Solicitation Amendment - FA460025B00030004.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section A - Solicitation/Contract Form Quarters 16 Generator Installation Offutt AFB, NE

NAICS: 236220

Size Standard: USD 45,000,000.00 Annual receipts

Small Business Type: Small Business Set Aside Percent: 100

Product Service Code: N059

FA460025B00030004

Section B - Supplies or Services & Prices or Costs Additional Information/Notes

Item Supplies / Services Quantity Unit Unit Price Amount

Provide all labor, transportation, tools, equipment, permits, supervision necessary to install generator at Quarters 16 in accordance with the attached DRAWINGS and SPECIFICATIONS.

Product Service Code: N059 Pricing Arrangement: Firm Fixed Price

1 Each

Section C - Description/Specifications/Statement of Work

Requirements The contractor shall provide all labor, equipment, materials, and transport needed for the installation of a new natural gas generator w/ enclosure at Quarters 16, Offutt AFB. The project is 100% designed and all construction shall meet or exceed all requirements per the attached drawings and specifications.

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.246-12 Inspection of Construction. Aug 1996 Overall Contract Inspection/Acceptance Locations

Inspection and Acceptance Location

Both Destination Instructions: Acceptance and Inspection will be conducted in accordance with contract terms and conditions.

DoDAAC: F3HSH2 CountryCode: USA

F3HSH2 USSTRATCOM J4

AF NO MILSBILLS PROC CP 4029124004, 900 SAC BLVD BLDG 1000 S1 152

OFFUTT AFB, NE 68113-5455

UNITED STATES

Thomas Smeed Email: thomas.a.smeed.civ@mail.mil Telephone: 4029124291

Section F - Deliveries or Performance Overall Contract Delivery Period

Line Item Delivery Schedule Quantity Address and POC

Delivery On Or Before Delivery Date 01 Jun 2026

1 Each Place of Performance DoDAAC: F3HSH2 CountryCode: USA

F3HSH2 USSTRATCOM J4

AF NO MILSBILLS PROC CP 4029124004, 900 SAC BLVD BLDG 1000 S1 152

OFFUTT AFB, NE 68113-5455

UNITED STATES

Thomas Smeed Email: thomas.a.smeed.civ@us.af.mil Telephone: 4029124291

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.247-34 F.o.b. Destination. Jan 1991

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.231-7000 Supplemental Cost Principles Dec 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018 252.236-7000 Modification Proposals--Price Breakdown. Dec 1991

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. (Jan 2023)

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) Definitions. As used in this clause-

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall-

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

Construction

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F3HSH2 Issue By DoDAAC FA4600 Admin DoDAAC FA4600 Inspect By DoDAAC F3HSH2 Ship To Code ____ Ship From Code ____ Mark For Code ____ Service Approver (DoDAAC) FA4600 Service Acceptor (DoDAAC) FA4600 Accept at Other DoDAAC ____ LPO DoDAAC ____ DCAA Auditor DoDAAC ____ Other DoDAAC(s) ____ (*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

blaine.terry.2@us.af.mil

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Section H - Special Contract Requirements

Section I - Contract Clauses 52.222-9 Apprentices and Trainees (July 2005)

(a) Apprentices. (1) An apprentice will be permitted to work at less than the predetermined rate for the work performed when employed-

(i) Pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment and Training Administration, Office of Apprenticeship Training, Employer, and Labor Services (OATELS) or with a State Apprenticeship Agency recognized by the OATELS; or

(ii) In the first 90 days of probationary employment as an apprentice in such an apprenticeship program, even though not individually registered in the program, if certified by the OATELS or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice.

(2) The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the Contractor as to the entire work force under the registered program.

(3) Any worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise employed as stated in paragraph (a)(1) of this clause, shall be paid not less than the applicable wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed.

(4) Where a Contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman's hourly rate) specified in the Contractor's or subcontractor's registered program shall be observed. Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice's level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination.

(5) Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination.

(6) In the event OATELS, or a State Apprenticeship Agency recognized by OATELS, withdraws approval of an apprenticeship program, the Contractor will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved.

