36C25919R0091-007.pdf

FIRE BARRIER MITIGATION, BUILDING 1

Project # 575-17-102

For the

Department of Veterans Affairs VA Western Colorado Health Care System

2121 North Avenue Grand Junction, CO 81501

PROJECT MANUAL

100% BID DOCUMENTS

November 19, 2018

GUIDON DESIGN INC.

PROJECT CONTACTS:

COR / OWNER: Department of Veteran Affairs VA Western Colorado Health Care System

Attn: Rojelio R. Chavez, JR.

2121 North Avenue Grand Junction, CO 81501 Phone: (970) 263-2810 Email: Rojelio.Chavez@va.gov

ARCHITECT / PROJECT MANAGER:

GUIDON DESIGN INC.

Attn: James Gooden 905 N. Capitol Ave. Suite 100 Indianapolis, Indiana 46204 Phone: (317) 800-6388 x 145 Email: jgooden@guidondesign.com

ISSUE DATE: 19 November 2018 mailto:Rojelio.Chavez@va.gov

VA Western Colorado Health Care System 08-01-18

Fire Barrier Mitigation, Building 1 100% Bid Documents

575-17-102 November 19, 2018

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 10-17

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 02-15

01 33 23 Shop Drawings, Product Data, and Samples 05-17

01 35 26 Safety Requirements 02-17

01 42 19 Reference Standards 05-16

01 58 16 Temporary Interior Signage 07-15

01 74 19 Construction Waste Management 09-13

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

DIVISION 03 – CONCRETE – NOT USED

DIVISION 04 – MASONRY – NOT USED

DIVISION 05 – METALS – NOT USED

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES – NOT USED

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 81 00 Applied Fireproofing 10-17

07 84 00 Firestopping 02-16

07 92 00 Joint Sealants 10-17

DIVISION 08 – OPENINGS – NOT USED

DIVISION 09 – FINISHES

09 29 00 Gypsum Board 09-18

09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES – NOT USED

DIVISION 11 – EQUIPMENT – NOT USED

DIVISION 12 – FURNISHINGS – NOT USED

VA Western Colorado Health Care System 08-01-18

00 01 10-2

DIVISION 13 - SPECIAL CONSTRUCTION – NOT USED

DIVISION 14– CONVEYING EQUIPEMENT – NOT USED

DIVISION 21- FIRE SUPPRESSION – NOT USED

DIVISION 22 – PLUMBING – NOT USED

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC) – NOT USED

DIVISION 25 – INTEGRATED AUTOMATION – NOT USED

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16

26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17

26 05 33 Raceway and Boxes for Electrical Systems 01-18

26 51 00 Interior Lighting 01-18

DIVISION 27 – COMMUNICATIONS – NOT USED

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY – NOT USED

DIVISION 31 – EARTHWORK – NOT USED

DIVISION 32 – EXTERIOR IMPROVEMENTS – NOT USED

DIVISION 33 – UTILITIES – NOT USED

DIVISION 34 – TRANSPORTATION – NOT USED

DIVISION 48 – Electrical Power Generation – NOT USED

VA Western Colorado Health Care System 07-01-15

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

Drawing No. Title

GENERAL

G001 Title Sheet

G002 Abbreviation and Symbols

G101 Life Safety Plan

G102 Life Safety Plan

ARCHITECTURAL

AS001 Key Note Chart

AS101 Basement Floor Plan - North

AS102 Basement Floor Plan - South

AS103 Ground Floor Plan – North

AS104 Ground Floor Plan – South

AS105 Second Floor Plan – North

AS106 Second Floor Plan – South

AS107 Third Floor Plan – North

AS108 Third Floor Plan – South

AS109 Fourth Floor Plan

AS110 Fifth Floor Plan

AS111 Sixth and Seventh Floor Plan

AS112 Fire Barrier Details

AS113 Fire Barrier Details

- - - E N D - - -

VA Western Colorado Health Care System 10-01-17 Fire Barrier Mitigation, Building 1 100% Bid Docume nts i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

1.10 RESTORATION

1.11 PHYSICAL DATA

1.12 AS-BUILT DRAWINGS

1.13 USE OF ROADWAYS

1.14 CONTRACTOR'S FIELD OFFICE

1.15 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.16 TEMPORARY TOILETS

1.17 AVAILABILITY AND USE OF UTILITY SERVICES

1.18 TESTS

1.19 INSTRUCTIONS

1.20 GOVERNMENT-FURNISHED PROPERTY

1.21 RELOCATED EQUIPMENT ITEMS

1.22 CONSTRUCTION SIGN

1.23 SAFETY SIGN

1.24 CONSTRUCTION COORDINATION DRAWINGS

Grand Junction VAMC 10-01-17

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for bui lding operations, including demolition and removal of existing struct ures, and furnish labor and materials and perform work for Grand Junc tion VAMC as required by drawings and specifications.

