CDRLs B001-B008 NGATS Spares.pdf
PDF 2 MB Posted
- Attached to
- Next Generation Automatic Test System (NGATS) Spare Parts Federal contract opportunity
- Solicitation number
- W15QKN-22-R-0029
About this file
This document contains eight Contract Data Requirements Lists (CDRLs) related to a contract for spare parts to support the Next Generation Automatic Test Systems (NGATS).
The CDRLs require the following data submissions: a monthly status report; meeting minutes from post-award meetings; an acceptance test plan and test and evaluation master plan due 60 days after award; government property and furnished equipment inventory reports due 30 days after award and as updates occur; mandatory training certifications for antiterrorism, insider threat, and operations security training due 45-90 days after award and annually; an operations security plan due 90 days after award and updated as needed; and delivery delay reports for late shipments due within 5 days of a delayed deadline and for subsequent delays. The CDRLs identify the requiring offices, distribution statements, submission frequencies, and other submission details. Submissions must be provided electronically to the contracting officer's representative.
This federal contract opportunity is a small business set-aside issued by the U.S. Army Contracting Command - New Jersey to provide NGATS spare parts. Proposals are due by March 15, 2022.
View the file
Other files for this federal contract opportunity
Show all 19
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
DD FORM 1423-1, FEB 2001
CONTRACT DATA REQUIREMENTS LIST
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/MGMT DATA
Acquisition of NGATS Parts/Modules
B001 Status Report
DI-MGMT-80368A SOW Paras 4.4.1, 4.8.2 FCDD-ACW-NT
LT
N/A D
N/A
N/A
30 DAC
MONTHLY
FCDD-ACW-NT 1
ACC-NJ 1
0 2 0
Block 4: CONTRACTOR FORMAT ACCEPTABLE.
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE (DOD) AND UNITED STATES (U.S.) DOD
CONTRACTORS ONLY FOR ADMINISTRATIVE AND OPERATIONAL USE.
OTHER REQUESTS SHALL BE REFERRED TO CONTRACTING OFFICER
REPRESENTATIVE (COR), BLDG 91, FCDD-ACW-NT, PICATINNY ARSENAL, NJ
07806-5000, 973-724-7330.
Block 12 - First submission due thirty (30) calendar days after contract award (DAC).
Status Report shall include all items detailed in SOW paragraphs 4.4.1 and 4.8.2.
Block 14: Electronic copies shall be provided to the COR, FCDD-ACW-NT. Refer to contract for email address.
ACC-NJ - Refer to contract for email address.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2019.11.12 13:36:19 -05'00'
12 Nov 19 CUCCARO.JOSEPH.A.12288 46151
Digitally signed by
CUCCARO.JOSEPH.A.1228846151
Date: 2019.11.20 07:33:55 -05'00'
20 Nov 19
Adobe Professional 8.0
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/MGMT DATA
Acquisition of NGATS Parts/Modules
B002 Report, Record of Meeting Minutes
DI-ADMN-81505 SOW PARA 4.7.1 FCDD-ACW-NT
LT
N/A D
N/A
N/A
SEE BLK 16
N/A
FCDD-ACW-NT 1
ACC-NJ 1
0 2 0
Block 4: Contractor format acceptable.
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE (DOD) AND UNITED STATES (U.S.) DOD
CONTRACTORS ONLY FOR ADMINISTRATIVE AND OPERATIONAL USE.
OTHER REQUESTS SHALL BE REFERRED TO CONTRACTING OFFICER
REPRESENTATIVE (COR), BLDG 91, FCDD-ACW-NT, PICATINNY ARSENAL, NJ
07806-5000, 973-724-7330.
Block 12: The Contractor shall document proceedings and action items discussed at the Post-Award Meeting. Minutes shall be distributed to all attendees within one (1) day of the conclusion of the meeting.
Block 14: Electronic copies of all data submittals shall be provided to the COR, FCDD-ACW-NT. Refer to contract for email address.