(b) Trainees. (1) Except as provided in 29 CFR 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training Administration, Office of Apprenticeship Training, Employer, and Labor Services (OATELS). The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by OATELS.

(2) Every trainee must be paid at not less than the rate specified in the approved program for the trainee's level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed in the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate in the wage determination which provides for less than full fringe benefits for apprentices. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the OATELS shall be paid not less than the applicable wage rate in the wage determination for the classification of work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate in the wage determination for the work actually performed.

(3) In the event OATELS withdraws approval of a training program, the Contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved.

(c) Equal employment opportunity. The utilization of apprentices, trainees, and journeymen under this clause shall be in conformity with the equal employment opportunity requirements of Executive Order 11246, as amended, and 29 CFR Part 30.

(End of clause)

52.228-13 Alternative Payment Protections (July 2000)

(a) The Contractor submit one of the following payment protections if the resultant contract price is greater than shall $35,000, but not greater than $150,000:

Payment bond or irrevocable letter of credit (ILC)

(a)(1) If the resultant contract price is greater than $150,000, see 52.228-15.

(b) The amount of the payment protection be 100 percent of the contract price. shall

(c) The submission of the payment protection is required within days of contract award. 10

(d) The payment protection provide protection for the full contract performance period plus a one-year period. shall

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the is authorized to access funds under the payment protection when it has been alleged by Contracting Officer in writing a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor utilize only suppliers of labor and material that shall signed the escrow agreement.

(End of clause)

52.249-10 Default (Fixed-Price Construction) (Apr 1984)

(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government , by written notice to the Contractor, terminate the right to proceed with the work (or the may separable part of the work) that has been delayed. In this event, the Government take over the work and may complete it by contract or otherwise, and take possession of and use any materials, appliances, and plant on may the work site necessary for completing the work. The Contractor and its be liable for any damage to the sureties shall Government resulting from the Contractor's refusal or failure to complete the work within the specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the- work.

(b) The Contractor's right to proceed not be terminated nor the Contractor charged with damages under this shall clause, if-

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include-

(i) Acts of God or of the public enemy,

(ii) Acts of the Government in either its sovereign or contractual capacity,

(iii) Acts of another Contractor in the performance of a contract with the Government,

(iv) Fires,

(v) Floods,

(vi) Epidemics,

(vii) Quarantine restrictions,

(viii) Strikes,

(ix) Freight embargoes,

(x) Unusually severe weather, or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the ), Contracting Officer notifies the of the causes of delay. The ascertain the facts and Contracting Officer in writing Contracting Officer shall the extent of delay. If, in the judgment of the , the findings of fact warrant such action, the time for Contracting Officer completing the work be extended. The findings of the be final and conclusive on the shall Contracting Officer shall parties, but subject to appeal under the Disputes clause.

(c) If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

(d) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.

(End of clause)

5352.223-9000 Elimination of Use of Class I Ozone Depleting Substances (ODS) (JUN 2024)

(a) Contractors shall not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS as part of this contract/order.

(b) For the purposes of Department of the Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Department of the Air Force definition of a Class I ODS.]

(End of clause)

5352.242-9000 Contractor Access to Department of the Air Force Installations (JUN 2024)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Department of the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or Security Forces for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver's license, current vehicle registration, valid vehicle insurance certificate, and [ insert any additional requirements to comply with local security procedures ] to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with [insert any additional requirements to comply with AFI 31-101 , Integrated Defense, and DODMAN5200.02_AFMAN 16-1405 , Air Force Personnel Security Program ] citing the appropriate paragraphs as applicable.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) The contractor shall provide an after-hours contact number or after-hours email in the Emergency Mass Notification System (EMNS) for each of their personnel, whose normal place of duty is on a DoD installation or within a DoD facility. The contractor shall comply with any additional requirements in DAFMAN 10-206 for emergency operational reporting. Foreign Nationals may participate and may remove themselves from the Emergency Mass Notification System at any time. To update information, personnel can access the globe icon on their system desktop screens and choose the "Access Self-Service" option.

(g) Failure to comply with these requirements may result in withholding of final payment.

