GenerateSF1442.pdf

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

���� #$��%&'(�)'%(�*#�++��$,-&�.$(/%(0�&)$ )�+$&1�(�1�2*��&1�)%0.+$'$�-'�3-'#-& )�+$&1�(�1�2*��/'$(�($)$-4-&, &%'-)$�'%�.(%)$$1��� #-*�.$(/%(0�&)$�.$(-%1�-*�3�(15 0�&1�'%(2 &$,%'-��+$������� ��

�������������� �7

1� �//$(*�.(%4-1-&,�+$**�'#�& )�+$&1�(�1�2*�/%(��%4$(&0$&'��))$.'�&)$��/'$(�'#$�1�'$�%//$(*��($�18$�3-++�&%'��$�)%&*-1$($1��&1�3-++��$

($9$)'$1�

++�%//$(*��($�*8�9$)'�'%�'#$�"�:�3%(;�($<-8($0$&'*5��&1�"�:�%'#$(�.(%4-*-%&*��&1�)+�8*$*�-&)%(.%(�'$1�-&�'#$�*%+-)-'�'-%&�-&�/8++�'$='�%(��2

&�%//$(�,8�(�&'$$ -*5 -*�&%'�($<8-($1�

�����$�+$1�%//$(*�-&�%(-,-&�+��&1 )%.-$*�'%�.$(/%(0�'#$�3%(;�($<8-($1��($�18$��'�'#$�.+�)$�*.$)-/-$1�-&��'$0����2 ���� �

+%)�+�'-0$ "1�'$:����/�'#-*�-*���*$�+$1��-1�*%+-)-'�'-%&5�%//$(*�3-++��$�.8�+-)+2�%.$&$1��'�'#�'�'-0$����$�+$1�$&4$+%.$*

)%&'�-&-&,�%//$(*�*#�++��$�0�(;$1�'%�*#%3�'#$�%//$(%(>*�&�0$��&1��11($**5�'#$�*%+-)-'�'-%&�&80�$(5��&1�'#$�1�'$��&1�'-0$�%//$(*��($�18$�

������"�����@A�?:

�($*)(-�$1��2��� �A��

��"@�����:�?����BA�"1:

See Attached

6. PROJECT PLAN

OFFER (Must be fully completed by offeror)

�B������

��� #$�%//$(%(��,($$*�'%�.$(/%(0�'#$�3%(;�($<8-($1��'�'#$�.(-)$*�*.$)-/-$1��$+%3�-&�*'(-)'��))%(1�&)$�3-'#�'#$�'$(0*�%/�'#-*�*%+-)-'�'-%&5�-/�'#-*�%//$(�-*��))$.'$1

�2�'#$��%4$(&0$&'�-&�3(-'-&,�3-'#-& )�+$&1�(�1�2*��/'$(�'#$�1�'$�%//$(*��($�18$������&

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

AWARD (To be completed by Government)

�B��

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

'%�/8(&-*#��&1�1$+-4$(��++� -'$0*�%(�.$(/%(0��++�3%(;�($<8-($0$&'*�-1$&'-/-$1�%&�'#-* /%(0��&1��&2�)%&'-&8�'-%&�*#$$'*�/%(�'#$�)%&*-1$(�'-%&�*'�'$1�-&�'#-*�)%&'(�)'��� #$ (-,#'*��&1�%�+-,�'-%&*�%/�'#$�.�('-$*�'%�'#-*�)%&'(�)'�*#�++��$�,%4$(&$1��2�"�:�'#-* )%&'(�)'� �3�(15� "�:� '#$� *%+-)-'�'-%&5� �&1� "):� '#$� )+�8*$*5� ($.($*$&'�'-%&*5 )$('-/-)�'-%&*5� �&1� *.$)-/-)�'-%&*� -&)%(.%(�'$1� �2� ($/$($&)$� -&� %(� �''�)#$1� '%� '#-*