ACC-NJ - Refer to contract for email address.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2019.11.12 13:37:01 -05'00'
12 Nov 19 CUCCARO.JOSEPH.A.12288 46151
Digitally signed by
CUCCARO.JOSEPH.A.1228846151
Date: 2019.11.20 07:34:17 -05'00'
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/MGMT DATA
Acquisition of NGATS Parts/Modules
B003 ACCEPTANCE TEST PLAN (ATP) Test and Evaluation Master Plan (TEMP)
DI-QCIC-80553A SOW PARA 4.10.1 FCDD-ACW-NT
LT
A D
ONE/R
N/A
SEE BLK 16
N/A
FCDD-ACW-NT 1
ACC-NJ 1
0 2 0
BLOCK 8 - THE GOVERNMENT HAS FOURTEEN (14) CALENDAR DAYS TO
REVIEW THE INITIAL SUBMISSION AND SEVEN (7) CALENDAR DAYS TO
REVIEW EACH SUBSEQUENT SUBMISSION UNTIL APPROVAL.
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE (DOD) AND UNITED STATES (U.S.) DOD
CONTRACTORS ONLY FOR ADMINISTRATIVE AND OPERATIONAL USE.
OTHER REQUESTS SHALL BE REFERRED TO CONTRACTING OFFICER
REPRESENTATIVE (COR), BLDG 91, FCDD-ACW-NT, PICATINNY ARSENAL, NJ
07806-5000, 973-724-7330.
BLOCK 12 - FIRST SUBMISSION DUE SIXTY (60) CALENDAR DAYS AFTER TASK
AWARD.
BLOCK 14 - ELECTRONIC COPIES OF ALL DATA SUBMITTALS SHALL BE
PROVIDED IN CONTRACTOR FORMAT TO THE CONTRACTING OFFICER'S
REPRESENTATIVE (COR), FCDD-ACW-NT, REFER TO CONTRACT FOR EMAIL
ADDRESS.
ACC-NJ - REFER TO CONTRACT FOR EMAIL ADDRESS.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2019.11.12 13:35:26 -05'00'
12 Nov 19 CUCCARO.JOSEPH.A.12288 46151
Digitally signed by
CUCCARO.JOSEPH.A.1228846151
Date: 2019.11.20 07:33:39 -05'00'
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/MGMT DATA
Acquisition of NGATS Parts/Modules
B004 Government Property Inventory Report Property Management Plan
DI-MGMT-80441D SOW PARA 5.4.2 FCDD-ACW-NT
LT
N/A D
N/A
N/A
SEE BLK 16
SEE BLK 16
FCDD-ACW-NT 1
ACC-NJ 1
0 2 0
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE AND U.S. DOD CONTRACTORS ONLY FOR
ADMINISTRATIVE AND OPERATIONAL USE. OTHER REQUESTS SHALL BE
REFERRED TO CONTRACTING OFFICER'S REPRESENTATIVE (COR), BLDG 91,
FCDD-ACW-NT, PICATINNY ARSENAL, NJ 07806-5000, 973-724-7330.
BLOCKS 12 AND 13 - SUBMIT WITHIN THIRTY (30) CALENDAR DAYS AFTER
CONTRACT AWARD. ANY UPDATES TO THE PROPERTY MANAGEMENT PLAN
SHALL BE FORWARDED TO THE COR WITHIN TEN (10) CALENDAR DAYS OF
UPDATE.
BLOCK 14 - SUBMIT ELECTRONICALLY IN CONTRACTOR FORMAT TO
THE COR, FCDD-ACW-NT, REFER TO CONTRACT FOR EMAIL ADDRESS.
ACC-NJ - REFER TO CONTRACT FOR EMAIL ADDRESS.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2020.06.11 11:21:25 -04'00'
11 Jun 2020 MOKAY.JOSEPH.J.12291354
Digitally signed by
MOKAY.JOSEPH.J.1229135461
Date: 2020.06.16 08:40:42 -04'00'
16 Jun 2020
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/MGMT DATA
Acquisition of NGATS Parts/Modules
B005 Government Furnished Equipment (GFE) Inventory Report
DI-MGMT-82173 SOW PARA 5.4.2 FCDD-ACW-NT
LT
N/A D
N/A
N/A
SEE BLK 16
AS REQUIRED
FCDD-ACW-NT 1
ACC-NJ 1
0 2 0
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE AND U.S. DOD CONTRACTORS ONLY FOR
ADMINISTRATIVE AND OPERATIONAL USE. OTHER REQUESTS SHALL BE
REFERRED TO CONTRACTING OFFICER REPRESENTATIVE (COR), BLDG 91,
FCDD-ACW-NT, PICATINNY ARSENAL, NJ 07806-5000, 973-724-7330.
