DEPARTMENT OF THE NAVY

NAVAL FACILITIES ENGINEERING SYSTEMS COMMAND, MID-ATLANTIC

MARINE CORPS AIR STATION, CHERRY POINT, NORTH CAROLINA

FACILITY PREPARATION AND PROVIDE ULTRA SONIC CLEANING SYSTEM,

BUILDINGS 133

AT THE

MARINE CORPS AIR STATION

CHERRY POINT, NORTH CAROLINA

PROJECT: 7357358

DESIGNED BY:

FACILITIES AND INFRASTRUCTURE DESIGN TEAM

INFRASTRUCTURE INVESTMENT BRANCH (JC21200)

FLEET READINESS CENTER EAST

MCAS, CHERRY POINT, NC

SPECIFICATION PREPARED BY:

STEPHANIE A. FLICK

ROGELIO VELAZQUEZ

AUTUMN L. WILLIAMS

JASON S. HOPKINS

SPECIFICATION APPROVED BY:

Design Director: _____________________________________________

PATRICK FAULKNER, PE

Date: ___________________ heather.perry Typewritten Text on behalf of

XZ62190 VAPOR DEGREASER 7357358

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 15 02/24 LIST OF DRAWINGS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 02/24 SUMMARY OF WORK

01 14 00 11/22, CHG 4: 02/25 WORK RESTRICTIONS

01 20 00 11/20, CHG 5: 02/25 PRICE AND PAYMENT PROCEDURES

01 30 00 11/20, CHG 5: 02/25 ADMINISTRATIVE REQUIREMENTS

01 31 23.13 20 08/23 ELECTRONIC CONSTRUCTION AND FACILITY

SUPPORT CONTRACT MANAGEMENT SYSTEM

(eCMS)

01 32 16.00 20 08/18, CHG 1: 08/20 SMALL PROJECT CONSTRUCTION PROGRESS

SCHEDULES

01 33 00 08/18, CHG 4: 02/21 SUBMITTAL PROCEDURES

01 35 26 05/24 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 05/24 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00 08/23, CHG 1: 05/24 QUALITY CONTROL

01 50 00 11/20, CHG 3: 08/24 TEMPORARY CONSTRUCTION FACILITIES AND

CONTROLS

01 57 19 08/22 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 02/19, CHG 3: 11/21 CONSTRUCTION WASTE MANAGEMENT AND

DISPOSAL

01 78 00 05/19, CHG 1: 08/21 CLOSEOUT SUBMITTALS

01 78 23 05/23 OPERATION AND MAINTENANCE DATA

01 80 00 04/15 REPORTS

DIVISION 02 - EXISTING CONDITIONS

02 41 00 08/22 DEMOLITION

02 83 00 11/18 LEAD REMEDIATION

DIVISION 03 - CONCRETE

03 30 00 02/19, CHG 9: 08/24 CAST-IN-PLACE CONCRETE

03 42 13.00 10 05/16 PLANT-PRECAST CONCRETE PRODUCTS FOR

BELOW GRADE CONSTRUCTION

DIVISION 05 - METALS

05 12 00 08/18, CHG 2: 05/21 STRUCTURAL STEEL

05 51 00 08/23 METAL STAIRS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 73 01 08/23 FIBERGLASS REINFORCED PLASTIC (FRP)

GRATING

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 92 00 08/23 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 31 00 05/17, CHG 1: 08/18 ACCESS DOORS AND PANELS

PROJECT TABLE OF CONTENTS Page 1

FINAL

DIVISION 09 - FINISHES

09 67 23.14 08/16, CHG 1: 08/18 CHEMICAL RESISTANT RESINOUS FLOORING

09 90 00 02/21 PAINTS AND COATINGS

DIVISION 11 - EQUIPMENT

11 71 00 05/20 STERILIZERS AND ASSOCIATED EQUIPMENT

DIVISION 22 - PLUMBING

22 00 00 05/24 PLUMBING, GENERAL PURPOSE

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 03 00.00 20 08/10, CHG 3: 08/18 BASIC MECHANICAL MATERIALS AND METHODS

23 07 00 08/24 THERMAL INSULATION FOR MECHANICAL

SYSTEMS

23 64 10 11/16, CHG 2: 08/18 WATER CHILLERS, VAPOR COMPRESSION TYPE

23 64 26 08/09, CHG 7: 02/24 CHILLED, CHILLED-HOT, AND CONDENSER

WATER PIPING SYSTEMS

DIVISION 26 - ELECTRICAL

26 20 00 08/23 INTERIOR DISTRIBUTION SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 08/23 EARTHWORK

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

DOCUMENT 00 01 15

LIST OF DRAWINGS

02/24

PART 1 GENERAL

1.1 SUMMARY

This section lists the drawings for the project pursuant to contract clause "DFARS 252.236-7001, Contract Drawings and Specifications."

1.2 CONTRACT DRAWINGS

Contract drawings are as follows:

DRAWING

NO.

NAVFAC DWG

NO.