B. Visits to the site by Bidders may be made only a s described in the solicitation in accordance with FAR 52.236-27 Site Visit

(Construction).

C. Before placement and installation of work subjec t to tests by testing laboratory retained by Department of Veterans Affai rs, the Contractor shall notify the COR in sufficient time to enable t esting laboratory personnel to be present at the site in time for pro per taking and testing of specimens and field inspection. Such pri or notice shall be not less than three work days unless otherwise desi gnated by the COR.

D. All employees of general contractor and subcontr actors shall comply with VA security management program and obtain perm ission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Work includes gene ral construction, alterations, mechanical and electrical work, necess ary removal of existing construction and certain other items.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the FedBixOps website where the solicitation is posted. Hard copi es will be the responsibility and expense of the Contractor.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

01 00 00 -2

1. The security plan defines both physical and admi nistrative security procedures that will remain effective for the entir e duration of the project.

2. The General Contractor is responsible for assuri ng that all sub-contractors working on the project and their employ ees also comply with these regulations.

B. Security Procedures:

1. A Special Agreement SAC form is required for eve ry contract employee. See the SPECIAL NOTES specification for an example of this SAC form. This needs to be supplied by the COR for every contract employee. Even if the contractor has an a ctive badge, an

SAC for is needed for the COR’s records.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the pr emises in the event of a national emergency. The General Contrac tor may return to the site only with the written approval of the Cont racting Officer.

C. Document Control:

1. The General Contractor is responsible for safeke eping of all drawings, project manual and other project informat ion. This information shall be shared only with those with a specific need to accomplish the project.

2. These security documents shall not be removed or transmitted from the project site without the written approval of Co ntracting

Officer.

3. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

4. Notify Contracting Officer and Site Security Off icer immediately when there is a loss or compromise of “sensitive in formation”.

D. Motor Vehicle Restrictions

01 00 00 -3

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitt ed 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (inc luding storage of materials) on Government premises to areas authoriz ed or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harml ess from liability of any nature occasioned by the Contractor's perfor mance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the appr oval of the

Contracting Officer and shall be built with labor a nd materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the

Contractor and shall be removed by the Contractor a t its expense upon completion of the work. With the written consent of the Contracting

Officer, the buildings and utilities may be abandon ed and need not be removed.

C. The Contractor shall, under regulations prescrib ed by the Contracting

Officer, use only established roadways, or use temp orary roadways constructed by the Contractor when and as authorize d by the Contracting

Officer. When materials are transported in prosecut ing the work, vehicles shall not be loaded beyond the loading cap acity recommended by the manufacturer of the vehicle or prescribed by an y Federal, State, or local law or regulation. When it is necessary to cr oss curbs or sidewalks, the Contractor shall protect them from d amage. The

Contractor shall repair or pay for the repair of an y damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

D. Working space and space available for storing ma terials shall be as shown on the drawings and as determined by the COR.

E. Workmen are subject to rules of Medical Center a pplicable to their conduct.

01 00 00 -4

F. Execute work in such a manner as to interfere a s little as possible with work being done by others. Keep roads clear of construction materials, debris, standing construction equipment and vehicles at all times.

G. Execute work so as to interfere as little as pos sible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any e xisting equipment, and with work being done by others. Use of equipmen t and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during co nstruction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other th an assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of

Veterans Affairs in quantities sufficient for not m ore than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vaca ted portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and saf ety requirements.

