Solicitation_FA462617R0005.pdf

DESCRIPTION OF WORK: This w ork w ill be performed at one or more Missile Alert Facilities (MAFs). Work consists of upgrading electrical components and grounding systems in the Water Pump Houses, Small and Large Garages. The contractor shall provide all plant, labor, equipment, supervision, services, and materials to execute and satisfy the requirements of this Contract. NO w ork shall occur during a one

(1) w eek period at facilities located w ithin a Code Change Squadron.

SPECIAL AWARD PROVISION: This acquisition is being set-aside for 100 percent small bsiness.

The NAICS code for this project is 238210 w ith a small business size standard of $15,000,000.00.

The magnitude of this project is betw een $1,000,000 and $5,000,000.

NOTICE TO OFFERORS: Funds are not presently available for this contract. The government's obligation under this contract is contingent upon the availability of appropriated funds from w hich payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until the funds are made available to the Contracting Officer.

TAMARA R. WYATT 406-731-3855

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

12-Apr-2017

(RFP)

(IFB)

X

CALL:

Upgrade Electrical Components

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________360 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________3 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________11 May 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______180 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

FA4626 341ST CONTRACTING SQUADRON

7015 GODDARD DRIVE BLDG 145

MALMSTROM AFB MT 59402-6863

FA4626

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

NZAS 16-6001

8. ADDRESS OFFER TO (If Other Than Item 7)

406-731-3748FAX:TEL: TEL: FAX:

FA462617R0005 49

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA462617R0005

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot Update Electrical Components at MAFs

FFP

This CLIN is the total of Sub-CLINS 000101-000104. The prices provided for Sub-CLINS 000101 thru 000104 will be the prices paid for any sites, mobilization, materials, labor and equipment.

FOB: Destination

PROJECT: NZAS 16-6001

SIGNAL CODE: A

NET AMT

000101 Mobilization

FFP

All costs related to general contract requirements, administration, and overhead shall be merged and included in the contract costs for "Mobilization”. The cost of all insurance, permits, safety, fees and licenses, shop drawings and samples, general administration, movement of equipment, tools, and other incidental work required for occupying the site and performing the work shall be merged and included in the contract price for “Mobilization”. The Government will exercise every effort to keep the mobilization from one site to the next to a minimum distance. The Government will only pay for one mobilization per site. One site shall be completed before moving to the next. The maximum number of sites that may be accomplished is 15.

SIGNAL CODE: a

000102 MAF Electrical Update

FFP

All costs for work, materials, and equipment necessary for electrical updates at 15 MAFs, including but not limited to, electrical demolition, new power, wiring devices, branch circuiting, conduits, services, feeders, electric heating, equipment connections, controls, surge protection, panelboards, disconnects and circuit breakers for the Pump Houses, Small and Large Garages shall be included in the contract costs for “MAF Electrical Update”.

000103 MAF Pump House Grounding

FFP

Includes all work, materials, and equipment necessary to provide a new grounding system for the existing water piping and equipment in 15 MAF Pump Houses.

000104 MAF Lighting Update

FFP

Includes all work, materials, and equipment necessary to replace existing lighting at 15 MAFs with new energy efficient LED lighting in the Pump Houses, Large and Small Garages.

0002 5 Each Pump House Feeder Conduit

FFP

All costs for materials, work and equipment necessary to provide new conduits for Pump House feeders, Maintenance Receptacles and Security Lighting, including but not limited to, conduits, conductors, grounding, trenching and backfill for the Pump Houses shall be included in the contract costs for “New Conduit for Pump House Feeder”. Cost for Pump House Feeder Conduit, shall be paid as Each (EA).

FOB: Destination

0003 1 Each Performance and Payment Bonds

FFP

Purchase and maintenance of all required bonds including but not limited to Performance and Payment Bonds, and all other bonds required for completion of the work. Cost for Performance and Payment Bonds, shall be paid as Each (EA).

Payment for Bonds will be paid by the government for the actual costs of bonds as identified on the submitted bonds. At no time shall payment exceed the actual costs of bonds.