�E��

%8(�%//$(

%&�'#-*�*%+-)-'�'-%&�-*�#$($�2��))$.'$1��*�'%�'#$�-'$0*�+-*'$1��� #-*��3�(1�)%&*800�'$* '#$�)%&'(�)'5�3#-)#�)%&*-*'*�%/�"�:�'#$��%4$(&0$&'�*%+-)-'�'-%&��&1�2%8(�%//$(5��&1�"�:

'#-*�)%&'(�)'��3�(1����%�/8('#$(�)%&'(�)'8�+�1%)80$&'�-*�&$)$**�(2�

������"�����@A�?:�����

RECOVERY ACT 2009

Sam M. Gibbons U.S. Courthouse, Tampa, FL

MEP UPGRADE PROJECT

Award of contract is subject to availability of funds IAW FAR 52.232-18 Availability of Funds.

Funds are not presently available for this contract. The Governments obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer ARRA Project - Sam M. Gibbons MEP ARRA Funded Project No. VFL01233 Design-Build project to provide general Mechanical, Electrical and Plumbing upgrades, repairs and alterations to the existing Sam M. Gibbons U. S. Courthouse

0001 ARRA Funded

DELIVERY DATE: 04/28/2010

SHIP TO:

GSA,PBS, Real Estate, Design & Construction (4PG) 401 W Peachtree St Atlanta GA 30308

FOB : Destination

1.00 EA

SCHEDULE Continued

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

SECTION 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

00100. 1 52.215-1 INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN 2004)

00100. 2 52.215-16 FACILITIES CAPITAL COST OF MONEY (JUN 2003)

00100. 3 52.215-20 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR PRICING

DATA (OCT 1997)

00100. 4 52.215-20 I REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA (OCT 1997)--ALTERNATE I (OCT 1997)

00100. 5 52.215-20 III REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA (OCT 1997)--ALTERNATE III (OCT 1997)

00100. 6 52.215-5 FACSIMILE PROPOSALS (OCT 1997)

00100. 7 52.216-1 TYPE OF CONTRACT (APR 1984)

00100. 8 52.222-5 DAVIS-BACON ACT -- SECONDARY SITE OF THE WORK (JUL 2005)

00100. 9 52.225-10 NOTICE OF BUY AMERICAN ACT REQUIREMENT--CONSTRUCTION MATERIALS (FEB 2009)

00100. 10 52.233-2 SERVICE OF PROTEST (SEP 2006)

00100. 11 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

00100. 12 52.236-27 I SITE VISIT (CONSTRUCTION) (FEB 1995)--ALTERNATE I (FEB 1995)

00100. 13 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

00100. 14 552.236-73 BASIS OF AWARD--CONSTRUCTION CONTRACT (APR 1985)

SECTION 00600 REPRESENTATIONS AND CERTIFICATIONS

00600. 1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (FEB 2009)

00600. 2 52.236-28 PREPARATION OF PROPOSALS--CONSTRUCTION (OCT 1997)

SECTION 00700 CONTRACT CLAUSES

00700. 1 52.202-1 DEFINITIONS (JUL 2004)

00700. 2 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997)

00700. 3 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (SEP 2007)

00700. 4 52.203-3 GRATUITIES (APR 1984)

00700. 5 52.203-5 COVENANT AGAINST CONTINGENT FEES (APR 1984)

00700. 6 52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (SEP 2006)

00700. 7 52.203-7 ANTI-KICKBACK PROCEDURES (JUL 1995)

00700. 8 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(JAN1997)

00700. 9 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON RECYCLED PAPER (AUG 2000)

00700. 10 52.204-7 CENTRAL CONTRACTOR REGISTRATION (APR 2008)

00700. 11 52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (SEP 2007)

00700. 12 52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (SEP 2006)

00700. 13 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

00700. 14 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

00700. 15 52.211-13 TIME EXTENSIONS (SEP 2000)

00700. 16 52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2004)

00700. 17 52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

00700. 18 52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER THAN

PENSIONS (JUL 2005)

00700. 19 52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

00700. 20 52.215-2 AUDIT AND RECORDS--NEGOTIATION (MAR 2009)

00700. 21 52.215-21 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA--MODIFICATIONS (OCT 1997)