H. Utilities Services: Where necessary to cut exis ting pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (excep t telephone), they shall be cut and capped at suitable places where sh own; or, in absence of such indication, where directed by COR. All such actions shall be coordinated with the COR or Utility Company involve d:

I. Phasing:

1. The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in servic e must be scheduled and coordinated with the COR to ensure that no laps es in operation occur. It is the CONTRACTOR'S responsibility to de velop a work plan and schedule detailing, at a minimum, the procedure s to be employed, the equipment and materials to be used, the interim life safety measure

01 00 00 -5 to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outli ned shall include, but not be limited to:

J. Building(s) No.(s) 1 will be occupied during p erformance of work.

1. Contractor shall take all measures and provide a ll material necessary for protecting existing equipment and pro perty in affected areas of construction against dust and debris, so t hat equipment and affected areas to be used in the Medical Centers op erations will not be hindered. Contractor shall permit access to Depa rtment of

Veterans Affairs personnel and patients through oth er construction areas which serve as routes of access to such affec ted areas and equipment. These routes whether access or egress s hall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc. to facilitate patient and s taff access.

Coordinate alteration work in areas occupied by Dep artment of

Veterans Affairs so that Medical Center operations will continue during the construction period.

K. When a building and/or construction site is turn ed over to Contractor, Contractor shall accept entire responsibility inclu ding upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specif ied.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for p re-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractor's employee or watchman.

L. Utilities Services: Maintain existing utility se rvices for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uni nterrupted services.

Where necessary to cut existing water, steam, gases , sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (incl uding telephone), 01 00 00 -6 they shall be cut and capped at suitable places whe re shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, se wers or electricity, or fire protection systems and communications syste ms may be interrupted without prior approval of COR. Electri cal work shall be accomplished with all affected circuits or equipmen t de-energized.

When an electrical outage cannot be accomplished, w ork on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s p rior knowledge and written approval. Refer to specification Sectio ns 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS additiona l requirements.

2. Contractor shall submit a request to interrupt a ny such services to

COR, in writing, 7 days in advance of proposed inte rruption. Request shall state reason, date, exact time of, and approx imate duration of such interruption.

3. Contractor will be advised (in writing) of appro val of request, or of which other date and/or time such interruption w ill cause least inconvenience to operations of Cemetery. Interrupti on time approved by Medical Center may occur at other than Contracto r's normal working hours.

4. Major interruptions of any system must be reques ted, in writing, at least 15 calendar days prior to the desired time an d shall be performed as directed by the COR.

5. In case of a contract construction emergency, se rvice will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the c onstruction project, for such items as water, sewer, electricit y, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

M. Abandoned Lines: All service lines such as wires , cables, conduits, ducts, pipes and the like, and their hangers or sup ports, which are to be abandoned but are not required to be entirely re moved, shall be

01 00 00 -7 sealed, capped or plugged at the main, branch or pa nel they originate from. The lines shall not be capped in finished are as, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or par titions; so that they are completely behind the finished surfaces.

N. To minimize interference of construction activit ies with flow of

Medical Center traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to p arking and to occupied areas of buildings clear of construction m aterials, debris and standing construction equipment and vehicles.

O. Coordinate the work for this contract with other construction operations as directed by COR. This includes the sc heduling of traffic and the use of roadways, as specified in Article, U SE OF ROADWAYS.

P. The contractor must provide a construction sched ule indicating the location of work and the dates it will be completed at least three weeks before work begins to allow the COR to coordi nate with Station sections affected.

1.7 ALTERATIONS – NOT USED

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work remov ed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of t he Government are identified by attached tags or noted on drawings or in specifications as items to be stored. Items that re main property of the Government shall be removed or dislodged from p resent locations in such a manner as to prevent damage which would b e detrimental to re-installation and reuse. Store such items where d irected by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

01 00 00 -8

3. Items of portable equipment and furnishings loca ted in rooms and spaces in which work is to be done under this contr act shall remain the property of the Government. When rooms and spac es are vacated by the Department of Veterans Affairs during the alter ation period, such items which are NOT required by drawings and s pecifications to be either relocated or reused will be removed by th e Government in advance of work to avoid interfering with Contracto r's operation.

