FA4528-20-R-0003 Amendment 2.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

The Purpose of This Amendment Is: A) Update Clause 52.211-12 "Liquidated Damages-- Construction" to $211.16 for the first day and $167.53 for every calendar day thereafter.

B) Update Clause 52.233-2 "Service of Protest" to Mr. Wade Vinje at 165 Missile Ave, Minot AFB ND 58704.

C) Update Clause 52.222-23 "Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction" to 4.4% for Minority Participation goal for each trade and 6.9% for Female Participation goal for each trade at Minot AFB, Ward County, ND.

D) Add Attachment 8 - Questions & Answers document.

E) Add Attachment 9 - Drawing Amendment Item List #1.

F) Remove FAR Clause 52.236-1.

G) Extend offer due date from 13 January 2020 to 16 January 2020, 2:00PM CST.

Section H - Special Contract Requirements

Additional Information/Notes

The following clauses were deleted:

FAR Clauses Incorporated by Full Text

52.236-1 - Performance of Work by the Contractor. Apr 1984

As prescribed in 36.501(b), insert the following clause: [Complete the clause by inserting the appropriate percentage consistent with the complexity and magnitude of the work and customary or necessary specialty subcontracting (see 36.501 (a)).]

Performance of Work by the Contractor (Apr 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least ____ [insert the appropriate number in words followed by numerals in parentheses] percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

Section I - Contract Clauses

Additional Information/Notes

The following clauses were modified:

52.211-12 - Liquidated Damages-Construction. Sep 2000 hereby reads as follows:

As prescribed in 11.503(b), insert the following clause in solicitations and contracts:

Liquidated Damages-Construction (Sept 2000)

FA452820R00030002

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $211.16 for the first day and $167.53 for each calendar day thereafter of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

Section J - List of Attachments

Miscellaneous text in this section has been modified to:

Attachment 1 - Bldg 975 Specifications

Attachment 2 - Bldg 975 Drawings

Attachment 3 - DBA Wage Determination

Attachment 4 - Past Performance Questionnaire

Attachment 5 - Financial Institution Reference Sheet

Attachment 6 - Section L - Instructions to Offerors

Attachment 7 - Section M - Evaluation Criteria

Attachment 8 - Questions and Answers

Attachment 9 - Drawing Amendment Item List #1

Section K - Representations, Certification, & Other Statements

The following clauses were modified:

52.222-23 - Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. Feb 1999 hereby reads as follows:

As prescribed in 22.810(b), insert the following provision:

Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (Feb 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

| Goals for Minority Participation for EachTrade || Goals for Female Participation for EachTrade |

| __4.4%__ || __6.9%__ |

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1)its implementation of the Equal Opportunity clause, (2)specific affirmative action obligations required by the clause entitled Affirmative Action Compliance Requirements for Construction, and (3)its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order11246, as amended, and the regulations in 41 CFR 60-4.

Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the-

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the covered area is Minot AFB, Ward County, ND.

(End of provision)

Section L - Instructions, Conditions, & Notices to Offerors or Quoters

The following clauses were modified:

52.233-2 - Service of Protest. Sep 2006 hereby reads as follows:

As prescribed in 33.106 , insert the following provision:

Service of Protest (Sept 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Mr. Wade Vinje, 165 Missile Ave, Minot AFB, ND. (b) The copy of any protest shall be received in the office designated above within oneday of filing a protest with the GAO.

(End of provision)

165 MISSILE AVE

CP 701 723 2889

MINOT AFB, ND 58705

United States Bryan Smith, Email: bryan.smith.75@us.af.mil Telephone: 723-3055

SEE CONTINUATION PAGE

Email: wade.vinje@us.af.mil Telephone: 453-4184