25-0144 7115 Pricing Schedule.pdf
PDF 269 KB Posted
- Attached to
- FA466125R0006 B7115 Roof Sealant Solicitation
- Solicitation number
- FA466125R0006
About this file
This document is a Pricing Schedule for a roof replacement project at the Coat Bowling Alley, Building B7115, under solicitation FNWZ 25-0144. The pricing schedule covers a sustainment work item that includes all necessary survey, layout, labor, supplies, equipment, materials, supervision, and incidentals required to complete the roof replacement in compliance with the contract's Statement of Work.
The contract performance terms specify that the contractor will have a limited number of calendar days to complete the project and reach the Beneficial Occupancy Date (BOD), with an additional 90 days to complete closeout documentation. Liquidated damages of $368.92 per day, per facility may be applied after the performance period expires until BOD is achieved. The pricing schedule also accounts for 10 weather days in the construction portion, with additional weather-related delays subject to verification and approval by the Contracting Officer on a daily basis when affecting the critical path.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Attachment D Coat Bowling Alley Roof, B7115
PRICING SCHEDULE FNWZ 25-0144
Attachment D – Pricing Schedule
0001 Base Pricing - Item 1 – Coat Bowling Alley Roof B7115, FNWZ 25-0144 (SUSTAINMENT) This item includes all survey, layout, plant, labor, supplies, equipment, materials, supervision and incidentals required to complete all SUSTAINMENT work in compliance with the Statement of Work and terms & conditions of the contract for Replace Roof B7115, FNWZ 25-0144.
1 LS $________________________
CONTRACT PERFORMANCE TIME:
1. The Contractor will have a limited number of calendar days to complete the project and reach the
Beneficial Occupancy Date (BOD). Once the BOD is complete, the Contractor will have 90 days to complete all the Closeout Documentation.
2. Liquidated damages of $368.92 per day, per facility may apply after expiration of Performance Period until BOD is achieved.
3. 10 weather days have been included in each CLIN for the Construction portion of the project. Additional time for weather-related delays will be site verified & granted by the Contracting Officer on a daily basis when weather affects the critical path.
File details come from the government source that posted it. Updated .