Revised RFQ 6973GH-22-Q-00045.pdf

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

CS-22-00310

AAQ-722 DIVERSIFIED FRANCHISE ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ0722-AFN

OKLAHOMA CITY OK 73125

FAA, Mike Monroney Aeronautical Center

Attn: Jason Fox, AAQ-722 6500 S. MacArthur BLVD. BLDG 014-AHQ, RM 233A Oklahoma City, OK 73169

Jason Fox

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

405-954-4940 Jason.A.Fox@faa.gov

112/22/2021 24

PURCHASE REQUEST NO.

6973GH-22-Q-00045

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date) o Proposals are due on March 14, 2022 at 5:00 pm CST. Proposals will not be accepted after this timeframe.

o This acquisition is Set Aside for Total Small Business.

o The estimated price range of this procurement is $23,000 - $47,000.

o Please see the Specifications for the Building Improvements – Siding, Doors, and

Paint at the LLANO (LLO), TX VOR; Dated 08/18/201, 34 pages.

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

15 10 calendar days and complete it within ________________ ________________ calendar days after receiving x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

Jason A Fox Highlight

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

AAQ-722 DIVERSIFIED FRANCHISE ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ722-AFN

OKLAHOMA CITY OK 73125

Janice K. Hammonds

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

x

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 24

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

6973GH-22-Q-00045

(A) (B) (C) (D) (E) (F)

Period of Performance: 11/18/2021 to 09/30/2022

JCN: 20011127

00001 The contractor is responsible for furnishing all materials (unless noted otherwise in the contract documents), equipment, labor, transportation, insurance, notifications, licenses, permits, fees and supervision necessary for the Building

Improvements- Siding, Floor and Painting at the

LLANO (LLO), TX VOR in accordance with the applicable drawings, specifications and conditions of the contract.

Electronic & IT: 03

Total Bid

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Section -- - Terms and Conditions Terms and Conditions List

(a) The contractor is responsible for accomplishing all items of work in accordance with the applicable drawings, SOW and attachments. Additional labor, materials, equipment, and/or appurtenances not specifically detailed or specified, but required to complete the project, must be provided by the contractor as an integral part of the scope of work specified. All work performed and any materials and equipment used will be subject to approval by the Contracting Officer Representative (COR) and Contracting Officer (CO). This shall include but not be limited to testing, inspection, scheduling, reporting, and submittals.

(b) Limit work to normal business working hours of 7:00 a.m. to 5:00 p.m., Monday through Friday, unless otherwise indicated, amounting to a total of 40 hours/week. No work shall be scheduled or performed on Saturdays, Sundays, federal holidays, or during holiday maintenance moratorium periods, unless approved by the FAA in writing. Deviation from this work schedule may be discussed prior to the Notice to Proceed date during the Pre-Construction Conference. Additional changes/requests to agreed upon work schedule shall be submitted to the COR and forwarded to the CO for approval. All work beyond normal work hours shall be requested in writing to the COR 48 hours in advance.

(c) The contractor must coordinate and report each day's work in advance with the Resident Engineer/COR.

The contractor will not be allowed access to or to work at the site without the RE/COR on site to serve as an escort.

(d) By submission of this offer, the offeror attests that all representations and certifications as reflected in the System for Award Management (SAM) are current and accurate as of the date the offer is submitted. The offeror shall provide immediate written notice to the Contracting Officer if at any time prior to award the offeror learns that any certification or representation in SAM was erroneous when this offer was submitted or has become erroneous by reason of changed circumstances.

(e) Specific attention is invited to AMS paragraph 3.2.2.3.1.2.2, Communications with Offerors. The FAA may communicate with one or more Offerors at any time during the RFQ process. Communications with one Offeror do not necessitate communications with other Offerors, since communications will be Offeror-specific. Information determined to have common application and not considered prejudicial to Offerors will be communicated to all Offerors.

(f) It is anticipated that price analysis will be based on adequate price competition; therefore, vendors are not required to submit cost or pricing data with its quote. However, if after receipt of offers it is determined that adequate price competition does not exist, uncertified, yet detailed, cost or pricing data may be required.