(End of clause)

252.225-7013 Duty-Free Entry (NOV 2023)

(a) Definitions. As used in this clause--

"Component," means any item supplied to the Government as part of an end product or of another component.

"Customs territory of the United States" means the 50 States, the District of Columbia, and Puerto Rico.

"Eligible product" means--

(1) "Designated country end product," as defined in the Trade Agreements (either basic or alternate) clause of this contract;

(2) Free Trade Agreement country end product, other than a Bahraini end product, a Moroccan end product, a Panamanian end product, or a Peruvian end product, as defined in the Buy American--Free Trade Agreements--Balance of Payments Program (either basic or alternate II) clause of this contract; or

(3) Free Trade Agreement country end product other than a Bahraini end product, Korean end product, Moroccan end product, Panamanian end product, or Peruvian end product, as defined in the Buy American--Free Trade Agreements--Balance of Payments Program (either alternate IV or alternate V) clause of this contract.

"Qualifying country" and "qualifying country end product" have the meanings given in the Trade Agreements clause, the Buy American and Balance of Payments Program clause, or the Buy American--Free Trade Agreements--Balance of Payments Program clause of this contract, basic or alternate.

(b) Except as provided in paragraph (i) of this clause, or unless supplies were imported into the customs territory of the United States before the date of this contract or the applicable subcontract, the price of this contract shall not include any amount for duty on--

(1) End items that are eligible products or qualifying country end products;

(2) Components (including, without limitation, raw materials and intermediate assemblies) produced or made in qualifying countries, that are to be incorporated in U.S.- made end products to be delivered under this contract; or

(3) Other supplies for which the Contractor estimates that duty will exceed $300 per shipment into the customs territory of the United States.

(c) The Contractor shall--

(1) Claim duty-free entry only for supplies that the Contractor intends to deliver to the Government under this contract, either as end items or components of end items; and

(2) Pay duty on supplies, or any portion thereof, that are diverted to nongovernmental use, other than--

(i) Scrap or salvage; or

(ii) Competitive sale made, directed, or authorized by the Contracting Officer.

(d) Except as the Contractor may otherwise agree, the Government will execute duty-free entry certificates and will afford such assistance as appropriate to obtain the duty-free entry of supplies--

(1) For which no duty is included in the contract price in accordance with paragraph (b) of this clause; and

(2) For which shipping documents bear the notation specified in paragraph (e) of this clause.

(e) For foreign supplies for which the Government will issue duty-free entry certificates in accordance with this clause, shipping documents submitted to Customs shall--

(1) Consign the shipments to the appropriate--

(i) Military department in care of the Contractor, including the Contractor's delivery address; or

(ii) Military installation; and

(2) Include the following information:

(i) Prime contract number and, if applicable, delivery order number.

(ii) Number of the subcontract for foreign supplies, if applicable.

(iii) Identification of the carrier.

(iv)(A) For direct shipments to a U.S. military installation, the notation: "UNITED STATES GOVERNMENT, DEPARTMENT OF DEFENSE Duty-Free Entry to be claimed pursuant to Section XXII, Chapter 98, Subchapter VIII, Item 9808.00.30 of the Harmonized Tariff Schedule of the United States. Upon arrival of shipment at the appropriate port of entry, District Director of Customs, please release shipment under 19 CFR Part 142 and notify Commander, Defense Contract Management Agency (DCMA), St. Louis, MO, ATTN: Duty Free Entry Team, 1222 Spruce Street, Room 9.300, St. Louis, MO 63103-2812, for execution of Customs Form 7501, 7501A, or 7506 and any required duty-free entry certificates."

(B) If the shipment will be consigned to other than a military installation, e.g., a domestic contractor's plant, the shipping document notation shall be altered to include the name and address of the contractor, agent, or broker who will notify Commander, DCMA New York, for execution of the duty-free entry certificate. (If the shipment will be consigned to a contractor's plant and no duty-free entry certificate is required due to a trade agreement, the Contractor shall claim duty-free entry under the applicable trade agreement and shall comply with the U.S. Customs Service requirements. No notification to Commander, DCMA New York, is required.)

(v) Gross weight in pounds (if freight is based on space tonnage, state cubic feet in addition to gross shipping weight).