BLOCK 12 - GOVERNMENT FURNISHED EQUIPMENT (GFE) INVENTORY
REPORT SHALL BE SUBMITTED AT THE ONSET OF PERFORMANCE,
FOLLOWING CONTRACT AWARD.
SUBMIT ELECTRONICALLY TO THE COR, FCDD-ACW-NT, REFER TO
CONTRACT FOR EMAIL ADDRESS.
ACC-NJ - REFER TO CONTRACT FOR EMAIL ADDRESS.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2020.06.11 11:22:37 -04'00'
11 Jun 2020 MOKAY.JOSEPH.J.12291354
Digitally signed by
MOKAY.JOSEPH.J.1229135461
Date: 2020.06.16 08:41:38 -04'00'
16 Jun 2020
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/MGMT DATA
Acquisition of NGATS Parts/Modules
B006 CERTIFICATION/DATA REPORT Mandatory Training Certification
DI-MISC-80678 SOW PARAS 7.2, 7.4, 7.13 FCDD-ACW-NT
LT
N/A D
N/A
N/A
SEE BLK 16
SEE BLK 16
FCDD-ACW-NT 1
ACC-NJ 1
0 2 0
BLOCK 4 - CONTRACTOR FORMAT ACCEPTABLE.
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE AND U.S. DOD CONTRACTORS ONLY FOR
ADMINISTRATIVE AND OPERATIONAL USE. OTHER REQUESTS SHALL BE
REFERRED TO CONTRACTING OFFICER REPRESENTATIVE (COR), BLDG 91,
FCDD-ACW-NT, PICATINNY ARSENAL, NJ 07806-5000, 973-724-7330.
SOW PARAGRAPH 7.2 - ANTITERRORISM (AT) LEVEL 1 TRAINING SHALL BE
COMPLETED FORTY FIVE (45) CALENDAR DAYS AFTER CONTRACT AWARD
AND ANNUALLY THEREAFTER.
SOW PARAGRAPH 7.4 - iWATCH TRAINING SHALL BE COMPLETED FORTY
FIVE (45) CALENDAR DAYS AFTER CONTRACT AWARD AND ANNUALLY
THEREAFTER.
SOW PARAGRAPH 7.13 - OPERATIONS SECURITY (OPSEC) TRAINING SHALL BE
COMPLETED THIRTY (30) CALENDAR DAYS AFTER REPORTING FOR DUTY
AND ANNUALLY THEREAFTER.
BLOCK 14 - ELECTRONIC COPIES OF ALL DATA SUBMITTALS SHALL BE
PROVIDED TO THE COR, REFER TO CONTRACT FOR EMAIL ADDRESS.
ACC-NJ - REFER TO CONTRACT FOR EMAIL ADDRESS.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2019.11.12 13:37:43 -05'00'
12 Nov 19 CUCCARO.JOSEPH.A.12288 46151
Digitally signed by
CUCCARO.JOSEPH.A.1228846151
Date: 2019.11.20 07:35:02 -05'00'
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/ MGMT DATA
Acquisition of NGATS Parts/Modules
B007 Operations Security (OPSEC) Plan
DI-MGMT-80934C SOW PARA 7.12 DEVCOM AC OPSEC
LT
N/A D
N/A
N/A
SEE BLK 16
AS REQUIRED
DEVCOM AC OPSEC 1
FCDD-ACW-NT 1
ACC-NJ 1
0 3 0
BLOCK 4 - CONTRACTOR FORMAT ACCEPTABLE.
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE AND U.S. DOD CONTRACTORS ONLY FOR
ADMINISTRATIVE AND OPERATIONAL USE. OTHER REQUESTS SHALL BE
REFERRED TO CONTRACTING OFFICER REPRESENTATIVE (COR), BLDG 91,
FCDD-ACW-NT, PICATINNY ARSENAL, NJ 07806-5000, 973-724-7330.