4. Copies of the following listed CFR titles may be obtained from the

Government Printing Office:

40 CFR 261........Identification and Listing of Haz ardous Waste

40 CFR 262........Standards Applicable to Generator s of Hazardous

Waste

40 CFR 263........Standards Applicable to Transport ers of

Hazardous Waste

40 CFR 761........PCB Manufacturing, Processing, Di stribution in

Commerce, and use Prohibitions

49 CFR 172........Hazardous Material tables and Haz ardous

Material Communications Regulations

49 CFR 173........Shippers - General Requirements f or Shipments and Packaging

49 CRR 173........Subpart A General

49 CFR 173........Subpart B Preparation of Hazardou s Material for

Transportation

49 CFR 173........Subpart J Other Regulated Materia l; Definitions and Preparation

TSCA..............Compliance Program Policy Nos. 6- PCB-6 and 6-

PCB-7

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all st ructures, equipment, and vegetation (such as trees, shrubs, and grass) o n or adjacent to the

01 00 00 -9 work site, which are not to be removed and which do not unreasonably interfere with the work required under this contrac t. The Contractor shall only remove trees when specifically authorize d to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract per formance, or by the careless operation of equipment, or by workmen, the Contractor shall trim those limbs or branches with a clean cut and p aint the cut with a tree-pruning compound as directed by the Contractin g Officer.

B. The Contractor shall protect from damage all exi sting improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any dam age to those facilities, including those that are the property o f a third party, resulting from failure to comply with the requireme nts of this contract or failure to exercise reasonable care in performin g the work. If the

Contractor fails or refuses to repair the damage pr omptly, the

Contracting Officer may have the necessary work per formed and charge the cost to the Contractor.

(FAR 52.236-9)

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair ex isting work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, an d do not disturb any ducts, plumbing, steam, gas, or electric work witho ut approval of the

COR. Existing work to be altered or extended and th at is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restor ing work, shall conform in type and quality to that of original exi sting construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work comple te and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work , shall be patched, repaired, reinstalled, or replaced with new work, a nd refinished and left in as good condition as existed before commenc ing work.

01 00 00 -10

C. At Contractor's own expense, Contractor shall im mediately restore to service and repair any damage caused by Contractor' s workmen to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications sy stems (including telephone) which are not scheduled for discontinuan ce or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered b y adjustment to contract time and price in accordance with clause e ntitled "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING S ITE CONDITIONS" (FAR

52.236-2).

1.11 PHYSICAL DATA – NOT USED

1.12 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of t he project, to include all contract changes, modifications and cla rifications.

B. All variations shall be shown in the same genera l detail as used in the contract drawings. To insure compliance, as-built d rawings shall be made available for the COR review, as often as requ ested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR.

D. Paragraphs A, B, & C shall also apply to all sho p drawings.

E. Contractors shall update (as work is completed), the VA electrical, medical gas, domestic plumbing and mechanical pipin g master schematic books. These books are located in the FM Office.

1.13 USE OF ROADWAYS

A. For hauling, use only established public roads a nd roads on Medical

Center property and, when authorized by the COR, su ch temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed and restoration performe d by the Contractor at Contractor's expense. When necessary to cross cu rbing, sidewalks, or

01 00 00 -11 similar construction, they must be protected by wel l-constructed bridges.

1.14 CONRACTOR'S FIELD OFFICE – NOT USED

1.15 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical e quipment to provide heat, ventilation, plumbing, light and power will b e permitted subject to written approval and compliance with the followi ng provisions:

1. Permission to use each unit or system must be gi ven by COR in writing. If the equipment is not installed and main tained in accordance with the written agreement and following provisions, the

COR will withdraw permission for use of the equipme nt.

2. Electrical installations used by the equipment s hall be completed in accordance with the drawings and specifications to prevent damage to the equipment and the electrical systems, i.e. tran sformers, relays, circuit breakers, fuses, conductors, motor controll ers and their overload elements shall be properly sized, coordina ted and adjusted.

Installation of temporary electrical equipment or d evices shall be in accordance with NFPA 70, National Electrical Cod e, (2014

Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be corr ect and it shall be determined that motors are not overloaded. The e lectrical equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuu m cleaning and wiping clean interior and exterior surfaces.

3. Units shall be properly lubricated, balanced, an d aligned.

Vibrations must be eliminated.

4. Automatic temperature control systems for prehea t coils shall function properly and all safety controls shall fun ction to prevent coil freeze-up damage.

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elemen ts shall be replaced at completion of construction and prior to testing and balancing of system.

01 00 00 -12

6. All components of heat production and distributi on system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the Government.

Boilers, pumps, feedwater heaters and auxiliary equ ipment must be operated as a complete system and be fully maintain ed by operating personnel. Boiler water must be given complete and continuous chemical treatment.

