A001.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

Amendment A001

SOLICITATION, OFFER

AND AWARD

(Construction, Alteration or Repair)

1. SOLICITATION NO.

6982AF23B000027

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

11/6/2023

PAGE OF

PAGES

IMPORTANT - THE "OFFER SECTION ON THE REVERSE MUST BE FULLY COMPLETED BY OFFEROR.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

HFLCEO230500PR

6. PROJECT NO.

UT FLAP 73(2)

7. ISSUED BY:

FEDERAL HIGHWAY ADMINISTRATION

CENTRAL FEDERAL LANDS DIVISION

12300 WEST DAKOTA AVENUE, SUITE 167

LAKEWOOD, COLORADO 80228

CODE: 69050001 8. ADDRESS OFFER TO:

Ryan Phillips, Contract Specialist Federal Highway Administration Central Federal Lands Division Office 12300 W. Dakota Avenue Lakewood, CO 80228

9. FOR INFORMATION CALL

SEE PAGE A-3

A. NAME:

SEE PAGE A-3

B. TELEPHONE NO. (Include area code)

SEE PAGE A-3

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS:

ROADWAY CONSTRUCTION PROJECT IN STRICT ACCORDANCE WITH:

1. FEDERAL ACQUISITION AND TRANSPORATION ACQUISITION REGULATIONS (FAR & TAR)

2. DEPARTMENT OF LABOR, CONSTRUCTION WAGE RATE REQUIREMENT RATES

3. SPECIAL CONTRACT REQUIREMENTS

4. PLANS

5. BID SCHEDULE

6. STANDARD SPECIFICATIONS FOR CONSTRUCTION OF ROADS AND BRIDGES ON FEDERAL HIGHWAY

PROJECTS, FP-14, U.S. CUSTOMARY UNITS

7. SUBCONTRACTING PLAN (IF APPLICABLE)

See Subsection 104.04 of the FP-14 for governing order of precedence

11. The Contractor shall begin performance within 10 calendar days and complete it within * calendar days after receiving award notice to proceed. The performance period is mandatory negotiable. *Refer to Subsection 108.01 as amended in the Special Contract Requirements.

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.) YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 0 copies to perform the work required are due at the place specified in Item 8. by 2:00 p.m. (hour) local time on 12/19/23 (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is is not required.

C. All offers are subject to the (1) work requirements and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA

FAR (48 CFR) 53.236-1(d)

X

X

X

X

X

A-1

E-15

UT FLAP 73(2)

La Sal Mountain Loop Road

Section 108. — PROSECUTION AND PROGRESS

108.01 Commencement, Prosecution, and Completion of Work. Add the following:

Limit operations according to Subsection 107.10(e) and Section 156.

Limit operations as follows:

(a) Do not perform ground disturbing activities before March 1, 2024

(b) Between station range 545+00 to 650+91; Perform no work other than surveying between February 1st and May 15th

(c) Complete all work for station range 545+00 to 650+91 from May 16th to September 26th in one construction season. Partial acceptance will be issued for completing this segment if completed in the first construction season.

(d) Within 14 days of removing pavement from 380+00 to 397+00 complete culvert removal, culvert replacements, and complete subexcavation from 380+00 to 389+00. Within 30 days of removing pavement from 380+00 to 397+00 complete placement of full depth aggregate base. Pave within the same construction season, either temporary (at no cost to the government) or permanent.

(e) Special Events: Coordinate with event holders for the annually scheduled Grand Fondo May 11, 2024 and May 10, 2025 and Skinny Tire Century Tour events September 15, 2024 and September 14, 2025, dates are estimated and subject to change depending on the year of the event. Perform no work except to maintain traffic control devices, erosion control devices and the roadway driving surface during these events. Ensure two lanes are open for public traffic and participants during these events.

(f) Before commencement of work, meet with the bicycle concessionaires, commercial business, United States Post Office, local school bus routes, residents, and CO to discuss coordination logistics. Provide ongoing coordination until project completion including access expectations, schedules and contact information with the Public Information Officer, Traffic Control Supervisor, Project Superintendent and the CO. Determine need for piloted passage for the public listed above including bicycle concessionaires, commercial business, residents, and guests of residents when requested.

(g) Cattle Grazing Permits: Coordinate with BLM and USFS permit holders for two (2) permittees with cattle grazing permits in the project area. The permit holders are Steve Lowry and Matt Redd.

(1) Steve Lowry runs approximately 800 head of cattle and has a corral along the road at station 232+45, Right. He stages a cattle drive from the corral in June and picking up the cattle in November each year. Coordinate with the permittees to allow for

E-16

La Sal Mountain Loop Road cattle drop off and collection within the project limits during these times. Anticipate 2-3 days in June, and 2-3 days in November each year.

Contact: Lowry Redd La Sal Livestock LTD 435-686-2283 (office) 435-459-4466 (cell) Justice Redd 435-232-0448

(2) Matt Redd runs approximately 1000 head of cattle. He be staging his cattle drive in June and picking up in November each year. Coordinate with the permittees to allow for cattle drop off and collection within the project limits during these times.