(g) Inspection and Acceptance. The Contractor must only tender for acceptance those supplies or services that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair, replacement or re-performance will not correct the defects or is not possible to correct the defects in a time period deemed reasonable by the Government, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights.

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(h) The Contractor warrants that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier. (see clause 3.10.1-20 in the QVL SIR 6973GH-20-R-00040 Amendment 1)

(i) This RFQ will be awarded on the basis of the lowest priced quotation received.

(j) This RFQ is not to be construed as a contract or a commitment of any kind. The Government shall not be liable for payment of any costs attributed to the preparation and submission of quotes.

(k) Clause List: the clauses from the QVL SIR 6973GH-20-R-00040 are applicable to this requirement. The clauses listed below are in addition to the clauses on the QVL SIR.

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JUL 2018)

3.2.2.3-42 DIFFERING SITE CONDITIONS (JUL 2004)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (JUL 2004)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2004)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2004)

3.2.2.3-58 LAYOUT OF WORK (MAR 2009)

3.2.2.3-82 PROHIBITION ON CONDUCTING RESTRICTED BUSINESS OPERATIONS IN SUDAN

- CERTIFICATION (JUL 2012)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 2021)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2019)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2019)

3.2.5-7 DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (JAN 2022)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-10 AVAILABILITY OF FUNDS (APR 2014)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2021)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (JUL 2018)

3.3.1-40 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (JAN 2021)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2020)

3.4.1-13 ERRORS AND OMISSIONS (JUL 1996)

3.6.1-1 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (OCT 2019)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (JUL 2021)

3.6.2-9 EQUAL OPPORTUNITY (JUL 2020)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (JUL 2020)

3.6.2-18 DAVIS BACON ACT (OCT 2018)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2017)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (JAN 2019)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (JAN 2019)

3.6.2-39 TRAFFICKING IN PERSONS (APR 2019)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JAN 2019)

3.6.2-46 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JAN 2022)

3.6.3-4 RECYCLED CONTENT PRODUCTS CERTIFICATION (OCT 2016)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (JAN 2020)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (JAN 2020)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (JAN 2020)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.4-5 BUY AMERICAN - STEEL AND MANUFACTURED PRODUCTS (JAN 2022)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.4-23 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JAN 2021)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 1996)

3.10.1-16 CHANGES AND CHANGED CONDITIONS (APR 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV

1997)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (JAN 2018)

3.2.2.3-41 PERFORMING WORK (JUL 2004)

The Contractor (you) must perform, using your own organization, work equivalent to at least 51 percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if you request a reduction and the CO determines that it would be to the Government's advantage to do so.

(End of clause)

3.2.2.3-44 PHYSICAL DATA (JUL 2004)

Data and information the FAA (we, us) provides or refers to below is for the Contractor's (your) information. We are not responsible for your interpretation of or conclusions based on the data or information. Further, we do not warrant construction methodology which may be included in these documents.

(a) The descriptions of physical conditions on the drawings and in the specifications are the result of site investigations by the on-site engineer.

(b) Other relevant information it is the Contractor's responsibility to obtain weather patterns for the area, inspect the site in a manner which will provide the Contractor sufficient information concerning the site conditions in order to complete the project within the stated amount of time.

(End of clause)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009) - ALTERNATE

II (JUL 2004)

(a) If either the specifications or the drawings (but not both) mention tasks, the Contractor (you) must assume that the tasks are in both. If the drawings and specifications differ, the specifications govern. If there is a discrepancy in the figures, in the drawings, or in the specifications, submit the matter promptly to the Contracting Officer (CO), who will promptly determine which governs, and notify you in writing. Any adjustment you make without the CO's determination is at your own risk and expense. From time to time the CO will provide necessary detailed drawings and other information, unless otherwise provided.

(b) Wherever in the specifications or the drawings FAA (we, our) uses "directed," "required," "ordered," "designated," "prescribed," or similar words, they refer to the CO's requirements. Similarly, "approved," "acceptable," "satisfactory," or similar words refer to the CO's approval, unless otherwise expressly stated. You must have a complete set of plans and specifications on site and available for our use.