BLOCK 12 - SUBMIT NINETY (90) CALENDAR DAYS AFTER TASK AWARD.
BLOCK 13 - UPDATE AS REQUIRED.
BLOCK 14 - DELIVER ELECTRONICALLY TO:
DEVCOM ARMAMENTS CENTER OPERATIONS SECURITY (OPSEC) POINT OF
CONTACT (POC): <usarmy.pica.ccdc-ac.mbx.ardec-opsec@mail.mil>
COR, FCDD-ACW-NT, REFER TO CONTRACT FOR EMAIL ADDRESS.
ACC-NJ - REFER TO CONTRACT FOR EMAIL ADDRESS.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2019.11.12 13:38:26 -05'00'
12 Nov 19 CUCCARO.JOSEPH.A.12288 46151
Digitally signed by
CUCCARO.JOSEPH.A.1228846151
Date: 2019.11.20 07:34:38 -05'00'
(1 Data Item)
PREVIOUS EDITION MAY BE USED.
Form Approved OMB No. 0704-0188
The public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services (0704-0188). Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TDP ________ TM _______ OTHER
D. SYSTEM/ITEM E. CONTRACT/PR NO. F. CONTRACTOR
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE
7. DD 250 REQ
8. APP CODE
9. DIST STATEMENT
REQUIRED
10. FREQUENCY
11. AS OF DATE
12. DATE OF FIRST SUBMISSION
13. DATE OF SUBSEQUENT
SUBMISSION
14. DISTRIBUTION
a. ADDRESSEE
b. COPIES
Draft Final
Reg Repro
15. TOTAL
16. REMARKS
17. PRICE GROUP
18. ESTIMATED
TOTAL PRICE
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
Page of Pages
B ADMIN/MGMT DATA
Acquisition of NGATS Parts/Modules
B008 Technical Report - Study/Services Turn Around Time (TAT) Delivery Delay Report
DI-MISC-80508B SOW PARA 4.9.2 FCDD-ACW-NT
LT
N/A D
N/A
N/A
SEE BLK 16
AS REQUIRED
FCDD-ACW-NT 1
ACC-NJ 1
0 2 0
BLOCK 9 - DISTRIBUTION STATEMENT D. DISTRIBUTION AUTHORIZED TO
THE DEPARTMENT OF DEFENSE AND U.S. DOD CONTRACTORS ONLY FOR
ADMINISTRATIVE AND OPERATIONAL USE. OTHER REQUESTS SHALL BE
REFERRED TO CONTRACTING OFFICER'S REPRESENTATIVE (COR), BLDG 91,
FCDD-ACW-NT, PICATINNY ARSENAL, NJ 07806-5000, 973-724-7330.
BLOCK 12 - If it is determined that the TAT will not be met, the Contractor shall notify the Government as soon as possible via e-mail (WITHIN FIVE CALENDAR DAYS) to the Technical Representative identified in SOW Paragraph 5.5 prior to the TAT deadline. When a delay is identified, the Contractor shall provide the reason for the delay and the estimated date for shipment. Subsequent delays shall also follow notification procedure.
BLOCK 14 - SUBMIT ELECTRONICALLY IN CONTRACTOR FORMAT TO
COR, FCDD-ACW-NT - REFER TO CONTRACT FOR EMAIL ADDRESS.
ACC-NJ, CONTRACT OFFICER - REFER TO CONTRACT FOR EMAIL ADDRESS.
FREYERMUTH.SUZANNE.L.122
8919310
Digitally signed by
FREYERMUTH.SUZANNE.L.1228919310
Date: 2022.01.31 07:04:24 -05'00'
1/31/2022 MOKAY.JOSEPH.J.12291354
Digitally signed by
MOKAY.JOSEPH.J.1229135461
Date: 2022.01.31 07:09:46 -05'00'
1/31/2022
| CDRL B001 |
| CDRL B002 |
| CDRL B003 |
| CDRL B004 |
| CDRL B005 |
| CDRL B006 |
| CDRL B007 |
| CDRL B008 |
File details come from the government source that posted it. Updated .