TITLE

G-001 12892403 COVER SHEET

G-002 12892404 SYMBOL LEGEND & PROJECT NOTES

S-001 12892405 STRUCTURAL NOTES

SD101 12892406 STRUCTURAL FLOOR PLAN - DEMOLITION

S-101 12892407 STRUCTURAL FLOOR & ROOF PLAN - CONSTRUCTION

S-501 12892408 STURCTURAL DETAILS - STEEL

S-502 12892409 STURCTURAL DETAILS - CONCRETE

A-001 12892410 NOTES, SYMBOL LEGEND & ABBREVIATIONS

AD101 12892411 FLOOR PLAN - DEMOLITION

A-101 12892412 FLOOR PLAN - CONSTRUCTION

A-501 12892413 SECTION AND STAIR DETAILS

M-001 12892414 MECHANICAL NOTES, LEGEND AND ABBREVIATIONS

DOCUMENT 00 01 15 Page 1

DRAWING

NO.

NAVFAC DWG

NO.

TITLE

M-101 12892415 MECHANICAL FLOOR PLANS - CONSTRUCTION

M-501 12892416 MECHANICAL DETAILS

M-701 12892417 MECHANICAL ISOMETRIC - ROOF

M-702 12892418 MECHANICAL ISOMETRIC - GROUND FLOOR

E-101 12892419 ELECTRICAL FLOOR PLAN - CONSTRUCTION

E-102 12892420 ELECTRICAL ROOF PLAN - CONSTRUCTION

E-601 12892421 ELECTRICAL - DETAILS AND SCHEDULES

-- End of Document --

DOCUMENT 00 01 15 Page 2

SECTION 01 11 00

SUMMARY OF WORK

02/24

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for all submittals. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes furnishing and installation of an ultrasonic cleaning system and supporting chiller. Work will include concrete demolition, new concrete, electrical and plumbing utilities, and roof work. Chiller will be located on roof.

1.2.2 Location

The work is located at MCAS Cherry Point, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract. Occupancy notifications will be posted in a prominent location in the work area.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 EXISTING WORK

Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.5 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation, and comply with Installation requirements for locating and marking underground utilities.

Contact local utility locating service a minimum of 48 hours prior to excavating, to mark utilities, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

Identify and mark all other utilities not managed and located by the local utility companies. Scan the construction site with Ground Penetrating

SECTION 01 11 00 Page 1

Radar (GPR), electromagnetic, or sonic equipment, and mark the surface of the ground or paved surface where existing underground utilities are discovered. Verify the elevations of existing piping, utilities,and any type of underground obstruction not indicated, or specified to be removed, that is indicated or discovered during scanning, in locations to be traversed by piping, ducts, and other work to be conducted or installed.

Verify elevations before installing new work closer than nearest manhole or other structure at which an adjustment in grade can be made.

1.5.1 Notification Prior to Excavation

Notify the Contracting Officer at least 15 days prior to starting excavation work.

1.6 NAVY AND MARINE CORPS INTRANET (NMCI) COORDINATION REQUIREMENTS

1.6.1 NMCI Contractor Access

Allow the NMCI Contractor access to the facility towards the end of construction (finishes 90 percent complete, rough-in 100 percent complete, Inside Plant (ISP)/Outside Plant (OSP) infrastructure in place) to provide equipment in the telecommunications rooms and make final connections.

Coordinate efforts with the NMCI Contractor to facilitate joint use of building spaces during the final phases of construction. After the Contracting Officer has facilitated coordination meetings between the two contractors, within one week, incorporate the effort of additional coordination with the NMCI Contractor into the construction schedule to demonstrate a plan for maintaining the contract duration.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 2

SECTION 01 14 00

WORK RESTRICTIONS

11/22, CHG 4: 02/25

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AIR-CONDITIONING, HEATING AND REFRIGERATION INSTITUTE (AHRI)

ANSI/AHRI 210/240 (2008; Add 1 2011; Add 2 2012) Performance Rating of Unitary Air-Conditioning & Air-Source Heat Pump Equipment

AMERICAN SOCIETY OF CIVIL ENGINEERS (ASCE)

ASCE 7-16 (2017; Errata 2018; Supp 1 2018) Minimum Design Loads and Associated Criteria for Buildings and Other Structures

FLORIDA ADMINISTRATIVE CODE (FAC)

FAC Chapter 15C-1 Department of Highway Safety and Motor Vehicles

INSTRUCTIONS AND STANDARDS FOR NAVBASE GUANTANAMO BAY CUBA

(COMNAVBASEGTMOINST)

11300.3 Base Energy Conservation Regulations

INTERNATIONAL CODE COUNCIL (ICC)

ICC IBC (2024) International Building Code

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (2023; ERTA 1 2024; TIA 24-1) National Electrical Code

NFPA 90A (2024) Standard for the Installation of Air Conditioning and Ventilating Systems

NFPA 101 (2024) Life Safety Code

NAVAL FACILITIES ENGINEERING AND EXPEDITIONARY WARFARE CENTER

(NAVFAC EXWC)

NFESC UG-2029-ENV (1998) Cross-Connection Control and Backflow Prevention Program Implementation at Shore Facilities, User's Guide

SECTION 01 14 00 Page 1

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2024) Safety and Occupational Health (SOH) Requirements

U.S. Code (USC)