B. Prior to final inspection, the equipment or part s used which show wear and tear beyond normal, shall be replaced with iden tical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the mechanical and electrical specifications sections.

D. Any damage to the equipment or excessive wear du e to prolonged use will be repaired replaced by the contractor at the contr actor’s expense.

1.16 TEMPORARY TOILETS

A. Contractor may have for use of Contractor's wo rkmen, such toilet accommodations as may be assigned to Contractor by Medical Center.

Contractor shall keep such places clean and be resp onsible for any damage done thereto by Contractor's workmen. Failur e to maintain satisfactory condition in toilets will deprive Cont ractor of the privilege to use such toilets.

1.17 AVAILABILITY AND USE OF UTILITY SERVICES

A. Contractor will be allowed to use VA utilities a s needed at no cost to the Contractor.

1.18 TESTS

A. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such s ystems before requesting final tests. Final test will not be cond ucted unless pre-tested.

01 00 00 -13

B. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Con tracting Officer.

Contractor shall furnish all labor, materials, equi pment, instruments, and forms, to conduct and record such tests.

C. Mechanical and electrical systems shall be balan ced, controlled and coordinated. A system is defined as the entire syst em which must be coordinated to work together during normal operatio n to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provide s comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, contr ols and electricity, etc. Another example of a system which involves sev eral components of different disciplines is a boiler installation. Eff icient and acceptable boiler operation depends upon the coordi nation and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

D. All related components as defined above shall be functioning when any system component is tested. Tests shall be complete d within a reasonably period of time during which operating an d environmental conditions remain reasonably constant and are typic al of the design conditions.

E. Individual test result of any component, where r equired, will only be accepted when submitted with the test results of re lated components and of the entire system.

1.19 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operati ng manuals (hard copies and electronic) and verbal instructions when requir ed by the various sections of the specifications and as hereinafter s pecified.

B. Instructions: Contractor shall provide qualified , factory-trained manufacturers' representatives to give detailed tra ining to assigned

Department of Veterans Affairs personnel in the ope ration and complete maintenance for each piece of equipment. All such t raining will be at the job site. These requirements are more specifica lly detailed in the various technical sections. Instructions for differ ent items of

01 00 00 -14 equipment that are component parts of a complete sy stem, shall be given in an integrated, progressive manner. All instructo rs for every piece of component equipment in a system shall be availab le until instructions for all items included in the system h ave been completed.

This is to assure proper instruction in the operati on of inter-related systems. All instruction periods shall be at such t imes as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough covera ge. The contractor shall submit a course outline with associated mater ial to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the co ntractual requirements. The Department of Veterans Affairs r eserves the right to request the removal of, and substitution for, any i nstructor who, in the opinion of the COR, does not demonstrate suffic ient qualifications in accordance with requirements for instructors abo ve.

1.20 GOVERNMENT-FURNISHED PROPERTY

A. The Government shall deliver to the Contractor, the

Government-furnished property shown on the drawings .

B. Equipment furnished by Government to be installe d by Contractor will be furnished to Contractor at the Medical Center.

C. Storage space for equipment will be provided b y the Government and the

Contractor shall be prepared to unload and store su ch equipment therein upon its receipt at the Medical Center.

D. Notify Contracting Officer in writing, 60 days i n advance, of date on which Contractor will be prepared to receive equipm ent furnished by

Government. Arrangements will then be made by the G overnment for delivery of equipment.

1. Immediately upon delivery of equipment, Contract or shall arrange for a joint inspection thereof with a representative of the Government.

At such time the Contractor shall acknowledge recei pt of equipment described, make notations, and immediately furnish the Government representative with a written statement as to its c ondition or shortages.

01 00 00 -15

2. Contractor thereafter is responsible for such eq uipment until such time as acceptance of contract work is made by the Government.

E. Equipment furnished by the Government will be de livered in a partially assembled (knock down) condition in accordance with existing standard commercial practices, complete with all fittings, f astenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the li ke) necessary to make the connection between the Government furnishe d equipment item and the utility stub-up shall be furnished and installe d by the contractor at no additional cost to the Government.

F. Completely assemble and install the Government f urnished equipment in place ready for proper operation in accordance with specifications and drawings.

G. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

1.21 RELOCATED EQUIPMENT ITEMS

A. Contractor shall disconnect, dismantle as necess ary, remove and reinstall in new location, all existing equipment a nd items indicated in the drawings shown to be relocated by the Contra ctor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR.