00700. 22 52.215-21 I REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA--MODIFICATIONS (OCT 1997)--ALTERNATE II (OCT 1997)

00700. 23 52.215-21 III REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA--MODIFICATIONS (OCT 1997)--ALTERNATE III (OCT 1997)

00700. 24 52.219-14 LIMITATIONS ON SUBCONTRACTING (DEC 1996)

00700. 25 52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REPRESENTATION (APR 2009)

00700. 26 52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (MAY 2004)

00700. 27 52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

Table of Contents

00700. 28 52.222-11 SUBCONTRACTS (LABOR STANDARDS) (JUL 2005)

00700. 29 52.222-12 CONTRACT TERMINATION--DEBARMENT (FEB 1988)

00700. 30 52.222-13 COMPLIANCE WITH DAVIS-BACON AND RELATED ACT REGULATIONS (FEB 1988)

00700. 31 52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

00700. 32 52.222-15 CERTIFICATION OF ELIGIBILITY (FEB 1988)

00700. 33 52.222-20 WALSH-HEALEY PUBLIC CONTRACTS ACT (DEC 1996)

00700. 34 52.222-21 PROHIBITION OF SEGREGATED FACILITIES (FEB 1999)

00700. 35 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT

OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

00700. 36 52.222-26 EQUAL OPPORTUNITY (MAR 2007)

00700. 37 52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (FEB 1999)

00700. 38 52.222-3 CONVICT LABOR (JUN 2003)

00700. 39 52.222-35 EQUAL OPPORTUNITY FOR SPECIAL DISABLED VETERANS, VETERANS OF THE VIETNAM ERA, AND OTHER ELIGIBLE VETERANS. [SEP 2006]

00700. 40 52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (JUN 1998)

00700. 41 52.222-37 EMPLOYMENT REPORTS ON SPECIAL DISABLED VETERANS, VETERANS OF THE VIETNAM ERA, AND OTHER ELIGIBLE VETERANS (SEP 2006)

00700. 42 52.222-39 NOTIFICATION OF EMPLOYEE RIGHTS CONCERNING PAYMENT OF UNION DUES OR FEES (DEC

2004)

00700. 43 52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT--OVERTIME COMPENSATION (JUL

2005)

00700. 44 52.222-50 COMBATING TRAFFICKING IN PERSONS (FEB 2009)

00700. 45 52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (JAN 2009)

00700. 46 52.222-6 DAVIS-BACON ACT (JUL 2005)

00700. 47 52.222-7 WITHHOLDING OF FUNDS (FEB 1988)

00700. 48 52.222-8 PAYROLLS AND BASIC RECORDS (FEB 1988)

00700. 49 52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

00700. 50 52.223-14 TOXIC CHEMICAL RELEASE REPORTING (AUG 2003)

00700. 51 52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (DEC 2007)

00700. 52 52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND CONSTRUCTION

CONTRACTS (MAY 2008)

00700. 53 52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION

CONTRACTS (DEC 2007)

00700. 54 52.223-3 I HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN 1997)--

ALTERNATE I (JUL 1995)

00700. 55 52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (AUG 2003)

00700. 56 52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

00700. 57 52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-DESIGNATED ITEMS

(MAY2008)

00700. 58 52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

00700. 59 52.225-9 BUY AMERICAN ACT--CONSTRUCTION MATERIALS (FEB 2009)

00700. 60 52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

00700. 61 52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (DEC 2007)...25

00700. 62 52.227-4 PATENT INDEMNITY--CONSTRUCTION CONTRACTS (DEC 2007)

00700. 63 52.228-11 PLEDGES OF ASSETS (SEP 2009)

00700. 64 52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (OCT 1995)

00700. 65 52.228-14 IRREVOCABLE LETTER OF CREDIT (DEC 1999)

00700. 66 52.228-15 PERFORMANCE AND PAYMENT BONDS--CONSTRUCTION (NOV 2006)

00700. 67 52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

00700. 68 52.229-4 FEDERAL, STATE, AND LOCAL TAXES (STATE AND LOCAL ADJUSTMENTS) (APR 2003)