8 USC 1101 Definitions

10 USC 6011 Navy Regulations

U.S. DEPARTMENT OF DEFENSE (DOD)

UFC 3-301-01 (2023; with Change 2, 2024) Structural Engineering

U.S. DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT (HUD)

24 CFR 3280 (2019) Manufactured Home Construction and Safety Standards

1.2 SUBMITTALS

Government approval is required for all submittals. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel

Health And Safety Plan for Work in Land Use Control (LUC) Areas

1.3 SPECIAL SCHEDULING REQUIREMENTS

a. Have materials, equipment, and personnel required to perform the work at the site prior to the commencement of the work.

b. The building will remain in operation during the entire construction period. Conduct operations so as to cause the least possible interference with normal operations of the activity.

c. Permission to interrupt any Activity roads, railroads, or utility service must be requested in writing a minimum of 15 calendar days prior to the desired date of interruption.

d. The Contractor shall develop and submit a project specific Health and Safety Plan for Work in Land Use Control (LUC) Areas for review and approval by the Environmental Protection Agency and the State of North Carolina prior to any work occurring in areas designated to be within the boundaries of an established Land Use Control (LUC) Area and involving excavation into the groundwater table.

(1) The Contractor shall allow for a 60 calendar day review period from receipt of an approved Health and Safety Plan (H&SP).

(2) The H&SP shall be submitted to the Contracting Officer who will forward it to the appropriate review authorities.

(3) The H&SP shall contain and/or address as a minimum the following

SECTION 01 14 00 Page 2 elements:

(a) General Project Scope and Description.

(b) Anticipated impacts to soil and/or groundwater.

(c) Protocol for minimizing exposure to potential contaminated materials including, but not limited to:

1. Training

2. Work Area Precautions

3. Personnel Safety and Health Precautions

4. Chemical Hazard Communications Program

(4) The Contractor shall submit seven (7) draft copies of the HS&P to the Contracting Officer for review. Written comments will be provided and shall be incorporated into the H&SP.

(5) The Contractor shall submit seven (7) copies of the final H&SP.

1.4 CONTRACTOR ACCESS AND USE OF PREMISES

1.4.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic, and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear appropriate personal protective equipment (PPE) in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Ensure all Contractor equipment, including delivery vehicles, are clearly identified with their company name.

1.4.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors, including addresses and telephone numbers, for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.4.1.2 Installation Access

Obtain access to Navy installations through participation in the Defense Biometrics Identification System (DBIDS). Requirements for Contractor employee registration, and transition for employees currently under Navy Commercial Access Control System (NCACS), are available at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/.

No fees are associated with obtaining a DBIDS credential.

Participation in the DBIDS is not mandatory, and Contractor personnel may apply for One-Day Passes at the Base Visitor Control Office, to access an installation.

1.4.1.2.1 Registration for DBIDS

Registration for DBIDS is available at

SECTION 01 14 00 Page 3 https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/.

Procedure includes:

a. Present a letter or official award document (i.e. DD Form 1155 or SF 1442), from the Contracting Officer, that provides the purpose for access to the base Visitor Control Center representative.

b. Present valid identification, such as a passport or Real ID Act-compliant state driver's license.

c. Provide completed SECNAV FORM 5512/1 to the base Visitor Control Center representative to obtain a background check. This form is available for download at https://www.cnic.navy.mil/Operations-and-Management/Base-Support/DBIDS/.

d. Upon successful completion of the background check, the Government will complete the DBIDS enrollment process, which includes Contractor employee photo, fingerprints, base restriction, and several other assessments.

e. Upon successful completion of the enrollment process, the Contractor employee will be issued a DBIDS credential, and will be allowed to proceed to worksite.

1.4.1.2.2 DBIDS Eligibility Requirements

Throughout the length of the contract, the Contractor employee must continue to meet background screen standards. Periodic background screenings are conducted to verify continued DBIDS participation and installation access privileges. DBIDS access privileges will be immediately suspended or revoked if at any time a Contractor employee becomes ineligible.

An adjudication process may be initiated when a background screen failure results in disqualification from participation in the DBIDS, and Contractor employee does not agree with the reason for disqualification. The Government is the final authority.

1.4.1.2.3 DBIDS Notification Requirements

a. Immediately report instances of lost or stolen badges to the Contracting Officer.

b. Immediately collect DBIDS credentials and notify the Contracting Officer in writing under the following circumstances:

(1) An employee has departed the company without having properly returned or surrendered their DBIDS credentials.

(2) There is a reasonable basis to conclude that an employee, or former employee, might pose a risk, compromise, or threat to the safety or security of the Installation or anyone therein.

1.4.1.2.4 One-Day Passes

Personnel applying for One-Day passes at the Base Visitor Control Office are subject to daily mandatory vehicle inspection, and will have limited access to the installation. The Government is not responsible for any cost or lost time associated with obtaining daily passes or added vehicle

SECTION 01 14 00 Page 4 inspections incurred by non-participants in the DBIDS.

1.4.1.3 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction, and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.4.2 Working Hours

Regular working hours will consist of an 8 1/2 hour period, between 7 a.m.

and 3:30 p.m., Monday through Friday, and 7 a.m. to 3:30 p.m. on Saturday, excluding Government holidays.