(vi) Estimated value in U.S. dollars.

(vii) Activity address number of the contract administration office administering the prime contract, e.g., for DCMA Dayton, S3605A.

(f) Preparation of customs forms.

(1)(i) Except for shipments consigned to a military installation, the Contractor shall--

(A) Prepare any customs forms required for the entry of foreign supplies into the customs territory of the United States in connection with this contract; and

(B) Submit the completed customs forms to the District Director of Customs, with a copy to DCMA NY for execution of any required duty-free entry certificates.

(ii) Shipments consigned directly to a military installation will be released in accordance with sections 10.101 and 10.102 of the U.S. Customs regulations.

(2) For shipments containing both supplies that are to be accorded duty-free entry and supplies that are not, the Contractor shall identify on the customs forms those items that are eligible for duty-free entry.

(g) The Contractor shall--

(1) Prepare (if the Contractor is a foreign supplier), or shall instruct the foreign supplier to prepare, a sufficient number of copies of the bill of lading (or other shipping document) so that at least two of the copies accompanying the shipment will be available for use by the District Director of Customs at the port of entry;

(2) Consign the shipment as specified in paragraph (e) of this clause; and

(3) Mark on the exterior of all packages--

(i) "UNITED STATES GOVERNMENT, DEPARTMENT OF DEFENSE"; and

(ii) The activity address number of the contract administration office administering the prime contract.

(h) The Contractor shall notify the Administrative Contracting Officer (ACO) in writing of any purchase of eligible products or qualifying country supplies to be accorded duty-free entry, that are to be imported into the customs territory of the United States for delivery to the Government or for incorporation in end items to be delivered to the Government. The Contractor shall furnish the notice to the ACO immediately upon award to the supplier and shall include in the notice--

(1) The Contractor's name, address, and Commercial and Government Entity (CAGE) code;

(2) Prime contract number and, if applicable, delivery order number;

(3) Total dollar value of the prime contract or delivery order;

(4) Date of the last scheduled delivery under the prime contract or delivery order;

(5) Foreign supplier's name and address;

(6) Number of the subcontract for foreign supplies;

(7) Total dollar value of the subcontract for foreign supplies;

(8) Date of the last scheduled delivery under the subcontract for foreign supplies;

(9) List of items purchased;

(10) An agreement that the Contractor will pay duty on supplies, or any portion thereof, that are diverted to nongovernmental use other than--

(i) Scrap or salvage; or

(ii) Competitive sale made, directed, or authorized by the Contracting Officer;

(11) Country of origin; and

(12) Scheduled delivery date(s).

(i) This clause does not apply to purchases of eligible products or qualifying country supplies in connection with this contract if--

(1) The supplies are identical in nature to supplies purchased by the Contractor or any subcontractor in connection with its commercial business; and

(2) It is not economical or feasible to account for such supplies so as to ensure that the amount of the supplies for which duty-free entry is claimed does not exceed the amount purchased in connection with this contract.

(j) The Contractor shall--

(1) Insert the substance of this clause, including this paragraph (j), in all subcontracts for--

(i) Qualifying country components; or

(ii) Nonqualifying country components for which the Contractor estimates that duty will exceed $200 per unit;

(2) Require subcontractors to include the number of this contract on all shipping documents submitted to Customs for supplies for which duty-free entry is claimed pursuant to this clause; and

(3) Include in applicable subcontracts--

(i) The name and address of the ACO for this contract;

(ii) The name, address, and activity address number of the contract administration office specified in this contract; and

(iii) The information required by paragraphs (h)(1), (2), and (3) of this clause.

(End of clause)

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.202-1 Definitions. Jun 2020 52.203-3 Gratuities. Apr 1984 52.203-5 Covenant Against Contingent Fees. May 2014 52.203-6 Restrictions on Subcontractor Sales to the Government. Jun 2020 52.203-7 Anti-Kickback Procedures. Jun 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. May 2014 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. May 2014 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. Jun 2020 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. Jan 2017 52.204-2 Security Requirements. (Alternate II) Mar 2021 Alternate II Apr 1984 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. Jun 2020 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014 52.204-21 Basic Safeguarding of Covered Contractor Information Systems. Nov 2021

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities.