C. Suitably cap existing service lines, such as ste am, condensate return, water, drain, gas, air, vacuum and/or electrical, a t the main whenever such lines are disconnected from equipment to be re located. Remove abandoned lines in finished areas and cap as specif ied herein before under paragraph "Abandoned Lines".

D. Provide all mechanical and electrical service co nnections, fittings, fastenings and any other materials necessary for as sembly and installation of relocated equipment; and leave such equipment in proper operating condition.

01 00 00 -16

E. All service lines such as noted above for reloca ted equipment shall be in place at point of relocation ready for use befor e any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

1.22 CONSTRUCTION SIGN – NOT USED

1.23 SAFETY SIGN – NOT USED

1.24 CONSTRUCTION COORDINATION DRAWINGS

A. Prepare and provide coordination drawings showin g the location of openings through slabs, the pipe sleeves and hanger inserts, as well as the location and elevation of utility lines, includ ing, but not limited to, conveyor systems, pneumatic tubes, ducts, all e xisting utilities, and conduits and pipes 50 mm (2 inches) and larger in diameter.

Drawings required for all areas being remodeled or new and ancillary areas required by such utility runs. Ancillary are a drawings to include equal space on each side of main runs from main source to final location. These drawings, including plans, elevati ons, and sections as appropriate shall clearly show the manner in which the utilities fit into the available space and how they relate to eac h other and to existing building elements and controls for mainten ance operations.

Drawings shall be of appropriate scale to satisfy t he previously stated purposes, but not smaller than 9 mm (3/8 inch) scal e. Drawings must be composite (with distinctive colors for the various trades) including but not limited to HVAC equipment, HVAC ductwork, m echanical piping, plumbing, fire protection, electrical, medical gase s, telecommunications, etc. The submitted drawings fo r a given area of the project shall show the work of all trades which will be involved in that particular area. A complete composite drawing set or complete sets of separate reproducible drawings and AutoCAD files shall be received by the Government not less than 20 days pr ior to the scheduled start of the work in the area illustrated by the dr awings, for the purpose of showing the contractor's planned method of installation. The objectives of such drawings are to promote carefull y planned work sequence and proper trade coordination, in order to assure the expeditious solutions of problems and the installat ion of lines and

01 00 00 -17 equipment as contemplated by the contract documents while avoiding or minimizing additional costs to the contractor and t o the Government.

In the event the contractor, in coordinating the va rious installations and in planning the method of installation, finds a conflict in location or elevation of any of the utilities with themselves, with structural items or with other construction items, the contractor shall bring this conflict to the attention of the contrac ting officer immediately. In doing so, the contractor shall expl ain the proposed method of solving the problem or shall request inst ructions as to how to proceed if adjustments beyond those of usual tra des coordination are necessary. Contractor to include initial and two r evisions as part of original contract. Utilities installation work wil l not proceed in any area prior to the submission and completion of the Government review of the coordinated drawings for that area, nor in any area in which conflicts are disclosed by the coordination drawing s until the conflicts have been corrected to the satisfaction o f the contracting officer. It is the responsibility of the contractor to submit the required drawings in a timely manner consistent wit h the requirements to complete the work covered by this contract withi n the prescribed contract time.

VA Western Colorado Health Care System 02-01-15

01 32 16.15 - 1

SECTION 01 32 16.15

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule) and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this contract (including all activities of subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officer's Representative (COTR).

B. The Contractor's representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements of this specification section.

C. The Contractor’s representative shall have the option of developing the project schedule within their organization or to engage the services of an outside consultant. If an outside scheduling consultant is utilized, Section 1.3 of this specification will apply.

1.3 CONTRACTOR'S CONSULTANT:

A. The Contractor shall submit a qualification proposal to the COTR, within 10 days of bid acceptance. The qualification proposal shall include:

1. The name and address of the proposed consultant.

2. Information to show that the proposed consultant has the qualifications to meet the requirements specified in the preceding paragraph.

3. A representative sample of prior construction projects, which the proposed consultant has performed complete project scheduling services. These representative samples shall be of similar size and scope.

01 32 16.15 - 2

B. The Contracting Officer has the right to approve or disapprove the proposed consultant and will notify the Contractor of the VA decision within seven calendar days from receipt of the qualification proposal.