1.4.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number, and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in accordance with requirements of EM 385-1-1. Make utility cutovers after normal working hours or on Saturdays, Sundays, and Government holidays unless directed otherwise.

1.4.4 Occupied Building

Work will be in an existing building which is occupied.

The existing buildings and their contents must be kept secure at all times. Provide temporary closures as required to maintain security as directed by the Contracting Officer.

Provide dust covers or protective enclosures to protect existing work that remains, and Government material located in the proximity during the construction period.

1.4.5 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in paragraph WORK OUTSIDE REGULAR HOURS.

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, are considered utility cutovers pursuant to the paragraph WORK

OUTSIDE REGULAR HOURS.

d. Connection to Existing Sanitary Sewer Line: Provide positive verification that the existing line conveys sanitary sewer; verify line is not incorrectly connected to a storm drain.

SECTION 01 14 00 Page 5

1.5 SECURITY REQUIREMENTS

Contract Clause FAR 52.204-2 Security Requirements and Alternate II and the following apply:

1.5.1 MCAS Cherry Point Regulations

No employee or representative of the contractor will be admitted to the work site without an Identification Badge or is specifically authorized admittance to the work site by the FEAD, Facilities Engineering & Acquisition Division.

IMPORTANT NOTE: FEAD personnel (Construction Managers, Engineers/Architects, Engineering Technicians, Contract Specialists, or Contract Surveillance Representatives) will not receive, process, re-transmit, or otherwise handle IN ANY WAY Personally Identifiable Information (PII) related to the badging process. Do NOT forward any of this information to the FEAD.

1.5.2 Contractor Access to MCAS Cherry Point and Outlying Areas

1. Documentation requirements for granting access to MCAS Cherry Point for commercial and contract employers and employees. This document is an aid in meeting ASO 5560.6C requirements and is not a substitute for the order.

2. The Pass & Identification Office at Building 251 will issue credentials to authorized contractors. Sub-Contractors and suppliers must coordinate through the Prime-Contractor.

3. Criminal Activity. In accordance with ASO 5560.6C, the below list of criminal activities within an applicant's record are considered not in the best interest of the Marine Corps and will be grounds for automatic denial of access aboard the Installation:

a. Conviction for espionage, sabotage, sedition, treason, terrorism, armed robbery, or murder.

b. Felony conviction for a firearms or explosives violation, regardless of the date of conviction.

c. Conviction of crimes encompassing sexual assault or rape.

d. Conviction of crimes encompassing child molestation, or the possession or production of child pornography.

e. Conviction of trafficking in persons.

f. Conviction of drug possession with intent to sell or distribute.

g. Convicted of three or more misdemeanor violations, or attempted violations, within the previous 10 years of the following offenses:

(1) Sex crime

(2) Assault

(3) Larceny

(4) Drugs

(5) Weapons

SECTION 01 14 00 Page 6

4. Persons requesting access to MCAS Cherry Point will be denied access based on the following:

a. The individual is a registered sex offender.

b. The individual has an active arrest warrant from Federal, State, local, or other civil law enforecement authorities, regardless of offense or violation.

c. The individual has a felony conviction within the last 10 years, regardless of the offense or violation.

d. The individual's name appears on any Federal or State agency watch list for criminal behavior or terrorist activity.

e. The individual is debarred entry or access to a Marine Corps site, other DoD installations or facilities, or other Federal site or facility.

f. The individual engaged in acts or activities designed to overthrow the U.S. Government by force.

g. The individual is known to be or reasonably suspected of being a terrorist or belongs to an organization with known terrorism links/support.

h. The individual is identified in the National Crime Information Center (NCIC) known suspected terrorist (KST) file, or the Terrorist Screening Database (TSDB) report as known to be, or suspected of being, a terrorist or belonging to an organization with known links to terrorism or support of terrorist activity. If an individual is identified on the NCIC KST files or TSDB, the Provost Marshal's Office (PMO) will immediately call the NCIS Multiple Threat Alert Center (MTAC) for further coordination. The MTAC will coordinate with the Department of Justice (DOJ) or Federal Bureau of Investigation (FBI) and provide handling instructions to MCAS Cherry Point Police, Criminal Investigations Division (CID), or NCIS.

i. The individual is illegally present in the U.S.

j. The individual has knowingly submitted an employment questionnaire with false or fraudulent information.

k. The individual is a prisoner on a work-release program or currently on felony probation or parole.

l. The individual is pending any felony charge.

m. The individual has criminal arrest information that the site commander determines the person presents a threat to good order, discipline, or health and safety on the Marine Corps site.

n. Any reason the Installation Commander deems reasonable for good order and discipline.

1.5.3 FLEET READINESS CENTER, EAST (FRC EAST) REQUIREMENTS

Work involved under this contract is in the FRC East Maintenance Depot and Flightline Area. No employee or representative of the Contractor will be

SECTION 01 14 00 Page 7 admitted to the work site unless they (1) are specifically authorized admittance by the FEAD, and (2) has a security badge. The Contractor shall obtain clearance and FRC East security badges for all personnel required to be on the project site prior to performing any work. The Contractor shall submit a written request for security badges to the FEAD and to FRC East Security. Each employee will be required to go to Trailer 32 to obtain a security badge with FRC East access. A limited number of Contractor vehicles will be allowed access to the site of work subject to meeting regular access requirements. No personal vehicles will be allowed behind the security fence. Parking of vehicles shall be restricted to the immediate project site as determined by FRC East Security. The security badges issued under this contract are valid for this specific project and are not transferable to another project.