00700. 69 52.232-17 INTEREST (OCT 2008)

00700. 70 52.232-23 ASSIGNMENT OF CLAIMS (JAN 1986)

00700. 71 52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (OCT 2008)

00700. 72 52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER--CENTRAL CONTRACTOR REGISTRATION (OCT

2003)

00700. 73 52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (SEP 2002)

00700. 74 52.233-1 DISPUTES (JUL 2002)

00700. 75 52.233-1 I DISPUTES (JUL 2002)--ALTERNATE I (DEC 1991)

00700. 76 52.233-3 PROTEST AFTER AWARD (AUG 1996)

00700. 77 52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

00700. 78 52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

00700. 79 52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

00700. 80 52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

00700. 81 52.236-12 CLEANING UP (APR 1984)

00700. 82 52.236-13 ACCIDENT PREVENTION (NOV 1991)

00700. 83 52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

00700. 84 52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

00700. 85 52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

00700. 86 52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

00700. 87 52.236-21 I SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)--ALTERNATE I (APR

1984)

00700. 88 52.236-21 II SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)--ALTERNATE II (APR

1984)

00700. 89 52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

00700. 90 52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

00700. 91 52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

00700. 92 52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

00700. 93 52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

00700. 94 52.236-8 OTHER CONTRACTS (APR 1984)

00700. 95 52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

00700. 96 52.242-13 BANKRUPTCY (JUL 1995)

00700. 97 52.242-14 SUSPENSION OF WORK (APR 1984)

00700. 98 52.243-4 CHANGES (JUN 2007)

00700. 99 52.244-2 SUBCONTRACTS (JUN 2007)

00700. 100 52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (AUG 2009)

00700. 101 52.245-1 GOVERNMENT PROPERTY (JUN 2007)

00700. 102 52.245-2 GOVERNMENT PROPERTY INSTALLATION OPERATION SERVICES (JUN 2007)

00700. 103 52.245-9 USE AND CHARGES (JUN 2007)

00700. 104 52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

00700. 105 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

00700. 106 52.246-21 I WARRANTY OF CONSTRUCTION (MAR 1994)--ALTERNATE I (APR 1984)

00700. 107 52.248-3 VALUE ENGINEERING--CONSTRUCTION (SEP 2006)

00700. 108 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

00700. 109 52.249-2 I TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (MAY 2004)--

ALTERNATE I (SEP 1996)

00700. 110 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

00700. 111 52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

00700. 112 552.203-71 RESTRICTION ON ADVERTISING (SEP 1999)

00700. 113 552.211-71 STANDARD REFERENCES (SEP 1999)

00700. 114 552.211-72 REFERENCES TO SPECIFICATIONS IN DRAWINGS (FEB 1996)

00700. 115 552.211-84 NON-COMPLIANCE WITH CONTRACT REQUIREMENTS (FEB 1996)

00700. 116 552.215-70 EXAMINATION OF RECORDS BY GSA (FEB 1996)

00700. 117 552.219-74 SECTION 8(A) DIRECT AWARD (SEP 1999)

00700. 118 552.228-5 GOVERNMENT AS ADDITIONAL INSURED (MAY 2009)

00700. 119 552.232-70 INVOICE REQUIREMENTS (SEP 1999)

00700. 120 552.232-78 PAYMENT INFORMATION (JUL 2000)

00700. 121 552.236-70 DEFINITIONS (APR 1984)

00700. 122 552.236-71 AUTHORITIES AND LIMITATIONS (APR 1984)

00700. 123 552.236-72 SPECIALIST (APR 1984)

00700. 124 552.236-74 WORKING HOURS (APR 1984)

00700. 125 552.236-75 USE OF PREMISES (APR 1984)

00700. 126 552.236-76 MEASUREMENTS (APR 1984)

00700. 127 552.236-77 SPECIFICATIONS AND DRAWINGS (SEP 1999)

00700. 128 552.236-78 SHOP DRAWINGS, COORDINATION DRAWINGS, AND SCHEDULES (SEP 1999)

00700. 129 552.236-79 SAMPLES (APR 1984)