FOB: Destination

0004 120 Hours Government Delays

FFP

Should the Contracting Officer determine that the Contractor incurred a work stoppage or could not begin work as scheduled, and that the stoppage or delay was caused by the Government, the Contractor will be paid for delays which result in verifiable lost progress. Any unused money left in this CLIN will be deobligated and returned to the funding source at the end of the contract. Cost shall include crew, labor, and equipment time lost during normal work hours and shall not include evenings, Saturdays, Sundays, Winter Exclusion, or Federal Holidays.

Government Delays shall be paid by the Crew-Hour (Cr-Hr).

FOB: Destination

Section C - Descriptions and Specifications

DESCRIPTIONS & SPECIFICATIONS

Furnish all labor, materials, supervision, quality control, testing, equipment and transportation necessary to perform the work required by the drawings and specifications applicable to Malmstrom AFB, Project Number NZAS: 16- 6001 dated January 2017 and that are identified as attachments to this solicitation in Section J hereof.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 000101 N/A N/A N/A N/A 000102 N/A N/A N/A N/A 000103 N/A N/A N/A N/A 000104 N/A N/A N/A N/A 0002 Destination Government Destination Government 0003 Destination Government Destination Government 0004 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 360 dys. ANP 1 F2W3D3 341CES/CEMS-MISSILE

COMPLEX

KEN MURPHY

39 78 ST N BLDG 470

MALMSTROM AFB MT 59402

406-731-6865 FOB: Destination

F2W3D3

000101 N/A N/A N/A N/A

000102 N/A N/A N/A N/A

000103 N/A N/A N/A N/A

000104 N/A N/A N/A N/A

0002 360 dys. ANP 5 F2W3D3 341CES/CEMS-MISSILE

COMPLEX

KEN MURPHY

39 78 ST N BLDG 470

MALMSTROM AFB MT 59402

406-731-6865

0003 360 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0004 360 dys. ANP 120 (SAME AS PREVIOUS LOCATION)

52.211-18 Variation in Estimated Quantity APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 360 days after receiving the notice to proceed, not to include the winter exclusion period from 1 Nov-1April. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $842.30 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Section G - Contract Administration Data

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS

(JUNE 2012)

(a) Definitions. As used in this clause–

(1) Contract financing payment and invoice payment have the meanings given in section 32.001 of the Federal Acquisition Regulation.

(2) Electronic form means any automated system that transmits information electronically from the initiating system to all affected systems. Facsimile, e-mail, and scanned documents are not acceptable electronic forms for submission of payment requests. However, scanned documents are acceptable when they are part of a submission of a payment request made using Wide Area WorkFlow (WAWF) or another electronic form authorized by the Contracting Officer.

(3) Payment request means any request for contract financing payment or invoice payment submitted by the Contractor under this contract.

(4) Receiving report means the data required by the clause at 252.246-7000, Material Inspection and Receiving Report.

(b) Except as provided in paragraph (c) of this clause, the Contractor shall submit payment requests and receiving reports using WAWF, in one of the following electronic formats that WAWF accepts: Electronic Data Interchange, Secure File Transfer Protocol, or World Wide Web input. Information regarding WAWF is available on the Internet at https://wawf.eb.mil/.

(c) The Contractor may submit a payment request and receiving report using other than WAWF only when–

(1) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor. In such cases, the Contractor shall include a copy of the Contracting Officer's determination with each request for payment;

(2) DoD makes payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoD-approved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System);

(3) DoD makes payment for rendered health care services using the TRICARE Encounter Data System (TEDS) as the electronic format; or

(4) When the Governmentwide commercial purchase card is used as the method of payment, only submission of the receiving report in electronic form is required.

(d) The Contractor shall submit any non-electronic payment requests using the method or methods specified in Section G of the contract.

(e) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payments requests.