FRC East is registered to the ISO 9001, AS9100, AS9110, ISO 14001, and OSHAS 18001 standards. To adhere to the standards required of these programs, FRC East must ensure that all individuals accessing the facility are aware of the conditions and factors that affect the well-being of all employees, temporary workers, contractor personnel, visitors, and any other person in the workplace.

The following are requirements for granting access to Fleet Readiness Center East (FRC East) for commercial and contract employers and employees.

a. The Contractor shall complete a "Contractor Work Notice- Form FRC-East 5000/10" and provide the Notice to the appropriate shop supervisor for signature and leave the top part of the Notice with the shop supervisor to post in a prominent location in the work area. The Contractor shall keep the bottom portion of the "Contractor Work Notice" for his records and provide a copy to the Contracting Officer. For projects occurring on facility roofs (roofing repair, HVAC replacement, or similar work), the Contractor shall complete a "Contractor Work Notice" form and provide the Notice to the shop directly under the area being worked, even if no direct impact to the shop is anticipated. A blank copy of this form is included at the end of this section.

b. In the event of an emergency, including hazardous material spills, the individual discovering the emergency shall call 911 from any FRC East phone. Relay the grid number listed on the phone for location assistance. If you are calling from a cell phone, call 252-466-3616 - Fire Department Dispatch. This does not relieve the Contractor from reporting the situation to the Contracting Officer which is required elsewhere in this specification.

c. Badges will be displayed at all times and shall be returned upon completion of work. Every badge is considered Government Property and all lost badges will be reported to the FRC East Badge and Decal Office located in Trailer 32.

d. Report any injury/illness occurring on site to the FRC East Safety Office immediately by calling 252-464-7015. This does not relieve the Contractor from reporting the situation to the Contracting Officer which is required elsewhere in this specification.

e. The facility must be kept clean and orderly at all times.

Ensure that you place all waste in proper receptacles so that the

SECTION 01 14 00 Page 8 facility is maintained in a "Clean as you go" condition.

f. When in the FRC East industrial areas, wear the personal protective equipment (PPE) required for that area. PPE requirements are generally marked but if there is uncertainty, check with the area supervisor. Typically, safety glasses with side shields and steel toed shoes are required in most shops.

g. Smoking is NOT authorized while traveling from one facility location to another while walking or in a vehicle being operated anywhere within the FRC East compound. ABSOLUTELY NO SMOKING on the property except in Designated Smoking Areas.

h. Extra caution shall be taken around the flight line and aircraft turn-up areas to control trash, debris, and materials.

Additionally, all personnel on the flight line must be continuously alert and stay clear of helicopter and jet operations in progress.

i. Vehicles must not obstruct aircraft movement or other daily operations.

j. Safety (252-464-7015), security (252-464-7999), and environmental (252-464-8042) infractions shall be reported to the appropriate office immediately.

k. If an emergency situation occurs which would endanger the health or safety of personnel, the area shall be evacuated.

Re-entry to affected buildings will be at the discretion of uniformed guards, fire department, or safety office personnel only.

l. Decisions to evacuate will be from the FRC East Commanding Officer or his/her representative. Visitors/contractors, along with non-essential facility personnel, south of Harrison Drive, adjacent to Building 4224, will evacuate the facility first.

Fifteen minutes later, the visitors/contractors south of Curtiss Road, between Buildings 83 & 84, will evacuate the facility.

Fifteen minutes later the visitors/contractors north of Curtiss Road will evacuate the facility.

m. Cellular phones and photographic equipment are not authorized within FRC East unless they are approved in advance by the Security Office (252-464-7999). Cellular phones may be used on roof areas for emergency purposes only.

n. All vehicles must have proper passes, and no pass may be transferred between vehicles.

o. All vehicles will follow posted speed limits, which are 5 MPH on the outside of buildings and 3 MPH inside of any building.

p. Vehicle headlights must be on at all times within the facility.

q. All vehicles are required to slow down, sound horn, and proceed with caution at all cross aisles and other locations where vision is obstructed.

r. Personnel are strictly forbidden to introduce any substance into the storm drain system including catch basins, roof drains, SECTION 01 14 00 Page 9 and floor drains.

s. All facility entrants are responsible for all materials they bring into the facility and shall handle them in such a manner to ensure they are not left as "foreign objects" anywhere in the facility.

t. In case of a utility emergency on weekends or after normal work hours, call the Public Works Department trouble call desk at 252-466-4363.

u. The use of gasoline is prohibited for any purpose other than fueling motor vehicles. All gasoline-powered vehicles are prohibited inside FRC East buildings.