In case of disapproval, the Contractor shall resubmit another consultant within 10 calendar days for renewed consideration. The

Contractor shall have their scheduling consultant approved prior to submitting any schedule for approval.

C. Consultants deemed pre-approved by VA: CCS/OS, Chicago, IL; Spire

Consulting Group, Austin, TX. Others proposed shall be compared to experience deemed similar to that offered by these entities.

1.4 COMPUTER PRODUCED SCHEDULES

A. The contractor shall provide monthly, to the Department of Veterans

Affairs (VA), all computer-produced time/cost schedules and reports generated from monthly project updates. This monthly computer service will include: three copies of up to five different reports (inclusive of all pages) available within the user defined reports of the scheduling software approved by the Contracting Officer; a hard copy listing of all project schedule changes, and associated data, made at the update and an electronic file of this data; and the resulting monthly updated schedule in PDM format. These must be submitted with and substantively support the contractor’s monthly payment request and the signed look ahead report. The COTR shall identify the five different report formats that the contractor shall provide.

B. The contractor shall be responsible for the correctness and timeliness of the computer-produced reports. The Contractor shall also responsible for the accurate and timely submittal of the updated project schedule and all CPM data necessary to produce the computer reports and payment request that is specified.

C. The VA will report errors in computer-produced reports to the

Contractor’s representative within ten calendar days from receipt of reports. The Contractor shall reprocess the computer-produced reports and associated diskette(s), when requested by the Contracting Officer’s representative, to correct errors which affect the payment and schedule for the project.

1.5 THE COMPLETE PROJECT SCHEDULE SUBMITTAL

A. Within 45 calendar days after receipt of Notice to Proceed, the

Contractor shall submit for the Contracting Officer's review; three

01 32 16.15 - 3 blue line copies of the interim schedule on sheets of paper 765 x 1070 mm (30 x 42 inches) and an electronic file in the previously approved

CPM schedule program. The submittal shall also include three copies of a computer-produced activity/event ID schedule showing project duration; phase completion dates; and other data, including event cost.

Each activity/event on the computer-produced schedule shall contain as a minimum, but not limited to, activity/event ID, activity/event description, duration, budget amount, early start date, early finish date, late start date, late finish date and total float. Work activity/event relationships shall be restricted to finish-to-start or start-to-start without lead or lag constraints. Activity/event date constraints, not required by the contract, will not be accepted unless submitted to and approved by the Contracting Officer. The contractor shall make a separate written detailed request to the Contracting

Officer identifying these date constraints and secure the Contracting

Officer’s written approval before incorporating them into the network diagram. The Contracting Officer’s separate approval of the Project

Schedule shall not excuse the contractor of this requirement. Logic events (non-work) will be permitted where necessary to reflect proper logic among work events, but must have zero duration. The complete working schedule shall reflect the Contractor's approach to scheduling the complete project. The final Project Schedule in its original form shall contain no contract changes or delays which may have been incurred during the final network diagram development period and shall reflect the entire contract duration as defined in the bid documents.

These changes/delays shall be entered at the first update after the final Project Schedule has been approved. The Contractor should provide their requests for time and supporting time extension analysis for contract time as a result of contract changes/delays, after this update, and in accordance with Article, ADJUSTMENT OF CONTRACT

COMPLETION.

D. Within 30 calendar days after receipt of the complete project interim

Project Schedule and the complete final Project Schedule, the

Contracting Officer or his representative, will do one or both of the following:

1. Notify the Contractor concerning his actions, opinions, and objections.

01 32 16.15 - 4

2. A meeting with the Contractor at or near the job site for joint review, correction or adjustment of the proposed plan will be scheduled if required. Within 14 calendar days after the joint review, the Contractor shall revise and shall submit three blue line copies of the revised Project Schedule, three copies of the revised computer-produced activity/event ID schedule and a revised electronic file as specified by the Contracting Officer. The revised submission will be reviewed by the Contracting Officer and, if found to be as previously agreed upon, will be approved.

E. The approved baseline schedule and the computer-produced schedule(s) generated there from shall constitute the approved baseline schedule until subsequently revised in accordance with the requirements of this section.