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

2 in 1 Stand Alone

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

Destination

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F87700 Issue By DoDAAC FA4626 Admin DoDAAC FA4626 Inspect By DoDAAC F2W3D3 Service Acceptor (DoDAAC) FA4626

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

tamara.wyatt.2@us.af.mil mark.jefferson.1@us.af.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

WAWF Help Desk

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

Section I - Contract Clauses

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-21 Basic Safeguarding of Covered Contractor Information

Systems

JUN 2016

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.215-2 Audit and Records--Negotiation OCT 2010 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--

Modifications

AUG 2011

52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting NOV 2011 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-60 Paycheck Transparency (Executive Order 13673) OCT 2016 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-3 Alt I Hazardous Material Identification and Material Safety Data

(Jan 1997) - Alternate I

JUL 1985

52.223-5 Alt I Pollution Prevention and Right-to-Know Information (May 2011) Alternate I

MAY 2011

52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.223-22 Public Disclosure of Greenhouse Gas Emissions and Reduction Goals -- Representation.

DEC 2016

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts MAY 2014 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.237-5 Payment by Contractor to Government APR 1984 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.243-5 Changes and Changed Conditions APR 1984 52.244-5 Competition In Subcontracting DEC 1996 52.244-6 Subcontracts for Commercial Items JAN 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.215-7000 Pricing Adjustments DEC 2012 252.223-7001 Hazard Warning Labels DEC 1991 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.225-7012 Preference For Certain Domestic Commodities DEC 2016 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

SEP 2004

252.227-7003 Termination AUG 1984 252.227-7033 Rights in Shop Drawings APR 1966

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7006 Cost Limitation JAN 1997 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to Mark Jefferson at 731-4014 or email mark.jefferson.1@us.af.mil.

52.223-11 OZONE-DEPLETING SUBSTANCES AND HIGH GLOBAL WARMING POTENTIAL

HYDROFLUOROCARBONS (JUN 2016)

Global warming potential means how much a given mass of a chemical contributes to global warming over a given time period compared to the same mass of carbon dioxide. Carbon dioxide's global warming potential is defined as 1.0.

High global warming potential hydrofluorocarbons means any hydrofluorocarbons in a particular end use for which EPA's Significant New Alternatives Policy (SNAP) program has identified other acceptable alternatives that have lower global warming potential. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables of alternatives available at (http://www.epa.gov/snap/).

Hydrofluorocarbons means compounds that only contain hydrogen, fluorine, and carbon.

Ozone-depleting substance means any substance the Environmental Protection Agency designates in 40 CFR part 82 as--

(1) Class I, including, but not limited to, chlorofluorocarbons, halons, carbon tetrachloride, and methyl chloroform;

or

(2) Class II, including, but not limited to, hydrochlorofluorocarbons.

(b) The Contractor shall label products that contain or are manufactured with ozone-depleting substances in the manner and to the extent required by 42 U.S.C. 7671j (b), (c), (d), and (e) and 40 CFR part 82, subpart E, as follows:

Warning: Contains (or manufactured with, if applicable) *_______, a substance(s) which harm(s) public health and environment by destroying ozone in the upper atmosphere.

* The Contractor shall insert the name of the substance(s).

(c) Reporting. For equipment and appliances that normally each contain 50 or more pounds of hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons, the Contractor shall--

(1) Track on an annual basis, between October 1 and September 30, the amount in pounds of hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons contained in the equipment and appliances delivered to the Government under this contract by--

(i) Type of hydrofluorocarbon (e.g., HFC-134a, HFC-125, R-410A, R-404A, etc.);

(ii) Contract number; and

(iii) Equipment/appliance;

(2) Report that information to the Contracting Officer for FY16 and to www.sam.gov, for FY17 and after--

(i) Annually by November 30 of each year during contract performance; and

(ii) At the end of contract performance.

(d) The Contractor shall refer to EPA's SNAP program (available at http://www.epa.gov/snap) to identify alternatives. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables available at http://www.epa.gov/snap.