1.5.4 Mandatory Contract Performance Requirements for FRC East

a. All personnel working on site at FRC East under this contract must document their receipt and review of the information listed in FRCEASTINST 5000.1B annually. The Security Department will provide a means of completing initial review prior to FRC East entrance.

b. Foreign object (FO) is defined as any article or substance alien to the aircraft or assembly which is allowed to invade the product. Foreign Object Damage (FOD) is the damage that occurs due to these FOs. All FRC East work sites will be maintained in such a manner as to prevent FOD to aircraft and/or aircraft components. Work sites shall be kept clean at all times. All debris, scrap material, tools, and equipment will be cleared from the work site as work progresses. At no time will hoses, power cords, materials, etc. be permitted to create tripping hazards in areas of the work site.

c. In those cases where a contractor supervisor determines that solving a safety or health problem is beyond their control, but within the control of FRC East, the contractor shall notify the Contracting Officer.

1.5.4.1 Additional Contract Performance Requirements for FRC East

a. Work above or anywhere near aircraft or passageways shall be avoided whenever possible. If this is not possible, the cognizant shop supervisor will be informed so arrangements can be made to protect, move, or evacuate assets from the area to minimize foreign object debris potential. The area below the elevated work area will be adequately marked and barricaded at all times. Under no circumstances will work be performed over unprotected spaces.

b. Constant control of tools and materials is required at all times in the following critical areas: Rotor Head Shop;

Ordinance/Survival Shop; Aircraft Paint Shop; Aircraft Clean Shop;

Aircraft Engine Shops; all shops in Building 4225; and all Aircraft Hangars.

c. Buildings 137, 188, 245, 4224, and 4247 are classified as hazardous areas and have special requirements. Do not utilize any ignitable items, items powered by electric motors, or internal combustion engines unless they are determined to be suitable to

SECTION 01 14 00 Page 10 the conditions of the buildings.

d. The recharging of mobile equipment shall not take place inside any FRC-East building.

e. Tools and hardware will be controlled at all times to prevent migration out of the work site. Lost tools shall be reported to the Contracting Officer who will then notify the FRC East Tool Control Manager at 252-464-9741. Tools found unattended will be confiscated and reported to the Contracting Officer.

f. Work requiring any modification to an air pollution control device must be approved in advance by the Contracting Officer, who will obtain approval from the FRC East Air Quality Program Manager. These devices are marked with a 5" x 9" red placard and a contact number, 252-464-7264.

g. Work accomplished that will impact industrial ventilation systems or fans will require prior notification of the Contracting Officer, who will then notify the FRC East Air Quality Program Manager at 252-464-7264. These systems are continuously monitored.

1.5.5 Staging Area

As indicated on the plans, the Contractor staging area will be (Construction Manager to coordinate). Amount of material on site shall be kept to a minimum and shall only be material that is pertinent to the work currently being performed. All stockpiling of equipment and materials shall be closely coordinated with the Government and shall not disrupt activities at the site.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 14 00 Page 11

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

11/20, CHG 5: 02/25

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

ASTM INTERNATIONAL (ASTM)

ASTM A615/A615M (2024) Standard Specification for Deformed and Plain Carbon-Steel Bars for Concrete Reinforcement

U.S. ARMY CORPS OF ENGINEERS (USACE)

EP 1110-1-8 (2021) Engineering and Design -- Construction Equipment Ownership and Operating Expense Schedule

1.2 SUBMITTALS

Government approval is required for all submittals. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Schedule of Prices

1.3 SCHEDULE OF PRICES

1.3.1 Data Required

Within 15 calendar days of Contract Award, prepare and deliver to the Contracting Officer a Schedule of Prices (construction Contract) as directed by the Contracting Officer. Schedule of Prices must have cost summarized and totals provided for each construction category. Provide a detailed breakdown of the Contract price, giving quantities for each of the various kinds of work, unit prices, and extended prices. Indirect activities (e.g., meetings, presentations, submittals, surveys, haul road or storage yard maintenance, dust control, security) will not be cost loaded. Evenly distribute the costs across the associated construction activities. Contractor overhead and profit including salaries for field office personnel, if applicable, must be proportionately spread over all pay items and not included as individual pay items.

1.3.2 Payment Schedule Instructions

Payments will not be made until the Schedule of Prices has been submitted to and accepted by the Contracting Officer.

Additionally, the Schedule of Prices must be separated as follows:

SECTION 01 20 00 Page 1

a. Primary Facilities Cost Breakdown:

Defined as work on the primary facilities out to the 5 foot line. Work out to the 5 foot line includes construction encompassed within a theoretical line 5 foot from the face of exterior walls and includes attendant construction, such as pad mounted HVAC cooling equipment, cooling towers, and transformers placed beyond the 5 foot line.

b. Supporting Facilities Cost Breakdown:

Defined as site work, including incidental work, outside the 5 foot line.

1.4 CONTRACT MODIFICATIONS

In conjunction with the Contract Clause DFARS 252.236-7000 Modification Proposals-Price Breakdown, and where actual ownership and operating costs of construction equipment cannot be determined from Contractor accounting records, base equipment use rates upon the applicable provisions of the

EP 1110-1-8.

