Attachment 4a - DAFFARS Clauses.pdf

Supplemental Clauses Incorporated by Full Text

5352.201-9101 FLDCOM Ombudsman (Jul 2023)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, for USSF (United States Space Force) acquisitions (excluding SMC acquisitions) please contact the Director of Contracts, Air Force Installation Contracting Center, Operating Location - Space (AFICC/KS OL-SPC) via the following e-mail workflow address: afica.ks.wf@us.af.mil. Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center /MAJCOM/DRU/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256- 2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the contracting officer.

(End of clause)

5352.204-9000 Notification of Government Security Activity and Visitor Group Security Agreements (Jul 2023)

This contract contains a DD Form 254, DOD Contract Security Classification Specification, and requires performance at a government location in the U.S. or overseas. Prior to beginning operations involving classified information on an installation identified on the DD Form 254, the contractor shall take the following actions:

(a) At least thirty days prior to beginning operations, notify the Information Protection Office shown in the distribution block of the DD Form 254 as to: (1) The name, address, and telephone number of this contract company's representative and designated alternate in the U.S. or overseas area, as appropriate;

(2) The contract number and military contracting command;

(3) The highest classification category of defense information to which contractor employees will have access;

(4) The Air Force installations in the U.S. (in overseas areas, identify only the APO number(s)) where the contract work will be performed;

(5) The date contractor operations will begin on base in the U.S. or in the overseas area;

(6) The estimated completion date of operations on base in the U.S. or in the overseas area; and,

(7) Any changes to information previously provided under this clause. (End of clause)

5352.209-9000 Organizational Conflict of Interest (Jul 2023)

(a) The following restrictions and definitions apply to prevent conflicting roles which may bias the Contractor's judgment or objectivity, or to preclude the Contractor from obtaining an unfair competitive advantage in concurrent or future acquisitions. (1) Descriptions or definitions:

""Contractor"" means the business entity receiving the award of this contract, its parents, affiliates, divisions and subsidiaries ""Development"" means all efforts towards solution of broadly-defined problems. This may encompass research, evaluating technical feasibility, proof of design and test, or engineering of programs not yet approved for acquisition or operation.

""Proprietary Information"" means all information designated as proprietary in accordance with law and regulation, and held in confidence or disclosed under restriction to prevent uncontrolled distribution. Examples include limited or restricted data, trade secrets, sensitive financial information, and computer software; and may appear in cost and pricing data or involve classified information.

""System"" means the system that is the subject of this contract.

""System Life"" means all phases of the system's development, production, or support.

""Systems Engineering"" means preparing specifications, identifying and resolving interface problems, developing test requirements, evaluating test data, and supervising design.

""Technical Direction"" means developing work statements, determining parameters, directing other Contractors' operations, or resolving technical controversies.

(2) Restrictions: The Contractor shall perform systems engineering and/or technical direction, but will not have overall contractual responsibility for the system's development, integration, assembly and checkout, or production.

The parties recognize that the Contractor shall occupy a highly influential and responsible position in determining the system's basic concepts and supervising their execution by other Contractors. The Contractor's judgment and recommendations must be objective, impartial, and independent. To avoid the prospect of the Contractor's judgment or recommendations being influenced by its own products or capabilities, it is agreed that the Contractor is precluded for the life of the system from award of a DoD contract to supply the system or any of its major components, and from acting as a subcontractor or consultant to a DoD supplier for the system or any of its major components.

(End of clause)

5352.223-9000 Elimination of Use of Class I Ozone Depleting Substances (ODS) (Jun 2024)

(a) Contractors shall not: (1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS as part of this contract/order.

(b) For the purposes of Department of the Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32- 7086) are Class I ODSs: (1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-

215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Department of the Air Force definition of a Class I ODS.]

5352.223-9001 Health and Safety on Government Installations (Jul 2023)

(a) In performing work under this contract on a Government installation, the contractor shall:

(1) Take all reasonable steps and precautions to prevent accidents and preserve the health and safety of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(2) Take such additional immediate precautions as the contracting officer may reasonably require for health and safety purposes.

(b) The contracting officer may, by written order, direct Air Force Occupational Safety and Health (AFOSH) Standards and/or health/safety standards as may be required in the performance of this contract and any adjustments resulting from such direction will be in accordance with the Changes clause of this contract.

(c) Any violation of these health and safety rules and requirements, unless promptly corrected as directed by the contracting officer, shall be grounds for termination of this contract in accordance with the Default clause of this contract.

5352.242-9000 Contractor Access to Air Force Installations (Jun 2024)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Department of the Air Force installation(s) cited in the contract.

Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.