36C26118R0541-0006000.docx

5. PROJECT NUMBER (if applicable)

CODE

7. ADMINISTERED BY

2. AMENDMENT/MODIFICATION NUMBER

CODE

6. ISSUED BY

8. NAME AND ADDRESS OF CONTRACTOR

4. REQUISITION/PURCHASE REQ. NUMBER

3. EFFECTIVE DATE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED

PAGE

OF PAGES

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED

BPA NO.

1. CONTRACT ID CODE

FACILITY CODE

CODE

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

E. IMPORTANT:

is extended,

(a) By completing Items 8 and 15, and returning __________ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY is not extended.

12. ACCOUNTING AND APPROPRIATION DATA

(REV. 11/2016)

is required to sign this document and return ___________ copies to the issuing office.

is not, A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

15C. DATE SIGNED

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER

BY

Contractor

16C. DATE SIGNED

14. DESCRIPTION OF AMENDMENT/MODIFICATION

16B. UNITED STATES OF AMERICA

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER

16A. NAME AND TITLE OF CONTRACTING OFFICER

15B. CONTRACTOR/OFFEROR

STANDARD FORM 30

PREVIOUS EDITION NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.243 (Type or print) (Type or print) (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

(Number, street, county, State and ZIP Code) (If other than Item 6) (Specify type of modification and authority) (such as changes in paying office, appropriation date, etc.)

(If required)

(SEE ITEM 11)

(SEE ITEM 13)

(X)

CHECK

ONE

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

(Signature of person authorized to sign) (Signature of Contracting Officer) 10-26-2018 654-18-2-6059-0272 654-18-831 Department of Veterans Affairs VA Sierra Pacific Network (VISN 21) VA Sierra Nevada Health Care System 975 Kirman Avenue Reno

NV

89502-2597 Department of Veterans Affairs VA Sierra Pacific Network (VISN 21) VA Sierra Nevada Health Care System 975 Kirman Avenue Reno

NV

89502-2597 To all Offerors/Bidders

36C26118R0541 06-19-2018

X X X ** HOUR & DATE for Receipt of Offers is EXTENDED to:

Nov. 14, 2018, 4:00PM PST The purpose of this amendment is to:

a) In accordance with (IAW) solicitation 36C26118R0541, this amendment serves as notification to the most highly rated offerors to submit their technical and price proposals due no later than November 14, 2018 4:00PM PST. The most highly rated offerors shall be notified by e-mail.

b) Incorporate revised wage determination, DBWD Number NV180077 NV77 dated 09/07/2018, and SCA Wage Determination 15-5595 dated 08/02/2018.

Any further changes will only be provided via SF30 amendment.

Dario Rissone Contracting Specialist

AMENDMENT OF SOLICITAITON/MODIFICATION OF CONTRACT

CONTINUATION PAGE

PAGE NO:

Solicitation No:

36C26118R0541 ORDER No:

Amendment No.:

A. Purpose of Amendment:

1. This amendment is to implement Phase II of Solicitation 36C26118R0541, Project Title: IPP USP 797/800 Compliance (Pharmacy), located at the VA Sierra Nevada Health Care System, 975 Kirman Avenue, Reno, Nevada, 89502, for the most highly rated firms identified during Phase I evaluations only.

2. In accordance with (IAW) the Solicitation 36C26118R0541, Phase II technical proposal/price shall be due no later than November 14, 2018, at 4:00PM PST.

a. All proposals shall be submitted to Dario.Rissone@va.gov, IAW submission requirements outlined in solicitation 36C26118R0541.

3. Offer guarantee shall now be required with proposal submission, IAW FAR 52.228-1.

4. A site-visit for the project has already been accomplished; however, if an additional site visit is deemed necessary, please make your request in accordance with 52.236-27, which is part of this amendment.

5. RFI for Phase II are due November 8, 2018 at 4:00PM PST.

6. All other solicitation provisions, clauses, terms and conditions of solicitation 3626118R0541 remain unchanged.

A.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) ALTERNATE I (APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 150 days after the Notice to Proceed (NTP). The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by TBD. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of Clause)

A.2 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Dan Davis Address: VA Sierra Nevada Health Care System 975 Kirman Avenue

Telephone: 775-789-6671 (End of Provision)

A.3 52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $ 3 Million, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of Provision) See attached document: SCA Wage Determination 15-5595.

See attached document: DBWD Number NV180077 09072018 NV77.