1.5 CONTRACTOR'S INVOICE AND CONTRACT PERFORMANCE STATEMENT

1.5.1 Content of Invoice

Requests for payment will be processed in accordance with the Contract Clause FAR 52.232-27 Prompt Payment for Construction Contracts and FAR 52.232-5 Payments Under Fixed-Price Construction Contracts. Invoices not completed in accordance with contract requirements will be returned to the Contractor for correction of the deficiencies. Include the documents listed below in the requests for payment.

a. The Contractor's invoice, on NAVFAC Form 7300/30 furnished by the Government, showing in summary form, the basis for arriving at the amount of the invoice. Form 7300/30 must include certification by Quality Control (QC) Manager as required by the Contract.

b. The Estimate for Voucher/Contract Performance Statement on NAVFAC Form 4330/54 furnished by the Government. Use NAVFAC Form 4330, unless otherwise directed by the Contracting Officer, on NAVFAC Contracts when a Monthly Estimate for Voucher is required.

c. Contractor's Monthly Estimate for Voucher and Contractors Certification (NAVFAC Form 4330) with Subcontractor and supplier payment certification. Other documents, including but not limited to, that need to be received prior to processing payment include the following submittals as required. These items are still required monthly even when a pay voucher is not submitted.

d. Monthly Work-hour report.

e. Updated Construction Progress Schedule and tabular reports required by the contract.

f. Contractor Safety Self Evaluation Checklist.

g. Updated submittal register.

h. Solid Waste Disposal Report.

SECTION 01 20 00 Page 2

i. Certified payrolls.

j. Updated testing logs.

k. Other supporting documents as requested.

1.5.2 Submission of Invoices

Monthly invoices and supporting forms for work performed through the anniversary award date of the Contract must be submitted to the Contracting Officer within 5 calendar days of the date of invoice. For example, if Contract award date is the 7th of the month, the date of each monthly invoice must be the 7th and the invoice must be submitted by the 12th of the month.

1.6 PAYMENTS TO THE CONTRACTOR

Payments will be made on submission of itemized requests by the Contractor which comply with the requirements of this section, and will be subject to reduction for overpayments or increase for underpayments made on previous payments to the Contractor.

1.6.1 Obligation of Government Payments

The obligation of the Government to make payments required under the provisions of this Contract will, at the discretion of the Contracting Officer, be subject to reductions and suspensions permitted under the FAR and agency regulations including the following in accordance with FAR

32.103 Progress Payments Under Construction Contracts:

a. Reasonable deductions due to defects in material or workmanship;

b. Claims which the Government may have against the Contractor under or in connection with this Contract;

c. Unless otherwise adjusted, repayment to the Government upon demand for overpayments made to the Contractor; and

d. Failure to maintain accurate "as-built" or record drawings in accordance with FAR 52.236.21 and the contract.

e. Failure to submit accurate monthly schedule updates in accordance with the contract.

1.6.2 Payment for Onsite and Offsite Materials

Progress payments may be made to the Contractor for materials delivered on the site, for materials stored off construction sites, or materials that are in transit to the construction sites under the following conditions:

a. FAR 52.232-5(b) Payments Under Fixed Price Construction Contracts.

b. Materials delivered on the site, but not installed, and off-site materials to be considered for progress payment must be major high cost, long lead, special order, or specialty items, not susceptible to deterioration or physical damage in storage or in transit to the construction site. Examples of materials acceptable for payment consideration include, but are not limited to, structural steel, SECTION 01 20 00 Page 3 non-magnetic steel, non-magnetic aggregate, equipment, machinery, large pipe and fittings, precast/prestressed concrete products, plastic lumber (e.g., fender piles/curbs), and high-voltage electrical cable.

Materials not acceptable for payment include consumable materials such as nails, fasteners, conduits, gypsum board, glass, insulation, and wall coverings.

c. Provide the Contracting Officer with documentation (e.g., Purchase Orders or Material Contracts) to justify payment for materials in advance of installation. When appropriate, include the Defense Priorities and Allocations System (DFAS) ratings (e.g., DX or DO) on purchase orders or material contracts to ensure timely delivery.

d. Materials to be considered for progress payment prior to installation must be specifically and separately identified in the Contractor's estimates of work submitted for the Contracting Officer's approval in accordance with Schedule of Prices requirement of this Contract.

Requests for progress payment consideration for such items must be supported by documents establishing their value (e.g., paid invoices) and that the title requirements of the clause at FAR 52.232-5 Payments Under Fixed-Price Construction Contracts have been met.

e. Ensure materials are adequately insured and protected from theft and exposure. Provide insurance documentation (e.g., Builder's Risk Insurance) which covers the overall value of the materials to be paid in advance of installation.

f. Provide a written consent from the surety company with each payment request for offsite materials.

g. Materials to be considered for progress payments prior to installation must be stored either in Hawaii, Guam, Puerto Rico, or the Continental United States. Other locations are subject to written approval by the Contracting Officer.

h. Materials in transit to the job site or storage site are not acceptable for payment.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 20 00 Page 4

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

11/20, CHG 5: 02/25

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2024) Safety and Occupational Health (SOH) Requirements

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

15 CFR 772 Definition of Terms

15 CFR 773 Special Licensing Procedures

1.2 SUBMITTALS

Government approval is required for all submittals. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

1.3 MINIMUM INSURANCE REQUIREMENTS

Provide the minimum insurance coverage required by FAR 28.307-2 Liability, during the entire period of performance under this contract. Provide other insurance coverage as required by North Carolina law.

