Contractor Insurance Certification.pdf
PDF 1 MB Posted
- Attached to
- Repair Vehicle Barrier Controls
- Solicitation number
- EEPZ232987
About this file
This document is a Contractor Insurance Certification, which outlines the insurance requirements for a federal contract. The key details are:
The contractor must maintain the insurance types and amounts specified in FAR 28.307-2 for the full duration of the contract, including any modifications or time extensions. The required insurance policies must contain an endorsement stating that any cancellation or material changes will not be effective for the period prescribed by the laws of the state where the contract is performed, or for 30 calendar days after written notice to the Contracting Officer, whichever is longer. The contractor must maintain Workers' Compensation Insurance for the full contract period, and must provide copies of all subcontractors' insurance proofs upon request.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| Solicitation Amendment FA302224R00080002 SF 30.pdf | ||
| Vehicle Barrier _SOW_REVISED 06 Aug 2024.pdf | ||
| 02-RFI_FA302224R0008.pdf | ||
| Solicitation Amendment FA302224R00080001 SF 30.pdf | ||
| Delta HPU Nameplate.pdf | ||
| RFI 02_FA302224R0008.pdf | ||
| RFI 01_FA302224R0008.pdf | ||
| Appendix A - Cost Breakdown.xlsx | XLSX spreadsheet | |
| Solicitation - FA302224R0008.pdf | ||
| AF Form 66_11Apr24.xlsx | XLSX spreadsheet | |
| Contractors CUI Training Slides.pptx | PPTX presentation | |
| SOW_Vehicle Barrier _18Apr24.pdf | ||
| MFR Contractor CUI Training Acknowledgment for Solicitations.pdf | ||
| Wage Determination DBA MS20240045.pdf |
Show all 14
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Please wait...
If this message is not eventually replaced by the proper contents of the document, your PDF viewer may not be able to display this type of document.
You can upgrade to the latest version of Adobe Reader for Windows®, Mac, or Linux® by visiting http://www.adobe.com/go/reader_download.
For more assistance with Adobe Reader visit http://www.adobe.com/go/acrreader.
Windows is either a registered trademark or a trademark of Microsoft Corporation in the United States and/or other countries. Mac is a trademark of Apple Inc., registered in the United States and other countries. Linux is the registered trademark of Linus Torvalds in the U.S. and other countries.
Notification of Compliance with Contract Insurance Requirements Page of The undersigned Contractor hereby acknowledges that he/she has read and understands the insurance requirements specified in this contract and hereby provides notification (1) that such insurance shall be maintained in at least the amounts and types as stated in FAR 28.307-2 and during any modifications and/or time extensions granted thereto; (2) that the required insurance policies shall contain an endorsement to the effect that any cancellation of material changes adversely affecting the Government's interest shall not be effective for such period as the laws of the State in which this contract is to be performed prescribe, or until thirty (30) calendar days after the insurer or contractor gives written notice to the Contracting Officer, whichever period is longer; (3) that Workers' Compensation Insurance, or letter of reciprocal agreement with another state, shall be maintained on this contract for and during the entire performance period and for any modifications and/or time extensions granted thereto; and (4) that a copy of all subcontractors' proofs of required insurance shall be maintained and shall be made available to the Contracting Officer upon request. This agreement shall be a part of subject contract and shall be legally binding and enforceable at law.
Insurance Company Information Name:
Address:
Policy Number:
Telephone Number:
E-mail Address:
Contractor Information Name:
Address:
Telephone Number:
E-mail Address:
Authorized Signature 9.0.0.2.20120627.2.874785
| CurrentPage: |
| PageCount: |
| TextField1: |
| State: AL |
| CoName: |
| CoAddress: |
| CoPolicyNumber: |
| CoPhoneNumber: |
| CoEmail: |
| Remove-Ins-Company: |
| Add an item: |
| TextField2: |
| Date: |
| Name: |
| Signature: |
File details come from the government source that posted it. Updated .