00700. 130 552.236-80 HEAT (APR 1984)

00700. 131 552.236-81 USE OF EQUIPMENT BY THE GOVERNMENT (APR 1984)

00700. 132 552.236-82 SUBCONTRACTS (APR 1984)

00700. 133 552.243-71 EQUITABLE ADJUSTMENTS (JAN 2009)

00700. 134 552.246-72 FINAL INSPECTION AND TESTS (SEP 1999)

00700. 135 552.246-75 GUARANTEES (MAY 1989)

SECTION 00100

INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

00100. 1 52.215-1 INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN 2004)

(Reference 52.215-1)

00100. 2 52.215-16 FACILITIES CAPITAL COST OF MONEY (JUN 2003)

(Reference 52.215-16)

00100. 3 52.215-20 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR PRICING

DATA (OCT 1997)

(a) "Exceptions from cost or pricing data."

(1) In lieu of submitting cost or pricing data, offerors may submit a written request for exception by submitting the information described in the following paragraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable.

(i) "Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) "Commercial item exception." For a commercial item exception, the offeror shall submit, at a minimum, information on prices at which the same item or similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include--

(A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities;

(B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market;

(C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(2) The offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the offeror's determination of the prices to be offered in the catalog or marketplace.

(b) "Requirements for cost or pricing data." If the offeror is not granted an exception from the requirement to submit cost or pricing data, the following applies:

(1) The offeror shall prepare and submit cost or pricing data and supporting attachments in accordance with Table 15-2 of FAR 15.408.

(2) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2.

(End of Provision)

00100. 4 52.215-20 I REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA (OCT 1997)--ALTERNATE I (OCT 1997)

(a) "Exceptions from cost or pricing data."

(1) In lieu of submitting cost or pricing data, offerors may submit a written request for exception by submitting the information described in the following paragraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable.

(i) "Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) "Commercial item exception." For a commercial item exception, the offeror shall submit, at a minimum, information on prices at which the same item or similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include--

(A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities;

(B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market;

(C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(2) The offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the offeror's determination of the prices to be offered in the catalog or marketplace.

(b) "Requirements for cost or pricing data." If the offeror is not granted an exception from the requirement to submit cost or pricing data, the following applies:

(1) The offeror shall submit cost or pricing data and supporting attachments in the following format:

(2) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2.

(End of Provision)

00100. 5 52.215-20 III REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA (OCT 1997)--ALTERNATE III (OCT 1997)

(a) "Exceptions from cost or pricing data."

(1) In lieu of submitting cost or pricing data, offerors may submit a written request for exception by submitting the information described in the following paragraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable.

(i) "Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) "Commercial item exception." For a commercial item exception, the offeror shall submit, at a minimum, information on prices at which the same item or similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include--

(A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities;

(B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market;

(C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(2) The offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the offeror's determination of the prices to be offered in the catalog or marketplace.

(b) "Requirements for cost or pricing data." If the offeror is not granted an exception from the requirement to submit cost or pricing data, the following applies:

(1) The offeror shall prepare and submit cost or pricing data and supporting attachments in accordance with Table 15-2 of FAR 15.408.

(2) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2.

(c) Submit the cost portion of the proposal via the following electronic media:

(End of Provision)

00100. 6 52.215-5 FACSIMILE PROPOSALS (OCT 1997)

(a) "Definition." "Facsimile proposal," as used in this provision, means a proposal, revision or modification of a proposal, or withdrawal of a proposal that is transmitted to and received by the Government via facsimile machine.

(b) Offerors may submit facsimile proposals as responses to this solicitation. Facsimile proposals are subject to the same rules as paper proposals.

(c) The telephone number of receiving facsimile equipment is:

(d) If any portion of a facsimile proposal received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document--

(1) The Contracting Officer immediately shall notify the offeror and permit the offeror to resubmit the proposal;

(2) The method and time for resubmission shall be prescribed by the Contracting Officer after consultation with the offeror; and

(3) The resubmission shall be considered as if it were received at the date and time of the original unreadable submission for the purpose of determining timeliness, provided the offeror complies with the time and format requirements for resubmission prescribed by the Contracting Officer.