(c) Where we use "as shown," "as indicated," "as detailed," or similar words, they refer to the drawings accompanying this contract, unless stated otherwise. The word "provided" means "provided and installed."

(d) Omissions from the drawings and specifications or the erroneous description of details of work which are necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve you from performing those omitted or erroneously described details of the work. You must perform them as if fully and correctly set forth and described in the drawings and specifications.

(e) You must check all drawings we provide to you before starting work and must promptly notify the CO of any discrepancies. In general you should follow figures marked on drawings, rather than scale measurements. In general, large scale drawings have precedence over small scale drawings. You must compare all drawings and verify the figures before laying out the work. If you do not verify the figures, you will be responsible for any errors you might have avoided had you verified them.

(f) "Shop drawings" means drawings, you or any subcontractor submit to us under a construction contract, showing in detail the proposed fabrication and assembly of structural elements and the installation (that is, form, fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials you provided to explain in detail specific portions of the work the contract requires.

FAA may duplicate, use, and disclose in any manner and for any purpose shop drawings you deliver under this contract.

(g) If this contract requires material offers (for example, shop drawings, catalog cuts, certificates of conformance), you must coordinate all of your offers, and review them for accuracy, completeness, and compliance with contract requirements. You must provide evidence that you approve the submittals. If you submit materials to us without this evidence, we may return them and ask you to resubmit them. The CO will indicate whether he or she approves or disapproves your offer, and if the CO does not approve it as submitted, will indicate our reasons for rejecting it. Any work done before the CO's approval is at your risk. The CO's approval does not relieve you from responsibility for any errors or omissions in the submittals, nor from responsibility for complying with the contract requirements, except as described under (h).

(h) If you submittals vary from the contract requirements, you must describe the variations in writing, separate from the submittal, when you submit them. Send this description, a copy of the offer, and a proposal to incorporate it into the contract directly to the CO. If the CO approves a variation, the CO must issue an appropriate contract modification, unless the variation is minor or does not involve a change in price or in time of performance.

(i) You must submit to the CO for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. The CO will keep three sets (unless otherwise indicated) of all offers and will return one set to you.

(j) You must insert this clause, with appropriate changes in the designation of the parties, in all subcontracts.

(k) When you finish the work under this contract, you must provide the COR & CO one (1) complete sets of all shop drawings as we finally approve them. These drawings must show all changes and revisions made up to the time you finish the work and we accept it.

(End of clause)

3.2.2.3-63 SITE VISIT (CONSTRUCTION) (JUL 2004)

(a) AMS clauses 3.2.2.3-42, Differing Site Conditions, and 3.2.2.3-43, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded under this SIR. Accordingly, FAA urges and expects offerors to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: [Enter name] Address: [Enter address] [Enter City, State and zip code] Telephone:[Enter phone number]

(End of provision)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014) - ALTERNATE I (JUL 2004)

(a) Before beginning work, the Contractor (you) must:

(1) Perform a hazards analysis of the work specified in this contract. Consider both the site and adjacent conditions.

Identify all significant hazards. Some of the hazards you might encounter are falling from structures, tripping, electrical shock, fire, falling objects, environmental hazards, vehicular accidents, etc.

(2) Submit a safety plan for dealing with each specific hazard identified, whether you or FAA identified it.

(3) Meet with the CO's representatives during the preconstruction conference to discuss and to develop a mutual understanding about the content and implementation of the plan.

(4) The CO or her or his representatives may require other hazards to be added to the plan. If the CO determines that your planned hazard avoidance measures are insufficient, the CO or a designated representative may require you to revise the plan. You may not begin work involving identified hazards unless you have submitted adequate plans to the CO and the CO has reviewed them. This approval does not relieve you of your liability for safe performance.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (OCT 2021)

The Contractor must (a) begin work under this contract within 15 calendar days after the date you receive the notice to proceed, (b) perform the work diligently, and (c) complete the entire work ready for use not later than 10 calendar days after the Notice to Proceed is issued. The time allowed for completion must include final cleanup of the premises.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (OCT 2021) -

ALTERNATE I (OCT 2021)

The Contractor (you) must

(a) begin work under this contract within 15 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 10 calendar days after the Notice to Proceed is issued.. The time allowed for completion must include final cleanup of the premises.

