S. government will not be held liable for any delays or breach of contract caused by refusal of the Turkish Air Force to grant a gate pass to a contractor. If a gate pass is not granted to a contractor allowing the delivery of goods, execution of warranty support, or performance of services please contact the contracting officer immediately. Below is a number to the Turkish Air Force Pass and ID for all gate pass issues: 322-316-4184 or 322-316-4186

(d) Performance of this contract is located on a Turkish Air Force installation, and all access to the installation is controlled and granted by the Turkish Air Force (TAF) Security Battalion.

(e) Prior to commencing work the Contractor shall furnish a complete list of all vehicles and personnel involved in the accomplishment of the contract work to the Turkish Air Force Pass and ID or designated representative to ensure access to the respective installations. The following information must be furnished on this list:

Vehicles: Make, model, year of manufacture, capacity, type, license number, and insurance policy number. Personnel: First and last name, date of birth, place of birth, passport or identification card number, place of residence and any such other information, as required, to satisfy individual air base or army security regulations governing access to granting of passes to the particular military establishment.

(f) All passes may be obtained from the Turkish Air Force Pass and ID or designated representative approximately 10 days after the aforementioned lists have been submitted. The contractor shall inform all assigned workers that they may be subject to search, at the discretion of the installation commander, when entering or leaving the installation.

(g) Installation passes will be returned immediately to the Issuing Officer when:

(1) Pass has expired.

(2) Pass holder is no longer employed by the Contractor.

(3) Contract is completed.

(4) Issuing Officer so directs.

(h) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(i) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel Security Program Management, as applicable.

(j) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(k) Failure to comply with these requirements may result in withholding of final payment.

(End of clause) Addendum to 5352.242-9000

OPERATIONS SECURITY

24 JAN07

In the performance of contract terms and conditions, contractors performing work on Incirlik Air Base may witness or hear of activities which provide them insight into present or future military activities. Each contractor is responsible to ensure its employees and/or subcontractors understand this type of information shall not be discussed and/or spread to any other sources. Infractions on the part of any contractor (or its employees or subcontractor[s]) may result in: 1) Immediate removal of the employee/subcontractor[s] from base, 2) A less than satisfactory past performance record for the project, and/or 3) Debarment actions.

(End of Addendum)

Section J - List of Documents, Exhibits and Other Attachments

ATTACHMENTS EXHIBIT/ATTACHMENT

Section J - List of Documents, Exhibits and Other Attachments

ATTACHMENTS

EXHIBIT/ATTACHMENTS

Attachments 1-4 will be provided to each offeror on a CD-ROM prior to or at a time of the scheduled Pre-Proposal Conference/Site Visit.

Section K - Representations, Certifications and Other Statements of Offerors

CLAUSES INCORPORATED BY REFERENCE

52.203-2 CERTIFICATE OF INDEPENDENT PRICE DETERMINATION (APR 1985)

(a) The offeror certifies that --

(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to –

(i) Those prices,

(ii) The intention to submit an offer, or

(iii) The methods of factors used to calculate the prices offered:

(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and

(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.

(b) Each signature on the offer is considered to be a certification by the signatory that the signatory --

(1) Is the person in the offeror's organization responsible for determining the prices offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision; or

(2) (i) Has been authorized, in writing, to act as agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provison ______________________________________________________ (insert full name of person(s) in the offeror's organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror's organization);

(ii) As an authorized agent, does certify that the principals named in subdivision (b)(2)(i) above have not participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) above; and

(iii) As an agent, has not personally participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision.

(c) If the offeror deletes or modifies subparagraph (a)(2) of this provision, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

(End of clause)

52.204-3 TAXPAYER IDENTIFICATION (OCT 1998)

(a) Definitions.

Common parent, as used in this provision, means that corporate entity that owns or controls an affiliated group of corporations that files its Federal income tax returns on a consolidated basis, and of which the offeror is a member.

Taxpayer Identification Number (TIN), as used in this provision, means the number required by the Internal Revenue Service (IRS) to be used by the offeror in reporting income tax and other returns. The TIN may be either a Social Security Number or an Employer Identification Number.

(b) All offerors must submit the information required in paragraphs (d) through (f) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the IRS. If the resulting contract is subject to the payment reporting requirements described in Federal Acquisition Regulation (FAR) 4.904, the failure or refusal by the offeror to furnish the information may result in a 31 percent reduction of payments otherwise due under the contract.

(c) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN.

(d) Taxpayer Identification Number (TIN).

___ TIN:.--------------------------------------------------------

___ TIN has been applied for.

___ TIN is not required because:

___ Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;

___ Offeror is an agency or instrumentality of a foreign government;

___ Offeror is an agency or instrumentality of the Federal Government.

(e) Type of organization.

___ Sole proprietorship;

___ Partnership;

___ Corporate entity (not tax-exempt);

___ Corporate entity (tax-exempt);

___ Government entity (Federal, State, or local);

___ Foreign government;

___ International organization per 26 CFR 1.6049-4;

___ Other--------------------------------------------------------

(f) Common parent.

___ Offeror is not owned or controlled by a common parent as defined in paragraph (a) of this provision.

___ Name and TIN of common parent:

Name-------------------------------------------------------------------

TIN--------------------------------------------------------------------

(End of provision)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2010)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238220.

(2) The small business size standard is N/A.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the clause at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the clause at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

(__) Paragraph (d) applies.

(__) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in ORCA are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the clause at 52.204-7, Central Contractor Registration.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business).This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vi) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(vii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(viii) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(ix) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(x) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xi) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xiv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xv) 52.225-2, Buy American Act Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvi) 52.225-4, Buy American Act--Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternate I, and Alternate II) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $67,826, the provision with its Alternate II applies.

(xvii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xviii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xix) 52.225-25, Prohibition on Engaging in Sanctioned Activities Relating to Iran--Certification. This provision applies to all solicitations.

(xx) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to--

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(Contracting Officer check as appropriate.)

----(i) 52.219-19, Small Business Concern Representation for the Small Business Competitiveness Demonstration Program.

------(ii) 52.219-21, Small Business Size Representation for Targeted Industry…