Dec 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.204-27 Prohibition on a ByteDance Covered Application. Jun 2023

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

Jan 2025

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. Oct 2018 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.211-13 Time Extensions. Sep 2000 52.214-26 Audit and Records-Sealed Bidding. Jun 2020 52.214-29 Order of Precedence-Sealed Bidding. Jan 1986 52.215-15 Pension Adjustments and Asset Reversions. Oct 2010 52.215-17 Waiver of Facilities Capital Cost of Money. Oct 1997 52.219-6 Notice of Total Small Business Set-Aside. Nov 2020 52.219-8 Utilization of Small Business Concerns. Jan 2025 52.219-33 Nonmanufacturer Rule. Sep 2021 52.222-3 Convict Labor. Jun 2003 52.222-4 Contract Work Hours and Safety Standards -Overtime Compensation. May 2018 52.222-6 Construction Wage Rate Requirements. Aug 2018 52.222-7 Withholding of Funds. May 2014 52.222-8 Payrolls and Basic Records. Jul 2021 52.222-9 Apprentices and Trainees. (DEVIATION 2025-O0003) Jul 2005 Deviation 2025-O0003 Mar 2025 52.222-10 Compliance with Copeland Act Requirements. Feb 1988 52.222-11 Subcontracts (Labor Standards). May 2014 52.222-12 Contract Termination-Debarment. May 2014 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations. May 2014 52.222-14 Disputes Concerning Labor Standards. Feb 1988 52.222-15 Certification of Eligibility. May 2014 52.222-35 Equal Opportunity for Veterans. Jun 2020 52.222-36 Equal Opportunity for Workers with Disabilities. Jun 2020 52.222-37 Employment Reports on Veterans. Jun 2020 52.222-40 Notification of Employee Rights Under the National Labor Relations Act. Dec 2010 52.222-50 Combating Trafficking in Persons. Nov 2021 52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. Jan 2022 52.222-62 Paid Sick Leave Under Executive Order 13706. Jan 2022 52.223-5 Pollution Prevention and Right-to-Know Information. May 2024 52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners. May 2024 52.223-21 Foams. May 2024 52.223-23 Sustainable Products and Services. (DEVIATION 2025-O0004) May 2024 Deviation 2025-O0004 Mar 2025 52.225-13 Restrictions on Certain Foreign Purchases. Feb 2021 52.226-7 Drug-Free Workplace. May 2024 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving. May 2024 52.227-1 Authorization and Consent. Jun 2020 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement. Jun 2020 52.227-4 Patent Indemnity-Construction Contracts. Dec 2007 52.228-2 Additional Bond Security. Oct 1997 52.228-5 Insurance-Work on a Government Installation. Jan 1997 52.228-11 Individual Surety-Pledge of Assets. Feb 2021 52.228-12 Prospective Subcontractor Requests for Bonds. Dec 2022 52.228-14 Irrevocable Letter of Credit. Nov 2014 52.228-15 Performance and Payment Bonds-Construction. Jun 2020 52.229-3 Federal, State, and Local Taxes. Feb 2013 52.229-12 Tax on Certain Foreign Procurements. Feb 2021 52.232-8 Discounts for Prompt Payment. Feb 2002

52.232-17 Interest. May 2014 52.232-23 Assignment of Claims. May 2014 52.232-27 Prompt Payment for Construction Contracts. Jan 2017 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. Oct 2018 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Mar 2023 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.233-4 Applicable Law for Breach of Contract Claim. Oct 2004 52.236-2 Differing Site Conditions. Apr 1984 52.236-3 Site Investigation and Conditions Affecting the Work. Apr 1984 52.236-5 Material and Workmanship. Apr 1984 52.236-6 Superintendence by the Contractor. Apr 1984 52.236-7 Permits and Responsibilities. Nov 1991 52.236-8 Other Contracts. Apr 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. Apr 1984 52.236-10 Operations and Storage Areas. Apr 1984 52.236-11 Use and Possession Prior to Completion. Apr 1984 52.236-12 Cleaning Up. Apr 1984 52.236-13 Accident Prevention. Nov 1991 52.236-14 Availability and Use of Utility Services. Apr 1984 52.236-17 Layout of Work. Apr 1984 52.236-21 Specifications and Drawings for Construction. Feb 1997 52.236-26 Preconstruction Conference. Feb 1995

52.240-1 Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities.