1.4 SUPERVISION

1.4.1 Superintendent Qualifications

Provide project superintendent with a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

For projects where the superintendent is permitted to also serve as the Quality Control (QC) Manager as established in Section 01 45 00 QUALITY CONTROL, the superintendent must have qualifications in accordance with that section.

SECTION 01 30 00 Page 1

1.4.2 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of Contract work. In addition, if a QC representative is required on the Contract, then that individual must also have fluent English communication skills.

1.4.3 Duties

The project superintendent is primarily responsible for managing subcontractors and coordinating day-to-day production and schedule adherence on the project. The superintendent is required to attend Red Zone meetings, partnering meetings, and QC meetings. The superintendent, or qualified alternate, must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.4.4 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to ensure timely completion. Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time or excess costs or damages by the Contractor.

1.5 PRECONSTRUCTION MEETING

Prior to commencing any work at the site, coordinate with the Contracting Officer a time and place to meet for the Preconstruction Meeting. The purpose of this meeting is to discuss and develop a mutual understanding of the administrative requirements of the Contract including but not limited to: daily reporting, invoicing, value engineering, safety, base-access, outage requests, hot work permits, schedule requirements, QC, schedule of prices, shop drawings, submittals, cybersecurity, prosecution of the work, government acceptance, final inspections, and contract close-out.

Contractor must present and discuss their basic approach to scheduling the construction work and any required phasing.

1.5.1 Attendees

Contractor attendees must include the Project Manager, Superintendent, Site Safety and Health Officer (SSHO), QC Manager, and major subcontractors.

1.6 FACILITY TURNOVER PLANNING MEETINGS (Red Zone Meetings)

Meet with the Government to identify strategies to ensure the project is carried to expeditious closure and turnover to the Client. Start planning the turnover process at the Pre-Construction Conference meeting with a discussion of the Red Zone process and convene at regularly scheduled Red Zone Meetings beginning at approximately 75 percent of project completion.

Include the following in the facility Turnover effort:

1.6.1 Red Zone Checklist

a. Contracting Officer's Technical Representative (COTR) will provide the Contractor a copy of the Red Zone Checklist template.

SECTION 01 30 00 Page 2

b. Prior to 75 percent completion, modify the Red Zone Checklist template by adding or deleting critical activities applicable to the project and assign planned completion dates for each activity. Submit the modified Red Zone Checklist to the Contracting Officer. The Contracting Officer may request additional activities be added to the Red Zone Checklist at any time as necessary.

1.6.2 Meetings

a. Conduct regular Red Zone Meetings beginning at approximately 75 percent project completion, or three to six months prior to Beneficial Occupancy Date (BOD), whichever comes first.

b. The Contracting Officer will establish the frequency of the meetings, which is expected to increase as the project completion draws nearer.

At the beginning, Red Zone meetings may be every two weeks then increase to weekly towards the final month of the project.

c. Using the Red Zone Checklist as a Plan of Action and Milestones (POAM) and basis for discussion, review upcoming critical activities and strategies to ensure work is completed on time.

d. During the Red Zone Meetings discuss with the COTR any upcoming activities that require Government involvement.

e. Maintain the Red Zone Checklist by documenting the actual completion dates as work is completed and update the Red Zone Checklist with revised planned completion dates as necessary to match progress.

Distribute copies of the current Red Zone Checklist to attendees at each Red Zone Meeting.

1.7 PARTNERING

Host the partnering session within 45 calendar days of contract award. To most effectively accomplish this Contract, the Contractor and Government must form a cohesive partnership with the common goal of drawing on the strength of each organization in an effort to achieve a successful project without safety mishaps, conforming to the Contract, within budget, and on schedule. The partnering team must consist of personnel from both the Government and Contractor including project level and corporate level leadership positions. Key Personnel from the supported command, end user, PWD, FEAD, Contractor, key subcontractors, and the DOR (regardless of whether the contract is a design-build or a design-bid-build) are required to participate in the Partnering process.

1.7.1 Team-Led (Informal) Partnering

a. The Contracting Officer will coordinate the initial Team-Led (Informal) Partnering Session with key personnel of the project team, including Contractor and Government personnel. The Partnering Session will be co-led by the Government Construction Manager and Contractor's Project Manager.

b. The Initial Team-led Partnering session may be held concurrently with the meeting. Partnering sessions will be held at a location mutually agreed to by the Contracting Officer and the Contractor, typically at a conference room on-base or at the Contractor's temporary trailer.

SECTION 01 30 00 Page 3

c. The Initial Team-Led Partnering Session will be conducted and facilitated using electronic media (a video and accompanying forms) provided by Contracting Officer.

d. The Partners will determine the frequency of the follow-on sessions.

e. Participants will bear their own costs for meals, lodging, and transportation associated with Partnering.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 30 00 Page 4

SECTION 01 31 23.13 20

ELECTRONIC CONSTRUCTION AND FACILITY SUPPORT CONTRACT MANAGEMENT SYSTEM (eCMS) 08/23

PART 1 GENERAL

1.1…