(d) The completion date is based on the assumption that the successful offeror will receive the notice to proceed by to be determined. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds to FAA within the time specified in the offer.

(End of clause)

3.2.2.3-81 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS-REPRESENTATION (OCT 2015)

(a) Definition: "Inverted Domestic Corporation" and "subsidiary" are defined in AMS clause 3.2.2.3-83 "Contracting with Inverted Domestic Corporations."

(b) The FAA is not permitted to use appropriated or otherwise made available funds for contracts with either an inverted domestic corporation or a subsidiary of an inverted domestic corporation unless the requirement is waived in accordance with applicable AMS guidance)

(c) Representation. By submittal of its offer, the offeror represents that it is not an inverted domestic corporation and is not a subsidiary of one.

(End of Provision)

3.2.2.7-7 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2021)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that

(i) All representations and certifications as reflected in the System for Award Management (SAM) are current and accurate as of the date the proposal/offer is submitted. The offeror must provide immediate written notice to the Contracting Officer if at any time prior to award the Offeror and/or any of its Principals learns that any certification or representation in SAM was erroneous when this proposal/offer was submitted or has become erroneous by reason of changed circumstances. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, vetbiz.va.gov.

(ii) The Offeror and/or any of its Principals-

(A) Are [ ] are not [ ] presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have [ ] have not [ ] within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public- (Federal, state, or local) contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws or receiving stolen property; and (C) Are [ ] are not [ ] presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in subdivision (a)(1) (ii)(B) of this provision. (D) Have [ ], have not [ ], within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,000 for which the liability remains unsatisfied. (1) Federal taxes are considered delinquent if both of the following criteria apply: (i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (2) Examples- (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(E) The Offeror has [ ] has not [ ] within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) 'Principals,' for the purposes of this certification, means officers; directors; owners; partners; and, persons having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a subsidiary, division, or business segment, and similar positions). THIS CERTIFICATION CONCERNS A

MATTER WITHIN THE JURISDICTION OF AN AGENCY OF THE UNITED STATES AND THE MAKING

OF A FALSE, FICTITIOUS, OR FRAUDULENT CERTIFICATION MAY RENDER THE MAKER SUBJECT

TO PROSECUTION UNDER SECTION 1001, TITLE 18, UNITED STATES CODE.

(b) The Offeror must provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this SIR. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing must be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this SIR for default.

(End of provision)

3.2.2.7-9 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY

OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (JAN 2017)

(a) As required by sections 745 and 746 of Title VII, Government-Wide General Provisions, of the Consolidated Appropriations Act, 2016 (Public Law 114-113), and similar provisions, if contained in subsequent appropriations acts, the FAA will not enter into a contract with any corporation that-

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the FAA is aware of the unpaid tax liability, unless the FAA has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the FAA is aware of the conviction, unless the FAA has considered suspension or debarment of the corporation and made a determination that the action is not necessary to protect the interests of the Government.

(b) The offeror represents that-

(1) It is ____ is not ____ a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is ____ is not ____ a corporation that was convicted of a felony criminal violation under a Federal criminal law within the preceding 24 months.

(End of provision)

3.2.2.8-5 LIQUIDATED DAMAGES - CONSTRUCTION (OCT 2019)

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor must pay to FAA as liquidated damages, the sum of $670.12 for each day of delay.

(b) If FAA terminates the Contractor's right to proceed, the resulting damage will consist of liquidated damages until such reasonable time as may be required for final completion of the work, together with any increased costs to FAA in completing the work.

(c) If FAA does not terminate the Contractor's right to proceed, the resulting damage will consist of liquidated damages until the work is completed or accepted.

(End of clause)

3.2.4-1 TYPE OF CONTRACT (APR 1996)

The FAA contemplates award of a Firm Fixed Price construction contract resulting from this Screening Information Request.