F. The Complete Project Schedule shall contain approximately 100 work activities/events.

1.6 WORK ACTIVITY/EVENT COST DATA

A. The Contractor shall cost load all work activities/events except procurement activities. The cumulative amount of all cost loaded work activities/events (including alternates) shall equal the total contract price. Prorate overhead, profit and general conditions on all work activities/events for the entire project length. The contractor shall generate from this information cash flow curves indicating graphically the total percentage of work activity/event dollar value scheduled to be in place on early finish, late finish. These cash flow curves will be used by the Contracting Officer to assist him in determining approval or disapproval of the cost loading. Negative work activity/event cost data will not be acceptable, except on VA issued contract changes.

B. The Contractor shall cost load work activities/events for test, balance and adjust various systems in accordance with the provisions in

Article, FAR 52.232 – 5 (PAYMENT UNDER FIXED-PRICE CONSTRUCTION

CONTRACTS) and VAAR 852.236 – 82 (PAYMENT UNDER FIXED-PRICE

CONSTRUCTION CONTRACTS).

C. The Contractor shall cost load work activities/events for all BID ITEMS including ASBESTOS ABATEMENT. The sum of each BID ITEM work shall equal the value of the bid item in the Contractors' bid.

01 32 16.15 - 5

1.7 PROJECT SCHEDULE REQUIREMENTS

A. Show on the project schedule the sequence of work activities/events required for complete performance of all items of work. The Contractor

Shall:

1. Show activities/events as:

a. Contractor's time required for submittal of shop drawings, templates, fabrication, delivery and similar pre-construction work.

b. Contracting Officer's and Architect-Engineer's review and approval of shop drawings, equipment schedules, samples, template, or similar items.

c. Interruption of VA Facilities utilities, and rough-in drawings, project phasing and any other specification requirements.

d. Test, balance and adjust various systems and pieces of equipment, maintenance and operation manuals, instructions and preventive maintenance tasks.

e. VA inspection and acceptance activity/event with a minimum duration of five work days at the end of each phase and immediately preceding any VA move activity/event required by the contract phasing for that phase.

2. Show not only the activities/events for actual construction work for each trade category of the project, but also trade relationships to indicate the movement of trades from one area, floor, or building, to another area, floor, or building, for at least five trades who are performing major work under this contract.

3. Break up the work into activities/events of a duration no longer than 20 work days each or one reporting period, except as to non-construction activities/events (i.e., procurement of materials, delivery of equipment, concrete and asphalt curing) and any other activities/events for which the COTR may approve the showing of a longer duration. The duration for VA approval of any required submittal, shop drawing, or other submittals will not be less than

20 work days.

4. Describe work activities/events clearly, so the work is readily identifiable for assessment of completion. Activities/events labeled

"start," "continue," or "completion," are not specific and will not be allowed. Lead and lag time activities will not be acceptable.

01 32 16.15 - 6

5. The schedule shall be generally numbered in such a way to reflect either discipline, phase or location of the work.

B. The Contractor shall submit the following supporting data in addition to the project schedule:

1. The appropriate project calendar including working days and holidays.

2. The planned number of shifts per day.

3. The number of hours per shift.

Failure of the Contractor to include this data shall delay the review of the submittal until the Contracting Officer is in receipt of the missing data.

C. To the extent that the Project Schedule or any revised Project Schedule shows anything not jointly agreed upon, it shall not be deemed to have been approved by the COTR. Failure to include any element of work required for the performance of this contract shall not excuse the

Contractor from completing all work required within any applicable completion date of each phase regardless of the COTR’s approval of the

Project Schedule.

D. Compact Disk Requirements and CPM Activity/Event Record Specifications:

Submit to the VA an electronic file(s) containing one file of the data required to produce a schedule, reflecting all the activities/events of the complete project schedule being submitted.

1.8 PAYMENT TO THE CONTRACTOR:

A. Monthly, the contractor shall submit an application and certificate for payment using the AIA application and certificate for payment documents

G702 & G703 reflecting updated schedule activities and cost data in accordance with the provisions of the following Article, PAYMENT AND

PROGRESS REPORTING, as the basis upon which progress payments will be made pursuant to Article, FAR 52.232 – 5 (PAYMENT UNDER FIXED-PRICE

CONSTRUCTION CONTRACTS) and VAAR 852.236 – 82 (PAYMENT UNDER FIXED-

PRICE CONSTRUCTION CONTRACTS). The Contractor shall be entitled to a monthly progress payment upon approval of estimates as determined from the currently…