2024 02 29 - Amendment 04.pdf

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Amendment 04 – RFP 47PF0024R0014 Design Build Contract for the Birch Bayh Federal Building and U.S. Courthouse Elevator Modernization, Indianapolis, IN

Amendment 04 is hereby issued to incorporate additional RFI's (see attached).

You must acknowledge this and all amendments.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

2. AMENDMENT/MODIFICATION NUMBER

PAGE OF PAGES

5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 5P2QEB 7. ADMINISTERED BY (If other than Item 6) CODE

R5 AMD Capital & Customer Projects Contracting Branch Capital Construction Team 230 S. Dearborn St Chicago IL 60604 USA

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) 9A. AMENDMENT OF SOLICITATION NUMBER

47PF0024R0014

9B. DATED (SEE ITEM 11)

01/31/2024

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE

(X)

4. REQUISITION/PURCHASE REQUISITION NUMBER 3. EFFECTIVE DATE

02/29/2024

1. CONTRACT ID CODE

Responses to RFI’s - Amendment 04

RFQ 47PF0024R0014

Design Build Elevator Modernization

Birch Bayh Federal Building and U.S. Courthouse

46 E. Ohio Street, Indianapolis, IN 46204

1) Question:

Does the DOR/A/E need to have the ability to practice the profession of architecture and engineering in the State of Indiana at the time of the Phase I proposal submission, or do they simply need the ability to have such ability to practice by the time of award of Phase II?

Response: The DOR/AE does not need to have the ability to practice the profession of architecture and engineering in the State of Indiana at the time of the Phase I proposal submission, but they will need to be able to provide proof of such ability and/or licensing at the time of the Phase II submission.

2) Question:

Will GSA consider granting a time extension to allow DORs to obtain appropriate licensure?

Response: No time extension will be granted for obtaining licensure.