(End of provision)

Jason A Fox Highlight

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (OCT 2021)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number (i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or (ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information: (i) Company legal business. (ii) Tradestyle, doing business, or other name by which your entity is commonly recognized. (iii) Company Physical Street Address, City, State, and ZIP Code. (iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address). (v) Company Telephone Number. (vi) Date the company was started. (vii) Number of employees at your location. (viii) Chief executive officer/key manager. (ix) Line of business (industry). (x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, https://vetbiz.va.gov/vip//.

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor must provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) Change the name in the SAM database; (B) Comply with the requirements of AMS regarding novation and change-of-name agreements; and (C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor must not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees must be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.3.1-35 CERTIFICATION OF REGISTRATION IN SYSTEM FOR AWARD MANAGEMENT (AUG

2012)

In accordance with Clause 3.3.1-33, System for Award Management (SAM), offeror certifies that they are registered in the SAM Database and have entered all mandatory information including the DUNS or DUNS+4 Number.

Name: ______________________________

Title: _______________________________

Phone Number: _______________________

(End of provision)

3.3.1-41 ELECTRONIC INVOICING - REPRESENTATION (JAN 2021)

(a) The FAA intends to use electronic invoicing as per AMS clause 3.3.1-40 "Electronic Submission of Payment Requests" for this contract when it is awarded. Offerors must indicate whether they are currently using this form of electronic invoicing on other contract(s), or can easily adapt to it upon award of the contract. [ ] Yes [ ] No

(b) If an offeror indicates "No" the offeror must explain in this space why a waiver of this requirement should be approved in the event they were awarded the contract.

(c) Waiver requests will be handled per (f) of clause 3.3.1-40.

3.6.1-17 NORTH AMERICAN INDUSTRY CLASSIFICATION SYSTEM (NAICS) CODE (JAN 2021)

The North American Industry Classification System (NAICS) code for this procurement is:

238990 Building and Property Specialty Trade Services.

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

Jason A Fox Highlight

The small business size standard as defined by the Small Business Administration (SBA) is the following:

For NAICS codes based on SBA's calculation of annual receipts, the annual average receipts cannot exceed $16.5 million.

For NAICS codes based on the number of employees, the average number of employees over the last twelve-month period cannot exceed N/A.

(End of provision)

3.6.2-5 CERTIFICATION OF NONSEGREGATED FACILITIES (MAR 2009)

(a) 'Segregated facilities,' as used in this provision, means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees, that are segregated by explicit directive or are in fact segregated on the basis of race, color, religion, or national origin because of habit, local custom, or otherwise.

(b) By the submission of this offer, the offeror certifies that it does not and will not maintain or provide for its employees any segregated facilities at any of its establishments, and that it does not and will not permit its employees to perform their services at any location under its control where segregated facilities are maintained. The offeror agrees that a breach of this certification is a violation of the "Equal Opportunity" clause in the contract.

(c) The offeror further agrees that (except where it has obtained identical certifications from proposed subcontractors for specific time periods) it will--

(1) Obtain identical certifications from proposed subcontractors before the award of subcontracts under which the subcontractor will be subject to the "Equal Opportunity" clause;

(2) Retain the certifications in the files; and

(3) Forward the following notice to the proposed subcontractors (except if the proposed subcontractors have submitted identical certifications for specific time periods):

NOTICE TO PROSPECTIVE SUBCONTRACTORS OF REQUIREMENT FOR CERTIFICATIONS OF

NONSEGREGATED FACILITIES

A Certification of Nonsegregated Facilities must be submitted before the award of a subcontract under which the subcontractor will be subject to the "Equal Opportunity" clause. The certification may be submitted either for each subcontract or for all subcontracts during a period (i.e., quarterly, semiannually, or annually).

Note: The penalty for making false statements in offers is prescribed in 18 U.S.C. 1001.

(End of provision)

3.6.2-6 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (MAY 1997)

The offeror represents that--(a) It ( ) has, ( ) has not, participated in a previous contract or subcontract subject either to the "Equal Opportunity" clause of this solicitation, the clause originally contained in Section 310 of Executive Order No. 10925, or the clause contained in Section 201 of Executive Order No. 11114; (b) It ( ) has, ( ) has not, filed all required compliance reports; and (c) Representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards.