Anticipate 2-3 days in June, and 2-3 days in November each year.

Contact: Kelsey Wilson project manager 970-739-5921 Steven Redd (Cell) 435-459-9444

Perform no work except to maintain traffic control devices, erosion control devices, the roadway driving surface, and to control dust during the listed Federal holidays and surrounding days as shown in Table 108-2.

E-36

Accommodate traffic according to the MUTCD, contract traffic control drawings, Section 635, and this Section. Submit a traffic control plan for approval according to Subsection 104.03.

Submit a traffic control plan at least 30 days before intended use.

When implementing road closures and allowable delays according to Subsection 156.07 (i) provide an updated traffic control plan and update the detour information, signing and notifications according to the MUTCD. Update message boards, signing in coordination with the public information program.

156.05 Maintaining Roadways During Work.

(a) Add the following:

Do not construct diversions outside of the clearing limits or use alternate route detours without the approval of the CO.

Add the following:

(h) Maintain a traversable wearing surface through the project during construction. Wearing surfaces may range from maintaining the existing surfacing, constructing and maintaining compacted earth roadway to placing and maintaining temporary asphalt surfacing.

(i) Provide access to emergency vehicles at all times during construction.

156.07 Limitations on Construction Operations.

(c) Delete the first sentence and substitute the following:

For alternate one-way traffic control, provide a minimum lane width of 10 feet (3 meters).

For two-way traffic, provide a minimum roadway width of 22 feet (6.7 meters).

In locations with curves less than 400 ft radius provide additional lane width as necessary to accommodate vehicles.

Provide signing and public information for traffic control of wide vehicles and vehicles hauling trailers.

(i) Delete the text and substitute the following:

See project commitments and construction restrictions in 107.10 and 108.

Limit construction-caused delays to public traffic according to Table 156-1 and the following:

• For Schedule A, only one daytime closure zone at a time is permitted.

• No daytime closure zone is permitted for work on Schedule A from December 15 through February 15.

E-37

• No daytime closure zone is permitted for work on Schedule A when access to Highway 128 via North La Sal Loop Road is closed due to snow.

• For Option X, one full closure zone at a time is permitted. Provide access to Ken’s Lake at all times.

E-38

Table 156-1 Limitations on Construction Operations for Allowable Delays, Full and Day Closures

Schedule/ Option

Zone Station to

Station Type Day to

Day Time Remarks

A/X 11+62 to 650+91

Alternate one-way traffic

Sunday- Saturday

12:00 am Sunday - 11:59 pm Saturday

Limit delay to a maximum of 30 minutes during active construction.

Limit delay to time required to pass traffic each way during non-active construction.

X 11+47 to 44+00

Full closure

Sunday- Saturday

12:00 am Sunday - 11:59 pm Saturday

Sta. 11+62 Beginning of Project- Old Airport Road to Sta. 44+00 Y-intersection to Private Aggregate Pit

X 44+00 to 87+78

Full closure

Sunday- Saturday

12:00 am Sunday - 11:59 pm Saturday

Sta. 44+00 Y- intersection to Private Aggregate Pit to Sta. 87+78 Ken’s Lake Cutoff

X 87+78 to 147+00

Full closure

Sunday- Saturday

12:00 am Sunday - 11:59 pm Saturday

Sta. 87+78 Ken’s Lake Cutoff to Sta.

147+00 Pack Creek Cutoff

A 147+00 to 284+23

Alternate one-way traffic

Sunday- Saturday

12:00 am Sunday - 11:59 pm Saturday

Limit delay to a maximum of 30 minutes during active construction.

Limit delay to time required to pass traffic each way during non-active construction.

Sta. 147+00 Pack Creek Cutoff to Sta.

284+23 Hardgrave Road

A 284+23 to 523+96

Daytime closure

Monday- Friday

8:30 am Monday - 5:30 pm Friday

Sta. 284+23 Hardgrave Road to Sta.

523+96 Private Property Access

A 523+96 to 617+43

Daytime closure

Monday- Friday

8:30 am Monday - 5:30 pm Friday

Sta. 523+96 Private Property Accesses to Sta. 617+32 Geyser Pass Road.

Daytime closure allowed for only one construction season between station Sta.

545+00 to Sta. 650+91.

A 617+43 to 650+91

Daytime closure

Monday- Friday

8:30 am Monday - 5:30 pm Friday

Sta. 617+32 Geyser Pass Road to 650+91 end of project.

Note: A week begins on 12:00am Sunday, and ends at 11:59pm Saturday.

*FAILURE TO ACKNOWLEDGE THIS AMENDMENT IN BLOCK 19 OF THE SF 1442 BY THE DESIGNATED DATE AND HOUR SPECIFIED IN THE SOLICITATION MAY RESULT IN REJECTION OF YOUR BID (REFER TO ITEM 11.)

CENTRAL FEDERAL LANDS HIGHWAY DIVISION

12300 WEST DAKOTA AVENUE, SUITE 360

LAKEWOOD, COLORADO 80228

ATTENTION: RYAN PHILLIPS