(e) The Government reserves the right to make award solely on the facsimile proposal. However, if requested to do so by the Contracting Officer, the apparently successful offeror promptly shall submit the complete original signed proposal.

(End of Provision)

00100. 7 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a contract resulting from this solicitation.

(End of Provision)

00100. 8 52.222-5 DAVIS-BACON ACT -- SECONDARY SITE OF THE WORK (JUL 2005)

(a)

(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Davis-Bacon Act, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)

(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

00100. 9 52.225-10 NOTICE OF BUY AMERICAN ACT REQUIREMENT--CONSTRUCTION MATERIALS (FEB 2009)

(a) "Definitions." "Commercially available off-the-shelf (COTS) item," "Construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American Act-Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) "Requests for determinations of inapplicability." An offeror requesting a determination regarding the inapplicability of the Buy American Act should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American Act before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) "Evaluation of offers."

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy

American Act, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) "Alternate offers."

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph

(c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of Provision)

00100. 10 52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the General Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

00100. 11 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name:

Address:

Telephone:

(End of Provision)

00100. 12 52.236-27 I SITE VISIT (CONSTRUCTION) (FEB 1995)--ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for--

(c) Participants will meet at--

(End of Provision)

00100. 13 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

(End of Provision)

00100. 14 552.236-73 BASIS OF AWARD--CONSTRUCTION CONTRACT (APR 1985)

(Reference 552.236-73)

SECTION 00600

REPRESENTATIONS AND CERTIFICATIONS

00600. 1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (FEB 2009)

(a)

(1) The North American Industry Classification System (NAICS) code for this acquisition is

(2) The small business size standard is

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)

(1) If the clause at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the clause at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronic ally, the offeror may choose to use paragraph

(d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

/_/ (i) Paragraph (d) applies.

/_/ (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in ORCA are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $100,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the clause at 52.204-7, Central Contractor Registration.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vi) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(vii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(viii) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(ix) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(x) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xi) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-38, Compliance with Veterans'' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xiv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xv) 52.225-2, Buy American Act Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvi) 52.225-4, Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternate I, and Alternate II) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $67,826, the provision with its Alternate II applies.

(xvii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xviii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification.

(xix) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to--

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(i) 52.219-19, Small Business Concern Representation for the

Small Business Competitiveness Demonstration Program.

(ii) 52.219-21, Small Business Size Representation for Targeted

Industry Categories Under the Small Business Competitiveness Demonstration Program.

(iii) 52.219-22, Small Disadvantaged Business Status.

(A) Basic.

(B) Alternate I.

(iv) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(v) 52.222-48, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment Certification.

(vi) 52.222-22 Exemption from Application of the Service Contract Act to Contracts for Certain Services-Certification.

(vii) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

(viii) 52.223-13, Certification of Toxic Chemical Release Reporting.

(ix) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(x) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the Online Representations and Certifications Application (ORCA) website at http://orca.bpn.gov. After reviewing the ORCA database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

| FAR | | | |

| Clause | Title | Date | Change |

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on ORCA.

(End of Provision)

00600. 2 52.236-28 PREPARATION OF PROPOSALS--CONSTRUCTION (OCT 1997)

(Reference 52.236-28)

SECTION 00700

CONTRACT CLAUSES

00700. 1 52.202-1 DEFINITIONS (JUL 2004)

(Reference 52.202-1)

00700. 2 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997)

(Reference 52.203-10)

00700. 3 52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (SEP 2007)

(Reference 52.203-12)

00700. 4 52.203-3 GRATUITIES (APR 1984)

(Reference 52.203-3)

00700. 5 52.203-5 COVENANT AGAINST CONTINGENT FEES (APR 1984)

(Reference 52.203-5)

00700. 6 52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (SEP 2006)

(Reference 52.203-6)

00700. 7 52.203-7 ANTI-KICKBACK PROCEDURES (JUL 1995)

(Reference 52.203-7)

00700. 8 52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY

(JAN 1997)

(Reference 52.203-8)

00700. 9 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON RECYCLED PAPER (AUG 2000)

(Reference 52.204-4)

00700. 10 52.204-7 CENTRAL CONTRACTOR REGISTRATION (APR 2008)

(Reference 52.204-7)

00700. 11 52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (SEP 2007)

(Reference 52.204-9)

00700. 12 52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (SEP 2006)

(Reference 52.209-6)

00700. 13 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to

(a) commence work under this contract within calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than The time stated for completion shall include final cleanup of the premises.