(End of provision)

3.6.2-14 EMPLOYMENT REPORTS ON VETERANS (JAN 2020)

Jason A Fox Highlight

(a) Unless the contractor is a State or local government agency, the contractor must report at least annually, as required by the Secretary of Labor, on:

(1) The total number of employees in the contractor's workforce, by job category and hiring location, who are disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans,

(2) The total number of new employees hired during the period covered by the report, and of the total, the number of disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans; and

(3) The maximum number and minimum number of employees of the Contractor or subcontractor at each hiring location during the period covered by the report.

(b) The above items must be reported by completing the VETS-4212 "Federal Contractor Veterans' Employment Report" (see "VETS-4212 Federal Contractor Reporting" and "Filing Your VETS-4212 Report" at http://www.dol.gov/vets/vets4212.htm).'

(c) The VETS-4212 Report must be submitted no later than September 30 of each year.

(d) The employment activity report required by paragraph (a)(2) of this clause must reflect total hires during the most recent 12-month period as of the ending date selected for the employment profile report required by paragraph (a)(1) of this clause. Contractors may select an ending date: (1) As of the end of any pay period during the period January through March 1st of the year the report is due, or (2) as of December 31, if the contractor has previous written approval from the Equal Employment Opportunity Commission to do so for purposes of submitting the Employer Information Report EEO-1 (Standard Form 100).

(e) The count of veterans reported according to paragraph (a) of this clause must be based on data known to the contractor when completing the VETS-4212. The Contractor's knowledge of veterans status may be obtained in a variety of ways, including an invitation to applicants to self-identify (in accordance with 41 CFR 60-300.42), voluntary self-disclosure by employees, or actual knowledge of veteran status by the contractor. This paragraph does not relieve the employer of liability for a determination under 38 U.S.C. 4212.

(f) Subcontracts. The Contractor must include the terms of this clause in every subcontract or purchase order of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor.

(End of clause)

3.6.3-12 ASBESTOS - FREE CONSTRUCTION (APR 2017)

(a) In performing this contract, the Contractor must not use asbestos or asbestos-containing building materials during construction, renovation, and/or modernization of this facility.

(b) The Contractor must provide to the Contracting Officer (CO) a signed statement [CO state due date of statement here related to completion of the project] indicating that no asbestos or asbestos-containing building materials were used during construction, renovation, and/or modernization of this facility. The Contractor's certification under this clause is considered to be a material requirement of the contract and the FAA may withhold payment pending submittal and receipt of an acceptable certification.

(c) The FAA retains the right to conduct sampling of contractor building materials used during construction, renovation, and/or modernization of this facility to verify that they are asbestos-free. If asbestos-containing material is found, the Contractor must bear the expense of the sampling conducted by the FAA, remove and replace the asbestos-containing material and decontaminate the site of asbestos contamination caused by the Contractor at no additional cost to the Government. In addition, the Contractor must bear the expense of all testing (bulk sampling and air sampling conducted by the contactor and the FAA) to determine that the asbestos removal and site decontamination are satisfactorily completed. The Contractor must follow all applicable federal, state, and local asbestos regulatory requirements as well as applicable FAA Orders with respect to asbestos abatement when the Contractor is required to remove asbestos materials they have installed.

(End of clause)

3.6.3-22 CONSTRUCTION WASTE MANAGEMENT (JAN 2020)

(a) In performance of this contract, the Contractor must establish a program to minimize waste generation, as well as recycle, reuse, and salvage construction and demolition (C&D) debris generated to the maximum extent possible.

Before commencing work, the Contractor must submit a Waste Management Plan to the Contracting Officer within 15 days after contract award prior to the start of construction activities. This plan must address the following:

(1) General: Provide an overall strategy for managing C&D debris associated with the project.

(2) Waste Identification: Indicate anticipated types and quantities by weight of demolition, site-clearing and construction…