Nov 2024

52.242-13 Bankruptcy. Jul 1995 52.242-14 Suspension of Work. Apr 1984 52.243-4 Changes. Jun 2007 52.243-5 Changes and Changed Conditions. Apr 1984 52.244-6 Subcontracts for Commercial Products and Commercial Services. Jan 2025 52.246-21 Warranty of Construction. Mar 1994 52.247-5 Familiarization with Conditions. Apr 1984 52.247-12 Supervision, Labor, or Materials. Apr 1984 52.249-2 Termination for Convenience of the Government (Fixed-Price). (Alternate I) Apr 2012 Alternate I Sep 1996

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011 252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies. Jan 2023 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Dec 2022 252.204-7000 Disclosure of Information. Oct 2016 252.204-7003 Control of Government Personnel Work Product. Apr 1992

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. (DEVIATION

2024-O0013 REVISION 1)

May 2024 Deviation 2024-O0013 May 2024

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2023

252.204-7020 NIST SP 800-171 DoD Assessment Requirements. Nov 2023 252.205-7000 Provision of Information to Cooperative Agreement Holders. Oct 2024

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

May 2019

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements. Jan 2023 252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials. Sep 2014 252.223-7008 Prohibition of Hexavalent Chromium. Jan 2023 252.225-7048 Export-Controlled Items. Jun 2013 252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. Jan 2023 252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region. Jun 2023

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns.

Jan 2023

252.232-7010 Levies on Contract Payments. Dec 2006 252.236-7005 Airfield Safety Precautions. Dec 1991 252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. Jan 2023 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.243-7002 Requests for Equitable Adjustment. Dec 2022 252.244-7000 Subcontracts for Commercial Products or Commercial Services. Nov 2023 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military Operations. Oct 2010 252.246-7008 Sources of Electronic Parts. Jan 2023 252.247-7023 Transportation of Supplies by Sea. Oct 2024

FAR Clauses Incorporated by Full Text

52.211-10 Commencement, Prosecution, and Completion of Work. (Alternate I) (Apr 1984) Alternate I (Apr 1984)

Alternate I . If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a (Apr 1984) certain day, add the following paragraph to the basic clause:

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by . The completion date will be 01 October 2025 extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

52.219-14 Limitations on Subcontracting (DEVIATION 2021-O0008) (Oct 2022) Deviation 2021-O0008 (Feb 2023)

LIMITATIONS ON SUBCONTRACTING (FEB 2023) (DEVIATION 2021-O0008)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that--

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to--

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with subparts 19.8, 19.13, 19.14, and 19.15;

(4) Orders expected to exceed the simplified acquisition threshold and that are--

(i) Set aside for small business concerns under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii);

(5) Orders, regardless of dollar value, that are--

(i) Set aside in accordance with subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to concerns that qualify for the programs described in subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 19.504(c)(1)(ii); and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a North American Industry Classification System (NAICS) code for--

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding certain other direct costs and certain work performed outside the United States (see paragraph (e)(1)(i)), to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract. The following services may be excluded from the 50 percent limitation:

(i) Other direct costs, to the extent they are not the principal purpose of the acquisition and small business concerns do not provide the service. Examples include airline travel, work performed by a transportation or disposal entity under a contract assigned the environmental remediation NAICS code 562910), cloud computing services, or mass media purchases.

(ii) Work performed outside the United States on awards made pursuant to the Foreign Assistance Act of 1961, or work performed outside the United States required to be performed by a local contractor.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause--

[Contracting Officer check as appropriate.]

[ ] By the end of the base term of the contract and then by the end of each subsequent option period; or

[X] By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (e) of this clause will be performed by the aggregate of the joint venture participants.

(1) In a joint venture comprised of a small business protégé and its mentor…