(End of Clause)

00700. 14 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of Clause)

00700. 15 52.211-13 TIME EXTENSIONS (SEP 2000)

(Reference 52.211-13)

00700. 16 52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2004)

(Reference 52.215-15)

00700. 17 52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

(Reference 52.215-17)

00700. 18 52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER THAN

PENSIONS (JUL 2005)

(Reference 52.215-18)

00700. 19 52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

(a) The Contractor shall make the following notifications in writing:

(1) When the Contractor becomes aware that a change in its ownership has occurred, or is certain to occur, that could result in changes in the valuation of its capitalized assets in the accounting records, the Contractor shall notify the Administrative Contracting Officer (ACO) within 30 days.

(2) The Contractor shall also notify the ACO within 30 days whenever changes to asset valuations or any other cost changes have occurred or are certain to occur as a result of a change in ownership.

(b) The Contractor shall--

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the ACO or designated representative ready access to the records upon request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of the Contractor's ownership changes; and

(4) Retain and continue to maintain depreciation and amortization schedules based on the asset records maintained before each Contractor ownership change.

(c) The Contractor shall include the substance of this clause in all subcontracts under this contract that meet the applicability requirement of FAR 15.408(k).

(End of Clause)

00700. 20 52.215-2 AUDIT AND RECORDS--NEGOTIATION (MAR 2009)

(Reference 52.215-2)

00700. 21 52.215-21 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR PRICING

DATA--MODIFICATIONS (OCT 1997)

(Reference 52.215-21)

00700. 22 52.215-21 I REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA--MODIFICATIONS (OCT 1997)--ALTERNATE II (OCT 1997)

(a) "Exceptions from cost or pricing data."

(1) In lieu of submitting cost or pricing data for modifications under this contract, for price adjustments expected to exceed the threshold set forth at FAR 15.403-4 on the date of the agreement on price or the date of the award, whichever is later, the Contractor may submit a written request for exception by submitting the information described in the following paragraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable--

(i) "Identification of the law or regulation establishing the price offered." If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) "Information on modifications of contracts or subcontracts for commercial items."

(A) If--

(1) The original contract or subcontract was granted an exception from cost or pricing data requirements because the price agreed upon was based on adequate price competition or prices set by law or regulation, or was a contract or subcontract for the acquisition of a commercial item; and

(2) The modification (to the contract or subcontract) is not exempted based on one of these exceptions, then the Contractor may provide information to establish that the modification would not change the contract or subcontract from a contract or subcontract for the acquisition of a commercial item to a contract or subcontract for the acquisition of an item other than a commercial item.

(B) For a commercial item exception, the Contractor shall provide, at a minimum, information on prices at which the same item or similar items have previously been sold that is adequate for evaluating the reasonableness of the price of the modification. Such information may include--

(1) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities.

(2) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market.

(3) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(2) The Contractor grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this clause, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the Contractor's determination of the prices to be offered in the catalog or marketplace.

(b) "Requirements for cost or pricing data." If the Contractor is not granted an exception from the requirement to submit cost or pricing data, the following applies:

(1) The Contractor shall submit cost or pricing data and supporting attachments prepared in the following format:

(2) As soon as practicable after agreement on price, but before award (except for unpriced actions), the Contractor shall submit a Certificate of Current Cost or Pricing Data, as prescribed by

FAR 15.406-2.

(End of Clause)

00700. 23 52.215-21 III REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR

PRICING DATA--MODIFICATIONS (OCT 1997)--ALTERNATE III (OCT 1997)

(a) "Exceptions from cost or pricing data."

(1) In lieu of submitting…