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1 Foreign construction material.... ........... ___ ........ ....... ………. ___ ................ ........ ___ Domestic construction material... ........ ___ ............... .............. ___ .................. ...... ___ Item 2 Foreign construction material.... ......... ___ ............. ........ ……. ___ ............... ......... ___ Domestic construction material... ....... ___ .................. ............. ___ ................. ....... ___ Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

52.228-5 INSURANCE--WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

(a) The Contractor shall, at its own expense, provide and maintain during the entire performance of this contract, at least the kinds and minimum amounts of insurance required in the Schedule or elsewhere in the contract.

(b) Before commencing work under this contract, the Contractor shall notify the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective (1) for such period as the laws of the State in which this contract is to be performed prescribe, or (2) until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule or elsewhere in the contract. The Contractor shall maintain a copy of all subcontractors' proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil http://www.acq.osd.mil.dpap/dars.dfars/index.htm

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any DoD FAR Supplement (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

SCHEDULE OF DRAWINGS

PLATE DESCRIPTION

G-1 COVER SHEET

G-2 MINUTEMAN MISSILE COMPLEX SITE PLAN

E-1 MAF SUPPORT BUILDING ELECTRICAL PLANS

E-2 ELECTRICAL DETAILS

E-3 ELECTRICAL DETAILS

E-4 PUMPHOUSE WATER SYSTEM DETAILS AND DIAGRAMS

E-5 ELECTRICAL DETAILS

E-6 ELECTRICAL DETAILS

E-7 PANEL SCHEDULES A01, B01 AND C01

E-8 PANEL SCHEDULES D01, E01, AND F01

E-9 PANEL SCHEDULES G01, H01 AND I01

E-10 PANEL SCHEDULES J01, K01 AND L01

E-11 PANEL SCHEDULES M01, N01 AND O01

EA-1 ALPHA 01 SITE ELECTRICAL PLAN

EA-2 ALPHA 01 PUMPHOUSE ELECTRICAL PLANS

EB-1 BRAVO 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EB-2 BRAVO 01 PUMPHOUSE ELECTRICAL PLANS

EC-1 CHARLIE 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EC-2 CHARLIE 01 PUMPHOUSE ELECTRICAL PLANS

ED-1 DELTA 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

ED-2 DELTA 01 PUMPHOUSE ELECTRICAL PLANS

EE-1 ECHO 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EE-2 ECHO 01 PUMPHOUSE ELECTRICAL PLANS

EF-1 FOXTROT SITE AND LARGE GARAGE ELECTRICAL PLANS

EF-2 FOXTROT PUMPHOUSE ELECTRICAL PLANS

EG-1 GOLF 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EG-2 GOLF 01 PUMPHOUSE ELECTRICAL PLANS

EH-1 HOTEL 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EH-2 HOTEL 01 PUMPHOUSE ELECTRICAL PLANS

EI-1 INDIA 01 SITE ELECTRICAL PLAN

EI-2 INDIA 01 PUMPHOUSE ELECTRICAL PLANS

EJ-1 JULIET 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EJ-2 JULIET 01 PUMPHOUSE ELECTRICAL PLANS

EK-1 KILO 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EK-2 KILO 01 PUMPHOUSE ELECTRICAL PLANS

EL-1 LIMA 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EL-2 LIMA 01 PUMPHOUSE ELECTRICAL PLANS

EM-1 MIKE 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EM-2 MIKE 01 PUMPHOUSE ELECTRICAL PLANS

EN-1 NOVEMBER 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EN-2 NOVEMBER 01 PUMPHOUSE ELECTRICAL PLANS

EO-1 OSCAR 01 SITE AND LARGE GARAGE ELECTRICAL PLANS

EO-2 OSCAR 01 PUMPHOUSE ELECTRICAL PLANS

AFFARS 5352.201-9101 OMBUDSMAN (Apr 2014)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the Center/MAJCOM ombudsman, HQ AF Global Strike Command/AFICA/KG, 841 Fairchild Ave, Building 5541, Rm 327, Barksdale AFB, LA 71110. Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/AFISRA ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (AUG 2007)

(a) The contractor shall obtain base identification and vehicle passes for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, and valid vehicle insurance certificate, in order to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel Security Program Management, as applicable.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are…